BROOKLYN VILLAGE AND WALTON PLAZA MASTER DEVELOPER ... County Br… · Mecklenburg County |...
Transcript of BROOKLYN VILLAGE AND WALTON PLAZA MASTER DEVELOPER ... County Br… · Mecklenburg County |...
BROOKLYN VILLAGE AND WALTON PLAZA
MASTER DEVELOPER SOLICITATION
REQUEST FOR PROPOSALS
Mecklenburg County, North Carolina
December 18, 2015
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 1
CONTENTS
I. Introduction ..................................................................................................................................................... 2
II. Submission Requirements ............................................................................................................................. 4
III. Evaluation and Selection ............................................................................................................................ 9
IV. Solicitation Schedule ................................................................................................................................. 11
V. Submission Instructions & Questions ........................................................................................................ 12
Appendices ...................................................................................................................................................... 13
Appendix A – Pro forma template ............................................................................................................... 14
Appendix B – Request for Qualifications .................................................................................................... 15
Appendix C – General Provisions ................................................................................................................. 42
Appendix D – Miscellaneous Project Requirements ................................................................................. 43
Appendix E - Mecklenburg County 2014 Area Median Income ........................................................... 45
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 2
I. INTRODUCTION
Mecklenburg County, NC (the “County”) invites pre-qualified development teams to submit a
proposal to act as the developer (the “Master Developer”) for a mixed-use program on an 11.3-
acre site known as “Brooklyn Village” and a 5-acre site known as “Walton Plaza” in the Second
Ward neighborhood of Uptown Charlotte, NC. This Request for Proposals (the “RFP”) follows a
Request for Qualifications (“RFQ”) issued on October 22, 2015 (see Appendix B).
The selected Master Developer will construct and comprehensively manage a mixed-use
development that fulfills the vision stated in the Second Ward Master Plan and the Center City
2020 Vision Plan, and as set forth by the County for the Brooklyn Village and Walton Plaza sites.
Specifically, the County requests that pre-qualified respondents submit a proposal that will
advance the following Project Objectives (in order of priority):
Facilitate creation of a program that creates long-term economic development benefits
for the County and surrounding community;
Complete development of a high-quality program in a timely and efficient manner;
Create and execute a thorough local resident and stakeholder engagement process, in
which local input is reflected in the eventual development program; and
Maximize the near-term financial return to the County upon acquisition of these parcels,
while balancing the above goals within the development program.
In response to the RFQ, respondents submitted statements of qualification and conceptual plans
that are of interest to the County. Respondents will now have an opportunity to refine their
redevelopment approach and demonstrate their ability to finance, construct, and manage large
mixed-use developments at these sites. The County will look to Respondents to provide more
elaborate site plans, full financial documentation, and a proposed deal structure and economic
offer to the County among other requirements detailed in the Submission Requirements section of
this RFP.
As part of this proposal, Respondents must provide a complete response including all requirements
specified in the Submission Requirements section. In particular, the County will look to Respondents
to fully describe the following components of their proposals.
Development Team and Qualifications. The County intends to provide a significant area
within the City of Charlotte’s Second Ward to the Master Developer for the creation of an
active, vibrant mixed-use program. In order to complete this transaction, the County must
have a complete description of the development team intending to execute this
program. The County is seeking development teams that bring the full range of experience
and qualifications necessary for executing this project, including horizontal and vertical
development for all phases of the project. Submissions should name and describe all firms
required for vertical development and horizontal development, and all partner firms that
will be part of the development team, including design, engineering, construction, and
outreach partners. If the development team is missing a specific discipline that is key to
the execution of the proposed concept, please specify the discipline, the intended role of
the unidentified firm, and a list of potential partner firms. Please note that the County will
require full teams to be identified before entering into negotiations with the preferred
development partner.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 3
Horizontal Development Program. The County requires respondents to refine their plans for
site preparation and horizontal development, including submission of a specific plan and
narrative for any horizontal improvements anticipated for the sites. This includes plans for
open space as well as site infrastructure and access.
As noted in the RFQ, the Respondents’ plans must include at least 1.6 acres of open space.
At least 1.5 acres of this total must be open space for recreation, and should be exclusive
of pedestrian linkages and connections. This park space should have as many active
edges as possible, and proposals should indicate intended programming for this space
(including types of active recreation and/or areas of passive recreation).
The County is also seeking detailed responses regarding site infrastructure, including
drainage systems, roadways, pedestrian access, and parking. RFP submissions should
include narrative, plans, and financial analysis for each of these items.
Affordable Housing Requirement. As specified in the Interlocal agreement between
Mecklenburg County and the City of Charlotte, future development of the Brooklyn Village
site must include a minimum of 30 units of affordable housing reserved for households with
an annual income of 80% and below of area median income. Respondents should specify
the type of affordable housing financing programs they may use, and how they will ensure
that these units are delivered and preserved as affordable for a minimum period of 15
years after initial occupancy.
Deal Structure and Program Delivery. The Center City 2020 Vision Plan allows the County
to dispose of these parcels through negotiated private sale. The County intends to sell both
parcels to the future Master Developer through this RFP process, but encourages
respondents to think creatively and specifically about the County’s role in the
development, and to raise alternate deal structures if applicable (which may include
varying forms of joint venture). Respondents should clearly define the County’s roles and
responsibilities, if any, for financing and/or delivery of any improvements. If public
participation is desired, respondents must identify the improvement, the type of
participation, the timing of participation, and, if financing is requested, the amount
required. Specific terms of any County participation will be negotiated between the
County and Master Developer finalist after proposals are submitted.
Financial Statements and Financing Plan. Given the complexity of redeveloping the sites,
the County is seeking a private partner with a proven track record of successfully financing
and executing similar projects. In order to conduct a thorough evaluation of each
respondent, the County must receive the most recent annual financial statement for the
lead development firm(s), which may be provided on a confidential basis subject to the
North Carolina General Statutes. In addition, the County requests a clear, detailed
approach describing the amount and timing of anticipated sources of public and private
funding. Additional information regarding the Respondents’ economic offers is included in
the Submission Requirements section of this RFP.
Respondents are required to provide complete proposals that include the components described
above and all other components specified in the Submission Requirements section below.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 4
II. SUBMISSION REQUIREMENTS
The County invites pre-qualified Respondents to submit proposals. Respondents must submit two
(2) hard copies and one (1) electronic version of the proposal on a flash drive, to be received by
HR&A Advisors no later than Friday, February 19, 2016 at 4pm EST. More detailed instructions for
submissions are provided in Section V: Submission Instructions and Questions.
The selected Master Developer will be responsible for creating and executing an overall
development plan that is consistent with the County’s vision for the sites and the Project Objectives
described above. To be considered as a valid response, the Respondent must clearly and
completely address each of the following areas in their proposal:
1. PROJECT VISION AND DESCRIPTION Respondents should submit a written narrative for
the vision, building on their proposed plan submitted in the RFQ phase, including greater
detail on development program, horizontal improvements, and architectural concept
for both sites. Respondents must note instances where the project approach differs from
what was initially submitted as part of their RFQ response. The project vision and
description should include:
a. Vision Statement. Respondents should begin with a Vision Statement that
establishes the aspiration for the proposed development and its alignment with
the Project Objectives, the Center City 2020 Vision Plan, and the Second Ward
Master Plan. This statement should be refined from the RFQ stage to clearly
articulate the elements of the proposed development, its open space program,
and relationship to other destinations within the Second Ward.
b. Vertical Development Program. A refined program should be submitted for
vertical development, including proposed uses, anticipated square footage of
each use, and number of units for residential uses. It should also include
identification of the target market(s) and market assumptions, including rents,
absorption, etc.
Specifically for residential use, the Respondent must describe the type of
ownership structure (e.g. rental, condominiums) and number of proposed
affordable residential units (proposals should include a minimum of 30 units for
households earning up to 80% of the area median income. See Appendix C for
Mecklenburg County area median income).
Specifically for retail, hotel, and office use, the Respondents may choose, but are
not required, to provide letters of intent or interest from potential
tenants/operators.
Respondents should confirm the program’s adherence to provisions of the City of
Charlotte’s UMUD and UMUD-O zoning and whether any additional review or
approvals by the County or City are required.
