Workbook
-
Upload
peter-fenn -
Category
Documents
-
view
213 -
download
0
description
Transcript of Workbook
Legal Issues
Elective Module
Peter Fenn
MACE
PO Box 88
Manchester
M60 1QD
Tel 01613064233
Email: [email protected]
1
Legal Issues
Table Of Contents And Workbook Outline
How To Use This Workbook
1. Introduction to the law
2. Contract
3. Tort
4. The Concepts of Standard Forms of Contract
5. The Key Areas Of Standard Forms; the Role of Management in Standard Forms
6. Health and Safety
7. Risk
8. Conflict Theory
9. Comparison Of Dispute Resolution Techniques
10. Negotiation
11. Mediation Principles; The Mediation Process
References And Bibliography
2
How to Use this Workbook
This workbook has been specially designed and written for the elective module in Legal
Issues. It will help you to plan your study and to work systematically through the course. You
should use this workbook as the basis of your studies. The workbook is just part of the
material which is provided at the Blackboard Virtual Learning Environment [VLE]. There
are 4 main teaching documents:
Uff, J. (2013), Construction Law, 11th Edition, Sweet and Maxwell *** eBook***
https://www.dawsonera.com/abstract/9780414028210 This Workbook [ available at any time as an ebook and on Blackboard]
The Learning Modules [available ONLY at Blackboard]
The Lecture Slides [copied by me and provided to each student; and available at any time on
Blackboard]
In addition I expect that you will do some reading. Uff, J. (2013), Construction Law, l is
very important and the workbook will refer to it repeatedly. NB the 11th
edition has been
published but be careful my references might be to the 9th
edition; there might be some
differences on page numbers between editions.
Content
The workbook is divided into sections that reflect the syllabus. Each section begins with an
introduction, which briefly explains the topic to be studied and may suggest areas to be
focused upon. This is followed by a list of objectives that should be achieved after studying
the section.
The substantive part of the text must be read very carefully and you must ensure that you
understand the concepts before moving on to the next section. It is important that you are sure
that you have achieved the objectives identified at the beginning of the section.
Writing an answer
It is important to understand how to write an answer to a question. When answering an essay
style question, you should try to structure your answer: start; middle and end is always a
good structure. Start your answer with a short introductory paragraph outlining your
treatment of the topic; set the stage for the text which follows. In the middle deal with the
substantive issues; what are they? At the end make sure you have answered the question; and
reach conclusions based on your text in the middle. Questions have a command work e.g.
discuss – this requires at least two viewpoints or opposing theories; make sure you deal with
the command word..
Having determined the issues in a problem (and remember there may be more than one issue
in a question) you may have to state the law that applies to the particular issue. In Mediation
this is less likely than other areas e.g. arbitration where a statute applies. If the law is from a
statute, you will need to state which Act and which section applies. So, for example, s 11 of
the Unfair Contract Terms Act 1977. It is not necessary to memorise s 11, but you should be
able to state the effect of the section. Having done so you must then show how it relates to the
problem you are dealing with and try to come to a conclusion on that issue. Sometimes it will
not be possible to arrive at a firm decision, normally because the question does not give you
3
all the facts. It is permissible to say that a particular conclusion is more or less likely in the
circumstances. It is also permissible to give one or two possibilities, but you must be careful
not to lose sight of the rest of the question.
The relevant law may also be found in the decision of a case; again less likely in Mediation
but needs to carefully monitored. You will need to state the name of the case and the principle
it provides. When stating the name it is not necessary to put down the entire citation just the
name of the case is sufficient: for example, Donoghue v Stevenson. Should you be unable to
remember the entire case name, simply 'the Donoghue Case' will suffice. When you cannot
remember either part of the name, but remember some salient facts, which will identify the
case, you may state those facts very briefly. For example, in relation to the above, you may
say, 'in the case of the snail in the ginger beer bottle'. Do not panic if you do not remember the
case name, it is more important to state the principle involved. Try to remember the most
important cases in each topic, rather than all the case names in the list. Many of the cases
merely illustrate a point, rather than create new law. These illustrative cases will help you to
understand how the courts apply already established principles of law.
I hope that you will find this course stimulating and challenging. It is hoped that when you
have completed the course you will have a sound appreciation of the basic principles of how
legal issues affect Engineers and Engineering.
Please note: Engineering projects operate within legal frameworks and jurisdictions; this
module describes the legal frameworks under generic headings and also provides some
analysis of the jurisdiction in England and Wales. Many countries share similarities with the
law of England and Wales, but many do not. It may be that the country in which you are
studying or working has a different legal system or that a particular area of the law is
different; you should always consider the effect of jurisdiction. The course you are following
attracts students of many disciplines [civil, mechanical and aerospace] and from many
nations and it would be impossible to consider all the aspects of law in the UK let alone in
each country and for each discipline
Good luck with your studies!
4
1. Introduction to law
This section deals with an introduction to, or of , the law. You are asked to do several things:
complete the Blackboard section [including some short discussion exercises]; read the
workbook; read some material from books in the library and visit some websites.
5
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
Aim: To consider the relevance of the law, to engineers, projects and other professionals.
Within the overall aim the following measurable objectives are set
The student will be able to:
Explain the relevance of the law to projects and professionals
Understand the complex nature of the law
Describe the stratification of English Law
Distinguish between Criminal and Civil Law
Explain the structure of the courts in England and Wales
o in particular the Technology and Construction Court
1.1. Introduction to the Law
The law is far too complex and contains far too great a variety of kinds of legal rules for it to
be reduced to a single proposition e.g. laws are commands.
1. Historical background
How then do I introduce law to engineers? One technique might be to provide an historical
background. But this is too complicated for a simple treatment; a specialist branch of both the
law and history exists. Combined the expertise rests in legal historians. You might try
anyone of several excellent texts; my favourite [or more truthfully the one I have read]:
An Introduction to Legal History, J H Baker
More realistically English Law Smith and Keenan tell us that the present legal system began,
for all practical purposes, in the reign of Henry II.
2. Read the literature
Another technique might be to require you to read text and then answer questions; in the
traditional university sense this would take the form of books held in the library. I have made
arrangements for multiple copies of an excellent book to be held in the library; you must go
there and read chapter 1.
Harris, P. (2007), An Introduction to Law 7th
Edition, Cambridge University Press
Exercise: write short notes [<100 words]
Discuss: The law as a system of rules [see http://en.wikipedia.org/wiki/Law]
Distinguish between legal rules and moral rules and explain why people obey rules
6
Max Weber ,seen by many as the founder of sociology, wrote extensively on the law. Weber
examined the question of authority and proposed three types of authority1
1. The authority of the leader may be the result of personal characteristics or traits of the
leader: his or her charisma.
2. Obedience to the leader is sustained because it is traditional.
3. The authority of the leader or regime is legitimised through rules and procedures.
Bureaucratic [rational legal]
Sources of Authority
Charismatic Authority
Traditional Authority
Bureaucratic Authority
3. Reductionism
A third technique is to try to break things down into valid representative sections and deal
with the overall issue that way. I want to make a distinction between criminal and civil law
and then to study [mostly] civil wrongs; there is one area of law which has great implications
for engineers and involves criminal law, but mostly we are going to study civil wrongs. The
area which involves criminal law, is Health and Safety.
Non lawyers often make the mistake of assuming all law is criminal law. I don’t know why
this; maybe because all the law we see on TV is criminal law. In fact the law is divided into
two great branches: criminal and civil. To further confuse things; “Civil Law” means several
things: not criminal [and this is what we are concerned with]; the law of a state; Roman Law.
England and Wales are common law countries; many other countries use the common law
system e.g. USA; many others do not and have a codified law sometimes based on Roman
Law e.g. France. France is a civil law country or jurisdiction.
The distinction between a crime and a civil wrong is not in the nature of the wrongful act but
in the legal consequences that flow from the act. If the wrongful act [or the omission to do
something] is capable of being followed by criminal proceedings then it is a crime. If it is
capable of being followed by civil proceedings then it is a civil wrong. If it is capable of
being followed by both civil and criminal proceedings then it is both a crime and a civil
wrong. Criminal and civil proceedings are easily distinguishable: the procedure is different
and the outcome is different. One useful difference is the standard of proof [wiki
http://en.wikipedia.org/wiki/Burden_of_proof] in criminal proceedings the standard is beyond
a reasonable doubt in civil proceedings the standard is the balance of probabilities. So in
civil proceedings to prevail the party bringing the action merely has to demonstrate on the
evidence that they are right on the balance of probabilities i.e. 51 plays 49.
Philosophy
Plato recorded the trial, condemnation and execution of Socrates in a series of dialogues,
Socrates himself left no written work.
1 Law in Economy and Society, Max Weber
7
In the dialogue with Crito; after Socrate’s trial a group of his friends, led by Crito, devised a
plan for Socrates to escape, and avoid execution, but Socrates would not join in the plan. He
argued that: life was only worth living and striving for if it was a good life. A good life meant
obedience to the laws of Athens. Even if he had been wronged, and he had; he could not
reply with a wrong. He had been condemned by due process and he must remain obedient to
the laws.
Socrates dreamt of the laws of Athens addressing him and concludes: the Laws are more
honorable than one's parents, for they too beget, educate, and nurture their citizens. He has
no choice but to obey the law. You might think about this when you think about why people
obey laws
Nature of law
Read Chapter 1 of Uff, J. (2002), Construction Law, 9th
Edition, Sweet and Maxwell.
He tells that English law is stratified in a number of ways.
Exercise: Distinguish between Criminal and Civil Law?
Exercise: Describe how the law differs from technology
The courts in England and Wales
Visit the courts service to see the structure of the courts
http://www.hmcourts-service.gov.uk/aboutus/structure/index.htm
in particular the Technology and Construction Court
http://www.hmcourts-service.gov.uk/infoabout/tcc/index.htm
Describe the matters which are generally brought before the Technology and Construction
Court
8
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises, can I:
2) Explain the relevance of the law to projects and professionals
3) Understand the complex nature of the law
4) Describe the stratification of English Law
5) Distinguish between Criminal and Civil Law
6) Explain the structure of the courts in England and Wales
i) in particular the Technology and Construction Court
Readings and other resources
http://www.out-law.com/ is a useful first stop and you should visit. OUT-LAW has 7,000
pages of free legal news and guidance.
http://www.accesstolaw.com/site/default.asp?s=79 identifies many other useful urls
9
2. Contract
Introduction
This section deals with an introduction to the law of contract. You are asked to do several
things: complete the Blackboard section [including brief exercises]; read the workbook; read
some material from the book which supports this section and visit some websites.
There is excellent material in the textbook which supports this section: Uff, J. , Construction
Law,. You should read pages 154-248 which describe general principles of contracts in
conjunction with this section. The intention here is not to repeat the material in the textbook
but to provide some additional material; and sometimes an alternative analysis.
Contracts are an essential part of every engineering project; a plethora of contractual
arrangements exist: between main contractor and sub-contractor; between client and main
contractor and between suppliers and contractors. It is essential that engineering professionals
understand the principles behind these contracts. However please note: Engineering projects
operate within legal frameworks and jurisdictions; this module describes the legal frameworks
under generic headings and also provides some analysis of the jurisdiction in England and
Wales. Many countries share similarities with law of England and Wales, but many do not.
It may be that the country in which you are studying has a different legal system or that a
particular area of the law is different; you should always consider the effect of jurisdiction.
This section provides an analysis of the way in which contracts can be formed; how they
might be vitiated; how they can be discharged and what the implications of a breach might be.
The course you are following attracts students from many disciplines and from many nations
and it would be impossible to consider all the aspects of all engineering and every engineer in
each country. However the issues facing the parties to engineering contracts are generic; and
by considering certain of these issues in differing countries you will be able to analyse the
effect of risk and contract conditions; no matter what the contract or how the risk is allocated.
10
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
To consider the law of contract and its relevance to engineering projects and engineering
professionals.
Within the overall aim the following measurable objectives are set
The student will be able to:
Explain the essential requirements for a binding contract
Discuss the factors which vitiate the formation of a contract
Identify the ways in which contract may be discharged:
o by performance
o frustration
o breach
Discuss the common remedies available in the event of breach of contract
o termination
o damages
11
INTRODUCTION
The law of contract is concerned with the rights and obligations governing persons who have
entered into a consensual relationship. The subject is vast, with many highly sophisticated, but
often bewildering rules.
Case Law via the citation of authorities is given to illustrate where a principle has been
applied by the courts, and as a useful reference point, not to burden the student with the task
of reading the cases.
Contracts can be defined in many ways; two definitions are based on:
Promise
Agreement
A promise based definition is:
Contract; a promise or set of promises which the law will enforce
The promise-based definition of contract focuses on the individual promises undertaken by
the parties and the reason to hold the parties to those promises to the contract (using the
doctrine of consideration).
An agreement-based definition is:
Contract; an agreement giving rise to obligations which are enforced or recognised
by law
The agreement-based definition concentrates on the entire package of obligations and rights
that parties are understood to have agreed as governing the relationship between themselves.
Modern practice amongst lawyers as well as businessmen is to talk of contracts as agreements
rather than promises.
In England and Wales, people are given considerable freedom to make legally enforceable
agreements (or to refrain from making agreements). People can make contracts about almost
anything, provided: they are capable of entering into a contract and do not agree to anything
which is either illegal or contrary to public policy or is simply impossible.
12
THE ESSENTIAL REQUIREMENTS FOR A CONTRACT
This section considers:
The essential requirements for a binding contract
The nature of an offer
The distinction between offer and invitation to treat
When an offer can be terminated
The mechanisms for creating a contract
2.1. Contract Formation
Contracts can generally be made informally (there are some exceptions) and an oral contract
is as good as a written one, parties’ conduct itself can give rise to a contract. The lack of
writing may cause problems in proving a contract exists. To avoid such problems, either party
may stipulate that any agreement must be in writing, such a stipulation will generally be
effective.
Some types of contract, including contracts for the transfer of interests in land, contracts of
guarantee, consumer credit agreements and arbitration agreements, are required by statute to
be in writing, or be evidenced in writing and/or require the signature of the person to be
bound.
There are various classifications of contracts. Bilateral and unilateral contracts, executory or
executed contracts.
Bilateral contracts contain obligations on both parties, for instance, in a contract for the sale of
a car for an amount the buyer is obliged to pay the price to the seller and the seller is obliged
to deliver the car to the buyer.
Unilateral contracts contain obligations on only one party, for instance, a contract for
rewarding a person who finds a lost pet, the finder is not obliged to find the pet but if he does
the owner is obliged to pay the reward. These are sometimes called “if” contracts.
Contracts may be executory or executed. In executory contracts there are obligations to be
performed under the contract, in executed contracts the obligations have already been
performed but there may be continuing secondary obligations: for instance upon the sale of a
car there will be a promise that the car is of satisfactory quality.
2.2. Essential Requirements For A Binding Contract (Legal Requirements For A
Contract)
There are three essential requirements for a legally enforceable contract.
the parties must intend to create a legal relationship between themselves.
the parties must have reached an agreement in the eyes of the law (in
accordance with the rules of offer and acceptance).
13
there must be “consideration” for the agreement (unless the agreement is made
by Deed).
Each of those requirements needs to be examined carefully because there are some detailed
technical rules in respect of those requirements. Before embarking upon that exercise it is
useful to consider the practical significance of these rules. In practice one of the most
common disputes, particularly in the construction industry is the basic question whether a
contract exists between the parties. Usually in such situations, one or other party is trying to
assert that there is or is not a contract, in order to secure a benefit or avoid a liability. This is
well illustrated by the case: British Steel Corp v Cleveland Bridge [1984] 1 All ER 504. In
that case the Defendants were contractors for a building in Dammam, Saudi Arabia, which
was to have a steel space-frame roof. They contacted the Plaintiffs to supply some special
cast steel nodes for the roof and issued a letter of intent. As the work was urgent, the
Plaintiffs started immediately and in fact completed and delivered all 137 nodes while
arguments over price and other terms were still unresolved. The Defendants had paid
nothing, so Plaintiffs sued for payment. Defendants responded by counterclaiming for loss,
which they alleged they had suffered as a result of late delivery of the nodes and delivery out
of sequence. The Court held that there was no concluded contract, since there was still
disagreement on the essential terms. (However Plaintiffs were entitled to payment of
£200,000 for work done, but that was on a restitutionary or quasi-contractual basis.)
Defendants counterclaim for £800,000 for late delivery and delivery out of sequence could
only succeed on the basis of breach of contract and, as there was no concluded contract, the
counterclaim failed.
2.3. Intention to create legal relations
The law accepts that certain types of agreement are not intended to be legally binding. For the
most social and domestic arrangements fall into this category. A friend’s promise to buy the
next round of drinks is not intended to end up in Court when he fails to do so. A “car pool”
between various parents taking their children to school is not intended to be legally binding.
Such obligations are moral or honourable only. This is not to say however that families cannot
enter into arrangements but that there is a presumption that the agreement is not to have legal
force.
In commercial relationships the presumption goes the other way so that the courts have shown
reluctance to accept arguments that there is no such intention in the absence of clear
statements to the contrary, for instance by stating that the agreement was “an honourable
pledge” not a legal agreement.
The most common and effective phrase is “subject to contract”. These words in a preliminary
offer or acceptance show a lack of intention to create legal relations: Fraser Williams v
Prudential Holborn (1993) 64 BLR 1. The heading ‘letter of intent’, on the other hand, does
not necessarily carry such a connotation and it will depend upon the precise terms of such a
letter.
The courts normally approach the questions of the parties’ intention to create legal relations
by applying an objective test which has been explained in Chitty on Contracts 27th
Edition
(1994) paragraph 2-001 at pp89-90.: “Once the parties have to all outward appearances
14
agreed in the same terms on the same subject matter then neither can generally rely on some
unexpressed qualification or reservation to show that he had not in fact agreed to the terms to
which he had appeared to agree. Such subjective reservations of one party therefore do not
prevent the formation of a contract.”
2.4. Agreement in the eyes of the law
The parties must have reached agreement or consensus ad idem (“a meeting of minds”).
Caution is required with this expression because it is not necessary for the parties actually to
have reached agreement in fact. The courts are not concerned to investigate what the parties
actually intended or what was in their minds (because it is impossible to judge such a thing
accurately). Instead the courts judge from an objective approach whether there was a
manifestation of agreement by what the parties have said, written and done. It is perfectly
possible that judged objectively, parties who did not intend to agree at all or did not think that
they had agreed, seem objectively to have made a contract and they will in law be stuck with
it. On the other hand there may be parties who consider that they did agree and had made a
contract but objectively viewed in law they have not. More common is the situation where
one party thinks there is a contract and the other does not consider that there is. Because this
causes difficulties, the Courts are astute to make sure that contracts are not “imposed” upon
parties unless they meet very stringent objective criteria.
For an agreement in the eyes of the law there must be from an objective standpoint consensus
on all the essential terms and conditions of the agreement. It is important that those terms are
certain and not vague. So if there is agreement on a number of points but other important ones
have not been objectively agreed, the court will say there was no contract.
In practice the courts will judge whether there is agreement which is sufficiently certain on all
the essential terms by a well established conventional analysis. This involves looking for an
‘offer’ and an unqualified ‘acceptance’ of that offer.
Sometimes that conventional analysis is difficult to operate in practice particularly in the
construction industry and an alternative (more flexible) approach is needed. If this approach
is to be adopted (and there is no guarantee that the court always will) the court will still look
very carefully to see that there is agreement on all the essential terms and that those terms are
certain. This means that even if the parties’ negotiations are ongoing or left unresolved despite
the work being performed there is a big risk that the court will hold there was no contract at
all.
2.5. The conventional analysis: Offer and Acceptance
An offer is an expression of willingness to be bound in contract as soon as the offer is
accepted. An offer can be made by words or conduct but in order to be capable of acceptance
an offer must be communicated to the offeree. Whether an offer is made is judged objectively
by what the person has said, written or done.
A distinction is made between an offer and a mere ‘invitation to treat’, which cannot be
directly accepted there and then either because it is uncertain or because it is not directed at
the offeree specifically but to the world at large or because there is no intention to be bound
there and then. For example, most advertisements would be held to be mere invitations to
treat even if they contain expressions such as “amazing offer, not to be missed!” because they
15
address the world at large and because it is not intended that there is a contract with everyone
who responds to such an advertisement. Similarly the prices marked on the goods in a
supermarket are mere invitations to treat - the contract is only concluded at the till when the
customer selects the goods he wishes to buy and offers to buy them at that price:
Pharmaceutical Society v Boots Chemist [1953] 1 QB 401.
In Carlill v Carbolic Smoke Ball Co [1892] 2 QB 484 the Defendant had advertised the
carbolic smoke balls for sale, with an offer to pay £100 to anyone who succumbed to
influenza after using one. The advertisement stated that £1,000 had been deposited with
bankers. The plaintiff, Mrs Carlill, bought and used a smoke ball but caught influenza. She
sued for the £100. It was argued by D that the advertisement was not intended to be taken
seriously, but it was held that the statement concerning the deposit with bankers showed
otherwise and P was entitled to the £100.
This case shows that an offer can sometimes (although not usually) be made to a wide or
indeterminate class of people and that the requirement of notification of acceptance can be
waived by the offeror manifesting such an intention. It is also used as an example of a
‘unilateral’ or ‘if’ contract. The offer was to be accepted by a party using the carbolic smoke
ball in accordance with the instructions.
For the most part, invitations to tender will be simply invitations to treat rather than offers
because there is usually nothing certain that can be accepted and it merely indicates an
intention to consider offers from tenderers. Usually the person who puts in the tender will
make the offer but there are no hard and fast rules and each communication will be carefully
scrutinised.
2.6. Acceptance and Counter-Offers
Because an offer is an expression of willingness to be bound on the terms offered immediately
the offer is accepted it follows that a contract will only be formed if there is unqualified
acceptance of the exact terms proposed by the offeror. A mere acknowledgment of the offer,
or a reply by the offeree that he “intends to place an order” will not amount to acceptance.
If a person to whom the offer is addressed does not accept the exact terms but responds by
introducing a new term, or deleting a term will not have given an ‘acceptance’ in law. Any
introduction of a new term or a change to the terms offered is categorised as a counter-offer.
The effect of a counter-offer in law is to kill off the original offer and it then falls to the
original offeror to communicate his acceptance of the counter-offer, if he is willing, or to
reinstate his original offer. The classic example is Hyde v Wrench (1840) 3 Beav 334, where
the defendant offered to sell property to the plaintiff for £1,000. The plaintiff, in reply,
offered £950, but this was refused by the defendant. The plaintiff then purported to accept the
original offer to sell for £1,000, but it was held that his counter-offer had killed the original
offer, which was therefore no longer open for acceptance. In that case the defendant could
have revived his offer, if he had so wished, to sell at £1,000. Alternatively, he could have
treated the plaintiff’s purported acceptance as an offer to buy at £1,000.
In commercial contracts there is usually a course of negotiations constituting a series of offers
and counter-offers usually on each party’s own standard terms and conditions. It is commonly
thought that he who gets in the ‘last shot’ with his terms and conditions wins. This has come
to be known as the “battle of forms”.
16
Where an offer contains alternatives the offeree must state which alternative he is accepting or
else there is no valid acceptance at all. One further possibility is that an offer to sell, say a car
for £5,000 made by X crosses in the post with an offer by Y to buy the same car for £5,000.
The position is that there are two (identical) offers but no acceptance. The parties do not really
know whether they are in fact agreed, and nor would the objective eye of the law standing in
the position of the parties. Accordingly there is no contract without any further contact
between the parties to signal acceptance of one of the offers.
Letters of intent can be an acceptance of a tender but not necessarily. Careful attention needs
to be paid to the exact wording of the letter. If it contains an indication that the letter is
“subject to contract” or that “ there is no contract until a formal contract document has been
signed by the parties” it is unlikely that there is an acceptance at that stage which matures into
a contract unless the parties subsequently agree to change the subject to contract position.
Sometimes though, a letter of intent will be sufficient to amount to an offer which can be
accepted by the other party acting in reliance on the letter of intent thereby creating a contract
in itself. In Turriff Construction v Regalia Knitting Mills (1971) 9 BLR 20, a letter of intent
was held to be a collateral contract to pay for preliminary work and this has been established
in a number of subsequent cases.
The general rule is that acceptance must be communicated to the offeror to be effective.
There can be no contract if a person writes to accept an offer but forgets to send it to the
offeror. The main reason for this is because it would be unfair to bind the offeror when he is
unaware of it. The objective eye of the law looks for the manifestation of acceptance as it has
been communicated to the offeror: from that point the offeror knows (or ought to know ) that
he has bound himself to a contract. It is crucial that acceptance has been received by the
offeror. Acceptance can be communicated by words or conduct, orally or in writing.
The offer may stipulate how an offer is to be accepted and generally the acceptance must
correspond to the stipulation. So if an offer states that acceptance must be in writing an oral
acceptance is unlikely to be a validly communicated acceptance. However the rather stringent
rule has been approached by the court as a means of discerning the object sought to be
achieved by the offeror so that, for example, an offer which required acceptance “by return of
post” was interpreted to mean the time for acceptance rather than a strict requirement to post a
letter. A telex would have sufficed (or in modern times a fax, telephone or email would have
also been acceptable). However where a bank requires completion of a standard application
form for opening a bank account the object is to have a proper record and it is unlikely a
written letter giving the relevant details would suffice. The general practice of the court is that
where the offeror prescribes a particular mode of acceptance but does not stipulate that only
acceptance in that mode shall be binding, acceptance may be communicated in any other
mode not less advantageous to the offeror. The offeror can always waive the stipulation at his
choice.
Silence is not capable of acceptance because silence does not communicate assent or dissent
(or indeed anything). This can sometimes cause some unfortunate results such as in
Felthouse v Bindley (1862) 11 CB 869, P offered to buy a horse from his nephew for £30 15
shillings adding “If I hear no more about him I shall consider the horse is mine at £30 15
shillings”. The nephew intended to sell the horse to his uncle, but did not do or say anything
before an auctioneer sold it by mistake. The uncle sued the auctioneer for the return of the
17
horse because it belonged to him by the ‘contract’. The court found that there had not been a
valid contract between nephew and uncle. This is a good example of how the law in
approaching agreements objectively will often find against parties who actually intended to
reach agreement and probably thought they had. The law requires an outward manifestation of
the agreement by what the parties do or say.
However, in Re Selectmove [1995] 2 All ER 531, the Court of Appeal noted that all the cases
on this topic concerned an offeror seeking to impose on an offeree a term as to acceptance by
silence. The view was expressed that where there was an express or implied undertaking by
the offeree to speak then, in exceptional circumstances, an offer might be accepted by silence
if he did not speak up to decline the offer.
Generally communication of acceptance must reach the offeror to be effective and it takes
effect when and where it reaches the offeror. There are, however, special rules, particularly
regarding letters (this is called the “postal rule”). Acceptance by letter is generally (but not
always necessarily) effected when and where the letter is posted: Henthorn v Fraser [1892] 2
Ch 27. The reason for this favourable concession is because offerees have done everything in
their control to make sure the letter arrives and can reasonably rely upon the letter duly
arriving in the post. But the rule does not apply if, for example, the letter is wrongly addressed
and goes astray as a result, or is handed to the postman instead of being put in an official post
box: re London & Northern Bank [1900] 1 Ch 221. Nor in certain circumstances would it be
reasonable to apply the postal rule where the offeree knew that the postal service is disrupted:
Bal v Van Staden [1902] T.S. 128. It has been said that the postal rule will not be applied
where it would lead to “manifest inconvenience and absurdity”.
