An Analysis of Cost Overruns and Time Delays of INDOT Projects
Time overruns
-
Upload
bhalchandra-tankkar -
Category
Engineering
-
view
127 -
download
4
Transcript of Time overruns
Factors responsible for Time Overruns in Execution of
Construction Projects in India
byBhalchandra Shyamkant Tankkar
Department of Civil EngineeringV.N.I.T. Nagpur, (India)
Contents
INTRODUCTION
Background of construction sector
Status of Infrastructure
Projects in India
Details of the projects facing time
overruns
Need for study
LITERATURE REVIEW
Defining Time Overruns
Classification of Delay
Past studies on Time overruns
RESEARCH METHODOLOGY
Research Design
Questionnaire Design
Data Collection
Contents
RESULTS & DISCUSSION
Demographic details of respondents
Data CollectionDemographic details of
respondentsTesting reliability of dataRanking of Factors based
on RIIANOVA
Principal Component factor Analysis
Comparisons with other countries
CONCLUSION & RECOMMENDATIONS
Conclusions of the study
Recommendations for mitigating top three
factors
FUTURE SCOPE
Areas for further study
Background of Construction sector
Role of construction sector
• Construction industry is the second employer and contributor in India after the Agriculture industry
• It accounts for second highest inflow of FDI and is valued at over USD 126 billion (Source: http://makeinindia.com/sector/construction/)
Investment in infrastructure & construction
• ₹ 55,74,663 crores to be invested in infrastructure during the Twelfth Five Year Plan period( 2012-2017) (Source: Infrastructure Statistics 2014, Central Statistics Office, MoSPI)
Challenges
• Cost and time overruns are the major issues faced by the sector
Status of Infrastructure Projects in India
The monitoring of public projects in India is done by Ministry of Statistics and Program Implementation (MoSPI)
As per the 346 Flash Report of August 2014 released by the Ministry of Statistics, out of 720 central sector infrastructure sector projects costing ₹ 150 crore and above, 295 projects were facing time overruns
Original cost of the 295 delayed projects is ₹ 5,48,838 crore and anticipated cost is ₹ 6,50,274 crore, thus leading to a total cost overrun of ₹ 1,01,436 crore
Details of the projects facing time overruns
Time Overrun No. of projects
Less than 12 months 62Between 13 to 24 months 66Between 25 to 60 months 98More than 60 months 69
21%
22%
33%
23%
Less than 12 monthsBetween 13 to 24 monthsBetween 25 to 60 monthsMore than 60 months
SECTORWISE DETAILS OF PROJECTS FACING TIME OVERRUNS
SectorNo. of
Projects delayed
Road 92
Railways 32
Petroleum 43
Power 64
Coal 34
Atomic Power 4
Steel 16
Road 32%
Rail-ways 11%
Petroleum15%
Power22%
Coal12%
Atomic Power
1%
Steel6%
Projects delayed in different sectors
Worst hit projects
Bankura-Damodar gauge conversion project of South Eastern Railways
• Initial cost estimated for was ₹ 111.9 crore in 2001• Now estimated to cost the exchequer ₹ 2,371.85 crore
Gondia-Jabalpur stretch gauge conversion project undertaken by South East Central Railway• Original cost was ₹ 386 crore and the project was to be completed in 1998• Now expected to be completed in 2019, a delay of 21 years and to cost ₹
590.63 crore
G1 and GS-15 oilfield project of ONGC off Andhra coast
• Cost overrun of 820 %• Delay of more than 9 years
Singareni Collieries Co. Ltd's shaft project at its Adriyala mine
• Cost overrun of 479 % • Delay of more than 2 years
NEED FOR STUDY
Services provided by infrastructure projects serve as input for other sectors
Due to delays in project implementation, people have to wait for the provision of public goods and services longer than necessary
Most infrastructure projects in India are funded by taxpayers’ money
Existing literature reveals that the underlying causes, and thus the remedies, differ from country to country
Defining Time Overruns
The time overrun variable is defined as the difference between the estimated project duration and the actual time taken to complete the project.
Mathematical representation
• Net duration=Date of project commencement −Date of project approval• Time overrun= Net duration − Project duration
In other words, time overrun may also be defined as the delays beyond the date for completion specified by the contract or beyond the extended contract period where an extension of time has been granted.
Delays have potential to result in disputes and claims leading to arbitration or litigation
Classification of Delay
Delays
Ahmed et al. (2003)
Internal causesThese arise from the parties to the contract (e.g. contractor,
client, and consultant)
External causes: These, on the other hand, arise from events beyond the control of the parties. They include the act of God, government action,
and material suppliers
Bolton (1990)
Excusable but non-compensable delay These are delays caused by occurrences which are not
attributable to any of the parties.