Respondents should provide a detailed explanation of on-site parking to be
provided, how different uses will be accommodated by this parking, how different
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 5
uses will share garages if necessary, and how parking facilities will accommodate
public parking, if at all.
c. Horizontal Improvement Program. Respondents should provide a detailed
description of horizontal improvements to be included throughout the sites,
including:
o Open space, as previously described;
o Roads;
o Pedestrian walkways;
o Utilities;
o Parking, if not integrated with vertical development; and
o Any other improvements necessary to support the vertical development
program.
The horizontal program must be accompanied by:
o A summary table of the amount or units of vertical development (e.g.
square feet, dwelling units or parking spaces) associated with each
horizontal component;
o Plans or drawings as appropriate (may be included as part of the
architectural concept described below); and
o Conceptual cost estimates.
d. Architectural Concept. Respondents should submit conceptual drawings that
depict all vertical development and horizontal improvements. For both sites,
proposals must include plans, massings, and a summary of the proposed buildings
with all square footages, unit counts, anticipated height, and floor area ratio
identified. Plans should also indicate proposed vehicular and pedestrian access
and egress points, the amount of usable space, and the location of the
programmatic elements and open spaces. In addition, plans must include a
preliminary approach to materials and design vocabulary, including any
incorporation of historical references and alignment with the vision laid out in the
Center City 2020 Vision Plan and Second Ward Master Plan. These drawings are
intended to be conceptual in nature and solely an expression of building typology
and of the respondent’s vision for vertical and horizontal improvements.
Respondents may choose, but are not required, to provide renderings for
architectural concepts.
e. Stakeholder Engagement & Marketing Strategy. Respondents must propose a
strategy for stakeholder engagement, which should include at minimum:
o Preliminary outreach targets;
o Timeline;
o Approach to incorporation of any feedback; and
o Approach to marketing and outreach for the completed development,
including the tenanting of affordable housing.
2. DEVELOPMENT PHASING AND SCHEDULE Respondents should include an overall
project timeline and phasing plan that describes the Respondent’s strategy and timing
for delivering the horizontal and vertical components of the project, with building and
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 6
land absorption projections consistent with the Project Vision described above and
aligned with market realities. This should include a graphic schedule and any necessary
accompanying narrative.
3. DEVELOPMENT TEAM & QUALIFICATIONS Respondents should include all of the below
information, including any requested information that was previously included in the RFQ
stage and any information that has changed since issuing responses to the RFQ.
Respondents must include:
a. A description of all firms comprising the development team, including intended
vertical and horizontal development partners, design partners, engineers,
construction team, etc. If the development team is missing a specific discipline
that is key to the execution of the proposed concept, please specify the discipline,
intended role of the unidentified firm, and a list of potential partner firms.
b. A diagram or organizational chart illustrating the relationship between the lead
developer and any partner firms or subcontractors.
c. For all key personnel at each firm, provide a resume, describing relevant
experience and intended role on the project team.
d. For teams led by a joint venture, clearly show the structure, percentage of
ownership held by each lead team member, and intended role (e.g. co-
developer, fee developer, limited partner, general partner, operator and/or
property manager).
e. A list of known project commitments for key personnel through 2018, along with a
statement indicating how the development entity and key principals plan to
manage the project, including the amount of time that would be available to
dedicate to the process.
4. FINANCIAL OFFER AND DEAL STRUCTURE PROPOSAL Respondents should specify their
proposed structure and financial terms for partnership with the County. All responses
should include detailed proposals for Master Developer and County roles, financial offer,
source and timing of funds, and breakup terms. At minimum, the financial and deal
structure proposal should address the subtopics listed below:
a. Financial Offer. Include the team’s financial offer for the two sites and any
included horizontal improvements. This offer should include a narrative indicating
the Respondent’s acceptance of, or differing approach to, the deal structure
described in the Introduction and below in item (c), including the anticipated
timing of payments to the County. Note that the County seeks to maximize the
near-term proceeds from disposition of these parcels.
b. Financial Statements. Include the most recent annual financial statements of the
lead development firm. Teams led by a joint venture must include financial
statements from all partners. Any submitted documentation to the County will be
subject to public records request unless clearly marked as “CONFIDENTIAL.”
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 7
Confidential documents may be protected from public disclosure per the
applicable North Carolina General Statutes (NCGS 66 and 132).
c. Deal Structure and Program Delivery. Submit a proposed approach for delivering
the horizontal and vertical components outlined in the Project Vision and
Description.
The County envisions a sale of both parcels to the future Master Developer, but is
open to participating in order to meet the County’s goals. Respondents must
clearly state whether their redevelopment approach requires County
participation in any form, and if so, Respondent must identify the improvement,
the type of participation, the timing of participation, and, if financing is requested,
the amount required.
d. Pro Forma. Respondents must complete a pro forma cash flow for the proposed
project for a period of no less than ten years, including all phases of development
(including construction and operations). Respondents must outline all assumptions
on which the pro forma document is based, including but not limited to minimum
rate of return, as well as construction costs and associated architectural
assumptions, and clearly include a table of sources and uses and total
development budget. The pro forma should include all necessary capital
improvements over time, reserve, and debt service payments associated with
construction financing. The cash flows should be submitted in Excel format with
active formulas and link to the section clearly outlining assumptions on which all
calculations were based.
A template for this pro forma is provided as an appendix to this RFP. Respondents
must use this pro forma as the basis for their analysis and submission.
The items identified below should be addressed within Respondents’ submissions,
separate from the pro forma template, even if they are included in those
calculations.
e. Financing Plan (Sources). Provide a detailed description of equity and debt
sources for financing this project. For equity, Respondents must describe each
investor’s equity commitment to the project, including letters of commitment from
each equity investor stating the full terms and conditions under which such
amounts will be provided to the project and with a schedule of disbursement
consistent with the Respondent’s requirement for construction and permanent
financing. For debt, Respondents must provide satisfactory evidence of
Respondent’s ability to secure project debt, including tentative commitment
letters from prospective lenders.
f. Financing Approach for Affordable Housing (Sources). Respondents must clearly
articulate their approach to financing the affordable housing components of the
project, including the use of Low Income Housing Tax Credits and/or other
potential sources of federal, state, public and/or other philanthropic funding
sources. Respondents who choose to include such sources of funding should
indicate their past experience in utilizing such sources or identify their anticipated
capacity to secure such funding sources.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 8
g. Long-Term Ownership and Management. Respondent should state whether it
intends to retain a long-term ownership position in the project or sell the
developed project to third parties.
5. MISCELLANEOUS PROJECT REQUIREMENTS Respondents should provide a statement
of compliance with the Miscellaneous Project Requirements described in the RFQ and
attached as Appendix B of this RFP. Specifically, this includes County requirements for:
a. Americans with Disabilities Act (ADA) Compliance
b. Minority/Women/Small Business Enterprise
c. Insurance and Indemnity Requirements
d. E-Verify
More information on these requirements can be found online at:
http://charmeck.org/mecklenburg/county/Finance/Procurement/Pages/default.aspx.
All work product submitted by Respondents shall become the property of the County upon
submission. Submitted materials will be subject to public records request unless clearly marked as
“CONFIDENTIAL.” Documents are protected from public disclosure per the applicable North
Carolina General Statutes (NCGS 66 and 132).
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 9
III. EVALUATION AND SELECTION
The County will review all proposals for completeness and compliance with the submission
requirements described above. Only complete RFP submissions will be evaluated. If any
components of the response are missing or otherwise not addressed, the County retains the right
to disqualify the Respondent. All Respondents with proposals deemed to be complete will be
evaluated based on the criteria and weighting described below.
I. REDEVELOPMENT APPROACH Respondents will be evaluated on their approach to
fulfilling the Project Objectives described in this RFP, and conformity to the vision expressed
in the Second Ward Master Plan.
Efficiently producing a mixed-use development that strives to bring a new and
exciting product to the Charlotte market, and that reflects a strong understanding
of market potential and timing.
Supporting the long-term economic development of the Second Ward by
incorporating employment-driven uses into the site and providing high-quality jobs
during the construction and ongoing operations of the project.
Demonstrating the commitment, ability, and willingness to incorporate affordable
housing. Proposals containing a commitment to more than the required number of
affordable housing units, a greater mix of affordable housing options, or both have
an opportunity to earn a higher score for this sub-component.