Telex acceptance takes effect when it received (where it appears on the offeror’s machine) at
least, if during normal office hours: Brinkibon v Stalag Stahl [1983] 2 AC 34. It is likely that
the court would apply the same rule in respect of e-mails and faxes because unlike posting,
the offeree will know pretty much instantaneously that the communication was not effective
and can try again to communicate. A telephone acceptance is effective when and where it is
heard by the offeror: Gill & Duffus Landauer Ltd v London Export Corp [1982] 2 Lloyd’s
Rep 627.
2.7. Termination of Offer
The general rule is that the offeror can revoke an offer at any time before it is accepted. The
rule applies even though the offeror has promised to keep the offer open for a certain time,
unless the promise to hold the offer open is, itself, not supported by consideration. If the
promise to hold the offer open is supported by consideration (or made under deed), then that
is itself a contract, and withdrawal of the offer would be a breach of that contract. In the
construction field, to overcome the problem, tenderers may be required to submit a ‘bid bond’
to be forfeited if the tenderer withdraws his offer before the stipulated date.
The general rule is that revocation of an offer must be communicated to the offeree to be
effective. The postal rule does not apply to revocation of offers. So if an offer is withdrawn
by a letter which is posted at a time when an acceptance has been sent in the post the offer
cannot be withdrawn because there is already a contract. It is not sufficient for the offeror just
to act inconsistently with the offer, e.g. selling the goods to another person. It is sufficient,
however, if the offeree learns of the inconsistent act through a third party before attempting to
accept: Dickinson v Dodds (1876) 2 Ch D 463.
18
An offer may cease to exist by the lapse of time. Thus, in Ramsgate Victoria Hotel Co v
Montefiore Same (1866) LR 1 Exch 109, it was held that persons who applied for shares were
not bound to take up the shares when the allotment was not made within a reasonable time.
What is a reasonable time in any particular context depends on the facts, for example, the
perishable nature of the goods, or the fluctuations of price in the particular commodity.
2.8. A commercial analysis of agreement (looking at the negotiations as a whole)
The conventional analysis of offer and acceptance seems somewhat artificial to commerce.
The practicalities of modern commerce mean that protracted negotiations take place during
which certain terms are taken as read and other terms will be thrashed out on an ongoing
basis. Sometimes there will be only be a sticking point over one or two terms. The reaching of
an agreement is an evolving process. The terms which have been agreed will usually be found
in various minutes of meetings, letters and heads of agreement and once agreed probably will
not be mentioned again. Such cases do not neatly fit in with the conventional analysis. To
make matters more complicated it is common in the construction industry to get on with the
work even whilst some of the terms contract are thrashed out. For the most part a standard
form of contract will be used which everyone will be broadly familiar with and it is only a
few particular items that need to be agreed and the practical approach is not to let these items
prevent performance of the work to be done under the ‘contract’.
The courts are not consistent in their approach but seem to adopt two guiding principles
which allows a degree of flexibility according to the merits of the case.
The principle that the courts will not make an agreement for the parties.
Alternatively the courts will try to give meaning to the performance of the parties by
holding that there was a contract if they find the parties intended to be bound provided
there is sufficient certainty of all the essential terms.
In some cases, such as British Steel v Cleveland Bridge, described above, the courts appear to
start from an open-minded position as to whether a contract exists. A useful judicial summary
of this approach is provided by HHJ Fox-Andrews in Arbiter Investments Limited v Wiltshier
London Limited (1987) 7 Const LJ 49. If no contract exists and the work has been done the
contractor will get paid on a quantum meruit. It may be that a contractor will prefer to avoid
the contractual provisions for payment i.e. that a quantum meruit is commercially
advantageous.
In other cases, particularly where work has been performed, the courts appear to start from a
presumption that a contract exists. Agreement was inferred by conduct in Brogden v
Metropolitan Railway Co (1877) 2 App Cas 666. D drew up a contract for the supply of coal.
P filled in the blanks and marked it ‘approved’, but there was no formal execution of the
contract. Both parties acted in accordance with its terms. A dispute arose and P denied there
was a contract. The House of Lords held there was a contract which was complete as soon as
the first load of coals was supplied and invoiced, and the invoice was paid at that price.
For agreement to be inferred from conduct, it would seem the conduct must be referable to
some agreement or draft agreement, which was in existence before the conduct started: Fraser
Williams v Prudential Holborn (above). If conduct is potentially referable to an alleged
contract, but could equally be explained on the basis of some other agreement, assent to the
19
alleged contract will not be implied: The ‘Aramis’ [1989] 1 Lloyd’s Rep 213. Per Bingham
LJ, at p224:
“It must, surely, be necessary to identify conduct referable to the contract contended for or, at
the very least, conduct inconsistent with there being no contract made between the parties to
the effect contended for. Put another way, I think it must be fatal to the implication of a
contract if the parties would or might have acted exactly as they did in the absence of a
contract.”
In the Court of Appeal decision in Percy Trentham v Archital Luxfer (1992) 63 BLR 44, the
defendant, a window works specialist supplier and installer, denied that a binding contract had
been concluded, on the grounds that there were conflicting exchanges in the negotiations.
The Court of Appeal held that, particularly as the transaction had been executed, it was
difficult to submit that the contract was void for vagueness or uncertainty. The sub-contract
came into existence “not simply by an exchange of correspondence but partly by reason of
written exchanges, partly by oral discussions and partly by performance of the transactions”.
This should be contrasted with the decision in Galliard Homes (above), where the parties had
shaken hands on a deal and the work had been performed, but it was held that there was no
contract. In Hillas v Arcos (1932) 147 LT 503, where it had been argued that the contract for
the supply of timber was void for uncertainty despite having been operated for a year, Lord
Thankerton commented, at p513:
“I am affected by the consideration that the contract is a commercial one and that the parties
undoubtedly thought that they had concluded a contract.”
But the fact that the parties thought that they had a contract cannot affect the position in law if
they did not reach agreement on all the essential terms. The issue may arise as to when, or
whether, agreement has been reached on essential matters, and this may depend on which
matters are to be regarded as ‘essential’. In Pagnan SpA v Feed Products [1987] 2 Lloyd’s
Rep 601, the intending sellers of a quantity of corn gluten pellets subsequently contended that
a contract negotiated through an intermediary had not been concluded, on the grounds that a
number of matters had not been agreed at the time and negotiations were continuing.
Bingham J held that a contract had been concluded because agreement had reached on all
matters which the parties themselves regarded as essential. The outstanding matters were
regarded by the parties as relatively minor details which could be sorted out once a bargain
had been struck.
It may be that the work is completed before the contract document is completed. In such a
situation the court will look to see whether the contract expressly or by implication has
retrospective effect in respect of work done or goods supplied before the contract was actually
made: Trollope & Colls Ltd v Atomic Power Construction Ltd [1963] 1 W.L.R. 333.
2.9. Subsequent Words or Conduct
Subsequent exchanges, whether words or conduct, will not affect a bargain unless they
amount to a further contract to vary the concluded contract. Once it is shown that there is a
complete contract, further negotiations between the parties cannot, without the consent of
both, get rid of the contract already arrived at: Perry v Suffields [1916] 2 Ch 187. However,
subsequent agreement on the time or price is, however, regarded as binding and superseding
the implied terms of reasonable time or price because there is in such a situation a general
20
power for the parties to agree as contractually binding minor matters left open when the
contract originally came into existence. Alternatively it can be explained on the basis that
such agreement varies the original terms. In construction contracts upon the standard forms it
is usual for contract machinery to deal with agreement on price and time.
2.10. Agreements to Agree are not contracts
A mere agreement to agree is regarded as uncertain and therefore does not create a binding
contract, in the absence of adequate machinery to resolve any lack of agreement. The court
will not make the agreement. The principle has been upheld by the House of Lords in Walford
v Miles [1992] 2 AC 128, where it was held that a lock-in agreement to negotiate was not
binding although an agreement locking-out agreement with anyone else was capable of
binding if it was supported by consideration.
2.11. Contracts made under seal: Deeds
The significance of the seal has largely disappeared, but the idea of a ‘Deed’ as a formal
document has been retained. The formalities required are now specified in the Law of
Property (Miscellaneous Provisions) Act 1989 and the Companies Act 1985, Section 36A
inserted by the Companies Act 1989, s130. As a matter of history, formal contracts required
an instrument executed ‘under seal’ known as a ‘deed’. The conveyance of interests in land
(as distinct from the contract), must be by deed. Construction contracts are still often
executed as deed mainly to obtain the advantage under the Limitation Act 1980 because a
cause of action for a contract by deed is twelve years, compared to six years under a simple
(or ordinary) contract. Also a contract by deed obviates the need for ‘consideration’.
2.12. Consideration
Apart from contracts executed by Deed, the third requirement for a valid contract is
‘consideration’. Consideration is a doctrine which developed when a contract was seen as a
promise or set of promises and consideration was what made a promise given by the promisor
enforceable by the promisee. A promise or a contractual obligation is only binding or
enforceable by the promisee if it is given for valuable consideration: it embraces the concept
of contract as a bargain whereby something is given in return for something else. This is why
lawyers talk of consideration moving from the promisee: it is because the promisee has
provided consideration that he is allowed to enforce the promise. Consideration can be either
the conferring of a benefit on someone else, or the suffering of a benefit by the person
providing the consideration. The House of Lords in Dunlop v Selfridge [1915] AC 847
defined consideration as:
“An act of forbearance of one party, or the promise thereof is the price for which the promise
of the other is bought, and the promise thus given is enforceable.”
Consideration is usually either money or a promise to pay money, but it can also be some
other benefit to the promisor or detriment to the promisee. For example, in Shanklin Pier v
Detel Products [1951] 2 KB 854, it was held that specification by P of D’s paints which were
to be used by the main contractor was sufficient consideration for D’s promise that the paint
was suitable for purpose. It is possible for the promisee in providing consideration to suffer a
detriment without conferring a benefit on the promisor (or alternatively for the promisee to
confer a benefit on a third party as consideration for the promisor’s promise. Whenever you
21
pay for goods by credit card, the supplier of the goods (as promisee) provides consideration
by handing over the goods to the customer (as a third party) pursuant to a promise by the
credit card issuer (the promisor) to pay the amount charged to the card.
The law is not concerned with the sufficiency or adequacy of consideration. This is because
the Courts will not interfere with the bargain made by the parties, which is part of their
freedom to contract for whatever bargain they choose. See for example Midland Bank & Trust
Co. Ltd v Green [1981] AC 513 where a husband sold a farm worth £40,000 to his wife for
£500. While the courts can and do interfere in special circumstances to prevent
unconscionable dealing and may use a panoply of common law and statutory principles to do
so, in general the Court will not judge whether a party has made a good or bad deal or to
decide questions of commercial acumen. The Court is designed to decide the law and the
market place is the best place to decide a bargain. Because the adequacy of consideration is
not investigated the parties have been permitted to give a nominal consideration such as a
‘peppercorn rent’ in contracts for leases or consideration of £1 which is written into many
forms of collateral warranty. Although nominal, consideration must be real in the sense of
being capable of evaluation in the eyes of the law, there must be some extrinsic value in the
consideration. For this reason natural love and affection is not capable of being consideration
in the eyes of the law.
Another important feature of the doctrine of consideration is that “past consideration is
generally no consideration”. Thus, in Roscorla v Thomas [1842] 3 QB 234, after the sale of a
horse had been concluded, the vendor gave a guarantee that it was ‘free from vice’. It
subsequently proved to be lame. It was held that the guarantee was not binding as the promise
was unsupported by consideration. The price paid for the horse was ‘past consideration’. In
IBA v EMI (1980) 14 BLR 1, the rule was confirmed by the House of Lords in the context of a
letter written after the contract had been entered into, warranting the adequacy of a design.
An exception to the rule on past consideration is that if work is carried out at the request of
the eventual promisor with the expectation by both parties that it will be paid for, agreement
on the amount of payment after the work is completed will be a valid promise: re Casey’s
Patents, Stewart v Casey [1892] 1 Ch 104. If there were no agreement in that situation, the
court would fix the amount on a quantum meruit.
2.13. Vitiating Factors In Contract
The factors which vitiate the formation of a contract are mistake and misrepresentation.
2.14. Mistake
Categories of Mistake
The heading ‘Mistake’ refers to situations where one or both parties to a contract is or are
under a misapprehension of present fact or law at the time of contract. The situations can be
divided for the purposes of legal analysis into two categories:
Unilateral Mistake
Where the mistake is such that the parties are at cross-purposes, or where the mistaken belief
of one party is known to the other party.
22
Common Mistake
Where the parties share the same misapprehension: they are both mistaken about the same
thing. This includes cases where one party knows of the mistake but is unaware of, or does
not consider its significance, as in Bell v Lever Bros. [1932] AC 161, described below.
Lawyers disagree over the terminology. While some call the latter category “common
mistake” others call it “mutual mistake” because the mistaken thing is mutual whereas the
supporters of common mistake terminology use “mutual mistake” to describe a sub-division
of former category where the parties are at cross-purposes, so that they both (mutually) make
a mistake but are mistaken in different ways. To confuse the issue further some textbooks use
the term “mistake” to embrace the equitable remedy of ‘rectification’ of a written contract
where it does not accurately record the agreement of the parties.
The doctrine of mistake is found in both common law and equity. At common law a contract
is void ab initio for mistake (i.e. treated as if never came into existence). In equity, the
contract is voidable (i.e. it is susceptible of being rescinded but exists until it is rescinded).
Unilateral Mistake
Where there is unilateral mistake as to a fundamental assumption on which a contract is
based, the contract may be held void on the ground that there never was true agreement. Such
relief will not lightly be granted. At common law only fundamental mistake is material:
Kennedy v Panama Royal Mail Co (1867) LR 2 QB 580. As regards equitable relief,
Baggalay LJ observed in Tamplin v James (1880) 15 Ch D 215 that:
“Where there has been no misrepresentation and where there is no ambiguity in the terms of
the contract, the defendant cannot be allowed to evade the performance of it by the simple
statement that he has made a mistake. Were such to be the law the performance of a contract
could seldom be enforced upon an unwilling party who was also unscrupulous.”
There are four situations where relief has been granted for mistake.
Cross-purposes as to a material fact
Where the parties have been at cross-purposes as to a material fact, as where the contract
referred to goods on board the “Peerless, ex Bombay” and there were two ships of that name
sailing from Bombay: Raffles v Wichelhaus (1864) 2 H & C 906. It was held that the
defendant was not bound to take delivery of the goods.
Mistake as to the identity
Where there has been a mistake as to the identity of the other party contracting and the first
party did not intend to enter, and would not have entered, into a contract with that person. In
Cundy v Lindsay (1878) 3 App Cas 459, a rogue by the name of Blenkarn ordered goods from
the plaintiffs, writing from an address, 37 Wood Street, Cheapside. There was, in fact, a
respectable firm by the name of Blenkiron, trading at another address in Wood Street.
Blenkarn wrote his name so that it would be read as Blenkiron, and the plaintiffs thought they
were dealing with Blenkiron, although they wrote back to 37 Wood Street. There was no
dispute that the contract with Blenkarn was voidable for fraud, but by the time the plaintiffs
23
discovered the fraud, Blenkarn had sold the goods to the defendants. The plaintiffs sued in
the tort of conversion, and the question was whether title in the goods had passed to Blenkarn
so that he could pass good title to the defendants, or whether the contract been void ab initio
for mistake. The judge at first instance held that the plaintiffs had been willing to trade with
the person at 37 Wood Street, so that the contract was not void ab initio, but this was reversed
on appeal. Both the Court of Appeal and the House of Lords held that the plaintiffs intended
to sell to Blenkiron and the acceptance by Blenkarn was void.
Non est factum
Where a party signing a contract document has been misled as to the nature of the document,
in which case the plea of ‘non est factum’ may apply. This defence is rarely used and almost
never successful particularly now there are few illiterate people: see Gallie v Lee [1971] AC
1004 where it was said by Lord Wilberforce “A man cannot escape from the consequences, as
regards innocent third parties, of signing a document if, being a man of ordinary education
and competence, he chooses to sign it without informing himself of its purport and effect.”.
Recently this statement was approved of in Norwich & Peterborough Building Society v Steed
(No 2) [1993] 1 All ER 330.
Mistake as to terms of the contract
The fourth situation, is where there is a clear mistake by the offeror as to the terms of the
contract, and the mistake is known to the other party when he purports to accept. In Hartog v
Colin and Shields [1939] 3 All ER 566, the defendants contracted to sell to the plaintiff
30,000 Argentine hare skins, but by mistake, they offered to sell them at X pence per pound,
when they intended to sell at X pence per piece, there being approximately three pieces per
pound. The defendants satisfied the judge that “the plaintiff could not reasonably have
supposed that the offer contained the offeror’s real intention” and the judge held that no
binding contract was made by the plaintiff’s acceptance. In the law report an Editorial Note
adds a comment: “An intending purchaser is not permitted to ‘snap up’ an offer which he
knows to have been made under a mistake.”
There is a distinction between the various situations of unilateral mistake, as to the relevant
test applicable. Where the mistake is known to one party, the test is subjective as to the belief
of the mistaken person. When the parties are at cross-purposes, the test is objective - what a
reasonable person would have understood from the agreement as expressed.
Common Mistake
The rules relating to unilateral mistake are essentially extensions of the rules on formation of
contract and the need for agreement. Because of the lack of true agreement, the contract will
be rescinded and it is not difficult to say that the contract never really existed.
Where the parties share a common misapprehension, the position is different as there is
clearly agreement. Nevertheless, in very limited situations the courts may hold that a contract
is rendered void by common mistake: either void ab initio at common law, or voidable in
equity.
It is well established that a contract will be void where the subject matter of the contract has
ceased to exist, unknown to the parties, before the time of contract. Thus, in Couturier v
24
Hastie (1856) 5 HL Cas 673, where a cargo of corn, supposed to be in transit, had already
been sold en route after becoming fermented, the contract was held void.
The principle would apply equally in relation to, say, a contract to refurbish a building where
the building had, unknown to the parties, burnt down before the time of contract. This class
of cases is referred to as “res extincta”. Note that if the property burnt down after the contract
the doctrine of frustration rather than mistake would apply. The law of res extincta is codified
by statute in the Sale of Goods Act 1979, s6 in relation to contracts for the sale of goods.
2.15. Misrepresentation
A misrepresentation is a representation, which is statement of fact (past or present), made by
one party (the representor) to another (the representee) or a statement known by the
representor to have been made, which is false and which induces the representee to enter into
the contract with the representor. In that definition there are four important elements which
must be present a statement of fact (past or present); made by the representor to the
representee or which is known to the representor; which is false; and which induces the
representee to enter into the contract with the representor.
The ways in which contracts may be discharged
2.16. Performance and Discharge
Generally a party is expected to perform exactly what he has undertaken to do. Where the
parties have performed their obligations according to what has been agreed not much needs to
be said. In many construction contracts what has been ultimately performed may be slightly or
substantially different from what was originally envisaged and agreed, although the parties
will usually have operated contractual machinery to achieve the end result satisfactorily.
Where the parties have performed the contract fully the obligations are fully executed. As a
matter of legal technicality it is said that the contract obligations are performed and thereby
discharged but the contract itself remains alive (though dormant) for the purposes of
executory secondary promises (for instance for latent defects, warranties as to quality and
fitness etc).
However there are occasions when performance of a contract is not fully completed . In
certain circumstances it may be terminated or discharged before performance is complete,
whereby the contract does come to an end and does not remain alive. A contract may be
discharged by agreement between the parties either by way of variation, rescission, waiver or
even provision for discharge in the terms of the contract itself. (In fact executory secondary
promises for a contract which has been performed can also be discharged by release or accord
and satisfaction.)
This section does not discuss discharge by agreement but there are two other methods by
which a contract may be discharged which are discussed in the remainder of this section. The
first is discharge by frustration. The second is discharge by breach of contract which is best
described as “termination”. We shall examine discharge by breach as one of the remedies
available in certain circumstances for breach of contract. It should be remembered that
“discharge” or “termination” is different from “rescission” or rendering a contract void. In the
former the contract obligations are stopped at the point of termination or discharge so that no
future performance is necessary, or is excused. In the latter, used in the context of the
25
doctrines of mistake and misrepresentation the contract is treated as if it never came into
existence: the contract is re-wound.
Discharge by Frustration
Frustration does not vitiate a contract in the same way as mistake or misrepresentation. The
latter two doctrines are concerned with matters which affect the basis of entering into a
contract (and may be said to vitiate the underlying notion of consent or agreement).
Frustration is a doctrine by which a contract, properly entered into, can be discharged because
something occurs after formation of the contract which renders it physically or commercially
impossible to fulfil the contract or radically changes the performance obligation from that
agreed in the contract.
Prior to 1863 the doctrine of frustration was unknown to English law. Instead the rule was
that once a party had made a contract he was absolutely bound to perform, even if by accident
or disablement he could no longer perform: failure to perform was a breach for which the
other party had his remedies. The reason for this strict rule was that it was open to the parties
to allocate risk for such events in their contract. (There were exceptions in the case of breach
of promise of marriage, or where performance was made illegal subsequent to the contract,
such as dealing with the enemy in time of war). Then in Taylor v Caldwell (1863) 3 B & S
826 the Court gave birth to the doctrine (although it was not called “frustration” until later
cases). The plaintiffs hired a music hall for concerts for 4 nights. Before the first night the
music hall was destroyed by fire. Although the defendants were not liable for damages it was
held to be an implied condition that the music hall would continue in existence for the
contract to be performed and so the plaintiffs were excused from performance.
The doctrine spread quickly beyond situations where the subject matter of the contract
perished. For example the doctrine applied to the “coronation cases” involving cancellation of
bookings because the coronation of King Edward VII was postponed, such as Krell v Henry
[1903] 2 K.B. 740 where the defendant agreed to hire rooms in Pall Mall to see the coronation
processions and subsequently refused to pay the rent and the Court of Appeal upheld his
refusal to do so because viewing the procession was “the foundation of the contract” (even
though it was proved by parol evidence, there being no mention of it in the written contract).
The doctrine can thus apply to cancellation of events (though note that it does not apply where
the cancellation is by one of the parties). The doctrine also spread to apply to cases where
there have been legislative or other legal changes or the exercise of statutory power. In Bailey
v De Crespigny (1869) L.R 4 Q.B. 180 there was a covenant in a lease that the lessor or his
successors would not build on the land. A subsequent statute allowed the compulsory
purchase of land by railway companies and the land in question was compulsorily purchased
and a station built on the land. The problem was that the lessor would be responsible for the
acts of his “assignee” but it was not contemplated by the contract that he might be responsible
for an assignee’s acts arising out of a having a building on the land: it was a different
obligation and so the contract was frustrated. More difficult are situations where delay is
alleged to have been the frustrating event. In order to succeed on a claim that delay had the
effect of frustrating the contract the Courts insist on abnormal delay that could not be
reasonably contemplated at the time of the contract: see Pioneer Shipping Ltd v B.T.P. Tioxide
Ltd (The Nema) [1982] A.C. 724; Sir Lindsay Parkinson & Co. Ltd v Commissioner of Works
[1949] 2 K.B. 632.
26
Commercial contracts usually attempt to limit the risk of unforeseen events that could
otherwise amount to frustration through “force majeure” clauses which appear in some
standard forms of construction contract. To a large extent this restricts the application of
frustration where the frustrating event is provided for and risk allocated accordingly.
Where a contract is frustrated the parties can where the circumstances permit, re-negotiate to
achieve the ultimate objective. But the courts are wary of permitting the doctrine of frustration
to be used by parties as a means of getting out of a bad bargain and re-negotiating.
Consequences of Frustration
Where a contract is frustrated, the parties are discharged from future performance, but accrued
rights and liabilities stand. At common law, this could work harshly either way, as it
depended whether or not entitlement to payment had accrued. For example, in Appleby v
Myers (1867) LR 2 CP 651, on a contract for the refurbishment of a theatre, the contract was
frustrated when the building burnt down. The contractor was not entitled to any payment,
despite the work having largely been completed, because it was an entire contract so
entitlement to payment did not accrue until it was complete.
The contract may itself provide for payment, etc in the event of frustration, in which case the
common law and statutory rules are overridden and the Law Reform (Frustrated Contracts)
Act 1943 Act insofar as it applies will only apply consistently with those provision: see
Section 2 (3) of the Act.
Breach Of Contract And Remedies
This section considers remedies for breach of contract. Where there has been mistake,
misrepresentation or frustration (which are not categorised as breaches of contract) the
remedies are given above and are not repeated. There are several potential remedies that a
party has against a party who is in breach, depending upon the circumstances, this section will
concentrate on the two most common remedies available in the majority of cases which are:
termination by way of accepting the other party’s repudiatory breach of contract
damages for breach of contract
It is worth mentioning that in addition to these remedies, in certain circumstances, a party can
seek equitable remedy of injunction to restrain a breach of contract (particularly in cases
where copyright or a patent is being infringed or there is a breach of confidentiality) or
specific performance of a contractual obligation but more often than not the Court will hold
that damages are an adequate remedy so that the equitable remedies need not be awarded.
In addition there may be extra-contractual remedies (which apply where there is no contract,
or where the basis of a claim is independent or separate from the contract). The most obvious
of these remedies is payment for work done on a quantum meruit with which the construction
industry is familiar. Sometimes it is more advantageous to argue that there is no contract
because the amount awarded on a quantum meruit can be greater and in addition any right of
set-off under the contract will not apply (because there is no contract). In addition, there are
proprietary claims for instance retention of title to goods in default of payment although these
are often not effective.
27
Termination
Termination of a contract is discharging the parties from further obligation to each other, can
take place in a number of circumstances.
There are a variety of circumstances in which termination of the contract is the appropriate
remedy.
Where the other party shows by words or conduct before or at the time for
performance of his obligations that he does not intend, or is unable, to perform them at
all it is said that he has renounced the contract. If this occurs before the time to start
performance has arrived, it is said to be ‘anticipatory breach’. If it is not plain that he
does not intend to perform all of the obligations but only some, it is not a question of
renunciation although the failure to perform may well constitute repudiation for which
the innocent party may terminate the contract.
Where the parties have agreed, whether by express words or implication of law, that
any failure by one party to perform a particular primary obligation (a condition)
should entitle the other party to regard the contract as discharged, irrespective of the
gravity of the event that has in fact resulted from the breach. This is called ‘breach of
condition’ and is to be distinguished from a breach of warranty (where termination is
not available, only damages
Where the other party fails to perform a primary obligation (an innominate term)
which has the effect of depriving the other party of substantially the whole benefit
which it was the intention of the parties that he should obtain from the contract. This
is sometimes called “fundamental breach”; it is sometimes said that the “breach goes
to the root of the contract” and stems from the Hong Kong Fir Shipping case.