Compensable delay These delays result from acts or omissions of the owner or
someone for whose acts an owner is liable
Inexcusable delay These delays result from a contractor's own fault or his
subcontractors or material suppliers
PAST STUDIES ON TIME OVERRUNSRuqaishi and Bashir (2014)-
Oman
Poor site management
Problems with subcontractors
Inadequate planning and scheduling
Marzouk and El-Rasas (2014)
Egypt
Finance and payments of
completed work by owner
Delay in revising and approving
design documents by owner
Ineffective planning and scheduling of
project
Shortage of construction
materials in market
Mistakes and discrepancies in
design documents
Kaliba et al (2009)
Zambia
Delayed payments
Financial processes and
difficulties on the part of
contractors and clients
Contract modification
Problems in materials
procurement
Changes in drawings
Sweis et al (2008)
Jordan
Presence of unskilled labors
Shortage of technical professionals in the
contractors organization
. Improper technical study by the contractor
Poor planning and scheduling of the
project by the contractor
Too many change orders from owner
PAST STUDIES ON TIME OVERRUNSLo et al (2006)
Hong Kong
Lack of running capital
Unforeseen ground
conditions
Exceptionally low bids
Inexperienced contractors
Works in conflict with
existing structures/
utilities
Sambasivan and Soon (2006)
Malaysia
Contractor’s improper planning
Contractor’s poor site
management
Inadequate contractor
experience
Inadequate client’s finance
Problems with subcontractors
Faridi and El-Sayegh (2006)
UAE
Slow preparation and approval of
drawings
Inadequate early planning of the
project
Slowness of owner’s decision
making
Shortage of manpower
Poor site management and
supervision
Low productivity of manpower
Koushkiet al (2005)
Kuwait
Changing orders
Owners’ financial constraints
Owners’ lack of experience in the
construction business
PAST STUDIES ON TIME OVERRUNS
Frimpong et al (2003)
Ghana
Improper Planning and scheduling
Shortages of technical personnel
Bad weather and Unexpected geological conditions
Research Design
Literature Review
Identify factors from literature
review
Discussions with
professionals from industry
Obtain opinions from professionals
Compare the most important
factors
Finalize factors to be used in
questionnaire
Preparation of questionnaireData collection
Data Analysis Compilation of results
Drawing out conclusion
Propose suitable
mitigation measures
Factors identifiedFactor causing time overrun Source
Poor site management and supervision
Elinwa, Odeh, Faridi, Fugar, Mydin, Rwakarehe, Aibinu
Poor Site management Al-Najjar, Kaliba, Sweis, Doloi, Le-Hoai, Ruqaishi, Danso
Rework due to frequent design changes or mistakes in construction
Kaming, Assaf, Odeh, Elinwa, Frimpong , Kaliba, Gardezi, Faridi
Unrealistic project duration given by the client
Odeh, Faridi, Fugar, Rwakarehe, Elinwa,
Delay in handing over the site to the contractor
Assaf, Frimpong , Kaming, Sambasivan, Le-Hoai, Doloi, Marzouk
Factors identified
Factor causing time overrun Source
Delay in financing and payment of running bills
Frimpong, Omoregie, Lo, Fugar, Gardezi , Dolage, Mizanur
Lack of co-ordination or communication between the parties
Odeh, Koushki, Iyer, Le-Hoai,Sambasivan, Ruqaishi, Doloi
Bad weather conditions Kaming, Assaf, Iyer, Apolot, Gardezi, Dolage
Shortage of human resources Assaf, Chan, Odeh, Faridi, Danso, Sweis,Dolage, Rwakarehe
Shortage of materials Chan, Omoregie, Faridi, Lo,Sambasivan, LeHoai, Danso, Rwakarehe
Questionnaire Design
• Section 1: General details• Section 2: Opinion regarding Factors responsible for
time overruns
Questionnaire consisted of two
parts
• Type of Organization• Work zone in India• Experience in years• Cost of current project
Section 1: General details
• The second section asked the respondent about his opinion for a given factor. The respondents were asked to select any one of the given options viz. Agree, Partially Agree, Partially Disagree and Disagree
Section 2: Respondent
Opinion
Data Collection
190 copies of the questionnaire were distributed among construction personnel engaged in works across India through e-mail and sometimes hard copies were circulated
The questionnaire was distributed to a random sample of 64 clients, 32 consultants and 94 contractors