Respecting community input, the site’s historical context, and making every
possible effort to infuse remembrances and flavor of the past Brooklyn
neighborhood into the project. Proposals with an especially strong plan for
engaging the community and incorporating community input into their
development plan have an opportunity to earn a higher score for this sub-
component.
[40% total for the above categories]
II. FINANCIAL OFFER AND TERMS Respondents proposed financial offer, deal structure, and
allocation of costs and risks with the County. [30%]
III. RELEVANT EXPERIENCE AND QUALIFICATION Respondents will be evaluated on relevant
recent past experience with developing successful projects that are similar in vision, scope,
size, and challenges as the Brooklyn Village/Walton Plaza project. Respondents, including
any potential development partners, will need to demonstrate relevant experience in
complex public-private ventures and mixed-use projects, with a proven track record of
projection execution and achievement of public-sector and community objectives. [10%]
IV. FINANCIAL SOUNDNESS AND CAPABILITY Respondents’ financial capability to fulfill the
obligations of redeveloping the site will be evaluated based on their previous experience
financially meeting the obligations of similar projects and on their demonstration of ability
and capacity to secure future financing that will appropriately fund the project through
construction and maintenance for many years to come. [15%]
V. INTERVIEW Respondents will be evaluated based on their presentation to and interview
with the County’s selection committee. [5%]
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 10
The County intends to evaluate Respondents solely based on their submission from the RFP stage.
As described in the Submissions Requirements section, the County expects respondents to include
and update any relevant materials previously submitted as part of their RFQ response.
Specifically for the Interview discussed in section V, above, the County intends to invite all
shortlisted Respondents with complete written proposals for interviews with a selection committee.
During the interview, Respondents will be required to deliver a brief presentation and answer
questions concerning the Respondent’s written proposal and presentation. The proposed key
individuals of the Respondent’s team will be expected to actively participate in the interviews and
to respond to the selection committee’s questions.
The County reserves the right, at any time during this process, to request additional or supporting
information in addition to the Respondent’s original submission. Except at this request from the
County, Respondents will not be entitled to change their proposals after submission.
After the review of written proposals and oral interviews, the County intends to enter into
negotiations with one or more Respondents to be the Master Developer for both properties. Those
respondents may be asked to submit a markup of a purchase and sale agreement. The business
terms of this purchase and sale agreement will be subject to final approval by the County Board
of Commissioners.
The County reserves the right, at any time, and at its sole discretion and without liability, to accept
or reject any or all proposals. At any time in this process, the County reserves the right to exclude
any Respondents that fail to comply with the written submission or interview requirements of this
RFP.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 11
IV. SOLICITATION SCHEDULE
Mecklenburg County anticipates the following schedule for the RFP process.
Milestone Date
RFP released by County December 18, 2015
Mid-course discussions Week of January 11, 2016
Deadline for questions to County January 18, 2016
Responses to questions posted by County Dec. 21, 2015 – Jan. 22, 2016
Proposal submissions due February 19, 2016
Evaluation February 22-March 4, 2016
Qualified Respondents invited to Interviews Week of March 7, 2016
Interviews Week of March 14, 2016
Preferred Respondent(s) announced/negotiations begin Week of April 18, 2016
Pre-qualified Respondents will have an approximately eight-week response period for written
proposals, followed by Respondent interviews and evaluations. The County will offer mid-course
discussions via web conference with a representative of Mecklenburg County and the solicitation
management team from HR&A Advisors during the week of January 11, 2015. Respondents can
request a time between 9am and 5pm EST on Monday, January 11 or Friday, January 15 by
emailing: [email protected], with your name, contact information, firm
name, and preferred dates and times for discussion. Please submit your request by December 30,
2015 at 5pm EST.
Questions may also be submitted to the Mecklenburg County email address above. Responses
to questions submitted and asked during mid-course discussions will be shared online.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 12
V. SUBMISSION INSTRUCTIONS & QUESTIONS
Responses should be delivered as a single bound package, including a table of contents and
tabs indicating the four sections described in the Submission Requirements section of this RFP.
The County has engaged HR&A Advisors, Inc. to serve as solicitation manager for this RFP and RFP
process. Respondents must submit two (2) hard copies and one (1) electronic version of their
responses on a flash drive. Submissions must be received by no later than Friday, February 19, 2015
at 4pm EST. Submissions should be labeled “RFP Response: Brooklyn Village and Walton Plaza
Redevelopment” and delivered to:
HR&A Advisors, Inc.
ATTN: Mecklenburg County Solicitation Team
99 Hudson Street, 3rd Floor
New York, New York 10013
All questions regarding this RFP should be submitted via email only to
[email protected] by January 18, 2016 at 5pm EST. Answers to
questions asked will be posted on the County’s website at: www.charmeck.org/redevelopment
in batches as they are received. The County will make efforts to respond to questions within 48
hours of receipt. While the County will attempt to answer all questions that are submitted, it
reserves the right to not respond to all questions.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 13
APPENDICES
A. Pro Forma Template
B. Request for Qualifications
C. General Provisions
D. Miscellaneous Project Requirements
a. ADA Compliance
b. MWSBE Participation
c. Insurance Requirements
d. E-Verify Requirement
E. Mecklenburg County Area Median Income
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 14
APPENDIX A – PRO FORMA TEMPLATE
Page intentionally left blank, see pro forma template linked on solicitation website at:
charmeck.org/redevelopment. The template will be posted by COB on Monday, December 21st,
at the latest.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 15
APPENDIX B – REQUEST FOR QUALIFICATIONS
Page intentionally left blank, please see following pages.
APPENDIX B ATTACHMENT
BROOKLYN VILLAGE AND WALTON PLAZA
MASTER DEVELOPER SOLICITATION
Mecklenburg County, North Carolina
October 22, 2015
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 1
CONTENTS
I. Overview .......................................................................................................................................................... 2
II. The Sites ........................................................................................................................................................... 4
Site Descriptions ......................................................................................................................................... 4
Past Planning Efforts .................................................................................................................................. 5
III. Local Context: The Second Ward ............................................................................................................. 7
History of the Second Ward ..................................................................................................................... 7
The Second Ward Today .......................................................................................................................... 8
IV. The Opportunity ......................................................................................................................................... 13
Deal Structure ........................................................................................................................................... 13
Project Objectives ................................................................................................................................... 13
V. Submission Requirements .......................................................................................................................... 14
VI. Evaluation Criteria ..................................................................................................................................... 17
VII. Solicitation Schedule ................................................................................................................................ 18
VIII. Submission Instructions & Questions ..................................................................................................... 19
IX. Key Reference Documents ...................................................................................................................... 20
Appendices ...................................................................................................................................................... 21
Appendix A – General Provisions ................................................................................................................. 22
Appendix B – Miscellaneous Project Requirements ................................................................................. 23
Appendix C - Mecklenburg County 2014 Area Median Income .......................................................... 25
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 2
I. OVERVIEW
Mecklenburg County, NC (“the County”) is soliciting proposals to select a development team
(“the Master Developer”) to construct and comprehensively manage mixed-use development on
an 11.3-acre site known as “Brooklyn Village” and a 5-acre site known as “Walton Plaza” in the
Second Ward neighborhood of Uptown Charlotte, NC. The properties are currently controlled by
the County. Redevelopment proposals for these parcels should be aligned with the Project
Objectives described in the Opportunity section of this Request for Qualifications (“RFQ”).
This effort to redevelop the Brooklyn Village and Walton Plaza sites is a partnership among the
County, the City of Charlotte, the Charlotte-Mecklenburg Board of Education, and the Charlotte
Housing Authority. Through this process, the partners seek to regain some of the diversity of
ethnicity, age, housing type, and architecture that was lost in the Brooklyn community of the
Second Ward as a consequence of earlier urban renewal efforts. The successful Master Developer
will demonstrate sensitivity to the history of the surrounding Brooklyn neighborhood and, where
possible, seek to incorporate remembrances of the neighborhood, residents, street names, history,
architecture, and important businesses and public facilities into its vision. Past planning efforts and
recommendations are summarized in the Second Ward Master Plan and Center City 2010 Vision
Plan (also linked to this RFQ in Section IX: Reference Documents). The Brooklyn Village site, with an
Uptown Mixed Use District – Optional (“UMUD – O”) zoning designation, and the Walton Plaza site,
with an Uptown Mixed Use District (“UMUD”) zoning designation, offer Respondents flexibility in
program, height, and density, and the opportunity to create a vibrant, active development within
the Second Ward.