The effects of termination
Where a contract is treated as discharged, the effect is that primary obligations as to future
performance are terminated. A secondary obligation is substituted in their place, by
implication of law, that the party in default should pay monetary compensation to the other
party for the loss sustained by him in consequence of the non-performance of the future
obligations. The secondary obligations substituted by implication of law may be modified by
the contract itself. As regards the primary obligations already performed, any rights and
liabilities which have already accrued (such as instalment payments for work done), are not
affected by the termination.
Damages for breach of contract
The most common remedy for breach of contract is “Damages” which is an award of
monetary compensation to be paid to the plaintiff/claimant by the defendant (or, on a
counterclaim, by the plaintiff/claimant to the defendant), which is enforceable through the
courts in the same way as a judgment order for a debt. An award of damages entails a
decision on the principle of liability together with a decision on the amount or ‘quantum’ of
damages. The process also involves various intervening issues including causation,
remoteness, measure of damages and mitigation.
28
In the construction industry, the use of standard forms will provide contractual machinery for
breach of contract by either the Contractor (via Liquidated and Ascertained Damages) or by
the Employer via the clauses which deal with claims for loss and expense (see for example
clause 26 of JCT80). These would ordinarily give rights to a party to claim damages for
breach of contract. The distinction between payments within the contract, and damages for
breach of contract should be strictly observed. That is not to say that the contractual
machinery precludes the common law remedy of damages: such contractual rights are usually
additional to, not substitutes for the common law remedy of damages: Modern Engineering v
Gilbert-Ash [1974] A.C. 689 (HL). However, it is open to the parties to exclude by contract
terms, the common law remedy but the terms will be very strictly construed by the courts who
will not permit common law rights to be ousted easily.
The basis of assessment of damages for breach of contract was stated by Parke B in Robinson
v Harman (1848) 1 Ex 855:
“Where a party sustains a loss by reason of a breach of contract, he is, so far as money can
do it, to be placed in the same situation as if the contract had been formed.”
This should be contrasted with ‘Damages’ that can be awarded in tort, where the object is to
put the party in the same position as if the tort had not been committed: it is the tort measure
of damages that applies to misrepresentation. This can lead to a different result, although in
some cases, damages in contract may be assessed on a ‘no transaction basis’ with the same
result.
An award of damages is meant to compensate a party for his loss. If there is a breach of
contract which results in no actual loss an award of nominal damages is appropriate rather
than substantial damages. Unlike tort, where damages are an essential element of the cause of
action, in contract a party has a cause of action when there is a breach of contract, and does
not have to show he has suffered a loss although if he wants substantial damages he must
demonstrate his losses otherwise he will only get nominal damages. An employee who,
without good reason, is sacked on the spot and escorted off the premises without being
permitted to work out his notice but in receipt of his wages in lieu of the notice period can
claim breach of contract (wrongful dismissal). However because he has been paid up to the
end of the notice period he has suffered no loss and would not be entitled at common law to
substantial damages but only notional or nominal damages.
Sometimes the person suffering the substantial loss may not be a contracting party who thus
does not have a remedy by way of a claim for breach of contract (a privity problem) whereas
the innocent contracting party who would have such a claim does not suffer any loss. The
general rule is that the contracting party can only recover in a breach of contract claim the loss
that he suffered: he cannot recover losses suffered by someone else who is affected as a result
of that breach of contract.
Causation
The general principle is that a defendant is liable to the plaintiff for loss or damage caused by
his breach of contract. The issue of causation is difficult and the Courts have avoided laying
down any formal tests, preferring the Court’s common sense and the facts to guide them in
deciding whether the defendant’s breach is a sufficiently substantial cause of the claimant’s
29
loss. In practice, a person may suffer loss for a whole host of reasons and it may be that the
defendant’s breach of contract triggers off a chain of events or reasons which result in the
claimant suffering loss. Some of those events may be reasonably unforeseeable at the time of
the contract (or indeed at the time of breach) and the extent and type of loss might not be
reasonably contemplated. Or another way of looking at it is to say that the defendant’s breach
has merely provided the opportunity or occasion for loss to occur as a result of some other
force or event.
Remoteness of damage
Remoteness of damage is a legal test used for deciding which types of loss are recoverable as
the result of a breach of contract which has caused the claimant’s loss. (This must be
distinguished from “measure of damages” or “quantification” which it an assessment of the
amount of damages not the type of loss which is recoverable). There are three landmark cases
which set out the principle and they are discussed below. The combined effect of those cases
the rule is neatly summarised by Chitty, 28th
Edition, para. 27-042, page 1291 as follows:
“A type or kind of loss is not too remote a consequence of a breach of contract if, at the time
of contracting (and on the assumption that the parties actually foresaw the breach in
question) it was within their reasonable contemplation as a not unlikely result of that
breach.”
Note that the test is judged by what the parties could be expected to foresee at the time of
contracting and not at the time of breach.
In Hadley v Baxendale (1854) 9 Exch 341, the plaintiffs were millers at Gloucester. Their
mill shaft broke and they sent it by the defendant, a common carrier, to the makers at
Greenwich to provide a pattern for a replacement. In breach of contract, the defendant
delayed the delivery of the mill shaft and the mill was kept idle longer than necessary. The
plaintiffs sued the defendant carrier for loss of profits they would have made had the mill
started again without the delay. However the defendant was only told “the article to be
carried was the broken shaft of a mill and that the plaintiffs were the millers of the mill”. The
classic statement of the rule on remoteness was made by Alderson B:
“Where two parties have made a contract which one of them has broken, the damages which
the other party ought to receive in respect of such breach of contract should be such as may
fairly and reasonably be considered either arising naturally, i.e. according to the usual
course of things, from such breach of contract itself, or such as may reasonably be supposed
to have been in the contemplation of both parties, at the time they made the contract, as the
probable result of it.”
The two ‘limbs’ of the rule in Hadley v Baxendale are commonly referred to as ‘general’ and
‘special’ damages. General damage is that which arises naturally as a result (e.g. if the roof of
a house caves in the damage which arises naturally is the direct damage to the house and its
contents and the cost of repair/replacement and also the cost to the occupants of the house
whose roof has caved in such as the cost of having to move to temporary accommodation or
eating out because the kitchen is unusable). As for special damage, the plaintiff must prove
that any special damages claimed may reasonably be supposed to have been in the
contemplation of the defendant at the time of contract. If the cabbie in an earlier example had
been told that the businessman had to catch the flight in order to complete a deal which
30
needed his signature by a certain imminent deadline, the businessmen could claim as special
damage the loss of the deal which was reasonably contemplated at the time of contract. It is
special to that contract, but would not ordinarily be so. The rule was amplified by the Court
of Appeal in Victoria Laundry (Windsor) Ltd v Newman Industries [1949] 2 KB 528.
It is important to remember that it is the type of damage which would be in the reasonable
contemplation of the parties at the time of contract, not necessarily the extent of the damages.
Measure or assessment of damages
The normal rule is that damages are assessed from the date of the breach of contract, which is
when the loss is said to arise. The precise measure of damages which apply vary depending
on the type of case. There are particular principles that apply in cases involving sale of goods,
carriage of goods, contracts concerning the sale or lease of land, contracts to pay or lend
money.
So far as construction cases are concerned where there is incomplete or defective
performance, the primary measure of damages is the difference between the defendant’s
performance in its defective state and performance in accordance with the contract: see C.R.
Taylor v Hepworths [1977] 1 W.L.R. 659; Dodd Properties v Canterbury City Council [1980]
1 W.L.R. 433 at 465 C.A; Cory & Son v Wingate Investments (1980) 17 B.L.R. 104 at 121
C.A. An alternative method is to allow the claimant to recover the reasonable cost of
completing or rectifying the work: the cost of making good (particularly when the party in
breach is unable or refusing to perform or sometimes when the innocent party prefers to have
the work done by himself or by someone else). This measure is called the cost of
reinstatement. The date of assessment of repair or completion costs will generally be when it
was reasonable for the plaintiff to have the repairs or work of completion carried out having
regard particularly to the date when the defects were discovered or ought reasonably to have
been discovered.
However the reinstatement measure of damages will not always be appropriate and it will
depend upon the circumstances of the case. The case of Ruxley Electronics and Construction
Ltd v Forsyth (1995) 73 BLR 1 serves as a useful reminder that if the cost of remedying the
defect is disproportionate to the benefit achieved the reinstatement costs will not be allowed.
In that case Mr Forsyth wanted a swimming pool with a deep end depth of 7 feet and 6
inches. The contractors built a pool which was not quite deep enough at 6 feet and 9 inches.
When Mr Forsyth refused to pay off the balance of the account, the contractors sued and Mr
Forsyth counterclaimed for the cost of rebuilding the pool to its proper specification (which
meant ripping out the existing one and starting again). Mr Forsyth’s counterclaim was
dismissed by the judge as disproportionate who awarded him damages instead for the loss of
amenity from a deeper pool. The Court of Appeal allowed Mr Forsyth’s appeal but this was
overturned in the House of Lords who held that reinstatement cost was not the appropriate
measure of damages because it was disproportionate, even though an alternative measure,
being diminution in value would have resulted in nominal damages. Although loss of amenity
in this case was available because this was a contract to provide a pleasurable amenity it
would not be available in a commercial construction context. A suggested answer to a
contractor’s claim for payment of the balance of the account is the defence of abatement
(reduction in the amount payable to take account of defects) but this was not argued in that
case.
31
Mitigation of loss
Recovery of damages, as Lord Haldane explained in the leading case on mitigation, British
Westinghouse v Underground Electric Railways [1912] AC 673, is
“qualified by a second[principle], which imposes on a plaintiff the duty of taking all
reasonable steps to mitigate the loss consequent on the breach, and debars him from claiming
any part of the damage which is due to his neglect to take such steps.”
In that case the railway company had purchased generators from Westinghouse, with a
stipulated efficiency rating. The generators when tested had not yielded the stipulated
efficiency. It might have been open to the railway company to claim as damages the
additional fuel costs incurred, but instead they chose to order substitute generators from the
Bush company. They claimed the cost of the new machines as damages, but the new
machines were in fact much more efficient than the efficiency stipulated in the original
contract, so much so that they provided a saving which was sufficient to cover the cost of the
new machines. The House of Lords held that the plaintiff had to account for the saving
achieved by his steps taken in mitigation, and no damages were recoverable.
The duty to mitigate is subject to limits, that is, to take reasonable steps and the innocent party
is not expected to do anything outside the ordinary course of business. The time when a party
should mitigate is when he knows or ought reasonably to have known that there was a breach
(rather than the damage): see the East Ham Corporation case (above).
If the defendant himself offers an opportunity to mitigate the loss, the courts will consider
whether the offer ought to have been accepted on a test of reasonableness: Payzu v Saunders
[1919] 2 KB 581.
If the innocent party takes reasonable steps to mitigate his loss, then the measure of damages
will be his actual loss. Where he has, by mitigating, reduced the loss to nil, he will recover
nothing (except any costs of taking the mitigating steps). If the party has attempted to
mitigate but in taking reasonable steps his attempt has backfired and actually increased the
loss he will be able to recover the greater loss from the defendant: Wilson v United Counties
Bank [1920] A.C. 102, 125; Quinn v Burch Bros. (Builders) Ltd [1966] Q.B.370.
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises can I:
2) Explain the law of contract and its relevance to engineering projects and engineering
professionals
3) Explain the essential requirements for a binding contract
4) Discuss the factors which vitiate the formation of a contract
5) Identify the ways in which contract may be discharged:
6) by performance
32
7) frustration
8) breach
9) Discuss the common remedies available in the event of breach of contract
a) termination
b) damages
33
3. Tort
Introduction
This section deals with an introduction to the law of tort. You are asked to do several things:
complete the Blackboard section [including brief exercises]; read the workbook; read some
material from the book which supports this section and visit some websites.
There is excellent material in the textbook which supports this section:
Uff, J., Construction Law,
You should read pages 429-462 which describe general principles of tort in conjunction with
this section. The intention here is not to repeat the material in the textbook but to provide
some additional material; and sometimes an alternative analysis
Tort is an essential part of every engineering project; while a plethora of contractual
arrangements exist there are relationships without contract and rights and obligations imposed
by the law. It is essential that engineering professionals understand the principles behind tort.
However you are reminded of the statement in the introduction: Engineering projects operate
within legal frameworks and jurisdictions; this module describes the legal frameworks under
generic headings and also provides some analysis of the jurisdiction in England and Wales.
Many countries share similarities with law of England and Wales, but many do not. It may
be that the country in which you have an interest or are studying has a different legal system
or that a particular area of the law is different; you should always consider the effect of
jurisdiction.
This section provides an analysis of the way in which the law of tort imposes rights and
obligations; the major tort for engineering is negligence which requires that a duty of care
exists; that the duty is breached and that damage is caused. A further tort of nuisance is
outlined,
34
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
To consider the law of tort and its relevance to engineering projects and engineering
professionals.
Within the overall aim the following measurable objectives are set
The student will be able to:
Describe the development of the law of tort;
Explain the essential requirements for a claim of negligence
o a duty of care;
o a breach of that duty;
o the breach must be the cause of the loss claimed;
o the loss must be foreseeable, i.e. not too remote;
o there must an actual loss or damage;
o the absence of any of the recognised defences.
Explain the tort of nuisance
35
The Law Of Tort
The law of tort imposes rights and obligations on individuals (and corporate entities) towards
fellow individuals and entities, which arise independently of any contract between them.
Those obligations arise as a matter of civil law, either by statute or (in most cases, including
negligence) as a result of the "common law" which evolves from judicial decisions.
Tort law covers a wide spectrum of wrongs including trespass, assault, libel and statutory
torts. Some of these civil wrongs are also criminal offences. However there are a number of
essential differences between a criminal and a civil wrong. In the case of a criminal wrong,
the obligations are said to be owed to the state at large. Any proceedings in respect of the
wrong are generally brought by the state. The sanction in respect of the criminal offence
(which usually has to be proved "beyond reasonable doubt") is punishment in the form of a
criminal sentence (although sometimes the court will also make an order that the criminal pay
compensation to the victim). In the case of a civil wrong, it is the party who has been wronged
who brings proceedings against the "tortfeasor" -in the civil courts. The burden of proof is a
lesser standard of "the balance of probabilities". Usually the wronged party claims damages
for compensation in respect of the loss caused by the wrong. In order to succeed, the wronged
party must prove that the tortfeasor owed him or her a particular "tortious" duty or obligation,
and that this was breached.
This section focuses on the most important of these "torts", at least so far so the engineering
industry is concerned.
These are:
negligence;
nuisance;
In the engineering law context, a contractual relationship will often exist between the party
guilty of the "wrong" and the other (wronged) party. If so, there will often be "concurrent" or
co-existing duties owed by one party to the other in tort and contract. It is where there is no
contract that tort plays a central role.
Negligence
By far the most important tort is that of "negligence". This is a common law based tort. Until
1932, a single tort of negligence did not exist. Liability for negligent conduct was recognised
only in discrete categories where particular circumstances were said to give rise to a "duty of
care". In a landmark decision which is now well known even to most laymen, Donoghue v
Stevenson 1932 AC 562 the famous snail in the gingerbeer, the House of Lords sought to
unify these duties into a single theory of negligence.
It is an essential feature of the law of negligence that liability does not arise for the
consequences of every careless act or omission. The law sets out various requirements which
must be met in order for a claim of negligence to succeed. These are, in summary, as follows:
the defendant must owe the claimant a duty of care;
the defendant must be in breach of that duty;
this breach must be the cause of the loss of which the claimant complains;
36
the claimant's alleged loss must be foreseeable, i.e. not too remote;
the claimant must actually suffer loss or damage;
the defendant must not be able to raise any of the recognised defences.
Duty of Care
There is no single test for establishing whether a duty of care exists. In each case it is
necessary to look at the case law in order to decide whether a particular situation or
relationship gives rise to a duty of care. However, the courts have laid down a number of
principles which provide some guidance in determining whether a duty of care exists.
The starting point is the neighbour principle laid down by Lord Atkins in Donoghue v
Stevenson in the following passage:
"The rule that you are to love your neighbour becomes in law. you must not injure
your neighbour; and the lawyer's question, who is my neighbour? receives a restricted
reply. You must take reasonable care to avoid acts or omissions which you can
reasonably foresee would be likely to injure your neighbour. Who then in law is my
neighbour? The answer seems to be -persons who are so dosely and directly affected
by my act that I ought reasonably to have them in contemplation as being so affected
when I am directing my mind to the acts or omissions which are called in question."
In other words. a duty of care (not to cause personal injury to others) is owed to persons who
you ought to foresee might be injured by your particular acts or omissions. It is as a result of
this passage that "reasonable foreseeability" became known as the touchstone of liability in
negligence. In a later case the House of Lords did attempt to lay down a simple two-stage test
for the existence of all liability in negligence. In Anns v Merton London Borough Council
1978 AC728, Lord Wilberforce said:
"...the question has to be approached in two stages. First one has to ask whether. as
between the alleged wrongdoer and the person who has suffered damage there is
sufficient relationship of proximity or neighbourhood such that. in the reasonable
contemplation of the former. carelessness on his part may be likely to cause damage
to the latter- in which case a prima facie duty of care arises. Secondly, if the first
question is answered affirmatively. it is necessary to consider whether there are any
considerations which ought to negative. or to reduce or limit the scope of the duty or
the class of person to whom it is owed or the damages to which a breach of it may give
rise".
This test essentially amounts to a presumption of liability where the defendant ought to have
foreseen injury to the claimant, unless public policy dictates otherwise. This proposition was
said to have "provided not only a definitive test whether or not a duty of care arose but a
panacea to the various dilemmas of previous years”. It also led to a great increase in the
number successful negligence cases before the court in the years following the decision.
More recently the courts have retreated from this approach. In the case of Murphy v
Brentwood District Council 1991 AC 398, the House of Lords overturned Anns in so far as it
applied to local authority duties. Lord Keith in Murphy expressed the view that Lord
Wilberforce's test should not be treated as being definitive, and emphasised the importance of
finding a relationship of "proximity" .
37
This trend culminated in the formulation of a "three-stage test for establishing a duty of care
in the case of Caparo Industries pIc v Dickman 1990 2AC 605, as follows:
What emerges is that, in addition to the foreseeability of damage, necessary
ingredients in any situation giving rise to a duty of care are that there should exist
between the party owing the duty and the party to whom it is owed a relationship
characterised by the law as one of 'proximity' or 'neighbourhood' and that the
situation should be one in which the court considers it fair, just and reasonable that
the law should impose a duty of a given scope on the one party for the benefit of the
other.
The three stage test is therefore: foreseeability of damage; proximity; and fair, just and
reasonable.
However, such concepts should not be treated as a formula, and are no more than labels under
which the court examines the policy considerations of imposing or refusing liability in a given
case. By policy considerations, we mean considerations of the effect of imposing a duty of
care not just on the parties in question but on all other members of society in the same
position as these parties.
Such policy considerations have particularly exercised the courts in relation to what has
become known as "pure economic loss", or financial loss, as opposed to personal injury losses
or property damage -in respect of which the courts have always been very ready to find the
existence of a duty of care. With pure economic loss, the courts have adopted a more
restrictive approach to ensure that members and groups of society are not flooded with
substantial claims for loss of profits by others ("the floodgates" consideration). Pure economic
loss is discussed in more detail below.
The Defendant Must Be In Breach Of That Duty
The question here is whether the defendant has fallen below the standard of care required in
the circumstances and has thus been negligent. The standard of care is a question of law, but
whether or not that standard has been attained in the particular case is a question of fact for
the judge to decide, having regard to all the circumstances of the case.
In general, the amount of care required by the law is an objective standard and is measured by
the conduct of the notional reasonable man, or the man on the Clapham omnibus. Negligence
is the omission to do something which a reasonable man, guided upon those considerations
which ordinarily regulate the conduct of human affairs, would do: or doing something which
a prudent and reasonable man would not do.
If a defendant holds himself out as possessing a special skill over and above that of reasonable
people, he or she will be judged by the degree of skill normally shown by those with that
special skill.
The standard relates to the type of activity in which the defendant is engaged rather than to the
category to which the defendant belongs, and the law does not take account of the personal
characteristics of the defendant. This gives priority to the reasonable expectations of the
claimant over those of the defendant.
38
However, the standard may be modified by:
the special circumstances of the case, for example, the fact that the defendant is acting
in an emergency situation;
the categorisation of the activity -where work is to be done which requires special
skill, the standard of care required is the degree of care normally shown by a specialist
in that kind of work;
the particular class of society to which the defendant belongs -a child will be judged
by the objective standard expected of a child of that age and not by the standard of an
adult.
The court also undertakes some cost and benefit analysis and takes into account the following
matters:
Magnitude of the Risk
The greater the risk, the more care should be taken.
Likelihood of Injury
This is matter to be taken into account in determining the degree of duty required: People
must guard against reasonable probabilities but they are not bound to guard against fantastic
possibilities. This is to be judged by reference to the state of knowledge that could be
attributed to the defendant at the time of the occurrence.
Gravity of the Consequences
The graver the consequences will be of a failure to take care, the greater the degree of care
which must be taken.
Cost and Practicability of Overcoming Risk
In every case of foreseeable risk, it is a matter of balancing the risk against the measures
necessary to eliminate it.
In Overseas Tankship (UK) Ltd v The Miller Steamship Go Pty (The Wagon Mound (No 2)
1961 AC 388: ...a reasonable man would only neglect a [small] risk if he had some valid
reason for doing so, e.g. that it would involve considerable expense to eliminate the risk. He
would weigh the risk against the difficulty of eliminating.
However, the cost of eliminating the risk does not necessarily allow the defendant Ito
dispense with remedial measures: A slight risk may be run if the cost of remedying it is
unreasonably and disproportionately high, but the greater the risk, before remedial measures
can be dispensed with, the greater must be the cost of remedying it.
Common practice by persons habitually engaged in a particular operation is strong evidence
of what is reasonable care in the performance of that operation. Where there is debate as to
the proper practice, it will generally be sufficient for the defendant to show that he acted in
39
accordance with the way that a responsible body of those in his field would regard as
reasonable.
The Breach Must Be The Cause Of The Loss Of Which The Claimant Complains
The question is whether the defendant's act is recognised in law as having caused the
claimant's loss.
In determining this, the first stage is to apply what is usually known as the "but-for" test: if,
"but for" the defendant's negligence, the claimant would not have suffered the loss, causation
is prima facie (that is, on the face of it, or presumptively) established. This is illustrated by the
case of Bamett v Chelsea and Kensington Hospital Management 169 1QB 428. The claimant's
husband felt very ill after drinking some tea and had gone to a casualty department. The duty
doctor refused to see him and Mr Bamett subsequently died from arsenic poisoning. It was
held that the doctor's negligent refusal to see him did not cause his death even if the doctor
had seen Mr Bamett it would have been too late to effectively treat him and he would have
died in any event.
The but for test does not work where more than one set of conditions combines to bring about
a result -so called cases of "multiple causation". Where a tort was sufficient in its own right to
bring about the result, but there was an additional event which would also have been
sufficient to produce the result, the application of the but-for test produces the absurd result
that neither event caused the loss. In the case of Performance Cars v Abraham 1962 1 QB 33,
the claimant's car was damaged first in a collision caused by the negligence of the first
defendant (D1) and a few days later in a collision caused by the negligent driving of the
second defendant (D2). Each collision on its own would have necessitated a re-spray of the
car. In an action for negligence for the cost of the re-spray against D1, the Court of Appeal
held that D2 was not liable on the grounds that he had not caused the loss -the need for the re-
spray arose from the first collision and this pre-empted the second.
In Baker v Willoughby 1970 AC 469, the claimant was first run down by the defendant's
negligent driving, and then shot in the same leg during a burglary attempt, and the leg had to
be amputated. The House of Lords rejected the argument that the defendant should only be
liable for the loss suffered prior to the second incident -the first injury was still a cause of the
injury and therefore was not obliterated by the shooting.
The Claimant's Alleged Loss Must Be Foreseeable, i.e. Not Too Remote
Foreseeability of damage is relevant in deciding whether a duty of care exists and is also
relevant in deciding whether the damage suffered by the plaintiff is of a sort that the law will
recognise and give its protection to.
In order to recover, the plaintiff must show that the injury he or she has suffered was a
reasonably foreseeable consequence of the defendant's negligence. This is a question of law.
It is not necessary to show that the manner in which the injury was caused was foreseeable,
nor that the extent of the damage was foreseeable, only that the type of damage was. This has
sometimes led to the court making fine distinctions between the type and extent of loss in
order to compensate a "deserving” claimant.
40
The "thin skull” rule is an exception to the general rule of foreseeability and provides that the
defendant takes the claimant as he finds him. If the claimant suffers a foreseeable injury as a
result of the defendant's negligence, and this triggers an unexpectedly serious reaction
because of some pre-existing susceptibility of the claimant, the defendant is liable for this
notwithstanding the fact that the consequence was unforeseeable. For example, in Smith v
Leech Brain & Co 1962 2 QB 405, the defendant was held liable for the death of the
claimant's husband when a negligently inflicted burn on his lip resulted in his death from
cancer, because he was suffering from a pre-malignant cancer which was caused to develop
by the burn. This rule is sometimes treated as an aspect of the rule that only type and not
extent of damage need be foreseeable, but it is probably better to treat the rules separately.
The defendant is liable if he could reasonably foresee the likelihood of loss as a possibility.
The Claimant Must Actually Suffer Loss Or Damage
The principal purpose of an award of damages in tort is to put the claimant, as far as possible,
in the position he would have been in had the tort not been committed. In other words, the
overriding principle of the law of damages is that the claimant should be fully compensated
for the loss he or she has suffered.
Occasionally, the courts award damages which go beyond that which is required to
compensate the claimant; for example where the defendant has acted in deliberate breach of
his duties on the basis that this will involve him making a profit which is greater than a
compensatory measure of damages ("exemplary damages"). Such awards are relatively rare.
Conversely, where the claimant has suffered no actual loss but has had his legal rights
infringed, a court may award nominal damages in recognition of the infringement.
An example of recoverable non-pecuniary loss is pain and suffering caused by a personal
injury, but damages for disappointment and distress are not normally recoverable in either
contract or tort. However, where a claimant suffers anxiety and mental distress which is
directly consequent on physical inconvenience caused by having to live in a house whilst
disruptive repairs are carried out, or having to move out whilst such repairs are undertaken,
damages may be recoverable - although any such claim is likely to be small, say, in the region
of £750, depending on the gravity.
Defences
The recognised defences to a negligence action include:
voluntary assumption of risk;
contributory negligence;
exclusions of liability;
limitation of actions.
The first, where it applies, is a complete defence, in that it extinguishes any liability of the
party in default. Contributory negligence, on the other hand, is a partial defence, since it gives
rise only to a discount on the amount of damages recoverable by the wronged party. Liability
on the part of the tortfeasor remains, albeit that the damages which he is liable to pay are
reduced by a proportion depending on the extent of the contributory negligence.
41
Voluntary Assumption Of Risk
A person may voluntarily assume the risk of harm by agreeing in advance not to sue should
the harm materialise. Such agreement may be express or implied. Express agreement usually
arises where the defendant excludes or limits his liability by means of a contractual term or
notice. In order for this defence to operate, the claimant must:
act freely and voluntarily;
have full knowledge of the risk; and
accept that he, not the defendant, undertakes responsibility for the risk.