85 sets of questionnaires were received after follow up
The overall response rate was found to be around 45%
Data Collection
Respondent typeNo. of
questionnaires distributed
No. of questionnaires
receivedResponse
rate
Clients 64 33 52%Consultants 32 10 31%Contractors 94 42 44%
All respondents 190 85 45%
Client Consultant Contractor All respondents0
20406080
100120140160180200
Responses received
DistributedReceived
Respondent type
No
. of
qu
es
tio
nn
air
es
Demographic Details of Respondents
• Respondent profile based on type of organization
Type of Organization
No. of responses
% of Total
Client33 39%
Consultant10 12%
Contractor42 49%
Client39%
Consultant12%
Contractor49%
Respondent profile based on type of Organiza-tion
Demographic Details of Respondents• Respondent profile based on working Region/Zone
in India Region/Zone
In IndiaNo. of
Respondents% of Total
East 5 6%
West 47 56%
Central 13 15%
North 7 8%
South 13 15%
East6%
West 55%
Central15%
North8%
South 15%
Respondent profile based on Zone/Region
Demographic Details of Respondents• Cross section of respondent profile based on Type of
Organization and Working Zone in India
Client
Consultant
Contractor
North 2 1 4
South 2 2 9
East -- 1 4
West 24 4 19
Central 5 2 6
North South East West Central0
5
10
15
20
25
30
2 20
24
5
12
1
42
4
9
4
19
6
Client Consultant Contractor
Demographic Details of RespondentsRespondent profile based on Experience
Experience of Respondents
No. of Respondents
% of Total
0 to 5 years 56 66%5 to 10 years 14 17%
10 to 15 years 2 2%15 to 20 years 6 7%
More than 20 years 7 8%
0-5 years66%
5-10 years16%
10-15 years
2% 15- 20 years
7%
more than 20 years8%
Respondent profile based on experience
Demographic Details of Respondents• Respondent profile based on Cost of current project
Cost of current project
Number of respondents
% of Total
Less than ₹ 10 cr 23 27%
Between ₹ 10 crto ₹50 cr 28 33%
Between ₹ 50 crto ₹100 cr 19 22%
More than ₹ 100 cr 15 18%
less than ₹ 10 crore27%
₹ 10 crore to
50 ₹crore33%
₹ 50 crore to ₹100
crore22%
more than
₹ 100 crore18%
Respondent profile based on cost of current project
Notation of factors
T1
• Inadequate experience of the contractor
T2
• Poor site management and supervision
T3
• Rework due to frequent design changes
T4
• Unrealistic project duration given by the client
T5
• Delay in handling over the site to contractor
T6
• Delay in financing and payment of running bills
T7
• Lack of co-ordination or communication between parties
T8
• Bad weather conditions
T9
• Shortage of human resourcesT10
• Shortage of materials
Response pattern- All Respondents
T7
T8
T1
T4
T5
T10
T3
T2
T6
T9
44
45
46
47
47
49
48
51
60
73
46
44
21
26
35
33
44
40
16
22
9
5
9
16
11
12
5
7
18
5
1
6
24
11
7
6
4
2
6
1
Agree Partially agree PartiallydisagreeDisagree No Idea
Coding the data
In order to code the data for purpose of calculating required parameters, the responses were coded using a four point Likert Scale
Response Weight assigned
Agree 4
Partially Agree 3
Partially Disagree 2
Disagree 1
No Idea Response not considered for analysis
Testing Reliability of Data
Reliability Analysis– The data collected was then tested for its reliability
by determination of Cronbach Alpha
Where,– α = Cronbach alpha– N= number of items– v = average inter-item covariance among the items– c = average variance
Testing Reliability of Data
• Cronbach’s alpha reliability coefficient normally ranges between 0 and 1.
• As per statisticians Gliem J. and Gliem R., (2003) the following rules of thumb may be followed:
• For the current study the Cronbach alpha value obtained was α = 0.705
Cronbach alpha value (α ) Reliability of data
α > 9 Excellent
9 > α > 8 Good
8 > α > 7 Acceptable
7 > α > 6 Poor
6 > α >5 Questionable
5 > α Discard the data
Relative Importance Index
• Relative Importance Index: – The term relative importance refers to the contribution a
variable makes to the prediction of a criterion variable by itself and in combination with other predictor variables.
– where,• A= highest weight given• N= total number of respondents for a given factor • ai = constant expressing the weight given to the ith response• i= 1,2,3,4• fi = the variable expressing the frequency of the ith response
Overall Ranking of Factors
Factors causing time overruns MeanStd.