The selected Master Developer must incorporate the partners’ specific objectives with respect to
affordable housing and open space into its redevelopment plan. Within the Brooklyn Village site,
the Master Developer must provide at least 30 units of affordable housing (geared toward
households with an annual income of 80% of area median income or lower), as specified in the
Interlocal agreement between Mecklenburg County and the City of Charlotte (see the Interlocal
agreement linked in Section IX: Reference Documents). In addition, the Master Developer will also
develop or preserve an urban open space of at least 1.6 acres within the Brooklyn Village site,
consistent with the recommended design approach in the Second Ward Master Plan.
As part of the redevelopment, the Master Developer will commit to financing and/or construction
of horizontal improvements for the sites as necessary to support development plans, which may
include rerouting the existing storm drainage pipe, removal of a fountain, grading, and road
construction. Additionally, the Master Developer will be responsible for financing and/or
performing hazardous material abatement and demolition for existing buildings located on the
properties. Respondents may, however, propose County participation in some or all of these
financing and delivery responsibilities. The terms of any participation will be negotiated between
the County and Master Developer finalist in the subsequent Request for Proposals stage.
The County intends to sell one or both parcels to a Master Developer (a single organization or joint
venture), and requests that Respondents express preferences and rationales for single parcel bids,
if any.
Selection of the Master Developer will occur in two phases. Phase I (Request for Qualifications) will
require Respondents to present information about their development teams’ ability to finance,
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 3
construct and manage large mixed-use developments in urban settings. This includes written
statements of qualification to demonstrate the Respondents’ current capabilities as well as past
successes in bringing such developments to the market.
Based on the results of Phase I, the most qualified Respondents, as determined by the County, will
be invited to present more refined financial documentation, site plans, and an offer to the County
to purchase and develop the sites. This will constitute Phase II (Request for Proposals). Those
selected to participate in the Request for Proposals phase will have demonstrated an ability to
achieve successful urban development through public-private partnerships. This includes the
ability to understand, implement, and manage essential elements of a successful development,
such as the ability to finance, design, construct, operate, and maintain all improvements that are
to become part of the Brooklyn Village and Walton Plaza project.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 4
II. THE SITES
SITE DESCRIPTIONS
Brooklyn Village and Walton Plaza are located in the heart of Charlotte’s Second Ward
neighborhood.
The Brooklyn Village site is approximately 11.3 acres and is bounded by First Baptist Church, S.
McDowell Street, E. 3rd Street, and E. Martin Luther King, Jr. Boulevard. Immediately surrounding
the Brooklyn Village parcels are several institutional uses including the Charlotte-Mecklenburg
Government Center, the Mecklenburg County Aquatic Center, Charlotte-Mecklenburg Schools
Metro School, and the Mecklenburg County Courthouse. The property is named as a tribute to
the “Brooklyn” community that called the area home from the end of the Civil War to the 1960s.
Until recently, the property was home to the Charlotte-Mecklenburg Board of Education
administrative headquarters (known as the Education Center) and Marshall Park, which was
owned by the City of Charlotte. The parcels were assembled by Mecklenburg County in 2007
under an agreement between Mecklenburg County, the City of Charlotte, and the Board of
Education with the goal of redeveloping the site and returning it to community use in an effort to
contribute to the economic and social vitality of Uptown Charlotte and Mecklenburg County as
a whole.
The Walton Plaza site is approximately 5 acres and is bounded by East Stonewall Street, S.
McDowell Street, S. Alexander Street, and I-277. It is located on the southern edge of the Second
Ward and benefits from high accessibility and visibility from I-277. Immediately surrounding the site
are parcels slated for or undergoing development, including the Presley multi-family project
(formerly known as Fountains Uptown) and the Actor’s Theater. Walton Plaza is a seven-story Class
B office tower that is occupied by Mecklenburg County and Charlotte-Mecklenburg Schools
(“CMS”). CMS intends to vacate their premises within the 2016 calendar year. Mecklenburg
County also has plans to vacate the property. The timing of this vacancy will be part of
negotiations with the Master Developer finalist in the subsequent Requests for Proposals stage.
Between the two sites are the Mecklenburg County Aquatic Center, which is currently undergoing
significant renovation, and the Metro School site. Owned by the Charlotte-Mecklenburg Board of
Education, the Metro School site includes the old Metro School, which is no longer in use and could
potentially be incorporated into a broader redevelopment proposal, but is not directly part of this
solicitation.
The County seeks a Master Developer with the experience and ability to transform these parcels
into a diverse and vibrant neighborhood, as envisioned in the Second Ward Master Plan and
Center City 2010 Vision Plan (which aligned closely with the goals of the Master Plan) to create a
mixed-use hub in this area. This includes development of up to 9.7 acres of the Brooklyn Village
site and 5 acres of the Walton Plaza site. At least 1.6 acres of the Brooklyn Village site must be
delivered as open space to complement the vertical uses developed on the sites.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 5
Aerial of Brooklyn Village and Walton Plaza sites.
Source: Mecklenburg County/Pictometry
PAST PLANNING EFFORTS
In 2000, the City of Charlotte and Mecklenburg County both adopted the Center City 2010 Vision
Plan, a comprehensive vision for Uptown Charlotte that states a desire for variety in Uptown uses,
housing types, transportation options, open space and ethnic and racial diversity. The Second
Ward Master Plan was adopted in 2002 and is a component of the Center City 2010 Vision Plan.
The vision established in the Center City 2010 Vision Plan was reaffirmed in the Center City 2020
Vision Plan.
The Second Ward Master Plan set out a vision to “create a livable and memorable urban
neighborhood in the heart of the city through mixed land uses, diverse architecture and housing
types, unique infrastructure, and a hierarchy of open spaces. These components will combine to
welcome and support a diverse population with varied ages, races, and socio-economic
backgrounds.” The plan includes specific goals for creating a livable neighborhood and vibrant,
18-hour uses for a diverse residential population, including workforce housing; providing high-
quality architecture, accompanied by unique open space; and improving the local pedestrian
and transportation environment. This vision guides the County’s aspirations for the redevelopment
of the Brooklyn Village and Walton Plaza parcels. Respondents are encouraged to look to the
Second Ward Master Plan as a reference for these sites, to be built upon in their development
visions.
The Brooklyn Village property was rezoned in 2007 (#2007-088) from UMUD to UMUD-O. UMUD
allows for wide range of land uses, including residential, office, hotel, retail, educational,
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 6
institutional, and small-scale manufacturing, among other uses. UMUD-O allows for unique designs
and uses with exceptions from the base UMUD standards. Development plans should adhere to
the specific standards of the approved site plan and to the City of Charlotte’s Zoning Ordinance.
If changes are proposed, a new rezoning petition would need to be reviewed and approved by
the Planning Commission and City Council.
The Walton Plaza property is currently zoned UMUD, allowing for the wide range of uses described
above. If necessary, the County may consider support for rezoning the property as part of the
Master Developer’s development proposal.
The zoning description above is provided for informational purposes. Respondents are
encouraged to review the full text of the Charlotte Zoning Ordinance to inform proposed
development plans. An interactive GIS map of the sites is available via Mecklenburg County’s GIS
website.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 7
III. LOCAL CONTEXT: THE SECOND WARD
HISTORY OF THE SECOND WARD
The Second Ward is one of four wards within Uptown Charlotte, each with its own distinct
character and history. Charlotte’s Second Ward was home to many of Charlotte’s prominent
residents and businesses. Beginning in the 1860’s and following the Civil War, many freed African-
Americans settled in the Second Ward due to its housing stock and close proximity to business
establishments that served African-Americans. By the early 1900s, the majority of Second Ward
residents were of African-American descent, and the area became known as “Brooklyn.”
Brooklyn was home to many thriving small businesses and community institutions that served the
community, including Myers Street School and later Second Ward High School, which was the only
high school for African-Americans in Mecklenburg County. It was also home to such facilities as a
YMCA and the only public library for African-Americans in the state of North Carolina.