The concept of voluntariness is given a narrow definition, and it seems that where the
claimant exposes himself to a risk in order to avert injury to him or to others, he will not be
barred from recovery. On the other hand, a claimant who has exposed himself to risk without
good reason (i.e. by agreeing to be a passenger in an aeroplane piloted by a person the
claimant knows to be drunk), will be held to have voluntarily exposed himself to the risk and
the defendant will be able to avail himself of this defence. Knowledge of the defendant's
inebriation will not necessarily be sufficient for a claim of voi/enti non fit injuria to succeed,
but knowledge that the defendant is so drunk as to be unable to attempt to exercise care will
be.
Contributory Negligence
Under the Law Reform (Contributory Negligence ) Act 1945, the court has the power, under
section 1(1), to reduce an award of damages to "such an extent as the court thinks just and
equitable, having regard to the claimant's share in the responsibility for the damage". Under
the Act, a claimant cannot be 100% contributory negligent. If it is found that the sole cause of
the claimant's injury is his own fault, causation is not established and therefore no action in
negligence is made out.
The question is not one of whether the claimant owed the defendant a duty of care, but of
whether the claimant has taken due care for his own safety. This is assessed objectively, and
the same factors as apply in considering whether the defendant owes a duty of care are
applied. It is important to realise that contributory negligence will operate where the claimant
contributes to his own injury -even where the defendant is solely responsible for the incident
which gives rise to such injury.
There must be a causal link between the claimant's conduct and the harm suffered, and the
question of causation is dealt with in the same way as in the context of assessing liability for
negligence on the part of the defendant.
Exclusion Of Liability
At common law, in order to exclude or limit liability for negligence, a defendant could enter
into an express contract with the claimant excluding or limiting liability for negligence, or
give the claimant sufficient notice that the claimant entered onto his land subject to his
agreeing to exempt the defendant from any liability in respect of his occupation of the land, or
issue a disclaimer making it clear that he undertook no responsibility for information or
advice offered to the claimant.
42
The Unfair Contract Terms Act 1977 ("UCTA") greatly restricts the defendant's ability to opt
out of liability in all three cases.
In general, a third party cannot rely on an exclusion clause which would be operative as
between the parties to a contract. There is no doctrine of "vicarious immunity" in English law,
in other words, an exclusion clause contained within a contract cannot assist an employee or
agent who acts under the contract.
Limitation
The Limitation Period is the period of time within which a claimant must bring his or her
action (which is normally done by issuing a claim form under Part 7 of the Civil Procedure
Rules 1998, or by giving notice of reference of a dispute of arbitration).
The relevant periods are largely contained in the Limitation Act 1980. The limitation period
for most torts, including negligence, is six years. Where a claim is for damages for personal
injury, however, the period is three years. In contract, the limitation period is six years.
The period of limitation begins when the cause of action accrues. In tort, where the tort is only
actionable upon proof of damage, the cause of action accrues when damage occurs. In
contrast, in contractual actions, the cause of action occurs from the date of breach of contract.
In tort claims, it may be difficult to ascertain when the damage occurred. For example, where
a building has been constructed defectively, it may be thought that damage occurs when the
defect manifests itself in a manner that can be reasonably discovered. However, in Pirelli
General Cable Works v Oscar Faber and Partners 1983 2 AC 1 the House of Lords held that
the cause of action for negligent advice in relation to the design of a building, was held to
accrue when cracks first appeared in the chimney, as opposed to when the damage was
actually reasonably discoverable. This is to some extent altered by the Latent Damage Act
1986, which inserted section 14A into the Limitation Act. Section 14A provides that, in
actions for negligence, the limitation period is either six years from the accrual of the action,
or three years from when the claimant had (or is deemed to have had) knowledge of certain
material facts ("date of knowledge"). Essentially, the date of knowledge is the date when the
claimant knew or ought to have known:
that the relevant damage was sufficiently serious to justify proceedings;
that the damage was attributable in whole or in part to the act or omission which is
said to constitute negligence; and
the identity of the defendant.
As stated above, the limitation period for personal injury actions is three years. However, an
alternative period is provided by section 14 of the Limitation Act 1980, which provides that
time starts running when the claimant has actual or "constructive" knowledge (the latter being
when the claimant ought to have known) of the following facts:
that the injury in question was significant;
that the injury was attributable in whole or in part to the act or omission which is said
to constitute negligence, nuisance or breach of duty;
the identity of the defendant.
43
The court also has discretion to allow an action to proceed notwithstanding the expiry of the
limitation period under section 33, if it considers it equitable to do so.
Where a person to whom aright accrues is, at the date of accrual, under a disability, i.e. an
infant or of unsound mind, the action may be brought within the applicable period starting
from the date at which the disability ceases, or when he dies - whichever is the sooner.
The Restrictive Approach Of The Courts To Recovery For Pure Economic Loss
Pure economic loss is loss which does not directly flow from damage to the plaintiff's own
person or to the claimant's own other property. In general, economic loss is not recoverable in
an action for negligence, at least not as readily recoverable as personal injury or property
damage losses.
The most straightforward application of the rule concerns the situation where the defendant's
alleged negligence causes damage to property which does not belong to the claimant, but
which, because of an interest he has in that property, causes him loss. For example, where the
defendant negligently cuts through an electric cable which does not belong to the claimant,
but which the claimant uses in order to run his metal processing plant, the claimant will not be
able to claim for the lost profits caused by closing his business for the day, but will be able to
claim for damage caused to the metal being processed at the time the electricity was cut off,
as this is economic loss stemming directly from damage to the claimant's property.
A slightly more difficult example of the rule concerns defective products and buildings. The
courts have held that, where a product/building is defective, and the only loss occasioned is
the cost of repairing/replacing that property when the defect is discovered, this is
irrecoverable pure economic loss. The manufacturer, builder or designer of the product or
building will not be liable unless the defect causes damage to other property, or personal
injury. This rule was applied in Murphy v Brentwood District Council 1991 1 AC 398, in
which the claimant suffered loss because the foundations of his house were defective, causing
subsidence and cracking. It was held that the loss on the subsequent sale of the house was not
recoverable since it was occasioned by a defective product (the building itself) and not by
damage to other property or personal injury.
The courts are reluctant to allow recovery for pure economic loss, largely, it seems, because:
"the links between negligence and pure economic loss are primarily human in creation and
can form a complex web through which economic loss can ripple out from the one negligent
act. Establishing foreseeability of loss, and, more particularly, proximity or relationship, in
such a context is afar more difficult task [than in cases of physical damage]".
The law has developed in a slightly haphazard way, with the court developing differing rules
depending on how the loss was caused. In particular, a line has been drawn hitherto between
loss caused by negligent statements, and loss caused by negligent services.
It seems that the following general principles governing a claim for pure economic loss may
be derived from the case law. A claim may succeed:
where the claimant person is in a direct contractual or quasi contractual relationship
with the defendant;
44
where the defendant has made a negligent statement to or for the benefit of a person
that it knows may rely on the statement to their detriment and where that person does
place reliance on the defendant's statement and suffers loss;
where the defendant is or should be aware that the service it is providing is for the
direct benefit of a third party who is likely to suffer economic loss if the service is not
performed properly.
Nuisance
The law of nuisance is concerned with conflicting rights and interests over land. An action in
nuisance in the building context is most likely to occur in relation to the noise, dust and debris
created by building work.
This section will deal with:
the difference between material injury and personal discomfort;
the type of interference actionable;
who can sue;
the relevance of motive;
the relevance of the public interest;
the relevance of planning permission;
general points.
The Difference Between Material Injury and Personal Discomfort
In St Helen's Smelting Co v Tipping 1865 1 HL 642 vapours from the defendant's smelting
works damaged trees and shrubs on the plaintiff's land. The defendant argued that since
almost the whole neighbourhood was devoted to copper smelting or similar, there should be
no finding against them. It was held that there was a difference between "material injury to
property" and "sensible personal discomfort" .Lord Westbury LC said:
If a man lives in a street where there are numerous shops, and a shop is opened next
door to him, which is carried on in a fair and reasonable way, he has no ground for
complaint because to him individually there may arise much discomfort from the trade
carried out in that shop. But when an occupation is carried on by one person in the
neighbourhood of another, and the result of that trade...is a material injury to
property then there unquestionably arises a very different consideration.
In other words, locality is only relevant where the injury suffered is physical.
Type Of Interference Actionable
An important recent decision in this area is that of the House of Lords, in Hunter v Canary
Wharf 1 All ER 482, in which several local residents complained that the erection of canary
wharf interfered with their television reception. The Law Lords held that interference with
television reception was, in principle, actionable, but that it wasn't in this case. The general
approach was that more than the mere presence of a building was necessary. However care is
required when assuming that the presence of a building can never found an action in nuisance.
In a New Zealand case, Bank of New Zealand v Greenwood [1984] 1 NZLR 525, the
reflection of sunlight from a glass building dazzled the plaintiffs living in neighbouring
45
buildings and was held to be an actionable nuisance. The House of Lords, in Canary Wharf,
held that this was correct on its facts, but was an unusual case, since the sunlight was not
merely reflected, but deflected in such way as to cause dazzling glare to shine directly into
neighbouring building. The building was not, therefore, merely "in the way".
Who Can Sue?
In order to bring an action in nuisance, the claimant must have an interest in land. The exact
nature of the interest in land required is unclear, but it seems that the claimant needs exclusive
possession, or must be the owner or have a reversionary interest in the land.
Motive
The defendant's motivation for acting as he did is relevant to the question of whether his or
her actions constitute actionable nuisance. In Christie v Dave 1893 1 Ch316, the defendant
was disturbed by the plaintiff's musical activities occurring in the adjoining house,
particularly the singing (which it was claimed was hard to distinguish from the howling of a
dog). The defendant wrote to the plaintiff but his complaints were ignored. He took to
banging on the wall, beating on trays and whistling whenever he heard music from next door.
It was held that this constituted nuisance on the basis that the defendant had acted maliciously
for the purpose of annoying the plaintiff.
In Hollywood Silver Fox v Emmet 1936 2 KB 468t, the defendant threatened to fire his gun
during the fox breeding season -saying "I guarantee you will not raise a single cub" if the farm
continued to advertise its breeding activities which the defendant feared would put off
potential purchasers of his land. The farm continued to advertise the breeding and the
defendant carried out his threat with the result that all the vixens ate their cubs and others did
not mate. It was held that the defendant's malice made the disturbance actionable as a
nuisance. Motive is only irrelevant if the defendant has an absolute right to do what he did, for
example, to abstract water percolating under his land.
Relevance Of The Public Interest
Although the issue is unclear, it appears that it is now decided that the public interest is
irrelevant in the decision of whether something is actionable as a nuisance, but it may be
relevant to the question of whether an injunction is granted in the claimant's favour to prevent
the defendant from acting in the manner said to constitute a nuisance, or whether the claimant
is awarded damages instead.
In Miller v Jackson 1977QB 960 , the Claimant complained that on a number or occasions
cricket balls from the adjacent ground had landed in their garden, causing some property
damage. Lord Denning thought the private interest in the privacy of home and garden should
not be subordinated to the public interest in cricket, but in any event he thought no nuisance
had been committed, because there was no unreasonable use of land. The judge thought that
although there was a nuisance, on the facts the inhabitants of the village's enjoyment should
be given priority, and said that the plaintiffs must or ought to have realised the possibility of
cricket balls coming into the garden before they bought the house. The latter factor, often
referred to as "coming to the nuisance", was relevant to the issue of whether an injunction
should be granted, but not to whether there was a nuisance at all.
Planning Permission
46
In Wheeler v JJ Saunders Ltd 1995 3 WLR 460, the plaintiffs bought a house and
outbuildings, having obtained planning permission to convert the outbuildings into holiday
cottages. An adjacent farm (not owned by plaintiff) was let to the first defendants, who
obtained planning permission to build houses for pig breeding, one of which was only 11
metres from the house. An issue arose re access and rights of way and about nuisance and the
defendants argued that since they obtained planning permission for the pig houses, any smell
from the pigs in them could not amount to nuisance. The Court of Appeal concurred with the
view of Cummings-Bruce LJ in Allen v Gulf Oil Refinery 1981 AC 1001 who said: "the
planning authority has no jurisdiction to authorise a nuisance save (if at all) in so far as it had
statutory power to permit the change of the character of the neighbourhood".
It was further held that planning permission and subsequent change of neighbourhood was
only relevant in so far as the nuisance flowed inevitably from the authorised planning
permission.
General Points
A defendant who does not himself create the nuisance, will be liable if he knows or ought to
know of its existence and has allowed it to continue. Nuisance is not actionable without proof
of damage.
An action in nuisance in the building context is most likely to occur in relation to the noise,
dust and debris created by building work.
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises can I:
2) Explain the law of tort and its relevance to engineering projects and engineering
professionals.
3) Describe the development of the law of tort;
4) Explain the essential requirements for a claim of negligence
a) a duty of care;
b) a breach of that duty;
c) the breach must be the cause of the loss claimed;
d) the loss must be foreseeable, i.e. not too remote;
e) there must an actual loss or damage;
f) the absence of any of the recognised defences.
5) Explain the tort of nuisance
47
4. Standard Forms of Contract
This section deals with an introduction to the standard forms of contract available for
engineering projects. You are asked to do several things: complete the Blackboard section
[including brief exercises]; read the workbook; read some material from the book which
supports this section and visit some websites.
There is much material in the textbook which supports this section:
Uff, J. Construction Law,
You should read Chapters 11, 12 and 13 of the textbook in conjunction with this section.
Standard forms of contract are a feature of commercial life; they are the standardised terms
and conditions which businesspeople use instead of drafting a bespoke contract each and
every time a contract between parties is required.
This section considers the concepts of standard forms and the next section considers: The Key
Areas of Standard Forms and the Role of Management in Standard Forms
This section considers what constitutes a standard form; why standard forms are used; the
problems with standard forms; the content of standard forms. This lays the foundation for the
next section which discusses the use of standard forms via key areas. The areas are:
Site Possession
Commencement
Progress
Completion
Variations
Extension of time
Programming
Liquidated and Ascertained Damages
Finally the next section considers the role of management and contract administration; via the
Engineering and Construction Contract.
48
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
The section aim is:
To examine the application and use of standard forms of contract on engineering
projects.
Within the overall aim the following measurable objectives are set
The student will be able to:
Explain the need for standard forms;
Discuss what constitutes a standard form;
Explain why standard forms are used;
Understand the problems with standard forms;
Describe the content of standard forms
49
4.1. The Concepts of Standard Forms
This part introduces the concepts of standard forms and the reasons for their development and
use.
Introduction
Standard forms of contract does not mean the standard terms and conditions of a particular
party which are tailored to suit but rather the standardised terms and conditions which
businesspeople in particular commercial fields use instead of, or sometimes in conjunction
with, their own special terms and conditions. Standard forms are widespread in engineering;
indeed, there are so many available that it might be argued that they are not standard; printed
might be a better term.
The use of a standardised form is not unique to the engineering industry, although the industry
has a good deal more variety and sophistication than other commercial sectors due to:
the complexity of the contractual chains set up in the industry
the diverse needs of a particular type of project
the industry’s readiness to use standard forms.
In the construction industry there are long established standard forms to govern relationships
between employers and contractors with regard to building and civil engineering works. In
particular in contracts with local authorities governments and government bodies. There are
also standard forms of contract to govern relationships between contractors and sub-
contractors. These documents are the product of the applied expertise of all sectors of the
construction industry, working through bodies such as, in the UK, Joint Contracts Tribunal
(“JCT”) or the Institution of Civil Engineers (“ICE”). As well as traditional standard forms,
there are new forms e.g. the Engineering and Construction Contract (ECC) as a suitable all-
purpose standard form. Different standard forms continue to be published in successive
editions by a variety of professional bodies and organisations.
The parties to a contract do not have to use standard forms and they are free to contract on
whatever terms they agree. Frequently, parties amend the standard forms to suit their own
particular needs or to allocate risk in respect of particular circumstances. Sometimes an
attempt is made by a party to have the best bits of a standard form but leave out the rest and to
use that in conjunction with its own usual written terms of business. The results are not
always successful.
Why Standard Forms are used
There are a number of benefits to using a standard form. Standard forms avoid the need to
“reinvent the wheel” every time a contract is drawn up, and also saves the cost of lawyers or
contract drafters.
Standard forms are usually a response to widespread practice in the construction industry as to
how things are and should be done. By using a standard form the parties know the package of
obligations that they are using are common and familiar not just to themselves but to the other
party and affords confidence to the parties that the project will be run in a way they are used
50
to. By using standard forms general rules and principles become generally transparent.
Speed and timing play their part. Projects are run to tight timetables and budgets. Instead of
drafting out conditions wasting valuable time and money, the parties can be getting on with
the job. Standard forms of contract are partly used by way of shorthand so that parties can
progress with the job as soon as possible without having to set out the contract in a formalised
way.
A particular benefit is the provision of detailed and sophisticated contractual machinery
permitting the project to be an evolving process: things crop up during progress which require
some flexibility yet sufficient certainty. The contractual machinery makes the contract a
dynamic and practical agreement rather than a historical and rigid document.
Some problems with using Standard Forms
Standard forms are frequently amended by standardised updating of certain clauses or whole
new editions which may (or may not) change the obligations of the parties without them
realising. It cannot be assumed that the previous edition with which a party is familiar is the
same as the newer edition or vice versa. Parties are wise to brush up on the terms of the forms
actually being used on a particular contract from time to time.
Though the standard forms are generally transparent, they are far from perfect models: there
are inconsistencies and ambiguities that only become apparent when tested by an event which
causes a problem. This is a problem which is inherent in any attempt to make a contract where
“one size fits all”. Contract terms do not receive sufficient attention from parties to see
whether it suits their needs and it is only when a problem arises that they dust off the contract
documents.
Adapting a standard form for personal use has great potential for things to go wrong. The
terms of the contract are supposed to mesh together and the contract is to be construed as a
whole. Simply removing clauses (or parts of clauses) which a party does not like, or replacing
them with something alien, is likely to have a knock-on effect on other provisions in the
contract. Usually only when things go wrong that the party realises the full effect of the
adaptations made.
It is all too easy for a party using a standard form to adopt a commercial approach which may
be more practical and lax than the contract actually permits and if this is experience generally,
soon the principles of the standard form become replaced with general notions of “how I’ve
always worked on a project like this”. There is a danger that there is a gulf between what the
contract says and what the parties do and the perception that the contractual issues are left to
the lawyers at a later date.
There is, of course, an obvious tension between working on a project with a legalistic
approach with reference to the contract and the commercial practicalities of getting on with
the job at hand with co-operation from all parties and without unnecessary provocation.
The Main Standard Forms
In the UK the documents are the product of the applied expertise of certain sectors of the
construction industry, working through bodies such as the Joint Contracts Tribunal ("JCT”) or
51
of particular bodies such as the Institute of Civil Engineers ("ICE"), the Royal Institute of
British Architects ("RIBA") and the Association of Consulting Engineers ("ACE"). A simple
divide used to be that the JCT produced the forms for the building sector and the ICE for the
civil engineering sector. This has been eroded by the Engineering and Construction Contract
which is discussed later.
The forms establish common ground rules that assist contractors and consultants in preparing
their prices/fees and assist architects/engineers in monitoring performance of the works.
The JCT Standard Form
The first building contracts which were produced for general use appeared in 1909. A later
edition appeared in 1931. These forms stated that they had been prepared by a committee of
the RIBA with assistance from the RIBA's legal advisors. There are many provisions in the
present forms, which can be seen historically to have been derived from these earlier forms.
Responsibility passed from the exclusive hands of the RIBA to the JCT when it was formed in
the 1930s. JCT is not a tribunal but a standing committee, consisting of representatives of
the:
Royal Institute of British Architects;
Building Employers Confederation;
Royal Institution of Chartered Surveyors;
Association of County Councils;
Association of Metropolitan Authorities;
Association of District Councils;
Confederation of Associations of Specialist Engineering Contractors;
Federation of Associations of Specialists and Sub-Contractors;
Association of Consulting Engineers;
British Property Federation and the Scottish Building Contract Committee.
The first JCT form in 1939 has been replaced by further editions in 1963, 1980 and 1998 and
further forms have been provided for use in different procurement methods, e.g. the standard
form with contractor's design in 1981 (for design and build) and the standard form of
management and works contracts in 1987 (for management contracting).
Forms for use in so-called Minor Works (suitable for works of a relatively simple nature,
where no architect is engaged and the value is below a certain financial threshold) and a so-
called Intermediate Form of Contract (suitable for works of a slightly more complex nature,
with an architect supervising the design and again recommended for a certain value of work)
were published in 1980 and 1984 respectively. In 1987, the JCT produced a standard form of
management contract. In 1989 the JCT produced a standard form for term maintenance work.
In 1967 the JCT produced a form for cost-plus work, the Prime Cost standard form. All these
standard forms were updated by standard amendments issued by the JCT.
Content Of Standard Forms
In the UK, most standard forms comprise the following:
a set of articles of agreement for execution by the parties, incorporating all other
contract documents by reference;
52
a set of conditions of contract;
one or more appendices requiring insertion of particulars relevant to the parties, the
works and the contract sum.
Key Features of a Construction Contract
The key considerations in any construction contract will be the cost of the works, the quality
of the works and the time within which the works can be completed. Added to these will be
the need for flexibility, allowing the employer to change the brief in relation to the works
without unduly affecting their cost or quality or the time required for their completion.
One of the key features which distinguishes construction contracts from other forms of
commercial agreement is the facility for the employer to vary the works or for changes to
occur due to circumstances arising during execution of the works. The complex mechanisms
laid down to govern these matters under the majority of the standard forms are valuable
protections to the employer as well as the contractor insofar as they permit variations that
would otherwise be beyond the scope of the contract and limit the grounds upon which the
contractor may claim additional time and cost.
An understanding of construction contracts requires close attention to the mechanisms for
changes in the works, for the extension of time allowed for their completion and for variation
of the contract sum. Relevant considerations will include not only the substance of each
party's rights and obligations but also the formalities that must be observed in order for the
contractual mechanisms to take effect as intended. The standard forms address these issues in
different ways, in some instances illustrating a contrast between the nature of building works
and civil engineering works and in others simply reflecting different traditions that have been
established in different sectors of the construction industry.
Self-Appraisal Questions
Am I able to demonstrate that I can now meet the objectives set out at the start of this section
1) Examine the application and use of standard forms of contract on engineering projects.
Looking at my responses to the exercises, can I:
2) Explain the need for standard forms;
3) Discuss what constitutes a standard form;
4) Explain why standard forms are used;
5) Understand the problems with standard forms;
6) Describe the content of standard forms
53
5. The Key Areas Of Standard Forms
This part discusses the use of standard forms via key areas. The areas are:
Site Possession
Commencement
Progress
Completion
Variations
Extension of time
Programming
Liquidated and Ascertained Damages
54
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
The section aim is:
To examine the key areas of standard contract on engineering projects.
Within the overall aim the following measurable objectives are set
The student will be able to:
Describe the procedures and practice in standard forms in the areas of:
o Site Possession;
o Commencement;
o Progress;
o Completion;
o Variation;
o Extension of time;
o Programming;
o Liquidated and Ascertained Damages.
Discuss the relationship between management and standard forms using the example
of the Engineering and Engineering Contract
Discuss the development of the Engineering and Construction Contract;
Evaluate the link between standard forms of contract and the management of
construction projects;
Describe how the Engineering and Construction Contract improves process and
procedure in the areas of:
Flexibility;
Clarity and Simplicity
Stimulus to Good Management
Site Possession
For any proposed construction, building or civil engineering, the employer will need to make
available a site upon or within which those works are to be undertaken. This site need not be
owned by the employer, and often is not, but the employer should be in a position to make the
site freely available to the contractor in accordance with the terms of the construction
contract. Failure to give possession of the site affects not only the time agreed for completion
of the works but also the cost of those works, and may even relieve the contractor of any
obligation to perform the works.
Possession of the site is a fundamental right of the contractor. In order to perform its
contractual obligations effectively, a contractor must have access to and control over the site
where the works are to be performed. An employer who fails to grant possession of the site, or
who unlawfully ejects the contractor from the site prior to completion of the works, will
repudiate the construction contract.
55
The contractor's right to possession of the site is made explicit in most standard forms (e.g.
JCT 98 Clause 23), but even in the absence of an express provision, an equivalent term will
be implied: Hounslow London Borough Council v Twickenham Garden Developments Ltd
(1971).
The contractor is regarded as having a contractual licence for the duration of the works and
interference by the employer with the contractor's possession of the site will therefore be
regarded as a denial of possession.
Access to the Site
The employer's obligation to grant possession of the site should be distinguished from any
obligation and ability to ensure that the contractor has free and uninhibited access to the site.
Although the extent of the employer's obligation to provide access will depend on the terms of
the contract, it is likely to be a limited obligation in view of the difficulty for the employer in
guaranteeing non-interference by third parties over whom the employer has no control.
Many standard forms include provisions whereby any interference by the employer in the
contractor's right of ingress to or egress from the site will entitle the contractor to claim an
extension of time for completion of the works, to claim loss and/or expense incurred by the
contractor as a result of the interference and even to terminate its employment under the
contract (see e.g. JCT 98 Clauses 25.4.12, 26.2.6 and 28.2.2.4).
Termination of Right to Possession
The contractor's right to possession of the site generally comes to an end on completion
(practical completion) of the works, subject to a subsequent right of access to enable the
contractor to perform its obligations under the contract as to rectification of defects (e.g. JCT
98 Clause 23.3.1). After completion the contractor has no right to return to site to remedy any
defects. Most contracts use the date of practical completion as the starting point for
contractual limitation clauses e.g. "No claim may be commenced in respect of any right of
action (whether in contract, tort (including negligence) or otherwise under or in connection
with this agreement after the expiration of six [or twelve if the agreement is executed as a
deed] years from the date of Practical Completion."
Provisions in certain standard forms allow the employer to take early hand over of one or
more parts of the works in advance of completion of the whole of the works, either by
agreement at the time when a particular part of the works is completed or by operation of an
agreed sequence for completion of successive sections of the works on dates specified in the
contract (e.g. JCT 98 Clause 18; JCT 98 Sectional Completion Supplement). In such cases,
one or more parts of the site upon which the relevant parts of the works are located will also
be subject to early hand over, and the contractor's right to possession of those parts of the site
will end accordingly.
Termination of Employment
In the event of termination of the contractor's employment on the project for whatever reason
prior to completion of the works, the construction contract will normally require the
contractor to vacate the site in an orderly manner, on the express or implied understanding
that such termination will bring to an end the contractor's right of possession. In certain
56
instances, a contractor disputing an employer's right to terminate may be unwilling to vacate
the site and the employer may be unable to obtain an injunction evicting the contractor from
the site until a decision has been made on the validity of the termination: Hounslow London
Borough Council v Twickenham Garden Developments Ltd [1971] Ch 233.
Commencement
Construction contracts are constrained by time; it is one of the scarce resources, this has led to
the inclusion of detailed provisions in the standard forms governing the dates by which the
employer and the contractor agree that the works must be completed and the remedies
available to the employer in the event of any delay. It is also important for both parties to
establish when the contractor should commence performance of the works, and from the
contractor's point of view to ensure that commencement of the works is not impeded in any
way, for example by the employer failing to grant possession of the site.