Deviation RII Rank
Shortage of human resources- skilled, semi-skilled and unskilled (T9) 3.68 0.561 0.920 1
Poor site management (T2) 3.39 0.725 0.848 2
Lack of co-ordination or communication between parties (T7) 3.32 0.694 0.830 3
Delay in financing and payment of running bills (T6) 3.31 0.964 0.826 4
Bad weather conditions (T8) 3.29 0.815 0.823 5
Shortage of materials on site (T10) 3.26 0.888 0.815 6
Rework due to frequent design changes (T3) 3.25 0.815 0.813 7
Unrealistic project duration given by client (T4) 3.09 1.031 0.773 8
Delay in handing over site to the contractor (T5) 2.98 1.134 0.745 9
Inadequate experience of Contractor (T1) 2.89 1.225 0.723 10
Ranking of factors by Clients
Factors causing time overruns Mean Std. Deviation RII Rank
Inadequate experience of Contractor (T1) 3.76 0.502 0.938 1
Shortage of human resources- skilled, semi-skilled and unskilled (T9) 3.58 0.502 0.893 2
Poor site management (T2) 3.48 0.712 0.870 3
Rework due to frequent design changes (T3) 3.33 0.692 0.833 4
Bad weather conditions (T8) 3.27 0.517 0.818 5Shortage of materials on site (T10) 3.21 0.857 0.803 6
Lack of co-ordination or communication between parties (T7) 3.21 0.740 0.803 6
Delay in financing and payment of running bills (T6) 2.58 1.032 0.643 8
Unrealistic project duration given by client (T4) 2.36 0.994 0.590 9
Delay in handing over site to the contractor (T5) 2.15 1.004 0.538 10
Ranking of factors by ConsultantsFactors causing time overruns Mean Std.
Deviation RII Rank
Poor site management (T2) 3.70 0.483 0.925 1
Shortage of human resources- skilled, semi-skilled and unskilled (T9) 3.70 0.675 0.925 1
Delay in handing over site to the contractor (T5) 3.30 0.823 0.825 3
Delay in financing and payment of running bills (T6) 3.30 0.823 0.825 3
Rework due to frequent design changes (T3) 3.30 1.059 0.800 3
Lack of co-ordination or communication between parties (T7) 3.20 0.966 0.805 6
Unrealistic project duration given by client (T4) 3.20 1.033 0.805 6
Inadequate experience of Contractor (T1) 3.00 0.943 0.750 8
Shortage of materials on site (T10) 2.70 0.949 0.675 9
Bad weather conditions (T8) 2.60 0.966 0.650 10
Ranking of factors by Contractors
Factors causing time overruns Mean Std. Deviation RII Rank
Delay in financing and payment of running bills (T6) 3.88 0.395 0.970 1
Shortage of human resources- skilled, semi-skilled and unskilled (T9) 3.76 0.576 0.940 2
Unrealistic project duration given by client (T4) 3.64 0.656 0.910 3
Delay in handing over site to the contractor (T5) 3.55 0.889 0.885 4
Bad weather conditions (T8) 3.60 1.231 0.865 5Lack of co-ordination or communication between parties (T7) 3.43 0.590 0.858 6
Shortage of materials on site (T10) 3.43 0.859 0.858 6Poor site management (T2) 3.24 0.759 0.810 8
Rework due to frequent design changes (T3) 3.17 0.853 0.793 9
Inadequate experience of Contractor (T1) 2.19 1.254 0.548 10
ANOVA
One way ANOVA test can be used when we want to compare means of more than two groups of an independent variable
Null Hypothesis (Ho) – There is no significant difference among construction professionals in opinion for time overrun factor from different regions of India.
Alternate Hypothesis (H1) - There is significant difference among construction professionals in opinion for time overrun factor from different regions of India.
ANOVAFactors responsible for time overruns Variance Sum of
Squaresdf Mean Square F Sig.