Development patterns seen today in the Second Ward are a result of past redlining and urban
renewal projects that dismantled the fabric of the Brooklyn neighborhood and resulted in much
of the neighborhood’s history and character being lost. Beginning in the 1930s, federal and local
polices and guidelines resulted in the Brooklyn area being “redlined” and zoned industrial. This
made it difficult for homeowners and businesses in the area to obtain loans for home ownership
and community investment. As a result, many Brooklyn residents began to leave the Second Ward
for other Charlotte neighborhoods such as Biddleville and University Park in the northwest portion
of the City.
In 1961, the Charlotte City Council voted to clear eight blocks of the Brooklyn neighborhood to
make way for what would become space for government facilities, private businesses, and the
current Marshall Park as part of an urban renewal project largely funded by the federal
government. By the end of this period, over 1,000 families and many businesses were displaced
from the Brooklyn neighborhood.
Fourth of July in the historic Second Ward
Source: Mecklenburg County
Historic Second Ward homes
Source: Mecklenburg County
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 8
THE SECOND WARD TODAY
Revitalization of the Second Ward
The urban heart of Charlotte, known as Uptown, is a major employment hub for the southeastern
United States. The district is home to major corporate headquarters, including Duke Energy, Bank
of America, Ally Bank, Babson Capital Management, Babcock & Wilcox, and regional
headquarters for Wells Fargo and BB&T Bank; the City’s professional sports teams, including the
National Football League’s Carolina Panthers (playing at Bank of America Stadium) and the
National Basketball Association’s Charlotte Hornets (playing in Time Warner Cable Arena);
signature open space in Romare Bearden Park; and a growing residential population seeking an
urban lifestyle in Charlotte. Uptown Charlotte’s population in particular has grown rapidly over the
past decade, and combined with strong industry presence, has supported Charlotte’s recovery
since the recession.
Site Context
Source: HR&A Advisors, Inc.
The Second Ward is prime for transformation from a government office district into a vibrant mixed-
use district, including residential development, hospitality, and entertainment venues. In 1995,
City-led development of the 850,000-square foot Charlotte Convention Center spurred additional
development activity in the area, including the 2002 completion of Wachovia Bank’s 42-story
office tower and public space, The Green. The opening of the Charlotte Area Transit System’s
rapid rail LYNX line also supported local growth, and connected Uptown to neighborhoods to the
south.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 9
Today, a number of cultural institutions and entertainment destinations are located in the Second
Ward, including the Bechtler Museum of Modern Art, The Harvey B. Gantt Center for African-
American Arts and Culture, and the NASCAR Hall of Fame, all of which opened within the past 15
years. The area has also seen a high volume of hotel development, beginning with a 700-room
Westin Hotel in 2003, and is now home to other well-known hotel flags including Hilton, Hyatt, and
Le Meridien. In 2010, as part of the Center City 2010 Vision Plan, Charlotte citizens collaborated on
a master plan for the Second Ward, which laid out a vision to continue the area’s transformation
into a vibrant district, with a mix of uses along the Brooklyn Village site and adjacent sites.
Most recently, development has begun on eight acres along Stonewall Street and Interstate 277,
where highway construction left land vacant and readily available for disposition by the City. The
developments anticipated on these sites and adjacent private land provide further proof of the
corridor’s emergence as a vibrant area for residential, hotel, and retail activity.
Demographic Snapshot
Uptown Charlotte’s residential population has grown tremendously since 2000, increasing 122% by
2013, outpacing Mecklenburg County growth of 38%. Median household income in Uptown is
$65,000, higher than the County median of $53,000, driven by younger, affluent professionals
moving into the area seeking an urban lifestyle. The 20 to 34 year-old cohort, the largest rental
group in the City, is expected to grow by 2% this year, more than five times the national average,
increasing demand for urban product in the area.
Residential Market Overview
While this shift in demographics is spread throughout Uptown, new development has increasingly
moved into the Second Ward. Today, approximately 25% of the residential development pipeline
is located in the Second Ward. Along the Stonewall corridor, 230 units are anticipated at the
Presley Uptown Apartments (formerly known as Fountains Uptown) and another 440 units are
anticipated at Crescent Communities’ mixed-use development at Stonewall Station, proximate
to the Convention Center. An additional 280 units are planned in the 28-story 1 Brevard
condominium tower located near the northern part of the Second Ward. Planned and recently
completed projects are amenity-rich, often including gym space, rooftop decks, and high-end
appliances, and achieving rents at and above $2.00 per square foot, approximately 56% higher
than buildings built prior to 2010. An increase in vacancy rates, from 3% in 2014 to 5.4% this year,
is likely largely due to the amount of product being delivered to the market. There continues to
be an opportunity to capitalize on unmet demand for young professionals, empty nesters, and
Uptown workers who wish to live within a vibrant, urban lifestyle.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 10
Hotel Market Overview
Charlotte’s strong hotel market has been driven by the hub of activity present in Uptown Charlotte,
which hosts over 12 million visitors each year, welcoming them to 298 food, beverage, and
entertainment establishments, as well as 18 major event venues, from major league and
international sports to the arts to major conferences. In 2014, the city hosted 169 sporting events
attracting over 2.4 million attendees, including, for the first time in its history, two major international
soccer matches in the same summer, one of which was a Champions Cup match between
Chelsea and Paris-Saint Germain that attracted
over 60,000 fans. Additionally, local art museums,
galleries, and theatres hosted over 490 cultural
events in Uptown. Strong demand has driven a
healthy hotel market, with a weekend
occupancy rate remaining constant at
approximately 70% for the past two years. In that
same timeframe, the average weekend daily
rate has increased from $147 to $155, while
revenue per available room has increased
significantly in the past year (12.6%). Uptown
Charlotte’s hospitality industry is projected to
expand by 36% throughout next year.
The Second Ward, which is home to many of the
City’s entertainment venues and civic facilities,
has been a prime destination for hotel development over the past ten to fifteen years, and over
70% of the City’s existing 4,500 hotel rooms are located in the immediate area. A strong pipeline
also exists in the Second Ward, including:
A 250-room, 10-story Embassy Suites, now under construction directly across the street from the
Convention Center (right);
A 350-room hotel at Tryon Place, a mixed-use development that also includes an office,
residential, and retail component;
A 400-room hotel at mixed-use Stonewall Station project.
Despite this burst of development, local tourism and event marketers see additional opportunity
for as many as 1,000 additional rooms, especially to support Convention Center activity.
Office Market Overview
Uptown Charlotte’s office market is driven by a growing, educated workforce within the market’s
22.9 million square feet of office space, over 60% of which is Class A space. Over 100,000 people
work in 1,100 companies in the market and over 50% of Charlotte’s workforce holds at least a
bachelor’s degree, a rate that exceeds County and State-wide levels. Furthermore, growth in
office-using industries is driving demand for quality office space across Mecklenburg County.
Growth in the healthcare and professional, scientific and technical services industries has been
particularly pronounced, as these industries have increased local employment by 61% and 57%,
respectively, from 2002 to 2012. Since 2009, these and other industries, including administrative
and waste services, finance and insurance, and information employment, have produced
Embassy Suites, a 250-room hotel under construction
near the Convention Center.
Source: Charlotte Center City Partners
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 11
demand for 6.4 million square feet of additional commercial space. For example, recent office
activity in the Uptown office market includes the 115,000 square foot expansion of AvidXchange’s
Charlotte headquarters in the Fourth Ward. The automated bill payment software company is
planning to introduce at least 600 new jobs over the next five years and invest $21.4 million in the
local economy.
Commercial office development in the Second Ward is also tracking Uptown’s overall market
strength. Traditionally known as Charlotte’s Government District for its cluster of public-sector office
space including City Hall, Mecklenburg County Courthouse, and the Charlotte-Mecklenburg
Government Center, new development activity includes over 1 million square feet of planned
and under construction office within the Second Ward. Notable activity includes:
Tryon Place: Bordered by Tryon, Stonewall, College and Hill Streets adjacent to the
Charlotte Convention Center, Crescent Communities is developing a $300+ million project
expected to begin construction later this year. The development will consist of two towers,
one including a 350-room hotel and luxury apartment housing, and another containing
715,000 square feet of Class A office space and ground floor retail that is expected to
accommodate over 4,000 workers.
615 S. College: Across the street from Tryon Place, Portman Holdings will build a 15-story,
345,000 square foot office tower, including retail and a parking garage next to the Westin
Hotel on the corner of College and
Stonewall Streets. With expected
completion in 2017, construction is currently
underway with finalized designs calling for a
1/3 acre of green space to be built on its
roof deck for hosting corporate events or
outdoor meeting space.