Some standard forms indicate a specific date for commencement of the works (e.g. JCT 98
Clause 23.1). In all cases the contractor's obligation to commence the works will be subject to
the express and implied rights governing possession of the site. If the contract is silent as to
the commencement date, then there will be an implied term that the contractor will be given
possession of the site in order to permit commencement of the works within a reasonable time
of signing the contract. What constitutes a reasonable time is a question of fact, but it must be
sufficient to enable the contractor to complete the works by the contractual completion date.
Progress of the Works
At common law the general principle is that, in the absence of other contract terms, an
obligation on the contractor to complete its works does not require the contractor to proceed at
a regular or certain pace. It is up to the contractor how to proceed, as long as completion is
achieved by the due completion date. Programming is the province of the contractor.
Such a state of affairs may not, however, be acceptable to building owners who employ
contractors. It is therefore not surprising to find in standard form building contracts express
terms governing the manner in which the contractor should proceed with the works having
been given possession of the site.
Clause 23.1 of JCT 98 provides that: “On the Date of Possession, possession of the site shall
be give to the Contractor who shall thereupon begin the works and regularly and diligently
proceed with the same and shall complete the same on or before the Completion Date."
In the case of West Faulkner Associates v London Borough of Newham (1994) 71 BLR 1 the
judge said: "Taken together, the obligation upon the contractor is essentially to proceed
continuously, industriously and efficiently with appropriate physical resources so as to
progress the works steadily towards completion substantially in accordance with the
contractual requirements as to time, sequence and quality of work..."
Completion
Common features of standard form contracts are:
57
An imposition of an absolute obligation upon the contractor to complete the contract works
within an agreed period;
Elaborate terms which deal specifically with:
The date for completion;
The circumstances in which an extension of time for the completion of the works will
be granted;
The contractual and financial consequences of failing to meet the contractually agreed
date for completion of the works.
Given that standard forms place great emphasis on the contractor's timely completion of the
works, and impose financial consequences for failing to meet the date for completion, it is
obviously important to understand how they define completion. Completion, once it is
achieved, has many consequences under the standard forms:
Some retention money is released;
The defects liability or maintenance period starts;
Liquidated and ascertained damages cannot be claimed for any period after completion;
Extensions of time cannot extend beyond completion;
The licence under which the contractor occupied the site comes to an end
The works are then at the employer's risk and the employer (unless already done so) should
insure the completed works.
Definitions of Completion
The date by which the contract works are to be completed is usually set down in the appendix
to each standard form as is the date for commencement. Sometimes (e.g. in certain sub-
contract forms) the completion obligation is expressed as a period of time from
commencement, where the date for commencement is not predetermined. More commonly,
completion and commencement dates are expressly agreed. Since late completion of the
works by the contractor may lead to incurring liquidated and ascertained damages under the
terms of the contract, or alternatively, incurring damages for breach of such a contract, it is
important for both parties to be able to ascertain when the works have actually been
completed to the standard required by the contract. The level of completion demanded by
each standard form and the mechanisms by which it is to be assessed and certified differ.
Several of the more common formulations are discussed below:
The JCT 98 Standard Form
Clause 17.1 defines the appropriate standard of completion: "When in the opinion of the
Architect/the Contract Administrator Practical Completion of the works is achieved, he shall
forthwith issue a certificate to that effect and Practical Completion of the works shall be
deemed for all purposes of this Contract to have taken place on the day named in such a
certificate."
Thus, the works are to be "Practically Complete" in the opinion of the Architect or the
Contract Administrator. There is no elaboration within the JCT 98 of what is meant by
"Practical Completion". Although the House of Lords has had two opportunities of
considering the meaning of the term in the cases of Jarvis & Sons v Westminster Corporation
[1970] 1 WLR 637 and P&M Kaye v Hosier& Dickinson [1972] 1 WLR 146, its precise
scope is still far from clear. It has been said that "Practical Completion is perhaps easier to
recognise than define" (Keating on Building Contracts 6th Edition, page 590).
58
These two cases might be summarised via:
The works cannot be practically complete whilst patent defects of any significance in
their construction are apparent;
Latent defects within the work will not prevent the valid issue of a certificate of
Practical Completion;
Minor items of "snagging" will not prevent the certification of Practical Completion;
Practical Completion is the completion of all construction work that has to be done
Practical Completion means completion for all practical purposes. Thus, without its windows
and doors, a house construction is not practically complete. Practical Completion does not
usually mean 100% completion free of all defects; this is because the contract lays down
provision for putting right defects in the defects liability period which follows Practical
Completion. Ultimately it will be a matter of fact and degree as to when works are practically
complete. If major defects which affect the practical use and occupation of the works are
apparent prior to Practical Completion, then, usually, Practical Completion cannot arise until
such defects are rectified.
The GC/Works/1 (1998) Conditions of Contract
The approach to completion in GC Works/1 (1998) is unlike that in JCT 98. The GC Works/1
forms do not define a standard of completion to be achieved by the contractor prior to
certification by the Contract Administrator. The obligation upon the contractor is merely to
complete the works, remove the rubbish at the site and deliver up the works to the satisfaction
of the Superintending Officer ("the SO"). It may well be that completion of the works under
this form of contract would be construed as meaning substantial completion. This approach is
supported by the fact that there is a post-completion period in which the contractor is required
to put right defects. On any count, the "satisfaction" of the SO is subject ultimately to review
and revision by the arbitrator.
The IFC 1998 Conditions of Contract
Like JCT 98, the Intermediate Form of Contract conditions adopt the concept of Practical
Completion but does not mention any definition. Clause 2.9 of the IFC98 states: "When in the
opinion of the Architect/Contract Administrator Practical Completion of the works is
achieved he shall forthwith issue a certificate to that effect. Practical Completion of the works
shall be deemed for all purposes of this Contract to have taken place on the day named in such
certificate."
The certification of Practical Completion under the IFC98 form fixes the date of completion
"for all purposes of this Contract".
Procedures
Some of the standard forms lay down a procedure for the Completion Certificate to be issued.
For instance, the JCT 98 conditions require the contractor to give notice, dependent upon
59
which the Architect may or may not issue the requisite certificate. If the procedure is not
followed, there may be different consequences. If the employer takes possession, in effect
completion will be considered to have occurred for the purpose of stopping the imposition of
liquidated damages. If the employer does not take possession, the arbitration clauses may be
drawn sufficiently wide to leave it to the arbitrator to determine objectively when completion
in fact occurred.
60
Variations
A construction contract should identify clearly the scope of the works which the contractor is
required to undertake. The accuracy with which the works can be described is, however,
closely linked to the extent to which the design for the works has been developed at the time
when the employer and the contractor enter into the contract. Where any significant design
detail is absent in the contract, then the contractor may not be bound to implement that design
detail unless the contract contains a right to vary the design. The contractor may be able to
claim additional time and/or payment on the basis that such design detail constitutes a
variation to the scope of the works.
The scope of the works governed by a construction contract will generally be described in
detail in Bills of Quantities, specifications and drawings, with further general references in the
standard forms. Certain standard forms oblige the contractor to undertake only the works
specifically described in the contract documents (e.g. JCT 98 Clause 14.1 ), thereby
modifying the general principle that the contractor must do everything necessary to complete
the works.
In the absence of express contract terms to the contrary, a contractor is under no implied
obligation to carry out work additional to or different from that described in the contract.
Accordingly, if the employer wishes to alter the nature or scope of the works beyond the
scope of the contract in any way, in the absence of such express terms, the contract itself must
be varied by agreement or a new contract must be entered into. The corollary of this is that, in
the absence of an express contractual mechanism, a contractor who carries out additional or
different work has no automatic entitlement to be paid for such additional or different work:
Wilmot v Smith (1828) 3 C&P 453.
So long as work falls within the description provided in the contract, it will not give rise to an
entitlement to extra payment. For example, in the case of Sharpe v San Paulo Railway
Company (1873) 8 Ch App 597, a contractor who had agreed to build a railway in Brazil for a
fixed sum was entitled to no variation and no additional payment when redesign became
necessary due to problems encountered during the course of the works.
The majority of the standard forms contain detailed provisions governing variations, without
the need for an amendment to the contract itself. Frequently the Architect is empowered, on
behalf of the employer, to order variations to the works and to evaluate an appropriate change
in the contract sum.
Additional Work which is not a Variation
Where work has been done that falls outside the scope of a contract variation clause, or where
the requirements of that clause (such as an order in writing) have not been fulfilled, the fact
that the employer has received the benefit of the work does not in itself render liability for
payment for it. However, an employer who actually wished extra or different work to be done,
and who obtained the benefit of that work, cannot then rely on the absence of a written order
to avoid payment. If it can be established that work outside the scope of a contract variation
clause should nevertheless be aid for, then in the absence of evidence as to an agreed basis for
payment the contractor will be entitled to be paid a reasonable sum, which need not
necessarily conform to the rates agreed in compiling the contract sum
61
Extensions Of Time
Standard form construction contracts oblige the contractor to complete the works by a
particular date and provide for the employer to levy liquidated and ascertained damages
against the contractor should there be a failure to complete the works within such time.
However, construction projects are a dynamic process with a high probability of change
between start and finish. For instance, the employer may vary requirements to request
something different which may take longer to procure and complete. There may be other
factors that delay or hinder the contractor from completing the works on time, e.g. fires,
floods, events of force majeure, late instructions, incomplete design information, unforeseen
ground conditions etc. Without an extension of time mechanism, the contractual time limit
would become inoperable, perhaps through no fault of the contractor.
Whilst time is important to employers under standard form construction contracts, such forms
do not specify that time is of the essence. To do so would make time a fundamental term or
condition of the contract such that the contractor's inability to meet the condition would give
the employer a right to determine the contract. Such determination is, however, not an
adequate remedy; the project will be delayed even more by determination. Thus, in
construction contracts, time is dealt with as a contractual term (a warranty and not a
condition) and provisions are included to permit contractual time limits to be extended.
Functions of the Extension of Time Clause
The main functions of the extension of time clauses are:
To provide necessary flexibility by adjusting the date by which the works are to be
completed in certain defined circumstances, i.e. where the contractor is not responsible
for the delay (known as culpable delay);
By allowing the contract period to be extended following the occurrence of certain
events which may otherwise constitute a breach of contract by the employer, thereby
setting time at large and disabling the application of the liquidated damages
provisions. Extension of time clauses keep the liquidated damages provisions alive;
To revise the contractor's contractual obligation to complete by a certain date.
Acts of Prevention
Extensions of time are normally to be granted for two categories of events: matters which are
wholly outside the control of both parties (for instance exceptionally adverse weather) and
delay-causing factors which albeit outside the control of the contractor are dictated by the
employer (for instance the ordering of variations). If the contract did not contain extension of
time clauses, the contractor would bear the risk of all of the first category of delays. The
second category, however, would put time at large and invalidate the liquidated damages
clauses in the contract. This conclusion follows from a long line of legal authorities which
establish that "acts of prevention" by the employer, whether authorised by or in breach of the
contract, generally put time at large and prevent the imposition of any liquidated damages. In
the absence of an appropriately worded extension of time clause, acts of prevention could
include breaches of contract or even ordering variations on the part of the employer.
Accordingly, to avoid this draconian result, the standard forms whilst allowing extensions for
62
events within the first category (which removes certain elements of uncertainty in the
contracting process) also have to legislate for certain events which would otherwise be
considered as "acts of prevention".
Programming
At common law the general principle is that, in the absence of other contract terms, an
obligation on the contractor to complete its works does not require the contractor to proceed at
a regular or certain pace. It is up to the contractor how to proceed, as long as completion is
achieved by the due completion date. Programming is the province of the contractor.
The status of any programme for the execution of the contract works is dependent upon the
role assigned to such a programme within the individual standard form used. The scope and
form of a contractor's programme for the works is similarly varied and ranges from a detailed
daily analysis of the project to the broadest of outline schemes.
The Status of Contractor's Programmes under the Standard Forms
Only the GC/Works/1 (1998) expressly allows for the contractor's programme to become a
contract document, and thereby defines the sequence in which the works have to be executed
by the contractor. Other standard forms do not give such prominence to the contractor's
programme; the result is that the contractor is under an obligation only to commence the
works by the specified date, to proceed "regularly and diligently" (where the contract terms
expressly so provide) and to complete by the agreed date. As such, the method and sequence
of working adopted is at the contractor's discretion.
Even the ECC does not expressly incorporate the contractor's programme into the contract.
Indeed, the ECC goes to great lengths to provide for the contractor to produce a programme
and obtain approval to it but the contractor is not expressly required to carry out works in
compliance with such programme.
The Practical Effect of Programmes
In practice, a programme provides the contractor with a useful framework from which to
mastermind the execution of the works, and frequent references are made to it by both
contractor and contract administrator throughout the duration of the works. Indeed in London
Borough of Merton v Leach Ltd (1985) 32 BLR 57 a contractor's programme which set down
the dates by which the contractor would require information from the Architect in order to
proceed with the works was held to constitute a notice to the Architect of such a need in
accordance with the requirements of Clause 25.4.6 of the JCT 80 conditions; that clause
entitled the contractor to an extension of time for delays caused by the late receipt of
information requested in writing. However, only programmes which accurately represent the
contractor's performance of the works are thought to be able to fulfil such notice functions. If
the contractor is in delay with the works it may well be that the programme no longer
provides the necessary notice for such information, since under the programme, information
would be requested far in advance of when it was actually needed by the contractor.
It is not uncommon for contractors to construct programmes which show an earlier date for
completion than that actually stated in the contract (such programmes are often referred to as
"accelerated programmes"). The effect of such programmes was considered in the case of
63
Glenlion Construction v Guinness Trust (1987) 39 BLR 89. Here the contractor produced an
accelerated programme which allowed for the completion of the works some weeks earlier
than that formally provided in the contract. In fact, the contractor was delayed in execution of
the Works (though not beyond the contractual completion date) and sought to claim an
extension of time for the period in which according to the contractor’s own programme the
contractor had been delayed on the basis of, amongst other things, late receipt of information.
The court refused to allow such an extension and held it was unjust unilaterally to impose a
new date on the employer. Whilst the contractor may not have received information at the
time required by the accelerated programme, this was not the test by which such provision
was to be judged. The provision of information was to be assessed in relation to the
contractual completion date agreed by both parties.
Whatever the effect of a contractor's programme throughout the duration of the works, there is
no doubt that such a programme can be an extremely useful to the contractor when making
extension of time and loss and expense claims. It is often persuasive evidence of the planned
programme for the works by which any alleged delay event or material disruption to their
regular progress can be judged.
If consciously or otherwise the programme is incorporated into the contract as a contract
document, the practical and legal effect can be serious. If the contractor is prevented from
commencing or completing any individual operation identified on the programme at or
within or by the times therein set out, that could give rise to a claim against the employer for
breach of contract.
In some contracts, the standard forms are amended to incorporate complex programmes which
identify access and completion times for individual operations. Whilst understandable for
operation reasons, notably in sub-contracts, such incorporation can give rise to serious claims.
The practical effects and consequences of a programme can be summarised as follows:
Provides a useful tool (both to the contractor and to the employer) which to measure
progress and any delays;
If the programme is delivered early enough in the contract, it a useful indication as to
the dates by which important information and instructions should be released to the
contractor;
In the case of some contracts, it will enable the phased hand over of the site to be
prepared for properly.
The Society of Construction Law has considered the issue of programmes and delay. The
result is a protocol which exists to provide guidance to all parties to the construction process
when dealing with time/delay matters. It recognises that transparency of information and
methodology is central to both dispute prevention and dispute resolution.
You can view the protocol and download a copy at:
http://www.eotprotocol.com/
Liquidated and Ascertained Damages (LADs)
64
The relationship between the standard form clauses dealing with completion, extensions of
time and LADs is crucial to the understanding of time related clauses in such forms.
The contractor is under an obligation to complete the works by a given date, but the rigours of
such an obligation are mitigated by the clauses which provide for extensions of time for such
completion. However, if the contractor fails to complete the works by the due date (as
extended), the employer has the right to deduct liquidated damages, at the rate set down in the
contract from any sum due to the contractor. It is not necessary for the employer to prove
actual loss suffered.
LADs clauses have a number of distinct functions:
1. They provide an easy means of recompense for the employer if the contractor is in
culpable delay (and in so doing, encourage the contractor to complete the works on time);
2. Their use brings certainty to the tender process, enabling the tenderer to price a known
risk and produce a reliable price for the works rather than have to price for an
unquantifiable contingency if general damages for delay were allowed;
3. The employer is better able to compare and evaluate tenders which have (at least to this
extent) priced a contingency (delay) in a uniform way;
4. They allow the contractor to assess potential liabilities to the employer by reason of
failure to complete on time at the outset of the works, thereby permitting the contractor to
choose between incurring the cost of accelerating works as against the cost of forfeiting
liquidated damages;
5. They are frequently used as a commercial cap on the financial liabilities of the contractor
for delay, comprising a purposeful under-liquidation of loss on projects where the actual
losses would otherwise be such as to deter realistic tenders; and
6. They permit the parties to agree on a sum payable as damages for delay where the task of
precise pre-estimation (let alone proof of actual loss if damages were left unliquidated)
would be impossible or extremely impractical to achieve.
LADs clauses in construction contracts relate solely to the contractor's completion obligation;
they do not prevent the employer from recovering damages for other breaches of contract by
the contractor. However, insofar as they do relate to the contractor's completion obligations,
they are to provide "an exhaustive remedy as to damages which are or are not to be paid by
the contractor”.
The function of an award of damages under English law is compensatory and not punitive.
Thus, damages are intended to compensate a party for the actual loss suffered. The same
principles apply to LADs provisions under standard form contracts. The rule is that the sum
specified under the LADs clause must be (at most) a genuine pre-estimate of the loss which
the employer is likely to suffer in the event of a delay to the completion of the works. If the
sum set down constitutes a "penalty" (i.e. is a sum substantially greater than a genuine pre-
estimate of loss), the LADs provisions in the contract will be unenforceable and the
employer's only remedy lies at common law, i.e. will have to prove actual loss as general
damages for delay to the works. Liquidated damages clauses are construed strictly so that any
ambiguity in the drafting or doubt as to its application will be construed against the employer.
Penalty Clauses
65
In English law, whilst LADs are enforceable, penalty clauses are not. How then to distinguish
the two? The most important principles to be applied in determining the true nature of any
liquidated damages clause are derived from the House of Lords' judgment in Dunlop v New
Garage Co Ltd [1915] AC 79 and are as follows:
the name given to the clause in question is relevant but not conclusive;
the true nature of the clause is a question of construction and depends upon the
individual circumstances and terms of each contract;
the sum will be held to be a penalty if it is "extravagant and unconscionable in amount
in comparison with the greatest loss that could conceivably be proved to have
followed from the breach", and/or if the sum is so large that it can be considered as
being held "in terrorem" over the contractor; and
a clause can properly be construed as one setting down liquidated damages
notwithstanding the fact that the consequences of any breach are such as to make
precise pre-estimation of damages almost impossible.
Standard Forms and LADs
Whilst the standard form sub-contracts do not generally include a provision for deduction of
LADs, most standard forms of main contract make provision for payment or deduction of
LADs for non-completion of the contract works by the required date.
Certain standard forms, notably JCT 98 and IFC 98, make the levying of LADs against the
contractor subject to:
The issue of a certificate of non-completion of the works; and
A written notice from the employer informing the contractor of intention to deduct the
specified sums.
66
Background
The Engineering and Construction Contract (ECC) was developed from its predecessor the
New Engineering Contract (NEC) to meet the current and future needs for a form of contract
to be used in engineering and construction generally. There was a general feeling that while
management processes and procedures had developed strongly standard forms of contract had
remained rooted in outdated and outmoded management; put simply management had moved
on and this was not reflected in standard forms.
The objectives for the design of the ECC were to make improvements under three main
headings:
Flexibility;
Clarity and Simplicity
Stimulus to Good Management
Flexibility
The ECC is intended to be used for engineering or construction work containing any or all of
the traditional disciplines such as civil; electrical; mechanical and building work. It is
intended to be used whether the Contractor has some design responsibility, full design
responsibility or no design responsibility. Again put simply the ECC allows for all
procurement routes; it provides all the normal options for types of contract such as:
competitive tender; where the Contractor is committed to offered prices;
target contracts;
cost reimbursable contracts and management contracts.
All the commonly used standard conditions of contract from the various sectors of
engineering and construction were reviewed in the course of designing the ECC. Some of
their provisions which were peculiar to particular sectors were omitted where they can be
accommodated in the specification. Where they are essential, they are included in the ECC
itself. For example, the need to make full provision for off-site manufacture and testing of
work which is characteristic of mechanical and electrical contracts has been accommodated in
the ECC. In order to achieve uniformity across these sectors, some changes of terminology
have been necessary. An obvious example is that the word 'equipment' is used for what, in the
building and civil engineering sectors, has hitherto been called 'plant'. The word 'plant' is used
in the ECC as it is customarily used in all the other sectors of engineering. Some familiar
phrases, such as 'temporary works’, have disappeared in the interest of flexibility and
uniformity.
Clarity and Simplicity
Although a legal document, the ECC is written in ordinary language. This makes it easily
understood by people whose first language is not English, and can be translated into other
languages easily. As far as possible it uses only words which are in common use. Long
sentences are not used.
ECC is arranged and organised in a structure which helps its users to gain familiarity with its
contents. More importantly, the actions by the parties which follow from use of the ECC are
defined precisely so that there should be few disputes about who is to do what and how.
67
The design of the ECC is based upon flow charts of the procedures which are to be followed
by the parties to the contract. One of the benefits of using this approach to drafting is that
opportunities are taken for simplifying the structure of the contract as well as making sure that
the procedures are not open-ended or conflicting. For example, almost all circumstances
which may give rise to additional payment to the Contractor are identified as compensation
events. The procedure for dealing with these events is mainly set out in the core clauses. This
includes review of both the cost and time implications of the events. This is in contrast to
traditional forms of contract in which the procedure for compensation is different depending
upon the nature of each event.
The terminology compensation events rather than the emotive word claim which is normally
used reflects the theme of co-operation between the parties. It is hoped that any disputes
which do arise will concern amounts of compensation rather that is an entitlement exists.
The initial impact of reading the ECC may not convey its full simplicity, in part because a
number of newly defined expressions are used. The quantity of text used is very much less
than existing standard forms and the amount of text needed to give effect to the options is
small. For example, there is only one clause which is used in the target contract option
uniquely. This means that the simple arrangement of the ECC makes it necessary only to add
one clause to convert another option into a target contract.
The number of clauses used is less than in many standard forms. This is because, for
simplicity of use, the average amount of text in clauses is very heavily reduced. As a
symptom of this simplicity, it should be noted that the ECC neither requires nor contains any
cross-references between clauses.
It is a fundamental objective of the ECC that its use should minimise the incidence of
disputes. To this end, words like 'fair', 'reasonable' and 'opinion' have been used to the
minimum. This does not mean that the flexibility of administering the contract has been
reduced. For example, in most instances where the Project Manager is required to make a
decision, the basis of the decision is set down in the contract. This will significantly reduce
the amount of uncertainty about the outcome of the contract. This benefits the Contractor
without constraining the freedom of action of the Project Manager acting on behalf of the
Employer.
Stimulus to Good Management
This is the most important characteristic of the ECC. Every procedure has been designed so
that its implementation should contribute to rather than detract from the effectiveness of
management of the work. This aspect of ECC is founded upon the proposition that foresighted
co-operative management of the interactions between the parties can shrink the risks inherent
in construction work. Developments in project management techniques and their
implementation over the past 20 years have moved faster than the evolution of traditional
forms of contract. With the ECC it is now possible to build arrangements for the different
parties to contribute to the management of a project upon improved practices and to motivate
all of the parties, by means of the contract, to apply such practices to their work.
The two principles on which the ECC is based and which impact upon this objective are
foresight applied collaboratively mitigates problems and shrinks risk, and
68
clear division of function and responsibility helps accountability and motivates people to play
their part.
A further important theme is that people will be motivated to play their part in collaborative
management if it is in their commercial and professional interest to do so. Reliance need not
be placed upon exhortation either within the contract or outside it.
Uncertainty about what is to be done and about how the unexpected arising in the course of
construction will affect what has to be done are inevitable in construction projects. The ECC
allocates the risks arising in these ways clearly between the parties. However, its main task is
to reduce the incidence of each of those risks by application of collaborative foresight. In this
way, it aims to improve the outcome of projects generally for parties whose interests might
seem to be opposed.
All the procedures in the ECC are designed to stimulate good management. Examples of these
are:
The early warning procedure
The way in which compensation events are dealt with.
Compensation events are events which can lead to an extra payment to the Contractor or a
delay to the completion date, or which may affect the performance of the completed project.
A principle of the ECC is that the Project Manager, acting on behalf of the Employer and in
communication with the Project Manager, should be presented with options for dealing with
the problem which allow informed choice directed by the interests of the Employer. The
Contractor should be indifferent to the choice made. To achieve this, the valuation of
compensation events is based upon a forecast of the impact which the change or problem will
have upon the actual cost to the Contractor of carrying out the work as forecast at the time
that the event is assessed. Where alternative ways of dealing with the problem are possible,
the Contractor prepares quotations for the different ways in which the problem can be tackled.
The Project Manager selects one on the basis of which will most serve the interests of the
Employer. In some cases this will be the lowest cost solution, in others it might be the least
delay solution.
The change to the prices for the work is based upon the quotation. Subsequently, the
Contractor is at risk if the forecast of cost impact turns out to be wrong, but the Employer has
a firm commitment. The risk to the Contractor if this method of pricing is conceptually
similar to the risk taken by pricing work at tender. It is a lesser risk because the Contractor is
able to forecast costs very much more accurately at the time that the problem is identified than
the Contractor would have been able to do at the tender stage.
This arrangement stimulates foresight and enables the Employer to make rational decisions
about changes to the work with reasonable certainty of their cost and time implications, and to
put a risk on the Contractor which is entirely tolerable but which motivates to manage the new
situation efficiently. An important by-product is that few issues relating to valuation of the
work or extensions of time are left to be settled after the event.
This is a good example of how the procedures in the ECC have been designed to stimulate
good management and to shrink risk.
69
A typical aspect of this characteristic is the way in which the ECC makes use of the
programme for design, construction and installation. Many of the detailed procedures rely
upon the fact that an up-to-date and realistic programme maintained by the Contactor is used
in joint decision-making between the Contractor and the Project Manager. The use of the
programme (which includes method and resource statements) is defined in some detail. In
such a way that the Contractor is motivated to keep it up-to-date and realistic, not simply
exhorted or compelled to do so.
The Structure of the ECC
The documents which make up the ECC are:
the core clauses
the optional clauses
the Schedule of Cost Components
the Contract Data.
The core and optional terms
The conditions of contract themselves comprise the core clauses, which are used unaltered for
all projects, and the optional clauses. The six main options cover the six basic types of
contract such as conventional pricing with bill of quantities, target cost and management
contracts. One of these six options must be chosen and the block of clauses which apply must
be included in the contract. The secondary options provide for such things as the use of
multiple currencies, retention, bonds and price adjustment. In its simplest form, the ECC can
be used without any of these secondary options. At the other extreme, most of them can be
used, although it is unlikely that this would ever be necessary and there are some
combinations of secondary options which will never be used. For example, unless the
Contractor is to be made an advance payment, the option for an advanced payment bond
would not be used. Many of the clauses in the options are common to more than one option.