1. Inadequate experience of contractor
Between Groups 10.429 4 2.6071.804 .136Within Groups 115.619 80 1.445
Total 126.047 842. Poor site management and supervision
Between Groups 1.173 4 .293.546 .703Within Groups 43.015 80 .538
Total 44.188 843. Rework due to frequent design change or mistakes in construction
Between Groups 5.370 4 1.3432.129 .085Within Groups 50.441 80 .631
Total 55.812 844. Unrealistic project duration given by client
Between Groups 2.813 4 .703.651 .628Within Groups 86.434 80 1.080
Total 89.247 845. Delay in handing over site to contractor
Between Groups .993 4 .248.186 .945Within Groups 106.960 80 1.337
Total 107.953 846. Delay in financing and payment of running bills for completed works
Between Groups 1.913 4 .478.503 .734Within Groups 76.134 80 .952
Total 78.047 847. Lack of coordination and communication between parties
Between Groups .103 4 .026.051 .995Within Groups 40.320 80 .504
Total 40.424 848. Bad weather or environmental conditions
Between Groups 5.308 4 1.3272.104 .088Within Groups 49.835 79 .631
Total 55.143 839. Shortage of human resources Between Groups .819 4 .205
.640 .636Within Groups 25.604 80 .320Total 26.424 84
10. Shortage of materials Between Groups .419 4 .105.127 .972Within Groups 65.887 80 .824
Total 66.306 84
Interpreting ANOVA Results
Factors responsible for time overruns
Observed value of F statistic
Fobs
Observed value of
significancesigobs
Check for significance;
Whether sigobs >0.05
Maximum value of F statistic
Fmax
Check for F statistic;WhetherFobs< Fmax
Remark(Accept H0 OR Reject
H0)
1. Inadequate experience of contractor 1.804 0.136 Yes 2.486 Yes Accept H0
2. Poor site management and supervision 0.546 0.703 Yes 2.486 Yes Accept H0
3. Rework due to frequent design change or mistakes in construction 2.129 0.085 Yes 2.486 Yes Accept H0
4. Unrealistic project duration given by client 0.651 0.628 Yes 2.486 Yes Accept H0
5. Delay in handing over site to contractor 0.186 0.945 Yes 2.486 Yes Accept H0
6. Delay in financing and payment of running bills for completed works 0.503 0.734 Yes 2.486 Yes Accept H0
7. Lack of coordination and communication between parties 0.051 0.995 Yes 2.486 Yes Accept H0
8. Bad weather or environmental conditions 2.104 0.088 Yes 2.486 Yes Accept H0
9. Shortage of human resources 0.640 0.636 Yes 2.486 Yes Accept H0
10. Shortage of materials 0.127 0.972 Yes 2.486 Yes Accept H0
Inference from ANOVA
From the results of ANOVA it can be concluded that the null hypothesis can be accepted
There is no significant difference between the opinions of the professionals from different zones of the country about the time overrun factors
Principal Component Factor Analysis
It is a technique used for reducing large number of variables to a small number of components or factors
Generally used in order to classify variables or for detecting a possible structure in relationship between the variables
Carrying out Principal Component Factor Analysis
Initial examination• Determinant• KMO test• Test of sphericity
Extraction of Factors without Rotation
Check for logical grouping of factors Apply suitable
rotation and extract factors
Initial examinationCorrelation Matrixa
T1 T2 T3 T4 T5 T6 T7 T8 T9 T10T1-Inadequate experience of contractor 1.000
T2-Poor site management and supervision .463 1.000
T3-Rework due to frequent design change or mistakes in construction .337 .496 1.000
T4-Unrealistic project duration given by client -.388 .111 .115 1.000
T5-Delay in handing over site to contractor -.356 .075 -.017 .750 1.000
T6-Delay in financing and payment of running bills for completed works -.357 .128 .169 .645 .647 1.000
T7-Lack of co-ordination and communication between parties .111 .207 .309 .307 .258 .339 1.000
T8-Bad weather or environmental conditions -.113 -.023 .114 .253 .311 .090 .261 1.000
T9- Shortage of human resources -.033 .038 -.094 .363 .283 .244 .113 .229 1.000T10- Shortage of materials -.129 -.019 .133 .326 .259 .249 .316 .482 .379 1.000a. Determinant = .025
Initial examination
The correlation coefficient 0.025 is
considered as sufficient (> 0.00001), which
indicates that none of the two matrices have multi
collinearity or singularity.
The Kaiser-Meyer-Olkin (KMO) measure of
sampling adequacy was found to be 0.677 (> 0.50)
as well as the value of Chi-square for.
Bartlett test of sphericity (test of identity matrix) was 291.640 at 0.001 level of significance
These measures confirmed the suitability
of the data for proceeding to factor
analysis
Extraction of factors
The basic concept underlying the Principal Components Factor Analysis (PCFA) is that the extracted components explain most of the variance of the correlated variables
The factor analysis can extract common factors equal to or less than the number of variables involved
The significant factors are those whose eigen values are greater than or equal to 1
Eigen value is a measure of how a standard variable adds to the principal components
Total Variance ExplainedTotal Variance Explained
ComponentInitial Eigen values
Extraction Sums of Squared Loadings
Total% of
VarianceCumulative
% Total% of
VarianceCumulative
%1 3.271 32.712 32.712 3.271 32.712 32.7122 2.012 20.121 52.833 2.012 20.121 52.8333 1.288 12.880 65.713 1.288 12.880 65.7134 .917 9.174 74.8865 .676 6.760 81.6466 .589 5.891 87.5387 .411 4.109 91.6478 .333 3.330 94.9779 .320 3.198 98.175
10 .183 1.825 100.000Extraction Method: Principal Component Analysis.
Extraction of factors without rotationComponent Matrixa
Component1 2 3
1. Inadequate experience of contractor .742
2. Poor site management and supervision .786
3. Rework due to frequent design change or mistakes in construction .779
4. Unrealistic project duration given by client .855
5. Delay in handing over site to contractor .818
6. Delay in financing and payment of running bills for completed works .768
7. Lack of co-ordination and communication between parties .501
8. Bad weather or environmental conditions .623
9. Shortage of human resources .495
10. Shortage of materials .593
Extraction Method: Principal Component Analysis.a. 3 components extracted.