Historically strong commercial office
development and leasing activity in Uptown
and a vacancy rate under 10% suggests a
continued potential for office space to play
a role in mixed-use, large-scale programs.
Retail Market Overview
Across Uptown Charlotte’s 2.1-million square
foot retail market there is an opportunity to
address significant market demand for
walkable, neighborhood-serving retail and
grocery stores. With a vacancy rate of less
than 6%, there are more than 50 shops and
a range of 230 dining and entertainment options in the Uptown market including the 7th Street
Public Market, EpiCentre, and NC Music Factory. However, as household income and worker’s
salaries are expected to continue to increase with a growing job and housing market, there are
opportunities to capitalize on growing consumer spending potential beyond entertainment and
dining services.
A proposed mixed-use development adjacent to the
Stonewall LYNX station by Crescent Communities.
Source: Charlotte Center City Partners
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 12
The retail landscape within the Second Ward reflects the Uptown trend, representing an exciting
opportunity to support a growing residential market by investing in additional neighborhood-
serving retail amenities and food markets. Currently only the EpiCentre complex provides a
concentration of retail and food service outlets whose programming focuses largely on providing
and complementing surrounding entertainment venues, and not diversified enough to target the
needs of future residents. Other existing retail largely serves local office workers, including national
chain cafes that are not open after the workday. Currently there is only one retail project in the
Second Ward’s development pipeline, at the mixed-use project at the Stonewall LYNX station.
The Crescent Communities project will include 47,000 square feet of retail, with Whole Foods
serving as its anchor tenant along East Stonewall Street. New retail can provide an amenity for a
mixed-use program and benefit from growing demand from office workers, residents, and visitors
within the Second Ward as development arrives in the area.
Recently completed and ongoing developments in Uptown Charlotte.
Source: HR&A Advisors, per Charlotte Center City Partners
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 13
IV. THE OPPORTUNITY
DEAL STRUCTURE
Mecklenburg County controls the Brooklyn Village and Walton Plaza parcels under agreements
with the City of Charlotte and the Charlotte-Mecklenburg Board of Education. The County is
seeking disposition of both parcels.
To support site redevelopment, the Master Developer may be required to finance and perform
site infrastructure requirements, including grading, road construction, and demolition of existing
buildings on the properties (or property). Additionally, at least 1.6 acres of the Brooklyn Village site
must be delivered as, or remain, open space to complement the vertical uses developed on the
sites. The Master Developer must also provide at least 30 units of affordable housing on the
Brooklyn Village site, consistent with the current Interlocal agreement for the site (for households
earning 80% of area median income annually, or less). The County is open to negotiating sharing
financing or delivery of some or all of these responsibilities with the Master Developer finalist in the
subsequent Request for Proposals phase.
The County intends to sell one or both parcels to a Master Developer (a single organization or joint
venture), and requests that Respondents express preferences and rationales for single parcel bids,
if any. In the RFQ stage, Respondents are required to submit all material under the Conceptual
Plan requirement (described in Section V: Submission Requirements) for both sites. The County
values Respondents’ ability to execute their entire development program, as well as their
efficiency in timing and completion of development, while respecting reasonable absorption and
other market timing considerations.
PROJECT OBJECTIVES
Mecklenburg County seeks to fulfill the vision statement identified in the Second Ward Master Plan,
Center City 2010 Vision Plan, and subsequent goals set forth by the County for the Brooklyn Village
and Walton Plaza sites. Specifically, the County is seeking a development partner who will achieve
the following goals (in order of priority):
Facilitate creation of a program that creates long-term economic development benefits
for the County and surrounding community.
Complete development of a high-quality program in a timely and efficient manner.
Create and execute a thorough local resident and stakeholder engagement process, in
which local input is reflected in the eventual development program.
Maximize the near-term financial return to the County upon acquisition of these parcels,
while balancing the above goals within the development program.
Respondents should clearly and concisely demonstrate their ability to fulfill these goals in their
plans for the Brooklyn Village and Walton Plaza parcels. Development visions should clearly
describe how Respondents’ plans will fulfill the Project Objectives, honor the area’s historic past,
and support the vision outlined in the Second Ward Master Plan and reinforced in the Center City
2010 Vision Plan. Respondents are encouraged to use the Master Plan as a guide, though not a
required outcome, when formulating their development vision.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 14
V. SUBMISSION REQUIREMENTS
The County invites highly accomplished developers with a proven track record of delivering
successful and recognized developments to submit statements of qualification. Respondents must
submit two (2) hard copies and one (1) electronic version of responses on a flash drive no later
than Tuesday, November 24, 2015 at 4:00 PM EST. More detailed instructions for submissions are
provided in the Submission Instructions and Questions section.
The selected Master Developer will be responsible for creating an overall development plan that
is consistent with the County’s vision for the sites, guided by the goals of the Second Ward Master
Plan. To be considered for participation in Phase II (Request for Proposals), the Respondent must
clearly, completely and concisely address each of the following areas in its response to this RFQ:
I. DEVELOPMENT TEAM Respondents should include a description of all firms comprising
the development team, including intended design partners, engineers, construction
team, etc. For all key personnel, provide a resume, describing relevant experience and
intended role on the project team. For the development team, Respondents should
also include a diagram or organizational chart illustrating the relationship between the
lead developer and any subcontractors or partners. For teams led by a joint venture,
clearly show the structure and percentage of ownership held by each lead team
member.
II. RELEVANT PREVIOUS EXPERIENCE Respondents should demonstrate their ability to
succeed at designing, constructing, and managing the Brooklyn Village/Walton Plaza
project by sharing information on at least three previous projects that illustrate its ability
to fulfill the goals of this project. In particular, Respondents should highlight:
Experience in master development of mixed-use urban projects in an urban
context similar to Uptown Charlotte.
Residential or mixed-use development that contributed to a sense of place
and activated an area of a city’s urban core, especially those with a historic
component or that pay tribute to an area’s local history.
A successful public-private partnership that included horizontal
improvements.
Experience creating affordable housing or other subsidized housing
developments, and particularly those in which the developer took
advantage of The Low-Income Housing Tax Credit Qualified Allocation Plan
for the State of North Carolina or other similar programs.
For all projects submitted as examples of relevant previous experience, Respondents
should provide: project location; project size and program description, including
phasing; completion date; public sector involvement, if any; total project costs and
financing structure (detailing sources of capital); and a representative image (or
images) of the project.
III. CONCEPTUAL PLAN Respondents should submit a written narrative and high-level
conceptual site plan for both sites (including preliminary drawings, if useful) that
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 15
addresses the program identified in the Second Ward Master Plan, including historical
character. Mecklenburg County recognizes that this plan will be refined in the RFP
stage should Respondents move forward. The conceptual plan should include:
A description of adherence to provisions of the City of Charlotte’s UMUD
zoning category or use of any additional review or approvals processes
under the UMUD-O zoning provision, if applicable.
The location of improvements and proposed use types to be included
throughout the site.
Discussion of phasing and timeline for full project development.
A preliminary development program, including anticipated square footage
of each use, and number of residential units, including number of proposed
affordable residential units (Proposals should include a minimum of 30 units
for households earning up to 80% of the area median income. See Appendix
C for Mecklenburg County area median income).
Anticipated maximum building height.
A description of incorporation of historical references.
A description of the intended design scheme for the project, including how
the design is consistent with the program recommendations in the Second
Ward Master Plan.
A description of the Respondent’s approach to marketing and outreach,
including how the Respondent will engage the community.
If the Respondent prefers to bid on only one site going forward, a statement
expressing that preference, and rationale for this approach.
IV. FINANCIAL CAPABILITY Respondents should provide detailed information about their
ability to financially fulfill the obligations of the development project. Respondents
should provide the following information:
Information about the Respondent’s overall financial position, past history of
raising capital, and resources available to complete this project.
Most recent annual financial statements.
Composition of real estate portfolio by type and occupancy percentage.
Description of the sources of equity and/or debt Respondent believes will be
attracted to investing in this project and description of any tentative
commitments. Attach any letters of intent/interest that are available (if those
can be named at this time).