The Schedule of Cost Components
The Schedule of Cost Components is a complete identification of components of cost which is
not varied from one contract to another. It is used to avoid uncertainty where actual cost has
to be assessed in connection with any of the procedures of the contract itself. This occurs, for
example, in cost reimbursable contracts.
The Contract Data are filled in for each project and this identifies such things as the
completion dates, the contract-specific documents (e.g. specifications and drawings), interest
rates, price adjustment indices to be used (if any) and many other things.
Versions of the ECC are published separately for each main option.
Roles and Duties
The ECC sets out the responsibilities and roles of the following parties:
Employer,
Project Manager,
Supervisor,
70
Contractor,
Subcontractor,
Supplier,
Adjudicator,
Arbitrator.
The unfamiliar names on this list are Project Manager, Supervisor and Adjudicator. A
separate function of Employer's designer is assumed but not mentioned in the contract. The
role played by the Engineer in other standard forms is effectively divided between the Project
Manager, the Supervisor, the Employer's designer and the Adjudicator.
The role of the Project Manager is to manage the project on behalf of the Employer. The role
is defined in the contract in terms of the actions and decisions to be taken. The Project
Manager is expected to carry out this role unequivocally as Employer's Project Manager and
with the intention of achieving the objectives of the Employer for the complete project. The
Project Manager is constrained from acting unreasonably in this role by statements in the
contract governing how decisions should be made but not what decision should be made. If
the Contractor believes that any of the Project Manager's actions or decisions are not in
accordance with the contract, these may be referred to the Adjudicator. The Adjudicator
carries out the function formerly carried out in many contracts by the Engineer in a quasi-
arbitral role, although the procedure is simplified.
The Supervisor acts for the Employer in maintaining quality control, again within the limits of
authority set down in the contract. The role is like that of the Resident Engineer although
different in some significant respects. Note that the term Resident Engineer might be related
to an Architect on site.
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises, can I:
1. Describe the procedures and practice in standard forms in the areas of:
1.1. Site Possession;
1.2. Commencement;
1.3. Progress;
1.4. Completion;
1.5. Variation;
1.6. Extension of time;
1.7. Programming;
1.8. Liquidated and Ascertained Damages.
2. Discuss the relationship between management and standard forms using the example of
the Engineering and Engineering Contract
71
6. Health and Safety
Health and Safety
This section deals with Health and Safety. You are asked to do several things: complete the
Blackboard section [including brief exercises]; read the workbook; read some material from
books in the library and visit some websites.
Introduction
There is excellent material in the textbook which supports this section: Uff, J Construction
Law,. You should read pages 491-505 which describe general principles of health and safety
with this section. The intention here is not to repeat the material in the textbook but to
provide some additional material; and sometimes an alternative analysis.
The course you are following attracts students of many disciplines [civil, mechanical and
aerospace] and from many nations and it would be impossible to consider all the aspects of
health and safety in the UK let alone in each country. However the health and safety issues
facing the parties to engineering are generic; and by considering certain of these issues you
will be able to analyse the effect of health and safety law.
You might remember that I made a distinction between civil and criminal law; and that mostly
we were considering civil wrongs. Health and Safety law is an example where criminal law
dominates and you might return to the distinction between civil wrongs and criminal wrongs
that you considered in Section 1.
72
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
To consider the law associated with health and safety and its relevance to engineering
projects and engineering professionals.
Within the overall aim the following measurable objectives are set
The student will be able to:
Discuss the need for regulation in markets;
Describe the history of health and safety legislation in the UK
Consider 4 specific areas:
Health and safety at work act 1974;
Construction (Design and Management) Regulations [CDM];
Work in confined spaces
Corporate Manslaughter.
Introduction
One definition of law is that it regulates activity. Commercial law regulates commercial
activity: Article I, §8, Clause 3 of the U.S. Constitution provides that:
"The Congress shall have power . . . To regulate commerce
This is known as the Commerce Clause
http://itlaw.wikia.com/wiki/Commerce_Clause
Free marketers propose that the market will regulate and that no other regulation is necessary
but most accept that a mixed approach is required. The free market cannot be left to its own
devices and that some regulation is required. This regulation might protect the vulnerable.
Health and Safety legislation protects the vulnerable but has come to be seen by some as the
epitome of over-protection. “Health and Safety gone mad”.
Without health and safety legislation vulnerable people are left unprotected; it is worth
remembering that various legislations were required to prevent the worst excesses of the
industrial legislation [in 1788, the Act for the Better Regulation of Chimney Sweepers and
their Apprentices limited a sweeper to six apprentices who must be at least 8 years old].
Consider the various Factories Acts at:http://en.wikipedia.org/wiki/Factory_Acts
Some health and safety legislation
Examples of legislation seeking to provide some form of protection to workers include:
1802 Health & Morals of Apprentices Act. First attempt to regulate pauper children in the
textile industry
73
1819 Factory Act. No children under nine years old to work in cotton mills. Children under
nine years in other factories to work an 11 hour maximum day
1833 Althorp's Factory Act. Limited hours to be worked by children. Established four factory
inspectors
1842 Mines Act. Employment of all women (and children under 10 years of age) prohibited
underground
1901 Minimum working age set at 12 years. Trade Boards introduced to set minimum wages
in specific industries
1937 Factory Act. Limited workers under 16 years of age to a 44 hour week
1974 Health and Safety at Work Act. Health and safety legislation extended to all workplaces.
Provisions extended to off-shore gas and oil workers from 1975
Health and safety in engineering
It would impossible to cover all the aspects of health and safety in engineering because of the
broad nature of engineering, just look at the information under engineering at HSE
http://www.hse.gov.uk/fod/engid.htm.
I am going to consider 4 areas: health and safety at work act 1974; Construction (Design and
Management) Regulations [CDM]; work in confined spaces and Corporate Manslaughter.
Education of engineers
Consider the conclusions of the report into undergraduate education:
http://www.hse.gov.uk/engineering/engineer.pdf
The Health and Safety at Work Act
The Health and Safety at Work etc Act 1974 , also referred to as HASAW or HSW, is the
primary piece of legislation covering occupational health and safety in the United Kingdom.
The Health and Safety Executive is responsible for enforcing the Act and a number of other
Acts and Statutory Instruments relevant to the working environment.
The full text of the Act can be downloaded free of charge from:
http://www.hse.gov.uk/legislation/hswa.pdf
Statutory instruments are the secondary types of legislation made under specific Acts of
Parliament, in this case The Health and Safety at Work etc Act 1974 . The secondary
legislation is made up of Statutory Instuments (SIs), often referred to as ‘regulations’. It is
enforced by HSE and Local Authorities (LAs). HSE and LAs work locally, regionally and
nationallly, to common objectives and standards. These cover a wide range of subjects, from
control of asbestos at work, diving, escape and rescue from mines, ionising radiation and
working at height. A full list is available at
http://www.hse.gov.uk/legislation/statinstruments.htm.
Construction (Design and Management) Regulations [CDM]
74
The latest version is The Construction (Design and Management) Regulations 2007. Since
coming into force in 1995 the CDM regs have had a major impact on all major construction
work. Download a complete copy at: http://www.opsi.gov.uk/si/si2007/uksi_20070320_en_1
The CDM 2007 Regulations apply to most common building, civil engineering and
engineering construction work. The legislation demands that someone CDM Cordinator or
Principal Contractor must notify HSE of the site if the construction work is expected to either:
last longer than 30 days; or
involve more than 500 person days of construction work;
Work in Confined Spaces
This is an example of situations where people will often rush into complete work unaware of
the dangers. A number of people are killed or seriously injured in the UK each year in
confined spaces. These occur across a wide range of industries, from those involving complex
plant through simple storage vessels. Those killed include not only people working in the
confined spaces but those who try to rescue them without proper training or equipment. For
example domestic drainage manholes or inspection chambers are often too small to allow
access i.e. work must be done from above ground. Many people when faced with a manhole
which allows access to the system fail to see the danger and enter; never enter an enclosed or
confined space without appropriate training..
HSE define a confined space. A confined space is a place which is substantially enclosed
(though not always entirely), and where serious injury can occur from hazardous substances
or conditions within the space or nearby (e.g. lack of oxygen).
Under HASAW employers are responsible for ensuring the safety of their employees and
others. This responsibility is reinforced by regulations.
The Confined Spaces Regulations 1997 apply where the assessment identifies risks of serious
injury from work in confined spaces. The regulations contain the following key duties:
avoid entry to confined spaces, e.g. by doing the work from the outside;
if entry to a confined space is unavoidable, follow a safe system of work; and
put in place adequate emergency arrangements before the work start
http://www.hse.gov.uk/pubns/indg258.pdf
Corporate Manslaughter
Corporate Manslaughter and Corporate Homicide Act 2007
There was considerable disquiet at the perceived lack of action against corporations when
serious accidents had occurred. The law until 2007 required that a ‘controlling mind’ [ a
director or senior manager] be guilty of manslaughter. In practice, particularly in
prosecutions of large companies, it can be very difficult to prove a link between a death and
the ‘controlling mind’. One of the most notorious prosecutions to fail in this respect was that
of P&O European Ferries following the sinking of the Herald of Free Enterprise.
75
The Corporate Manslaughter and Corporate Homicide Act 2007 is a landmark in law. For the
first time, companies and organisations can be found guilty of corporate manslaughter as a
result of serious management failures resulting in a gross breach of a duty of care.
The Act, which came into force in 2008, clarifies the criminal liabilities of companies
including large organisations where serious failures in the management of health and safety
result in a fatality. The Act introduces a new offence, across the UK, for prosecuting
companies and other organisations where there has been a gross failing, throughout the
organisation, in the management of health and safety with fatal consequences.
http://www.justice.gov.uk/publications/corporatemanslaughter2007.htm
http://www.corporatemanslaughter.net/Index.php
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
2) Looking at my responses to the exercises, can I:
3) Discuss the need for regulation in markets;
4) Describe the history of health and safety legislation in the UK
5) Consider 4 specific areas:
a) Health and safety at work act 1974;
b) Construction (Design and Management) Regulations [CDM];
c) Work in confined spaces
d) Corporate Manslaughter.
76
7. Risk
Risk in Contracts
This section deals with Risks in Contracts. You are asked to do several things: complete the
Blackboard section [including brief exercises]; read the workbook; read some material from
books in the library and visit some websites.
Introduction
Contracts allocate risks; there is no direct material in the textbook which supports the module.
The intention here is to introduce risk in contracts; I do that via a classification of risk
allocation in contracts. The classification is 3 broad types of contract:
Lump Sum
Measure and value [remeasurement]
Cost reimbursement [cost plus]
You might need to reconsider sections 4 and 5: The Concepts of Standard Forms of Contract
and The Key Area of Standard Forms; the role of Management in Standard Forms.
This section is not about: Risk Theory; Stratification of Risk or Risk Management it is about
risk in contracts. I say this because all these terms are widely used in engineering, any search
engine will produce these and many others. In particular Risk Management is a distinct
engineering specialism.
77
Section Aim and Objectives
The section might be described via an overall aim and measurable objectives.
Aim: To consider the concept of risk in contract
Within the overall aim the following measurable objectives are set
The student will be able to:
Explain the allocation of risk in contracts
Understand the complex nature of risk theory; the stratification of risk and other risk
related topics
Distinguish between Risk Management and Risk in contracts
Explain the classification of contracts into:
o Lump Sum
o Measure and Value
o Cost reimbursement
The Concept of Risk
Most explanations differentiate between Risk and Uncertainty; they differentiate between risk
and uncertainty as:
Risk = quantifiable = insurable
Uncertainty = unquantifiable = not insurable
A further explanation in terms of probability goes:
Risk = Probability of event x Magnitude of loss/gain whereas in uncertainty it is not possible
to attach probability
While the future is largely unknown, businesses make decisions on the basis of expectations
about the future and this involves taking risks.
Risk and Uncertainty defined: there are lots of definitions. A useful combination of the many
definitions suggests that risk and uncertainty characterise situations where the actual
outcome for a particular event or activity is likely to deviate from the estimate or forecast
value. Of course this works two ways; actual outcome might be better than forecast or worse.
Some talk of Upside & Downside Risk. Risks works in two ways; the outcome my better or
worse than expected. These are known as upside and downside risks
78
Risk Theory
Risk theory is a theory of decision-making under probabilistic uncertainty, from a
mathematical point of view it is a branch of probability theory. Risk Theory applications
cover all aspects of life, but are perhaps most advanced in Finance [e.g. banking, insurance,
managing market and credit risks, investments and business risks]. This section is not about
risk theory, or Stratification of risk, or risk management; it is about risk in contracts.
Stratification of risk
Risk stratification is a statistical process used by clinicians by which quality of care can be
assessed. This section is not about Stratification of risk or risk theory or risk management; it
is about risk in contracts.
Risk Management
This is the biggest category of what this section is not about. Risk Management is a widely
used technique, across all engineering disciplines, directed towards the assessing, mitigating
(to an acceptable level) and monitoring of risks.
Spend some time at the risk wiki seeing what this section is not about.
http://en.wikipedia.org/wiki/Risk_management
Contracts and Risk
Contracts allocate risks; some of these come from experience. For example: Rain in
Manchester: experience tells us that it will rain in Manchester; rain delays outdoor activities.
What do construction contracts say about weather conditions? The standard form of building
contract talks about exceptionally adverse weather. If exceptionally adverse weather occurs
the contract provides that the contractor is allowed extra time to complete i.e. he gets an
extension of time which removes his liability to pay Liquidated and Ascertained Damages
[LADs]. Remember most contracts for project based engineering provide that the contractor
will execute the works for an agreed amount in a stated time. [I agree to build that office
block/bridge/aircraft/nuclear submarine for £x million in y weeks].
Classification of risk
One way of classifying risk allocation in contracts is to talk of 3 broad types of contract:
Lump Sum
Measure and value
Cost Reimbursement
Lump Sum
Here the work [the object of the contract] is fully defined and capable of quantification. The
contractor can assess the risk [including the contract conditions] and provide a lump sum
quote in advance. Typically most new building projects are capable of being let on a lump
sum basis. The Standard Form of Building Contract is an example of a lump sum contract.
Measure and Value [re-measurement]
79
Here the work is fully defined BUT is not capable of quantification in advance. The
contractor can assess the risk [including the contract conditions] but cannot provide a lump
sum quote in advance, since the quantity may change; he can however provide a list, or
schedule, of rates for the work defined. This list of rates can be used to measure and value the
work when completed. Typically Civil Engineering projects are let on a re-measurement
basis. For example tunnelling projects require re-measurement. Civil Engineering contract
[ICE 6th
Edition] is an example of a Measure and Value contract.
Cost Reimbursement [cost plus]
Sometimes the work is incapable of definition or quantification in advance. No contractor can
assess the risk. What to do in such circumstances? And they are not uncommon One
solution is to get the contractor to complete the work and to pay for the work on a cost
reimbursement basis; i.e. the contractor’s costs as they occur. Sometimes arrangements are
made to pay direct costs plus a fee [either a fixed fee or a percentage] this explains the
alternative name: cost plus. Cost Plus [a fee] the fee might be fixed [£X, or it might be a
percentage of the cost]. Examples of work that can neither be let on a lump sum or a measure
and value basis; and therefore require cost reimbursement include: repairs and maintenance or
new work where the object is technically innovative. An example: many of the university
buildings [and generally] have dangerous asbestos content; any repair and maintenance work
will expose the asbestos but the amount and how it can be treated cannot be judged until it is
exposed. The only way to let contracts is to get on with the work and to pay the contractor.
As to technically innovative work; examples include matters of national security and defence
e.g. The EuroFighter project.
Exercise: visit the Eurofighter wiki and write brief notes [100 words] about the cost increases.
http://en.wikipedia.org/wiki/Eurofighter_Typhoon
Exercise: I propose the following example of projects which fit into my classification of:
lump sum; re-measurement and cost re-imbursement:
A new luxury house for me designed by an architect – Lump Sum
A new drainage project – Re-measurement
Asbestos removal from the ceiling of my office - Cost re-imbursement.
Because
The house is designed and the quantities can be calculated;
The drains are designed but the quantities are uncertain;
The extent of the asbestos is unknown it was included when the Pariser Building was
built in the 1960’s and there are no records
Give 3 examples of your own with reasons.
80
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises, can I:
2) Consider the concept of risk in contract
3) Explain the allocation of risk in contracts
4) Understand the complex nature of risk theory, the stratification of risk and other risk
related topics
5) Distinguish between Risk Management and Risk in contracts
6) Explain the classification of contracts into:
a) Lump Sum
b) Measure and Value
c) Cost reimbursement
81
8. Conflict Theory
Conflict, Dispute and Conflict Theory
Introduction
This section deals with Conflict, Dispute and Conflict Theory.
There is a general feeling that conflict is a bad thing and should be avoided. Two of the
influential thinkers who first proposed that this view of conflict was simplistic are: Mary
Parker Follett and John Dewey. Any kind of search on either will bring dividends: Follett
suggested a distinction between functional and dysfunctional conflict; Dewey said:
Conflict is the gadfly of thought. It stirs us to observation and memory. It instigates
to invention. It shocks us out of sheeplike passivity, and sets us at noting and
contriving.
Exercise: Use a search engine to find quotations from Mary Parker Follett and John Dewey;
write brief notes on your favourite [with your reasons.
Exercise: Conflict and dispute are inevitable on commercial projects; therefore conflict
management is more important than dispute resolution. Write brief notes [100 words] .
The terms conflict and dispute are often interchanged; serious authors [e.g. Brown and
Marriot (1994) achieve it in the first paragraph] consider The Office of Government
Commerce: Dispute Resolution Guidance approach at http://www.ogc.gov.uk.
This section considers the role of conflict theory in explaining commercial conflict
management and dispute resolution.
Aim and Objectives
The section might be described via an overall aim and measurable objectives.
The section aim is
To consider the difference between conflict and dispute
Within the overall aim the following measurable objectives are set:
Explain the difference between conflict and dispute
Discuss the origins of Conflict Theory
Discuss the application of Conflict Theory to commercial conflict management and
dispute resolution.
Conflict and Dispute are difficult words; they are often interchanged. Some theorist take
conflict as the stronger term [i.e. dispute is all around but only occasionally does conflict
break out] and some take completely the opposite view [i.e. conflict is all around but only
occasionally does dispute break out]. This workbook takes the position that conflict is
necessary and inevitable but that disputes are to be avoided.
82
There exists enormous interest in commercial disputes amongst the professions, industry and
academia. The interest is mostly with the techniques used to resolve disputes; there exists
little by way of research into conflict and dispute.
Conflict and Dispute
Disputes are time consuming, expensive and unpleasant. They can destroy client/supplier
relationships which have been painstakingly built up over long periods of time. Disputes can
add substantially to the cost of a project even making a project unsuccessful, unfeasible or
nullifying any benefits. Disputes need to be avoided; if the dispute cannot be avoided then
they should be resolved as efficiently as possible to manage the ‘Problem’, negotiate a
‘Settlement’, help ‘Preserve Relationships’ and maintain ‘Value for Money’.
Is there a difference between conflict and disputes?
Many people would not recognize a distinct difference between the terms conflict and dispute.
Certainly most people would not concern themselves with any definition. Academics, and
others, would usually make definition their starting point. Definition provides structure and
structure may allow explanation and understanding.
Conflict and dispute studies do form academic disciplines. Any attempt here to summarise
the various strands of academic disciplines would be doomed to failure and debate on
definition. In an attempt to avoid this, it is suggested the following are some of the areas of
conflict and dispute studies:
Peace and Conflict Studies
Conflict Management as an Organisation Management Science
Conflict Management and Dispute Resolution
Much useful material is available on the Internet try:
http://www.cgpacs.uci.edu/
Many scholars do draw a distinction between the two terms.
Functional and dysfunctional conflict
Early conflict theory marked all conflict as a bad thing that should be avoided. Amongst the
first to question this was Mary Parker Follett; she said that effective conflict management
ought not to conceive conflict as a wasteful outbreak of incompatibilities, but a normal
process whereby socially valuable differences register themselves for the enrichment for all
concerned. Three methods: domination; compromise and integration were advanced for
dealing with conflict of which only integration was strongly advocated.
Domination, whereby there is a victory of one side over the other (a win-lose
situation).
Compromise, whereby each side gives up something in the process (a lose-lose
situation).
Integration, whereby each side refocuses their efforts so that neither side loses
anything and in fact each gains (a win-win situation).
83
Follett believed that domination should be avoided at all costs. Although application of this
strategy requires little effort on the part of the parties and their agents, the long-term side
effects can be devastating. Compromise carries with it the assumption that both parties will
be happy because each will gain something, but each loses something as well and this in turn
creates the potential for further conflict. Integration was favoured simply because if both
parties can become satisfied there will remain no issue or problem – obviously an ideal
situation not easily attained.
Often the following terms are used in discussing conflict:
Win-lose
Win-win
Lose-lose
No win no lose
Win-lose is often overused as a strategy for solving conflicts. It assumes the use of mental or
physical power to bring about compliance; a lose-lose approach will also leave no one entirely
happy. Compromise, side payments and submission of the issue to a neutral third party, as in
the arbitration procedure, constitute examples of this latter approach. The win-win approach
is now becoming more popular although it is still misunderstood by many parties and their
agents. This method yields solutions satisfactory to all in that each party to the conflict wins
something, and the conflict is therefore resolved constructively. It could be suggested that
important conflicts tend to be best managed with positive-sum (win-win) strategies, while
more trivial issues merit no more than zero-sum (win-lose/lose-lose) strategies, with most
situations calling for contingency or mixed modes (no win-no lose). Zero-sum and other
terms are borrowed from game theory; we will return to game theory later.
A further distinction between conflict and dispute that is particularly useful is the distinction
made by Burton (1993) which distinguishes the two based on time and issues in contention.
Disputes, Burton suggests, are short-term disagreements that are relatively easy to resolve.
Long-term, deep-rooted problems that involve seemingly non-negotiable issues and are
resistant to resolution are what Burton refers to as conflicts. Though both types of
disagreement can occur independently of one another, they may also be connected. In fact,
one way to think about the difference between them is that short-term disputes may exist
within a larger, longer conflict. A similar concept would be the notion of battles, which occur
within the broader context of a war. Other theorists talk of strategy and tactics; tactics win the
battle but strategy wins the war.
From this analysis of conflict and dispute it can be argued that conflict is necessary and
inevitable but that disputes are to be avoided. The school of Western thought which maintains
that conflict (but not dispute) is inevitable (see deBono, 1985). Conflict is part of Western
societies and idioms; there is a Western dialectic argument idiom to use the academic jargon.
Conflict is part of dynamic capitalism and an integral part of commercialism; conflict might
be seen as the functional and necessary part. Dispute on the other hand only develops when
conflict is not (or cannot be) managed; dispute is the unnecessary or dysfunctional element
and logically there should be two areas for consideration:
84
Conflict Management: Here the emphasis is on the axiom that it must be in all
parties interests to avoid disputes by managing conflict in such a way that disputes do
not arise; this is sometimes described as dispute avoidance.
Dispute Resolution: Notwithstanding the emphasis on the desire to avoid
dispute, there must be occasions where the parties have legitimate disputes and that
the techniques of dispute resolution are employed to bring about the conclusion or
resolution of the dispute.
The distinction between conflict and dispute is shown diagrammatically in Figure 1.
Conflict Management
Fig 1
Figure 1: Conflict Continuum
Conflict Theory
A theory of conflict does exist; it was founded by Karl Marx. Marx expresses the theory in
terms of a class struggle; the struggle between classes. Others took the theory forward
[notably Max Weber]. A glance at the conflict literature shows there is a great diversity of
conflict knowledge; from the everyday knowledge we all have to the sophisticated theoretical
writings of sociologists. The problem is how to present this broad range of knowledge in an
understandable manner. One way of dealing with this is to consider that the theories apply to
many different conflicts; even that they apply to all conflicts. Sociological theories apply to
commercial conflict. In addition the theories should be presented in a simple way. One
famous definition of economics is that it is a study of the allocation of scarce resources which
have alternative uses. Conflict theory might be expressed in a similar way; conflict is
CONFLICT
DISPUTE
Conflict
Avoidance Informal Negotiate Discussion
ADR Arbitrate Litigate
Adjudicate
Other
Action
Violence
85
inevitable as organisations seek to redistribute scarce resources. This is a classic Marxist
view.
Wikipedia provides a useful examination of Conflict Theory
http://en.wikipedia.org/wiki/Conflict_theory
Exercise: The Wikipedia entry is heavily focussed on social conflicts; you should consider
how the entry might be edited for conflicts between organisation as opposed to conflict
between classes. In particular, draft sections on:
Basic conflicts;
Modes of conflict;
Assumptions.
Self-Appraisal Questions
1. Am I able to demonstrate that I can now meet the objectives set out at the start of this
section.
Looking at my responses to the exercises:
2. Have I explained and understood the difference between conflict and dispute. In line
with the measurable objectives set, can I:
a. Explain the difference between conflict and dispute
b. Discuss the origins of Conflict Theory
c. Discuss the application of Conflict Theory to commercial conflict management
and dispute resolution.
3. Discuss the application of Conflict Theory to commercial conflict management and
dispute resolution
86
9. Comparison Of Dispute Resolution Techniques
Introduction
This section introduces the difference between conflict, disputes and the concepts of conflict
management and dispute resolution. A continuum of conflict and disputes and the techniques
of dispute resolution are outlined. The techniques predominantly practised tion Adjudication;
Arbitration and Mediation are introduced, and a comparative analysis is made.
At the end of this section you will be able to:
Discuss the stages of dispute resolution
Evaluate the process and strategies of:
o Construction Adjudication;
o Arbitration;
o Mediation.
Compare and contrast the key dispute resolution techniques of Construction Adjudication,
Arbitration, Mediation with Litigation in the areas of:
o Formality
o Speed
o Flexibility
o Cost
o Confidentiality
o Relationships
o Control and Choice
o Solutions
87
Conflict management and dispute resolution techniques
The range of conflict management and dispute resolution techniques include:
Conflict avoidance: a variety of techniques some used consciously and some subliminal to
avoid the escalation from normal conflict into dispute. Examples might include: risk
management to ensure that risks are identified; analysed and managed; procurement strategies
to ensure that risks are appropriately allocated and contractual arrangements to allow sensible
administration.
Negotiation: this is easily the most common form of dispute resolution, carried out in many
forms every day by just about everybody. In negotiation the parties themselves attempt to
settle their differences using a range of techniques from concession and compromise to coerce
and confront.
Mediation: a private and non-binding form of dispute resolution where an independent third
party [neutral] facilitates the parties reaching their own agreement to settle a dispute.
Mediation is often a structured process where the settlement becomes a legally binding
contract.
Conciliation: a process of mediation where the neutral proposes a solution. In the same way
that we distinguished between a continuum of conflict and dispute; a continuum of mediation
and conciliation shows mediation at one facilitative end and conciliation at the other
evaluative end of the continuum.
Med-arb: is a combination of mediation and arbitration where the parties agree to mediate
but if that fails to achieve a settlement the dispute is referred to arbitration. The same person
may act as mediator and arbitrator in this type of arrangement.