Extraction of factors After applying RotationRotated Component Matrixa
Component1 2 3
1. Inadequate experience of contractor .6632. Poor site management and supervision .8243. Rework due to frequent design change or mistakes in construction .799
4. Unrealistic project duration given by client .8545. Delay in handing over site to contractor .8416. Delay in financing and payment of running bills for completed works .8677. Lack of co-ordination and communication between parties .281
8. Bad weather or environmental conditions .7969. Shortage of human resources .55710. Shortage of materials .824
Extraction Method: Principal Component Analysis. Rotation Method: Varimax with Kaiser Normalization
a. Rotation converged in 4 iterations.
Inferences from result of Principal Component Factor Analysis
Factors extracted • The three components obtained were named as CFT 1, CFT 2 and CFT 3
CFT 1Client controlled factors
• Delay in financing and payment of running bills for completed works,
• Unrealistic project duration given by client• Delay in handing over site to contractor
CFT 2Contractor controlled
factors
• Poor site management and supervision, • Rework due to frequent design change or mistakes
in construction, • Inadequate experience of contractor• Lack of co-ordination and communication
CFT 3Planning related factors
• Shortage of materials, • Shortage of human resources
Comparison with other countriesCountry Major factors for time overruns
1 2 3 4 5
India (This study) Shortage of manpower
Poor site management
Lack of co-ordination or communication between the parties
Delay in Financing and payment of running bills
Bad weather conditions
Oman (Ruqaishi,2014)
Poor site management and supervision by contractors
Problems with subcontractors
Inadequate planning and scheduling of projects by contractors
Poor management of contractors’ schedules
Delay in delivery of materials,
Egypt (Marzouk, 2014)
Finance and payments of completed work by owner
Late in revising and approving design documents by owner
Owner interference Suspension of work,Mistakes and discrepancies in design documents
Tanzania (Rwakarehe, 2014) Inadequate design Change in the scope
of the projectChange in government policies
Delay in payment to contractors which results in interests
Inclement weather
Bangladesh (Mizanur, 2014)
Rapid increase in price of construction materials
Political situation (revolution/ public strikes)
Incompetent/and immature subcontractors
Poor financial condition of contractors
Frequent design changes
Uganda (Alinaitwe, 2013)
Changes in the work scope
Delayed payments to contractors
Poor monitoring and control
High inflation and interest rates.
Shortage of manpower
Sri Lanka (D.A.R. Dolage, 2013)
Delay in progress payment by clients, by contractors
Inaccurate planning and scheduling of projects
Rainy weather,Unavailability of experienced technical staff
Excessive work in hand of the contractors
Comparison with other countriesCountry
Major factors for time overruns1 2 3 4 5
Iran (Towhid Pourrostam, 2011)
Delay in progress payments by client
Change orders by client during Construction
Poor site managementSlowness in decision making process by client
Financial difficulties by contractor
Ghana (Fugar, 2010) Delay in honouring payment certificates
Underestimation of cost of projects
Underestimation of complexity of projects
Difficulty in accessing Bank credit Poor supervision
Libya (Tumi, 2009) Improper Planning Lack of Effective Communication Design Errors Shortage of materials
i.e. steel, concrete, Slow Decision Making
Vietnam (Long Le-Hoai, 2008)
Poor site management and supervision
Poor project management assistance
Financial difficulties of owner
Financial difficulties of contractor Design changes
Malaysia (Sambasivan, 2007) Improper planning Poor site management Inadequate contractor
experience
Inadequate client’s finance and payments for completed work
Problems with subcontractors
Jordan (Sweis, 2007)Financial difficulties faced by the contractor
Too many change orders from owner
Poor planning and scheduling of the project by the contractor
Presence of unskilled labour
Shortage of technical professionals in the contractor’s organization
Hong Kong (Tommy Y. Lo, 2006)
Inadequate resources due to contractor/lack of running capital
Unforeseen ground conditions Exceptionally low bids Inexperienced
contractors
Works in conflict with existing structures/ utilities
UAE (Faridi, 2006) Preparation and approval of drawings
Slowness of the owner’s decision-making process
Shortage of manpower
Poor supervision and Inadequate early planning of the project
Poor site management
Nigeria (Aibinu, 2006) Contractors’ financial difficulties
Clients’ cash flow problem
Architects’ incomplete drawing
Subcontractor’s slow mobilization
Equipment break-down and maintenance problem
Kuwait (Koushki, 2005) Change orders Financial constraints Contractor’s lack of
experience Shortage of materials Weather conditions
Conclusions
The professionals across India share by and large a similar opinion about the factors responsible for time overruns in execution of construction projects.