Narrative indicating the Respondent’s acceptance of, or differing approach
to, the deal structure described in this RFQ, including the anticipated timing
of payments to the County. Note that the County seeks to maximize the
near-term proceeds from disposition of these parcels.
A statement indicating that the Respondent does not currently and has not
had any loans in default within the past five years, and has not filed for
bankruptcy, had a project foreclosed on, or faced government fines.
Alternatively, if any of these have occurred, include a description of the
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 16
actions and the project-related circumstances in which the actions took
place.
Description of any litigation that has been filed against the development
team or its members related to real estate projects during the past 10 years,
as well as the outcome of that litigation. If no litigation has been filed, please
include a statement to this affect.
Shortlisted Respondents will be required to develop these materials further for the RFP stage,
including:
Refinement of development program and inclusion of architectural proposals, including
massings, plans, and illustration of phasing;
Confirmation of technical team members;
Full financial proposals, including a detailed pro forma for the County’s review;
Development schedule; and
Other requirements, as deemed necessary by Mecklenburg County, including
participation in an interview session.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 17
VI. EVALUATION CRITERIA
Based on the quality and scope of information presented by Respondents, the County will select
a shortlist of Respondents to participate in Phase II of the solicitation process for the
redevelopment of the Brooklyn Village and Walton Plaza parcels. Respondents will be evaluated
based on the criterion and weighting described below.
I. REDEVELOPMENT APPROACH Respondents will be evaluated on their approach to
fulfilling the Project Objectives described in this RFQ, and conformity to the vision expressed
in the Second Ward Master Plan. Those selected to move on to Phase II will demonstrate
an ability and willingness to embrace the goals of:
Efficiently producing a mixed-use development that strives to bring a new and
exciting product to the Charlotte market, and that reflects a strong understanding
of market potential and timing.
Supporting the long-term economic development of the Second Ward by
incorporating employment-driven uses into the site and provision of high-quality
jobs during the construction and ongoing operations of the project.
Demonstrating the commitment, ability, and willingness to incorporate affordable
housing. Proposals containing a commitment to more than the required number of
affordable housing units have an opportunity to earn a higher score for this sub-
component.
Respecting community input, the site’s historical context, and making every
possible effort to infuse remembrances and flavor of the past Brooklyn
neighborhood into the project. Proposals with an especially strong plan for
engaging the community and incorporating community input into their
development plan have an opportunity to earn a higher score for this sub-
component.
[40% total for the above categories]
II. RELEVANT EXPERIENCE AND QUALIFICATION Respondents will be evaluated on relevant
recent past experience with developing successful projects that are similar in vision, scope,
size, and challenges as the Brooklyn Village/Walton Plaza project. Respondents, including
any potential development partners, will need to demonstrate relevant experience in
complex public-private ventures and mixed-use projects, with a proven track record of
projection execution and achievement of public-sector and community objectives. [30%]
III. FINANCIAL SOUNDNESS AND CAPABILITY Respondents’ financial capability to fulfill the
obligations of redeveloping the site will be evaluated based on its previous ability to
financially meet the obligations of similar projects and demonstration of its ability and
capacity to secure future financing that will appropriately fund the project through
construction and maintenance for many years to come. [30%]
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 18
VII. SOLICITATION SCHEDULE Mecklenburg County anticipates the following schedule for the RFQ process.
Milestone Date
RFQ released by County October 21, 2015
Pre-bid conference November 3, 2015
Deadline for questions to County November 9, 2015
Response to questions posted by County November 16, 2015
Qualification submissions due November 24, 2015
Evaluation November 24-December 11, 2015
Shortlisted Respondents announced/invited to RFP December 14, 2015
Phase II will follow evaluation of RFQ responses. This stage is anticipated to launch approximately
two to three weeks after RFQ responses are received, and will allow for an eight-week response
period for RFP Respondents, followed by Respondent interviews and evaluations. A detailed
schedule for this process and the evaluation process will be included in the RFP document.
The County will host a pre-bid conference on Tuesday, November 3, 2015, at 10:00 AM EST, at the
Charlotte-Mecklenburg Government Center (600 E. Fourth Street, Charlotte, NC). This meeting will
provide information about the RFQ and RFP processes, include a walking tour of the sites and
surrounding area, and provide a forum for Respondents to ask questions about the process and
contents of this RFQ. Responses to questions asked at the pre-bid conference will be shared online.
Attendance at the pre-bid conference is optional. Please confirm your attendance at the pre-bid
conference by emailing: [email protected], with your name, firm
name, and intent to attend.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 19
VIII. SUBMISSION INSTRUCTIONS & QUESTIONS
Responses should be delivered as a single bound package, including a table of contents and
tabs indicating the four sections described in the Submission Requirements section of this RFQ.
The County has engaged HR&A Advisors, Inc. to serve as solicitation managers for this RFQ and
RFP process. Respondents must submit two (2) hard copies and one (1) electronic version of their
responses on a flash drive by no later than Tuesday, November 24, 2015 at 4:00 PM EST. Submissions
should be labeled “RFQ Response: Brooklyn Village and Walton Plaza Redevelopment” and
delivered to:
HR&A Advisors, Inc.
ATTN: Mecklenburg County Solicitation Team
99 Hudson Street, 3rd Floor
New York, New York 10013
All questions regarding this RFQ should be submitted via email only to
[email protected] by November 9, 2015. Respondents will also have an
opportunity to ask questions at the pre-bid conference on November 3, 2015. Questions asked at
the pre-bid conference and submitted online will be posted on the County’s website at:
www.charmeck.org/redevelopment. While the County will attempt to answer all questions that
are submitted, it reserves the right to defer any or all questions until later phases of the process.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 20
IX. KEY REFERENCE DOCUMENTS
All references or summaries of these documents within this RFQ are for informational purposes
only. Respondents are encouraged to review the full documents at the following links:
Second Ward Master Plan
Brooklyn Village Rezoning Application (#2007-088)
Charlotte Zoning Ordinance
Center City 2010 Vision Plan
Center City 2020 Vision Plan
Mecklenburg County- City of Charlotte Interlocal Agreement [available at the link
below]
Key reference documents and additional information about these sites are also available on the
RFQ webpage at: www.charmeck.org/redevelopment.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 21
APPENDICES
A. General Provisions
B. Miscellaneous Project Requirements
a. ADA Compliance
b. MWSBE Participation
c. Insurance Requirements
d. E-Verify Requirement
C. Mecklenburg County Area Median Income
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 22
APPENDIX A – GENERAL PROVISIONS
A. Submittal Ownership / Costs- Upon submission, all information becomes the property of
Mecklenburg County which has the right to use any or all ideas presented in any
submission in response to this RFQ, whether or not the submittal results in a contract with
the submitting Consultant. If any materials submitted by Respondents are confidential,
each page of containing confidential information must be marked as such. All costs for
development of the written submittal are entirely the obligation of the Consultant and
shall not be remunerated in any manner by Mecklenburg County.
B. Non-Warranty of Request for Qualifications - Due care and diligence has been used in
preparing this RFQ. However, the County shall not be responsible for any error or omission
in this RFQ, nor for the failure on the part of the Respondents to ensure that they have all
information necessary to affect their submittals.
C. Request for Clarification - Mecklenburg County reserves the right to request clarification
of information submitted and to request additional information of one or more
Respondents, either orally or in writing.
D. Acceptance/Rejection of Submittals - Mecklenburg County reserves the right to accept
or reject any or all submittals in whole or in part, with or without cause, to waive
technicalities, or to accept submittals or portions thereof which, in the County’s
judgment, best serve the interest of the County.
Mecklenburg County reserves the right to request additional clarification or information
regarding Respondent proposals at any time during the evaluation and selection process.
E. Collusion - The Respondent, by submitting a Qualifications Statement and/or Proposal,
declares that the submission is made without any previous understanding, agreement, or
connections with any persons, Respondents, or corporations making a competing
submission on the same project, and that it is in all respects, fair, and in good faith without
any outside control, collusion, or fraud.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 23
APPENDIX B – MISCELLANEOUS PROJECT
REQUIREMENTS
A. Americans with Disabilities Act (ADA) Compliance - Mecklenburg County will comply with
the Americans with Disabilities Act (ADA) which prohibits discrimination on the basis of a
disability. Mecklenburg County will make reasonable accommodations in all programs to
enable participation by an individual with a disability who meets essential eligibility
requirements. Mecklenburg County programs will be available in the most integrated
setting for each individual. If any accommodations are necessary for participation in any
program or services, participants are encouraged to notify County Staff.