Dispute Resolution Adviser (DRA): The concept of DRA is the use of an independent
intervener. This independent intervener is paid for equally by the employer and the contractor
to settle disputes as they emerged; rather than wait until the end of the contract.
Dispute Review Boards (and Dispute Review Panel): Dispute Review Board is a process
where an independent board evaluate disputes.
Neutral evaluation: a private and non-binding technique where a third party neutral (often
legally qualified, gives an opinion on the likely outcome at trail as a basis for settlement
discussions.
Expert Determination (Submission to Expert, Reference to an Expert, Expert
Adjudication): these are long-established procedures in English law and have been used
across a number of industries. Examples include - accountants valuing shares in limited
companies, valuers fixing the price of goods, actuaries carrying out valuations for pension
schemes, certifiers of liability for on-demand performance bonds, and Adjudicators who are
said to be acting “as expert and not as arbitrator”.
Mini-Trial (or Executive Tribunal): This is a voluntary non-binding process. The parties
involved present their respective cases to a panel comprised of senior members of their
organisation. The panel is assisted by a neutral facilitator and has decision making authority.
88
After hearing presentations from both sides, the panel ask clarifying questions and then the
facilitator assists the senior party representatives in their attempt to negotiate a settlement.
Adjudication: this refers to Statutory Adjudication in Construction Disputes as set out in the
Housing Grants, Construction Regeneration Act 1996. Here decisions of an adjudicator are
binding on the parties at least until a further process is invoked (Arbitration or Litigation).
Arbitration: a formal, private and binding process where disputes are resolved by an award
of independent tribunal [third party or parties, the arbitrator or arbitrators]. The tribunal is
either agreed by the parties or nominated by a further independent body: e.g. a court or a
professional institution The Chartered Institute of Arbitrators.
Litigation: the formal process whereby claims are taken through court and conducted in
public; judgements are binding on the parties subject to rights of appeal.
This is by no means an exhaustive or exclusive list; you will undoubtedly find others, the
references in the reading list contain many other examples. Indeed one definition of ADR is
Appropriate Dispute Resolution and there may be a ‘killer application’ yet to be devised. You
will see from Figure 1 that at the dispute end of the continuum lies violence, hopefully we
will not have to consider this option.
89
The Stages of Conflict Management and Dispute Resolution
The stages of conflict management and dispute resolution are usefully described in a
document produced by the Office of Government Commerce: Dispute Resolution Guidance
which can be viewed and downloaded from the internet at http://www.ogc.gov.uk. The stages
are:
Stage 1: Negotiation
Stage2: Non Binding Techniques and Processes
Stage 3: Binding Techniques and Processes
The Principal Stages and The Dispute Resolution Options are shown below
Principal Stages of Conflict Management and Dispute Resolution
90
Stage 1 Stage 3 Stage 2
Negotiation
Mediation
Conciliation
Neutral Evaluation
DRA’s etc
Adjudication
Expert
Determination
Arbitration
Litigation
91
METHOD COMMON
LAW/
STATUTE
BASIS
FREQUENCY
OF USE
SPEED COST CONFIDENTIALITY BINDING ADVERSARIAL SPECIAL
FEATURES
Stage 1
Negotiation No Very Common Ubiquitous
Varies Low Yes No No Can continue throughout the
dispute
Stage 2
Mediation No Common Fast Low Yes No (unless agreed) No
Conciliation No Fairly Common Fast Low Yes No (unless agreed) No Often included with
mediation
Neutral Evaluation No Infrequent Fast Low Yes No No
Adjudication Yes Common Fast Low Yes Yes (until completion or
Arb/Lit)
Yes Statutory adjudication is
construction
specific
Stage 3
Arbitration Yes Common Contingent Contingent Yes Yes Yes
Expert
Determination
No Fairly Common Fast Moderate Yes Yes Yes
Litigation Yes Common Slow High No Yes Yes
Stage 1
Negotiation No Very Common
Ubiquitous
Varies Low Yes No No Can continue
throughout the
dispute
Stage 2
Mediation No Common Fast Low Yes No (unless agreed) No
Conciliation No Fairly Common Fast Low Yes No (unless agreed) No Often included with
mediation
Neutral Evaluation No Infrequent Fast Low Yes No No
Adjudication Yes Common Fast Low Yes Yes Yes construction
specific
Stage 3
Arbitration Yes Common Contingent Contingent Yes Yes Yes
Expert
Determination
No Fairly Common Fast Moderate Yes Yes Yes
Litigation Yes Common Slow High No Yes Yes
92
Three ‘core’ processes of dispute resolution and a spectrum of dispute resolution
It is useful to consider the problem from a different angle, Authors talks of three core
techniques, which may be employed in the resolution of disputes. Firstly, negotiation, which
refers to the problem solving efforts of the parties. Second, third party intervention, which
does not lead to a binding decision being imposed on the parties, finally the adjudicative
process, the ultimate outcome of which is an imposed binding decision. Such an approach
has been adopted by Green and Mackie (1995), who refer to the “three pillars” of dispute
resolution. The discrete techniques may be introduced under one of the three pillars,
depending upon the main characteristics of the particular technique; see Figure 5 below:
Figure 5: 'The Dispute Resolution Landscape'
Negotiation Mediation Adjudication
Facilitative Evaluative mediation mediation
Mini-trial or executive tribunal
Med-Arb Consensus- building
Variations on 'neutral expert’ types of process
Conciliation Litigation Arbitration
Expert determination Adjudication Ombudsmen
Dispute Review Boards
Neutral fact-finding Expert appraisal
Early neutral evaluation
Source: Mackie, K. Miles, D. and Marsh, W. (1995)
Arguably, all dispute resolution techniques are built upon three basic principal methods:
negotiation, mediation/conciliation, and some form of adjudicative umpiring process.
93
Outline Of The 3 Dispute Resolution Techniques
This section provides an outline of the 3 dispute resolution techniques predominantly offered.
Construction Adjudication
Arbitration
Mediation
What follows is a simple introduction to each technique, followed by a comparison.
94
Construction Adjudication (under the Housing Grants Construction and Regeneration
Act 1996)
The Housing Grants Construction and Regeneration Act received Royal Assent on 24th July
1994. Those parts relating to construction (Part II of the Act) commenced on 1 May 1998.
The Act sets out a framework for a system of adjudication; all construction contracts must
meet minimum criteria and if they fail the Scheme for Construction Contracts will apply.
Statutory Adjudication - The Process
Under Part II of the Housing Grants, Construction and Regeneration Act 1996 a party to a
construction contract is unilaterally given the right to refer a dispute arising under the contract
to adjudication. The Act only applies to "construction contracts" which fall within the
detailed definition of Section 104 For example, "architectural design, surveying work or to
provide advice on building, engineering, interior or exterior decoration or the laying out of
landscape in relation to construction operations" are included within the scope of the Act,
whilst contracts of employment are expressly excluded. In addition, a construction contract is
defined to include an agreement to carry out "construction operations". Construction
operations are further defined in Section 105 to include a wide variety of general construction
related work together with a list of notable exceptions. A further notable exception is a
construction contract with a residential occupier. The provisions only apply where the
construction contract is in writing.
Section 108 sets out the minimum requirements for an adjudication procedure. These may be
summarised as follows:
Notices: A party to a construction contract must have the right to give a notice at any time of
his intention to refer a particular dispute to the adjudicator.
Appointment: A method of securing the appointment of an adjudicator and furnishing him
with details of the dispute within seven days of the notice is mandatory.
Time scales: The adjudicator is then required to reach a decision within 28 days of this
referral. It will not be possible to agree in advance of any dispute that additional time may be
taken for the adjudication. There are only two exceptions to this rule. First the adjudicator
may extend the period of 28 days by a further 14 days if the party referring the dispute
consents. Second, a longer period can be agreed by consent of all the parties. Such
agreement can only be reached after the dispute has been referred
Act impartially: The adjudicator is required to act impartially.
Act inquisitorially: The Act requires that the adjudicator "takes the initiative in ascertaining
facts and the law". This gives the adjudicator power to investigate the issue in whatever
manner he or she deems appropriate given the short time scale available.
Binding nature: The decision of the adjudicator is binding until the dispute is finally
determined by legal proceedings, by arbitration or by agreement. Phillip Capper (1997)
suggests that "the 'until' formulation gives an unfortunate interim air to the decision almost
inviting the view that it ought to be reopened at a later stage" The Act does, however, go on
to say that the parties may agree to accept the decision of the adjudicator as finally
determining the dispute.
Immunity: The adjudicator cannot be held liable for anything done or omitted in the
discharge of his function as an adjudicator unless acting in bad faith. This protection is
extended to any employee or agent of the adjudicator.
95
In addition to this basic procedural framework the Act further requires that any construction
contract complies with the provisions of the scheme for construction contracts.
96
Arbitration
Arbitration is a process, subject to statutory controls, whereby formal disputes are determined
by a private tribunal of the parties’ choosing. According to Stephenson, Lord Justice Sir
Robert Raymond provided a definition some 250 years ago which is still considered valid
today (Stephenson, D. A: 1998)
"An arbitrator is a private extraordinary judge between party and party, chosen by their
mutual consent to determine controversies between them, and arbitrators are so called because
they have an arbitrary power; for if they observe the submission and keep within due bounds,
their sentences are definite from which there lies no appeal."
The Arbitration Act 1996
The Aim of the Arbitration Act
Five main objectives underlie the Act:
1. To ensure that arbitration is fair, cost-effective and rapid.
2. To promote party autonomy, in other words to respect the parties choice.
3. To ensure that the courts’ supportive powers are available at the appropriate
times.
4. To ensure that the language used is user friendly and clearly accessible.
5. To follow the model law wherever possible.
The first of these objectives is included in section one of the Act:
"The provisions of this part are founded on the following principles, and shall be construed
accordingly -
a) The objective of arbitration is to obtain the fair resolution of disputes by an
impartial tribunal without unnecessary delay or expense;
b) The Parties should be free to agree how their disputes are resolved, subject
only to such safeguards as are necessary in the public interest;
c) In matters governed by this part of the Act the court should not intervene
except as provided by this part."
Mediation
Mediation is a way of settling disputes in which a third party, known as a mediator, helps
both sides to come to an agreement which each considers acceptable. Mediation can be
‘evaluative’, where the mediator gives an assessment of the legal strength of a case, or
‘facilitative’, where the mediator concentrates on assisting the parties to define the issues.
When a mediation is successful and an agreement is reached, it is written down and forms a
legally binding contract, unless the parties state otherwise.
The Chartered Institute teaches a facilitative model in its training courses on the basis that this
is considered the most successful of the techniques. Any settlement, which occurs, is the
parties' own and the analogy of chemical catalysts is often made. A catalyst makes a reaction
take place between two or more chemicals; the catalyst is not affected or changed by the
reaction. Sometimes the reaction will take place without the catalyst and the effect is to speed
97
reaction and sometimes the reaction will not take place without the catalyst. The analogies
with mediation are obvious.
Mediation is the most widely used and accepted ADR technique. Whilst there is no
prescriptive mediation process, the typical stages in a mediation might be:
1. A brief written summary of the matter in dispute is presented in advance to the
mediator;
2. The parties meet with a mediator for an initial joint meeting including perhaps
a brief oral presentation by the parties;
3. Caucus sessions, where the mediator has private meetings with the party in
turn. During the caucuses the mediator often shuttles backwards and forwards to
clarify issues and search for settlement possibilities. This process is often termed
shuttle diplomacy;
4. Plenary sessions are called to either continue negotiations directly, to conclude
agreement, or where the process is unsuccessful to conclude a mediation.
Most mediators agree to a contingency approach to mediation; that is there is no set procedure
but the procedure is tailored to suit the parties and the dispute in question. This often means
that mediation is conducted without joint meetings and the mediators play a variety of roles.
The mediator may act as a mere facilitator, there purely to assist communications.
Alternatively the mediator acts as a deal maker, to assist the parties in finding overlap in their
bargaining positions or encouraging concession and compromise. Perhaps the mediator acts
more as a problem solver assisting the parties in designing and searching for creative
solutions. The mediator may act as transformer transforming the dispute by allowing the
parties a fresh in-sight into the issues and their positions. The final role of the mediator maybe
as an adjudicator or assessor to provide the parties with an appraisal of the merits of the cases
on a legal, technical or even common sense standpoint.
98
Comparison of Litigation, with Construction Adjudication, Arbitration and Mediation
It is useful to compare and contrast the major dispute resolution techniques in areas where the
characteristics of each technique are highlighted. Litigation, Construction Adjudication,
Arbitration and Mediation are compared in the areas of:
Formality
Speed
Flexibility
Cost
Confidentiality
Relationships
Control and Choice
Solutions
Formality
Mediation is an informal process; the parties may agree to certain mediation rules but they are
at liberty to amend any rules. There is no requirement to produce specified information
before the mediation can commence neither is there are requirement to spend resources filing
and serving documents. Mediation in informal and uncomplicated.
Adjudication is an informal process and the procedure is, within the bounds of natural justice,
at the discretion of the adjudicator.
Arbitration has been criticised for mimicking litigation; many steps have been taken to redress
this and arbitrations are less formal, nevertheless arbitration may be considered formal and
complicated when compared with mediation.
Litigation is, properly, a highly formalised process with specialised rules; non-compliance
may prevent litigation proceeding. Resources have to be committed in filing and serving
documents. Litigation is a highly formal and complicated process.
Speed
In mediation the timing is within the control of the parties; subject to the availability of
suitable and acceptable mediators mediation may take place as quickly as the parties desire.
The length of the mediation is similarly in the control of the parties; they can agree to stay as
long, or as briefly, as required. The great majority of mediations are restricted to one working
day or less.
Adjudication operates under very tight timescales laid down by the Act; see above the
maximum time from notice to decision is 35 days which may be extended by agreement to 49
days.
Speed is often claimed as a feature of Arbitration; however the reality is that the availability
of all the parties involved, not least the arbitrators, dictate that the process is often protracted.
99
Litigation is often an infuriatingly slow process; in many jurisdictions advisors talk in terms
of years rather than months as the timescale for trial dates. Although many great strides have
been taken in many countries to address this, in the UK the Civil Procedure Rules following
the Woolf Review of Civil Justice is a particular example, time continues to be an issue.
Flexibility
Mediation is a flexible process; all arrangements can be changed if necessary if it becomes
apparent that this is necessary. Arbitration can share much of this flexibility and the 1996
Arbitration Act has given arbitrators wide ranging powers to achieve flexibility. Adjudicators
too have much scope for flexibility
Litigation is an inflexible process, specific steps must be taken to initiate and progress
matters.
Cost
Mediation is an inexpensive process; this is achieved and facilitated by the informality and
speed of the process. The amount of lawyer involvement can be reduced if the parties agree
and in many cases the cost of preparing for mediation is marginal to the other preparation.
The parties can share the mediator’s costs and the cost of the venue in an agreed fashion.
Adjudication can be an inexpensive process as a result of the tight timescales.
Arbitration can certainly help in reducing costs and dealing with a dispute in a proportionate
manner. In comparison to litigation it must be remembered that while the state pays for the
judge, and rooms in many cases, in arbitration the parties must pay the arbitrators costs.
Litigation is an expensive process, this is dictated by the formality and slowness of the
process. There are many, many examples of the disproportionate costs of litigation amongst
the most famous is the Dickens example of Jaryndyce v Jarndyce where the parties disputing
a will expended the entire legacy in legal costs when they disputed the terms of the will!
Confidentiality
Here things are clear; in adjudication, arbitration and mediation all matters are confidential.
This is an important issue for commercial disputes where the parties often wish to avoid
publicity and to keep commercial confidentialities. There is an issue often where arbitration
awards are the subject of appeal or referral to the courts; then all matters will become public.
Litigation is a public matter and though civil commercial litigation seldom attract tabloid
press interest; it is clear that litigation can expose confidential issues.
Relationships
Again a clear difference. Mediation is a non-adversarial process while litigation and
arbitration are both adversarial. Adjudication may avoid the dysfunctional aspects of
adversarialism.
In mediation the parties do not seek to convince the neutral that they are in the right; or that
others are in the wrong. The emphasis of facilitative mediation is on the parties’ interests as
100
opposed to parties’ rights. As a result mediation need not affect working relationships in an
adverse manner. Often mediation can improve relationships as parties achieve an improved
understanding of underlying interests and concerns.
Litigation and Arbitration on the other hand are not conducive to even maintaining
relationships let alone improving them. Opposing parties aim to convince the tribunal that the
law and the facts support their argument to the detriment of the other side; this seldom helps
relationships and often destroys them.
Adjudication allows the power imbalance in relationships to be dealt with in that weaker sub-
contractors have a clear route to deal with more powerful contractors.
Control and Choice
In mediation the control of the dispute always remains with the parties and the choice is
theirs. Who will be the mediator; where will the mediation take place; when will it take
place; and who will attend. Mediation is a voluntary process and the parties remain in
control. This control means that the parties have to ‘buy in’ to the settlement and any
resolution becomes their own settlement.
Litigation, Adjudication and Arbitration hands over the dispute to the lawyers and the judge
or arbitrator or adjudicator. The process passes control and choice in a similar fashion.
Solutions
The essential difference is that mediation allows for creative solutions to disputes; during a
mediation a wide range of issues can be addressed or uncovered. These issues can include
past unresolved matters and even future intentions. The solutions to the issues can take many
forms, and are not restricted to payment of money, they can be as creative as the parties to the
dispute. Mediated agreements have included:
Apologies
Future Business Arrangements
Revamped Commercial Arrangements
Litigation and Arbitration cannot allow for creative solutions but must be limited to legal
remedies available.
Adjudication is similarly restricted by legal remedies but does allow prompt solutions which
permit the project to be completed.
The comparison is shown in outline in Table 1
101
Dispute
Technique
Mediation Adjudication Litigation Arbitration
Area
Formality Informal Informal Formal Formal
Speed Fast Fast Slow Contingent
Flexibility Good Good Poor Contingent
Cost Inexpensive Inexpensive Expensive Contingent
Confidentiality Yes Yes No Yes
Adversarial No Contingent Yes Yes
Party Control Yes No No No
Party Choice Yes No No Contingent
Creative Solutions Yes No No No
Table 1: Litigation Compared With Construction Adjudication, Arbitration and
Mediation
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises, can I:
2) Evaluate the process and strategies of:
(1) Construction Adjudication;
(2) Arbitration;
(3) Mediation.
3) Compare and contrast the key dispute resolution techniques of Construction Adjudication,
Arbitration, Mediation with Litigation in the areas of:
4) Formality
5) Speed
6) Flexibility
7) Cost
8) Confidentiality
9) Relationships
(1) Control and Choice
(2) Solutions
102
10. Negotiation
This section introduces some of the theories of negotiation, mainly principled versus
positional negotiation; once again it is useful to think in terms of a continuum. Negotiation is
a continuum with positional negotiation and principled negotiation at either ends of the
continuum.
At the end of this section you will be able to:
Differentiate between the theories of negotiation:
o Positional
o Integrative
o Principled
Identify key factors in negotiation
o Positional Bargaining/Negotiation
o Principled Bargaining/Negotiation
Evaluate methods for closing the deal
o Getting to Yes
o Negotiation Tactics/Strategy
Introduction
A character in Molière; Monsieur Jordain was delighted to learn that he had been speaking
prose all his life; he thought that prose was something special. Equally most people negotiate
throughout their lives without realising that they are negotiating and without any training.
There are three commonly perceived attributes that most men claim to do, and do well,
without any training:
Drive
Make Love
Negotiate
It appears strange that most countries require men to pass a test only to be allowed to drive,
the others need no training and no licence!
This section considers some aspects of negotiation; unfortunately, or predictably, negotiation
suffers the same fashions and fads as many management areas. Be wary of the fads and
fashions; or in academic terms demonstrate organised scepticism. A glossary is provided.
The internet revolution has touched negotiation; for a useful starting point for web-based
negotiation try:
http://www.haas.berkeley.edu/Courses/BA252-1/home.html
The most used buzz words are BATNA and WATNA.
103
Glossary of Negotiation Terms
Anchoring and Adjustment: An opening position, from which a negotiator incrementally
moves away from (gains or losses) during a negotiation. The choice of an anchor may be
based on faulty or incomplete information, and can potentially be misleading.
Agenda: A plan for how a negotiation will progress.
Aspiration Point: Optimal settlement point that a negotiator hopes to achieve.
Bargaining Zone: The gap between the respective resistance points of each party.
BATNA (Best Alternative To a Negotiated Agreement): This is your back-up plan.
Consistency Principle: The need to appear consistent in beliefs, feelings and behaviours.
Distributive Negotiation: A negotiation technique and/or type that seeks to gain at the
opponent's loss. Any situation in which one person's gain is exactly equal to the opponent's
loss is considered distributive.
Dyadic Negotiation: A negotiation between two persons, as opposed to negotiations in which
more parties are involved.
Expanding the Pie: Finding resources to include in a negotiation that fulfil
both party's needs.
Golden Bridge: A strategy by which a negotiator makes his or her opponent's positive
decision as easy as possible.
Kinesics: The study of body movements, including posture.
Inaction Anxiety: Self-imposed pressure to achieve an agreement at any cost. Often leads a
negotiator to strike a deal when s/he should have walked away and chosen his/her BATNA.
Integrative Negotiation: A negotiation technique and/or type that seeks to expand the pie,
finding a win-win settlements. In an integrative negotiation, one person's gain is not
necessarily another person's loss.
Interests: The concerns underlying a position.
Issues: Negotiable items that will be included in the formal agreement.
Limited Authority: A negotiating gambit whereby a negotiator says he cannot make a decision
and must resort to a higher authority.
Linkage Effect: When one deal point of a negotiation is attached to another.
Negotiating Gambit: A strategy in negotiating that should be avoided because it damages
relationships.
104
Negotiating Roles: Different people in a negotiating team can have different roles such as
primary negotiator, Kinesics and paralanguage expert, etc.
Non-verbal cues: Body language that gives away how a person is feeling and what s/he is
thinking. This is closely related to kinesics.
Package: An offer which has many elements.
Paralanguage: Variations in speech : pitch, loudness, tempo, tone, duration, laughing , crying
-- how things are said.
PATNA (Probable Alternative To a Negotiated Agreement)
Position: Statement of what a person/party wants in a negotiation.
Positional negotiation: Positional negotiation strategy is, essentially, a manipulative approach
designed to intimidate the other party to lose confidence in their own case and to accept
demands.
Principled negotiation: this grew from alternatives to positional negotiation, a famous book
Getting to Yes, Fisher and Ury sets out a concept of "Principled Negotiation" with the main
points being:
Separate the People from the Problem
Focus on Interests, Not Positions
Invent Options for Mutual Gain
Select from Among Options by Using Objective Criteria
Reciprocity Principle: Occurs when a negotiating party feels obligated to return in kind what
the other side has offered or given them. This principle might result in on side making a
concession because the other side has done the same.
Resistance Point (RP): The point beyond which a person/party will not go. The lower limit of
the range of acceptable negotiation outcomes.
WATNA (Worst Alternative To a Negotiated Agreement)
Winner's Curse: Occurs when your aspiration point is too low. You accept a deal, and
wonder whether your opponent would have given you a better deal had you been more
persistent.
105
Negotiation Theory and Skills
It is common for theorists talk of two negotiation theories or strategic approaches to
negotiation:
Positional negotiation; and
Principled negotiation.
The terms positional and principled negotiating are not exclusive and in other reading material
you may find them replaced with any of the following:
Positional = competitive; compromise; Principled = interest-based; co-operative; collaborative
Also note that negotiations may be divided into two types:
Dispute negotiation, focused on resolving past facts; and
Transaction negotiation, focused on reaching agreement for the future.
While it is often helpful to appreciate this difference between dispute negotiation and
transaction negotiation, it is also beneficial to appreciate that many negotiation situations
involve the resolution of both past issues as well as planning future relations. The theories
and strategic approaches are generic and can be applied to either disputes or transactions.
Mediation often involves past dispute negotiation linked to future transactions.
Distinguish Strategic Approach from Personality
There may be some correlation between negotiation approaches and personality style, but the
two do not necessarily go together. A positional negotiator may be very pleasant to work with
in terms of demeanour, but can utilize extremely competitive tactics. Negotiator's pleasantries
may themselves be part of an overall manipulative approach. A principled negotiator may be
rather difficult or awkward in terms of personality, yet effectively utilize interest-based,
problem-solving strategies in negotiation.
It is often argued that the most effective negotiators will have a wide array of negotiation
skills, both positional (competitive) and principled (problem-solving), and will effectively
mix and match these approaches depending upon what the negotiator believes will work best
with a particular "negotiating partner" depending on the specific issue being negotiated and
depending on the nature of the overall negotiating relationship (one-time transaction or
continuing relations). This approach might be likened to the contingency approach to
mediation described in Section 4.
Another view of negotiation is that certain strategies and behaviours are intended to create
value (integrative and principled approaches) whereas other strategies and behaviours are
intended to claim value (principled and competitive approaches).
106
The Positional Approach
Positional negotiation strategy is, essentially, a manipulative approach designed to intimidate
the other party such that they lose confidence in their own case and are pressurised to accept
the other side’s demands. This approach is characterized by the following:
High opening demands;
Threats, Tension and Pressure;
Stretching the facts;
Sticking to positions;
Being tight lipped;
Desire to outdo, outmanoeuvre the other side; and
Desire for clear victory.
When a Positional negotiator is asked how they will know that they have reached a good
agreement, they may reply that the agreement is better than fair.
What is positional negotiating?
A positional approach involves adopting a position and aiming to negotiate an agreement
whilst remaining as close to that position as possible. Most people are familiar with positional
negotiating but it allows for only limited and fairly predictable negotiating. Negotiators
adopting a positional style will assume that only one party can emerge from the negotiation a
clear winner. This is often termed the "WIN/LOSE" approach. Positional negotiating is
characterised by:
Extreme opening positions
Emphasis on rights
Aggression
Predictable negotiating positions
Assumptions of the Positional Approach
There are certain assumptions, that lie behind the Positional approach to negotiation. This
"distributive" world view includes the following assumptions:
Negotiation is the division of limited resources;
One side's gain is the other's side's loss; and
A deal today will not materially affect choices available tomorrow.
Risks of the Positional Approach
While Positional negotiation tactics are often effective in "claiming" already defined value,
there are also certain risks. Foremost among these risks are damage to the negotiating
relationship and a lessened overall likelihood of reaching agreement. The disadvantages of the
Positional style include:
Confrontation leads to rigidity;
There is limited analysis of merits of dispute and relevant criteria for resolving
issues;
107
There is limited development of solution alternatives;
Difficulty in predicting the outcome of the competitive approach or control the
process;
Competitors are generally blind to joint gains;
Competitors threaten their future relations;
Competitors are more likely to have impasse and increased costs.
The Integrative Approach and The Harvard Negotiation Project
Before considering Principled Negotiation it is worth examining integrative negotiation and
the Harvard Negotiation Project (HNP) since Principled Negotiation is a result of both
integrative negotiation and the (HNP).
The integrative, collaborative or problem-solving approach to negotiation has been described
as "enlightened self-interest," rather than the "egocentric variety." This approach consists of
joint problem-solving, where gains are not necessarily viewed as at the expense of the other
party.