Lack of human resources emerged as the most significant factor and had the highest degree of agreement among all the parties involved in construction.
Poor site management emerged as the second most significant factor and reflected an agreement between the clients and consultants but the contractors differed in opinion.
Lack of coordination or communication between the construction parties was the third most significant factor in the view of all the three parties.
The factors ‘Delay in financing and payment of running bills’, ‘Unrealistic project duration given by client’, ‘Delay in handing over site to the contractor’ and ‘Inadequate experience of Contractor’ had a very high degree of disagreement between clients and contractors. This indicates a trust deficit between the client and contractor.
‘Bad weather conditions’’ were moderately significant for both the client and contractor but consultants considered it least significant. This indicates that the consultants more often do not consider external factors during planning.
Mitigation Measures
• Framework for overcoming Shortage of human resources
Mitigation Measures• Framework for overcoming Poor site management
Mitigation Measures
• Framework for overcoming Poor co-ordination and communication between construction parties
Future Scope
Systematic studies are required to be undertaken to determine the effectiveness of mitigation measures in order to improvise them further and develop suitable models that can help preventing the factors inhibiting time overruns.
There is a need of sector specific studies as generalization comes at a cost and may not reflect certain characteristics that are endemic to a particular sector.
An attempt can be made to develop regression models relating time overruns to cost escalation in order to estimate the impact of time overruns on the cost performance of the project.
Further studies need to undertaken in order to understand how modern construction management techniques like lean construction or relational contracts can help to mitigate the factors responsible for time overruns
References• Central Statistical Office, Ministry of Statistics and Program Implementation, New Delhi, “Infrastructure Statistics -
2014,” vol. I, 2014.• R. Singh, “Delays and Cost Overruns in Infrastructure Projects : Extent , Causes and Remedies,” Economics and
Political Weekly, vol. xlv, no. 21, pp. 43–54, 2010.• P. F. Kaming, P. O. Olomolaiye, G. D. Holt, and F. C. Harris, “Factors influencing construction time and cost overruns
on high-rise projects in Indonesia,” Construction Management and Economics, vol. 15, no. 1, pp. 83–94, 1997.• J. Al-Najjar, “Factors influencing time and cost overruns on construction projects in the Gaza Strip,” Islamic
University of Gaza, 2008.• Z. M. Kraiem, “Concurrent Delays in Construction Projects,” Journal of Construction Engineering and Management,
vol. 113, no. 4, pp. 591–602, 1988.• S. A. Assaf, M. Al-Khalil, and M. Al-Hazmi, “Causes of Delay in Large Building Construction Projects,” Journal of
Management in Engineering, vol. 11, no. 2, pp. 45–50, 1995.• D. W. M. Chan and M. M. Kumaraswamy, “An evaluation of construction time performance in the building industry,”
Building and Environment, vol. 31, no. 6, pp. 569–578, 1996.• A. U. Elinwa and M. Joshua, “Time-Overrun Factors in Nigerian Construction Industry,” Journal of Construction
Engineering and Management, vol. 127, no. 5, pp. 419–425, 2001.• A. M. Odeh and H. T. Battaineh, “Causes of construction delay: Traditional contracts,” International Journal of
Project Management, vol. 20, no. 1, pp. 67–73, 2001.• Y. Frimpong, J. Oluwoye, and L. Crawford, “Causes of delay and cost overruns in construction of groundwater
projects in a developing countries; Ghana as a case study,” International Journal of Project Management, vol. 21, no. 5, pp. 321–326, 2003.
• P. A. Koushki, K. Al Rashid, and N. Kartam, “Delays and cost increases in the construction of private residential projects in Kuwait,” Construction Management and Economics, vol. 23, no. 3, pp. 285–294, 2005.
• A Omoregie and D. Radford, “Infrastructure delays and cost escalation: causes and effects in Nigeria,” Proceeding of sixth International Postgraduate Research Conference. Netherlands, Delft University of Technology, pp. 79–93, 2006.
References• A. S. Faridi and S. M. El Sayegh, “Significant factors causing delay in the UAE construction industry,”
Construction Management and Economics, vol. 24, no. 11, pp. 1167–1176, 2006.• K. C. Iyer and K. N. Jha, “Critical Factors Affecting Schedule Performance: Evidence from Indian
Construction Projects,” Journal of Construction Engineering and Management, vol. 132, no. 8, pp. 871–881, 2006.
• T. Y. Lo, I. W. Fung, and K. C. Tung, “Construction Delays in Hong Kong Civil Engineering Projects,” Journal of Construction Engineering and Management, vol. 132, no. 6, pp. 636–649, 2006.