B. Minority/Women/Small Business Enterprise - It is the policy of Mecklenburg County to
provide minorities and women equal opportunity for participating in all aspects of the
County's contracting and procurement programs, including but not limited to
employment, construction development projects, and materials/services, consistent with
the laws of the State of North Carolina. The policy of Mecklenburg County prohibits
discrimination against any person or business in pursuit of these opportunities on the basis
of race, color, national origin, religion, sex, age, disability, or veteran's status. It is further the
policy of Mecklenburg County to conduct its contracting and procurement programs so
as to prevent such discrimination and to resolve any and all claims of such discrimination.
C. Insurance and Indemnity Requirements – The Master Developer will be required to conform
to specific insurance and indemnity requirements prior to completion of a contract with
the County. To the extent permitted by law the Respondent shall indemnify and save
harmless Mecklenburg County, its agents and employees and assigns from and against all
loss, cost damages, expense and liability caused by sickness and disease to any person;
or damage or destruction to property, real or personal; arising from the negligent acts,
errors, or omissions of the Respondent in the performance of professional services provided
to the County.
The Respondent further agrees to purchase and maintain during the life of any agreement
entered into with the County the following insurance with an insurance company
acceptable to Mecklenburg County and authorized to do business in the State of North
Carolina:
Automobile: Bodily injury and property damage liability covering all owned, non-owned,
and hired automobiles for limits of not less than $1,000,000 each person/ $1,000,000 each
occurrence.
Comprehensive General Liability: Bodily injury and property damage liability insurance as
shall protect the Respondent from claim of bodily injury or property damage which arises
from operations of this contract. The amounts of such insurance shall not be less than
$1,000,000 bodily injury and property damage liability each occurrence/aggregate. This
insurance shall include coverage for product/completed operations and contractual
liability assumed under the indemnity provision of this contract. Mecklenburg County shall
be listed as an “Additional Insured.”
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 24
Consultant's Professional Liability: In a limit of not less than $1,000,000.
Workers' Compensation and Occupational Disease Insurance:
Coverage A - Worker's Compensation: Meeting the statutory requirements of the State of
North Carolina.
Coverage B - Employer's Liability: $100,000 each accident / $100,000 disease - each
employee / $500,000 disease - policy limits.
D. E-Verify: Pursuant to NCGS §153A-449(b) and NCGS § 64-26(a), any Employer/Contractor
that transacts business in this State, and employs 25 or more employees in this State
entering into a contract with the County, is required to verify the work eligibility status of all
newly hired employees through the E-verify program.
Certificates of such insurance will be furnished to Mecklenburg County and shall contain
the provision that Mecklenburg County be given thirty (30) days written notice of any intent
to amend or terminate by either the Consultant or the insuring company.
APPENDIX B ATTACHMENT
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation 25
APPENDIX C - MECKLENBURG COUNTY 2014 AREA
MEDIAN INCOME
Mecklenburg
County Median
Income
$64,200
Persons in Family
1
$35,950
2
$41,100
3
$46,250
4
$51,350
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 42
APPENDIX C – GENERAL PROVISIONS
A. Submittal Ownership / Costs- Upon submission, all information becomes the property of
Mecklenburg County which has the right to use any or all ideas presented in any
submission in response to this RFP, whether or not the submittal results in a contract with
the submitting Consultant. If any materials submitted by Respondents are confidential,
each page of containing confidential information must be marked as such. All costs for
development of the written submittal are entirely the obligation of the Consultant and
shall not be remunerated in any manner by Mecklenburg County.
B. Non-Warranty of Request for Qualifications - Due care and diligence has been used in
preparing this RFP. However, the County shall not be responsible for any error or omission
in this RFP, nor for the failure on the part of the Respondents to ensure that they have all
information necessary to affect their submittals.
C. Request for Clarification - Mecklenburg County reserves the right to request clarification
of information submitted and to request additional information of one or more
Respondents, either orally or in writing.
D. Acceptance/Rejection of Submittals - Mecklenburg County reserves the right to accept
or reject any or all submittals in whole or in part, with or without cause, to waive
technicalities, or to accept submittals or portions thereof which, in the County’s
judgment, best serve the interest of the County.
Mecklenburg County reserves the right to request additional clarification or information
regarding Respondent proposals at any time during the evaluation and selection process.
E. Collusion - The Respondent, by submitting a Qualifications Statement and/or Proposal,
declares that the submission is made without any previous understanding, agreement, or
connections with any persons, Respondents, or corporations making a competing
submission on the same project, and that it is in all respects, fair, and in good faith without
any outside control, collusion, or fraud.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 43
APPENDIX D – MISCELLANEOUS PROJECT
REQUIREMENTS
A. Americans with Disabilities Act (ADA) Compliance - Mecklenburg County will comply with
the Americans with Disabilities Act (ADA) which prohibits discrimination on the basis of a
disability. Mecklenburg County will make reasonable accommodations in all programs to
enable participation by an individual with a disability who meets essential eligibility
requirements. Mecklenburg County programs will be available in the most integrated
setting for each individual. If any accommodations are necessary for participation in any
program or services, participants are encouraged to notify County Staff.
B. Minority/Women/Small Business Enterprise - It is the policy of Mecklenburg County to
provide minorities and women equal opportunity for participating in all aspects of the
County's contracting and procurement programs, including but not limited to
employment, construction development projects, and materials/services, consistent with
the laws of the State of North Carolina. The policy of Mecklenburg County prohibits
discrimination against any person or business in pursuit of these opportunities on the basis
of race, color, national origin, religion, sex, age, disability, or veteran's status. It is further the
policy of Mecklenburg County to conduct its contracting and procurement programs so
as to prevent such discrimination and to resolve any and all claims of such discrimination.
C. Insurance and Indemnity Requirements – The Master Developer will be required to conform
to specific insurance and indemnity requirements prior to completion of a contract with
the County. To the extent permitted by law the Respondent shall indemnify and save
harmless Mecklenburg County, its agents and employees and assigns from and against all
loss, cost damages, expense and liability caused by sickness and disease to any person;
or damage or destruction to property, real or personal; arising from the negligent acts,
errors, or omissions of the Respondent in the performance of professional services provided
to the County.
The Respondent further agrees to purchase and maintain during the life of any agreement
entered into with the County the following insurance with an insurance company
acceptable to Mecklenburg County and authorized to do business in the State of North
Carolina:
Automobile: Bodily injury and property damage liability covering all owned, non-owned,
and hired automobiles for limits of not less than $1,000,000 each person/ $1,000,000 each
occurrence.
Comprehensive General Liability: Bodily injury and property damage liability insurance as
shall protect the Respondent from claim of bodily injury or property damage which arises
from operations of this contract. The amounts of such insurance shall not be less than
$1,000,000 bodily injury and property damage liability each occurrence/aggregate. This
insurance shall include coverage for product/completed operations and contractual
liability assumed under the indemnity provision of this contract. Mecklenburg County shall
be listed as an “Additional Insured.”
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 44
Consultant's Professional Liability: In a limit of not less than $1,000,000.
Workers' Compensation and Occupational Disease Insurance:
Coverage A - Worker's Compensation: Meeting the statutory requirements of the State of
North Carolina.
Coverage B - Employer's Liability: $100,000 each accident / $100,000 disease - each
employee / $500,000 disease - policy limits.
D. E-Verify: Pursuant to NCGS §153A-449(b) and NCGS § 64-26(a), any Employer/Contractor
that transacts business in this State, and employs 25 or more employees in this State
entering into a contract with the County, is required to verify the work eligibility status of all
newly hired employees through the E-verify program.
Certificates of such insurance will be furnished to Mecklenburg County and shall contain
the provision that Mecklenburg County be given thirty (30) days written notice of any intent
to amend or terminate by either the Consultant or the insuring company.
Mecklenburg County | Brooklyn Village and Walton Plaza Master Developer Solicitation RFP 45
APPENDIX E - MECKLENBURG COUNTY 2014 AREA
MEDIAN INCOME
Mecklenburg
County Median
Income
$64,200
Persons in Family
1
$35,950
2
$41,100
3
$46,250
4
$51,350