• E. C. Ubani, K. A. Okorocha and S. C. Emeribe, “Analysis of factors influencing time and cost overruns on construction projects in south eastern nigeria.,” International Journal of Management Sciences and Business Research, vol. 2, no. 2, pp. 73-84, 2007.
• M. Sambasivan and Y. W. Soon, “Causes and effects of delays in Malaysian construction industry,” International Journal of Project Management, vol. 25, no. 5, pp. 517–526, 2007.
• L. Le-Hoai, Y. D. Lee, and J. Y. Lee, “Delay and cost overruns in Vietnam large construction projects: A comparison with other selected countries,” KSCE Journal of Civil Engineering, vol. 12, no. 6, pp. 367–377, 2008.
• M. Ruqaishi and H. A. Bashir, “Causes of Delay in Construction Projects in the Oil and Gas Industry in the Gulf Cooperation Council Countries : A Case Study,” Journal of Management in Engineering, pp. 1–8, 2009.
• C. Kaliba, M. Muya, and K. Mumba, “Cost escalation and schedule delays in road construction projects in Zambia,” International Journal of Project Management, vol. 27, no. 5, pp. 522–531, 2009.
• S. A. H. Tumi, A. Omran, and A. H. K. Pakir, “Causes of Delay in Construction Industry in Libya,” International Conference on Economics and Administration, University of Bucharest, Romania, pp. 265–272, 2009.
References• McKinsey and Company, “Building India-Accelerating Infrastructure projects,” 2009.• F. D. K. Fugar and A. B. Agyakwah-baah, “Delays in Building Construction Projects in,” Australasian Journal of Construction
Economics and Building, vol. 10, no. 1/2, pp. 103–116, 2010.• N. Hamzah, M. A. Khoiry, I. Arshad, N. M. Tawil, and A. I. Che Ani, “Cause of construction delay - Theoretical framework,”
Procedia Engineering, vol. 20, pp. 490–495, 2011.• I. A. R. Aftab Hameed Memon Mohd Razaki abdullah, Ade Asmi Abdul Aziz, “Time Overrun in Construction Projects from the
Perspective of Project Management Consultant (PMC),” Journal of Surveying, Construction and Property, vol. 2, no. 1, pp. 54-66, 2011.
• T. Pourrostam and A. Ismail, “Significant Factors Causing and Effects of Delay in Iranian Construction Projects.,” IACSIT International Journal of Engineering and Technology, vol. 4, no. 5, pp. 450–456, 2012.
• H. Doloi, A. Sawhney, K. C. Iyer, and S. Rentala, “Analysing factors affecting delays in Indian construction projects,” International Journal of Project Management, vol. 30, no. 4, pp. 479–489, 2012.
• K. A. Mohammed, “Causes of Delay in Nigeria Construction Industry,” Interdisciplinary Journal of Contemporary Research in Business, vol. 4, no. 2, pp. 785–794, 2012.
• K. Wong and V. Vimonsatit, “A study of the factors affecting construction time in Western Australia,” Scientific Research and Essays, vol. 7, no. 40, pp. 3390–3398, 2012.
• H. Danso and J. K. Antwi, “Evaluation of the Factors Influencing Time and Cost Overruns in Telecom Tower Construction in Ghana,” Civil and Environmental Research, vol. 2, no. 6, pp. 15–25, 2012.
• O. E. A. and A. Akinsulire, “Stakeholders’ Perception of the Causes and Effect of Construction Delays on Project Delivery,” KICEM Journal of Construction Engineering and Project Management, vol. 2, no. 4, pp. 25–31, 2012.
• R. Apolot and D. Tindiwensi, “Investigation into the Causes of Delays and Cost Overruns in Uganda’s Public Sector Construction Projects,” Journal of Construction in Developing Countries, vol. 18, no. 2, pp. 33–47, 2013.
• M. Desai and R. Bhatt, “Critical Causes of Delay in Residential Construction Projects : Case Study of Central Gujarat Region of India,” International Journal of Engineering Trends and Technolog, vol. 4, no. 4, pp. 762–768, 2013.
• I. Mahamid, “Common risks affecting time overrun in road construction projects in palestine: Contractors’ perspective,” Australasian Journal of Construction Economics and Building, vol. 13, no. 2, pp. 45–53, 2013.
• S. S. S. Gardezi, I. A. Manarvi, and S. J. S. Gardezi, “Time Extension Factors in Construction Industry of Pakistan,” Procedia Engineering, vol. 77, pp. 196–204, 2014.
• G. J. Sweis, R. Sweis, M. A. Rumman, R. A. Hussein, and S. E. Dahiya, “Cost Overruns in Public Construction Projects: The Case of Jordan,” International Journal of Project Management, vol.26, pp. 665-674, 2008.