Assumptions of the Integrative Approach
There is a different view behind the integrative approach to negotiation. The primary
assumptions of the integrative approach are the following:
Some common interests exist between parties;
Negotiation is benefited by a full discussion of each participant's perspective
and interests; and
We live in an integrated and complex world and our problems can be best
resolved through application of our best intelligence and creativity.
Risks of the Integrative Approach
Risks of the integrative approach are based upon the common sense observation that "it takes
two to collaborate." If one party is unwilling to participate in integrative, problem solving
negotiation, the more collaborative negotiator may put themselves at risk in the following
ways:
The negotiator will be forced to either "give in" or adopt a competitive stance;
The negotiator may see themselves as a failure if they do not reach
agreement; and
The negotiator lays themselves open by honestly disclosing information that is
not reciprocated.
The Harvard Negotiation Project
The Harvard Negotiation Project's mission is to improve the theory, teaching, and practice of
negotiation and dispute resolution, so that people can deal more constructively with conflicts
ranging from the interpersonal to the international.
108
The Project, or HNP as it is commonly known, was created in 1979 and was one of the
founding organizations of the Program on Negotiation consortium. The work of HNP
routinely moves back and forth between the worlds of theory and practice to develop ideas
that practitioners find useful and scholars sound. In general, HNP's work can be grouped into
four categories: theory building; education and training; real-world intervention; and written
materials for practitioners. A sampling of HNP activities in each category follows.
Theory Building
HNP is perhaps best known for the development of the theory of "principled negotiation," as
presented in Getting to YES: Negotiating Agreement Without Giving In, by Roger Fisher, Bill
Ury, and Bruce Patton. First published in 1981, and revised and expanded in a tenth
anniversary edition (Penguin 1991), Getting to YES outlines a commonsense approach to
negotiation that has been read by millions of people in 25 different languages. In clear,
straightforward writing, Getting to YES shows negotiators how to separate relationship issues
from substance and deal with the latter by focusing on interests, not positions; inventing
options for mutual gain; and using independent standards of fairness to avoid a bitter contest
of will.
Real-World Intervention
HNP frequently tests its theories in practice, often in the heat of some of the world's most
intransigent conflicts. From South Africa to Latin America, the Middle east to the Balkans,
HNP works with individuals and governments on initiatives ranging from injecting a single
idea at a crucial time to initiating and framing an entire process for dealing with a conflict.
Recently an HNP technique called "facilitated joint brainstorming" was tested with a high-
level but unofficial group from Ecuador and Peru to generate new options that both sides
could jointly present to their superiors. The conference led to a peace initiative that ultimately
settled a highly contentious border dispute that had persisted for 50 years and resulted in
numerous armed conflicts.
Of course you can find more at http://www.pon.harvard.edu/
Principled Negotiation
Principled negotiation was a product of HNP and grew from the alternatives to positional
bargaining offered by the integrative approach. In their book, Getting to Yes, Fisher and Ury
set forth their concept of Principled Negotiation. A brief summary of the main points of
principled negotiation includes:
Separate the People from the Problem
Focus on Interests, Not Positions
Invent Options for Mutual Gain
Select from Among Options by Using Objective Criteria
Separate the People from the Problem
Fisher and Ury suggest that we are all people first and that there are always substantive and
relational issues in negotiation and mediation. They describe means of dealing with relational
109
issues, including considering each party's perception (for example by reversing roles);
seeking to make negotiation proposals consistent with the other party's interests; making
emotions explicit and legitimate; and through active listening.
Focus on Interests, Not Positions
Positions may be thought of as one dimensional points in a space of infinite possible
solutions. Positions are symbolic representations of a participant's underlying interests. To
find out interests, you may ask questions like: "What is motivating you here?" "What are you
trying to satisfy" or "What would you like to accomplish?" You may also ask: "If you had
what you are asking for (your position), what would that experientially get you - what
interests would that satisfy?"
In negotiation, there are multiple, shared, compatible, and conflicting interests. Identifying
shared and compatible interests as "common ground" or "points of agreement" is helpful in
establishing a foundation for additional negotiation discussions. Principles can often be
extrapolated from "points of agreement" to resolve other issues. Also note that focusing on
interests tends to direct the discussion to the present and future, and away from the difficulties
of the past. If we have learned anything about the past, it is that "we can not change it." The
past may help us to identify problems needing solution, but, other than that, it does not tend to
yield the best solutions for the future.
Invent Options for Mutual Gain
Before seeking to reach agreement on solutions for the future, Fisher and Ury suggest that
multiple solution options be developed prior to evaluation of those options. The typical way
of doing this is called brainstorming. In brainstorming, the parties, with or without the
mediator's participation, generate many possible solution before deciding which of those best
fulfil the parties' joint interests. In developing options, parties look for mutual gains.
Select from Among Options by Using Objective Criteria
Using objective criteria (standards independent of the will of any party) is where the label
"principled negotiation" comes from. Fisher and Ury suggest that solution selection be done
according to concepts, standards or principles that the parties believe in and are not under the
control of any single party. Fisher and Ury recommend that selections be based upon such
objective criteria as precedent, tradition, a course of dealing, outside recommendations, or the
flip of a coin.
The advantages of principled negotiating
The main advantages of principled negotiation are that it:
Maintains relationships
Achieves satisfactory / efficient agreements
Is Flexible
Can redress power imbalances
Principled negotiation can be seen unlikely to provoke the aggression that may be shown in
positional negotiating; the emphasis is on mutually beneficial agreements and there is no need
110
for undue competitiveness. Parties can negotiate in an atmosphere conducive to ending on
good terms with each other.
Principled negotiating can achieves satisfactory and efficient agreements since the parties are
not limited to the narrow confines of rights based arguments. The agreement can meet as
many of the parties needs as they have been prepared to reveal.
The nature of principled negotiating means that there can be flexibility over what and who is
included in the negotiation..
Where a significant power imbalance exists, principled negotiating may establish that
interests of the powerful party make their dependence upon the less powerful party
surprisingly strong.
The disadvantages of principled negotiating
Of course there exists potential for disadvantage. Principled negotiating can take time to reach
a settlement. The ultimate result should justify the time spent but parties engaged in
principled negotiating may need to be prepared to exercise patience. Principled negotiating is
often far more complex than its positional counterpart. More effort will be required of parties
both in preparing for and during the negotiation. It may take a number of attempts before
people feel comfortable negotiating in this way, especially for those people who regard
themselves as having a good track record with their positional bargaining approach. Since it
can take longer and is likely to demand, overall, more man hours, it may be seen as being the
more expensive option. However, the cost should be looked at in the context of the whole
negotiation and, we have seen that the end result should be a much better agreement than
would otherwise have been achieved.
Some Issues in Principled Negotiating
What if the other party is more powerful? - Developing a BATNA
In the event that the other party has some negotiating advantage, Fisher and Ury suggest that
the answer is to improve the quality of your "best alternative to a negotiated agreement" (your
BATNA). For example, if you are negotiating for a job and want to make a case for a higher
wage, you improve your negotiating power by having another job offer available, or at least as
a possibility.
What if They Won't Play or Use Dirty Tricks
Fisher and Ury's answer to the resistant competitive negotiator is to "insist" on principled
negotiation in a way that is most acceptable to the competitor. The principled negotiator might
ask about the competitor's concerns, show he or she understands these concerns, and, in
return, ask the competitor to recognize all concerns. Following the exploration of all interests,
Fisher and Ury suggest inducing the competitive negotiator to brainstorm options and to think
in terms of objective criteria for decision-making.
Another way of thinking about encouraging principled or integrative bargaining is to think in
terms of matching, pacing, leading and modelling. To get a negotiator to shift orientations, it
is critical that they first experience themselves as fully heard in terms of content, intensity and
111
emotion. By so matching and pacing with a negotiator (asking a few clarifying questions), the
negotiator will become more open to your lead and modelling of productive means of
negotiating.
Converting Positions to Interests to Positive Intentions
Negotiating parties tend to come to negotiation with well-rehearsed positional statements
about the truth of the situation. As wise negotiators, we know that we want to assist all parties
to get below their positions to achieve a full understanding of their respective interests. If you
view negotiating parties as, essentially, survivors, wanting to improve their situations, you
may be able to assist negotiating parties to recognize that even the most difficult interests, like
revenge and anger, can be understood in terms of positive intentions, such as a desire for
acknowledgment and respect. So reframed, the mediation effort can become a joint search for
mutually acceptable solutions to the parties identified positive intentions. This reframing of
the entire mediation effort can dramatically shift the entire atmosphere of your negotiation.
Some Negotiation Basics and Negotiation Tactics
Important areas in negotiation and negotiation tactics include:
Negotiation Power
Preparation for Negotiation
Opening Offers
Stages of Negotiation
Negotiation Power
Negotiation power might be defined as an ability of the negotiator to influence the behaviour
of another. Commentators have observed a variety of aspects and qualities of negotiation
power. It is important to take note of these various aspects and qualities of negotiating power:
a number of aspects and qualities of negotiating power that have been identified include:
Negotiating power is relative between the parties;
Negotiating power changes over time;
Negotiating power is always limited;
Negotiating power can be either real or apparent;
The exercise of negotiation power has both benefits and costs;
Negotiating power relates to the ability to punish or benefit;
Negotiating power is enhanced by legal support, personal knowledge, skill,
resources and hard work;
Negotiating power is increased by the ability to endure uncertainty and by
commitment;
Negotiating power is enhanced by a good negotiating relationship;
Negotiating power depends on the perceived BATNA; and
Negotiating power exists to the extent that it is accepted
Preparation
There are only three things which matter in negotiation: preparation, preparation and
preparation.
112
To facilitate that preparation a framework of questions which skilled negotiators ask includes:
What are the (hypothesised) causes of conflict?
What range of interventions may be helpful?
What are the Parties Needs, Concerns and Goals
o What are each party's needs, concerns and goals?
o Which of these need urgent attention?
o Rank needs, concerns and goals from “vital” to “desirable”,
o What needs, concerns, and goals are apparently shared; independent; or
in conflict?
o What is WATNA; BATNA and PATNA for each party?
Facts
o What are the alleged facts?
o What is the evidence supposedly supporting the alleged facts?
o What facts are agreed upon?
o What degree of clarity on agreed, disputed and missing facts is
necessary for advice/negotiations to begin?
Rules and Objective Criteria
o What range of rules and precedents may apply to this situation ?
o What are the standard arguments to and fro arising from these
o precedents?
Outcomes
o What range of outcomes are possible -best to worst? Lateral thinking?
o What is client's targeted or preferred outcome?
o What outcomes will be resisted (the resistance point)?
Dynamics
o Who should engage in preliminary meetings (for example, lawyers,
parties, experts)?
o Who should be present at the negotiation; who should not be present?
o What is known about the preferred negotiation style of all parties
involved?
o What authority to settle does each party have? What influential people
exist in the background?
o What are past patterns of interaction? What fears exist about a
negotiation meeting?
o What documents need to be prepared/submitted/read by whom? By
what deadlines'?
o To what extent can complex alleged facts, evidence, arguments pro and
con, precedents, interests and needs and agreements be summarised visually?
Opening Offers
113
Two vital and interrelated questions for practising negotiators and for students seeking to
understand, systematise and measure negotiator behaviour are: Who should make the first
offer? And What form should the first offer take?
Who should make the first offer
Anecdotally, many negotiators predictably try to avoid making the first offer; or begin with
offers or respond to offers with an exaggerated ambit claim. This is a natural feature of
positional negotiation and is greatly alleviated by principled negotiation
What form should the first offer take
There are three classic ways to open negotiations:
soft high (the maximalist opening);
firm reasonable (the "equitable" opening);
problem solving.
Each opening has a number of predictable and well documented advantages and
disadvantages. It is essential that skilled negotiators:
know how to open by anyone of these three methods.
even thought they may have a preferred style, are able to use all three openings
with confidence.
practise in damage-free simulations using alternative methods.
negotiate with the "opposition", before the first offers are made, about which
of the three forms of opening is most appropriate. (This may require considerable
education of "the opposition".)
be able to articulate openly the well-known advantages and disadvantages of
each form of opening.
openly or by known coded messages identify to the other side which of the
three openings appears to have been used. For example, negotiators use a number of
codes to indicate a high soft opening:
On the current facts, our client would be prepared to settle for...
Our client is claiming ...
Stages of Negotiation
Studies of negotiation behaviour suggest that there are predictable stages through which most
negotiations pass. Although there are many variables which affect the timing of each stage.
Thee four stages are summarised as:
Stage One: Orientation and positioning
Working relationship established
Initial negotiating positions adopted
Stage Two: Argument, compromise and search for alternative solutions
Argument and persuasion
Search for alternative solutions
114
Concession making
Stage Three: Emergence and crisis;
Pressure for agreement or deadlock builds
Crisis occurs
Stage Four: Agreement or final breakdown
Deadlock or basic agreement occurs
Wrap up details
These four observed stages are worthy of further thought:
What factors speed up or slow down the stages?
How can the third (crisis) stage be managed?
What management styles appear to be more or less effective?
Online Negotiation
As one might expect there are opportunities presented by the use of negotiation via the
Internet. There are many companies offering their services as intermediaries and their servers
as space for negotiation; these are often secure negotiation rooms e.g.
http://www.browndavisclark.bigstep.com/aboutus.html
http://www.coolsolar.com/en/negotiation/default.asp
Online teaching of negotiation is also widely available try:
http://www.haas.berkeley.edu/Courses/BA252-1/home.html
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
2) Looking at my responses to the exercises, can I:
3) Differentiate between the theories of negotiation:
i) Positional
ii) Integrative
iii) Principled
4) Identify key factors in negotiation
i) Positional Bargaining/Negotiation
ii) Principled Bargaining/Negotiation
5) Evaluate methods for closing the deal
i) Getting to Yes
ii) Negotiation Tactics/Strategy
115
11. Mediation Principles
Introduction
This section introduces the history of mediation and the types of mediation commonly
encountered. These are Facilitative; Evaluative; Settlement and Transformative. The styles
are compared and again the concept of a continuum is used to explain the different styles and
models of mediation. The position of the Chartered Institute of Arbitrators is explained: a
facilitative model of Mediation in favoured since this is the most successful and robust of the
mediation types and mediators trained and experienced in facilitative models can apply other
techniques and models on an ad-hoc basis. The use of mediation styles and models must be
contingent on the dispute.
At the end of this section you will be able to:
Explain the different mediation styles and models
o Facilitative
o Evaluative
o Settlement
o Transformative
Discuss the arguments for and against the different mediation styles and
models
o Facilitative
o Evaluative
o Settlement
o Transformative
Evaluate the use of the different mediation styles and models
o Facilitative
o Evaluative
o Settlement
o Transformative
o Discuss the contingent model of the mediation
Mediation History and Types
Early mediation theory recognised only one type of mediation. The mediator or neutral,
whilst remaining in control of the process, merely facilitated the parties’ negotiation in an
attempt to assist the parties to create their own solution. This became known as Facilitative
(or Interest Based) Mediation.
Following from facilitative mediations some parties, and some mediators, recognised that in
certain situations there would have to be consideration of parties’ rights and that parties
unable to reach a facilitated solution would require some help via an evaluation. This
developed Evaluative (or Rights Based) mediation. In a similar vein a Settlement Based
mediation model developed.
In the 1990’s mediation developed further the initial facilitation when mediators and theorists
developed a school of Transformative Mediation. Here the mediator by empowering the
parties allows all parties or their relationships to be transformed during the mediation.
116
The Chartered Institute of Arbitrators teaches a facilitative model of Mediation in training
courses for mediators. It is the opinion of the ADR committee, and this is supported by
mediation research, that the facilitative model is the most successful and robust of the
mediation types. Further mediators trained and experienced in facilitative models can apply
other techniques and models on an ad-hoc basis. The experience of the Chartered Institute is
that mediators trained in settlement models and evaluative models are not as able to apply
facilitative models. Therefore; facilitation first and then the mediator may choose to proceed
with other techniques and types
Facilitative Mediation (Interest Based)
In facilitative mediation, the mediator structures a process to assist the parties in reaching a
mutually agreeable resolution. The mediator asks questions; validates and normalizes parties'
points of view; searches for interests underneath the positions taken by parties; and assists the
parties in finding and analyzing options for resolution.
The facilitative mediator does not make recommendations to the parties, give advice or
opinion as to the outcome of the case, or predict what a tribunal would do in the case. The
mediator is in charge of the process, while the parties are in charge of the outcome.
Facilitative mediators want to ensure that parties come to agreements based on information
and understanding. They hold joint sessions with all parties present so that the parties can hear
each other's points of view, but hold private meeting (caucuses) regularly with the parties
where they explore options and test the parties’ positions. Facilitative mediators seek for the
parties to have the major influence on decisions made, rather than the parties’ advisors; legal
or otherwise.
Evaluative Mediation (Rights Based)
In evaluative mediation the mediator assists the parties in reaching resolution by pointing out
the weaknesses of their cases, and predicting what a tribunal would be likely to do. Based on
the parties’ rights an evaluative mediator makes formal or informal recommendations to the
parties as to the outcome of the issues. Evaluative mediators are concerned with the rights of
the parties rather than needs and interests, and evaluate based on concepts of fairness.
Evaluative mediators meet most often in separate meetings with the parties and their advisors,
practicing "shuttle diplomacy". They help the parties and advisors evaluate their legal position
and the costs versus the benefits of pursuing a legal resolution rather than settling in
mediation. The evaluative mediator structures the process, and directly influences the
outcome of mediation.
Settlement Mediation
Settlement mediation (compromise mediation) takes as its main objective encouragement of
incremental bargaining, towards a compromise a central point between the parties positional
demands. Mediators employing the settlement model control both the parties and the process;
the mediator seeks to determine the parties’ bottom line. Then through persuasive
interventions the mediator moves the parties off their initial positions to a compromise point.
Transformative Mediation
117
Transformative mediation is the newest concept based on the values of "empowerment" of
each of the parties as much as possible, and "recognition" by each of the parties of the other
parties' needs, interests, values and points of view. The potential for transformative mediation
is that any or all parties or their relationships may be transformed during the mediation.
Transformative mediators meet with parties together, since only they can give each other
"recognition".
In some ways, the values of transformative mediation continue and expand those of early
facilitative mediation, in its interest in empowering parties and transformation. Modern
transformative mediators want to continue that process by allowing and supporting the parties
in mediation to determine the direction of their own process. In transformative mediation, the
parties structure both the process and the outcome of mediation, and the mediator follows
their lead.
Arguments for and Against
Proponents say facilitative and transformative mediation empower parties, help the parties
take responsibility for their own disputes and the resolution of the disputes. Critics say that
facilitative and transformative mediation takes too long, and too often ends without
agreement. There are legitimate worries that outcomes can be contrary to standards of fairness
and that mediators in these approaches cannot protect the weaker party.
Proponents of transformative mediation say that facilitative and evaluative mediators put too
much pressure on clients to reach a resolution. They believe that the clients should decide
whether they really want a resolution, not the mediator.
Proponents of evaluative mediation say that clients want an answer when they are unable to
reach agreement, and they want to know that their answer is fair. Critics of evaluative
mediation say that its popularity is due to the lawyers and advisors who choose evaluative
mediation because they are familiar with the process. They believe that the clients would not
choose evaluative mediation if given enough information to make a choice. They also worry
that the evaluative mediator may not be correct in the evaluation of the case.
Mediators tend to feel strongly about these styles of mediation and there is a healthy and
useful debate. The opinion of The Chartered Institute of Arbitrators is reiterated: facilitation
is a robust and effective model and from that basis mediators can proceed on a contingency
basis. There is no one model rather a selection of techniques which can be employed
depending on the circumstances. There appear to be more concerns about evaluative and
transformative mediation than facilitative mediation. Facilitative mediation appears
acceptable to almost everyone, although some find it less useful or more time consuming.
However, much criticism has been levelled against evaluative mediation as being coercive,
top-down, heavy-handed and not impartial. Transformative mediation is criticized for being
too idealistic, not focused enough, and not useful for business or court matters.
Another concern is that many lawyers and clients do not know what they may get when they
end up in a mediator’s office. Some people feel that mediators ought to disclose prior to
clients appearing in their offices, or at least prior to their committing to mediation, which style
or styles they use. Other mediators want the flexibility to decide which approach to use once
they understand the needs of the particular case.
118
Styles versus. Continuum
Fig 1 shows conflict and dispute in terms of a continuum and this is used again to differentiate
between conciliation and mediation. Again the differences in mediation styles and models
might be seen as more a continuum than distinct differences, from least interventionist to
most interventionist. It would seem that in general mediators are on a continuum from
transformative to facilitative to evaluative mediation, but are not squarely within one camp or
another.
The Mediation Process
Civil And Commercial Mediation
Background
This section provides a history of ADR and introduces civil and commercial mediation. This
workbook is concerned with Civil and Commercial Mediation and procedures that are
generally thought to be recent and alternative forms of dispute resolution. As with many
developments there are problems with definition, the workbook defines ADR, distinguishes
between conflict and dispute and outlines the history of ADR.
At the end of this section you will be able to:
Describe and explain the history of ADR
Describe the process of mediation
Discuss the frequently asked questions (FAQs) about mediation
Discuss how to work with a mediator
Definitions
There are many definitions of ADR
Alternative Dispute Resolution
Amicable Dispute Resolution
Appropriate Dispute Resolution
Another Disappointing Result
Another Damn Rip-Off
In the UK because of the long history of arbitration; the term ADR has normally been taken to
those techniques alternative to litigation and arbitration i.e. arbitration is not ADR. This has
caused confusion since arbitration in the USA is considered ADR! The water has been further
muddied by the Lord Chancellor's Department Current Consultation Paper Alternative
Dispute Resolution - a Discussion Paper which states:
119
The phrase Alternative Dispute Resolution now covers a variety of processes that
provide an alternative to litigation through the courts, and can be used to resolve
disputes where those involved would be unlikely to resort to the courts.
ADR processes include arbitration, early neutral evaluation, expert determination, mediation,
and conciliation. A description of how these processes work is included at the glossary. At
least for some, negotiation within the processes of litigation forms part of the ADR repertoire,
with important links to existing litigation practice.
Other more formal mechanisms for resolving disputes such as the private sector ombudsman
schemes, utility regulators, trade association arbitration schemes in certain trade sectors, and
even tribunals can also provide alternatives to the courts in some circumstances.
The various processes have very different characteristics. It can, sometimes be unhelpful and
confusing to group them together under one heading. A useful distinction is that between
processes in which a neutral third party makes a decision and those where the neutral offers
an opinion, and/or seeks to bring to the parties to an agreement. Here the term "alternative
adjudication" is used to encompass decision-making processes other than litigation through
the courts, such as arbitration, and expert determination, ombudsmen and regulators.
"Assisted settlement" is used to encompass processes designed to help the parties come to an
agreement, such as mediation, conciliation, and early neutral evaluation. Of course, it is
possible to have hybrid processes. "Med-arb", for example, describes a process where there is
an initial agreement to mediate the dispute and, if that fails to achieve settlement, to submit
outstanding issues to arbitration. In addition, some ombudsman schemes incorporate
mediation into their procedures.
In this context, the word "alternative" conveys only that these are methods of dispute
resolution which are not those in general use in litigation (which is why, for some, negotiation
does not fall within the ADR territory). It does not imply that the use of ADR techniques is in
some way second-best to going to court. A case has been made for referring instead to
appropriate dispute resolution, to reflect the arguments that some ADR techniques are better
suited to the needs of some cases or litigants than court proceedings. The term "Alternative
Dispute Resolution" is, however, probably now so well established that there is little prospect
of changing it.
Of course some of the procedures now considered as ADR are considered elsewhere in this
course; and discussing what constitutes ADR is one of life’s more meaningless and pointless
activities. This workbook is mainly concerned with Commercial Mediation but the next
Section also considers:
Med-Arb
Mini-trial (Executive Tribunal)
Early Neutral Evaluation
Expert Determination
Dispute Review Boards
Dispute Review Advisers
History Of ADR
120
There exists a widely held belief that ADR is a recent development, and that the techniques
referred to as ADR came from the USA. An interesting variant, variously quoted, is that
society and culture may affect dispute resolution; the most common manifestation of this
being that ‘Eastern’ cultures are less attracted to confrontation and therefore ADR came form
the East. Evidence for the first belief is contained in just about every section of Fenn and
Gameson (1992) and the second belief is widely alluded to in the same book.
Of course the widely held belief that ADR is a modern development is simplistic but the fact
that the American Bar Association (ABA) noted in 1985 a dearth of scholarship on the
historical aspects of ADR (See Sanchez 1996), indicates that a revival in interest in ADR took
place in the mid 1980’s. This is often the date ascribed by many of the ADR advocates when
recounting the widely held belief on the development of ADR.
From the ABA note of the lack of research into the history of ADR came a research
programme. That research considered dispute processing in Anglo-Saxon England, one of the
earliest stages on English legal history. The central findings of the research are that the
Anglo-Saxons used an array of dispute resolution processes. The array included processes,
which might be compared with:
Negotiation
Adjudication
Arbitration
Mediation
Further these processes were available to the parties during the life of an action on a dispute-
processing continuum. The processes and the inter-relationships of the dispute-processing
continuum were aimed at fostering respect for the legal processes and effecting the peaceful
and enduring resolution of disputes and promoting the reconciliation of the parties.
It could be argued that the recent interest in ADR shares many of these sentiments. Perhaps
not the fostering of respect for the law and legal processes since business, commerce and
industry have become more sophisticated. Many people would argue that commercial people
have no interest in the majesty of the legal process; their concern is for the effective resolution
of disputes; both peaceful and enduring. At the heart of the ADR philosophy has been the
reconciliation of the parties in order that they might have continuity in their commercial
affairs.
ADR is not a recent development and although it suits many people to claim truth in the
‘widely held belief’ the history of ADR can be reliably traced to 5th
Century England.
Commercial Mediation
Facilitative mediators are reluctant to provide decisions or recommendations, indeed some
mediators will not. Mediation lies at the facilitative end of the spectrum. Any settlement,
which occurs, is the parties' own and the analogy of chemical catalysts is often made. A
catalyst makes a reaction take place between two or more chemicals; the catalyst is not
affected or changed by the reaction. Sometimes the reaction will take place without the
catalyst and the effect is to speed up and sometimes the reaction will not take place without
the catalyst. The analogies with mediation are obvious.
121
Mediation is the most widely used and accepted ADR technique. Whilst there is no
prescriptive mediation process, the typical stages in a mediation might be:
A brief written summary of the matter in dispute is presented in advance to the
mediator;
The parties meet with a mediator for an initial joint meeting including perhaps
a brief oral presentation by the parties;
Caucus sessions, where the mediator has private meetings with the party in
turn. During the caucuses the mediator often shuttles backwards and forwards to
clarify issues and search for settlement possibilities. This process is often termed
shuttle diplomacy;
Plenary sessions are called to either continue negotiations directly, to conclude
agreement, or where the process is unsuccessful to conclude a mediation.
Most mediators agree to a contingency approach to mediation; that is there is no set procedure
but the procedure is tailored to suit the parties and the dispute in question. This often means
that mediation is conducted without joint meetings and the mediators play a variety of roles.
The mediator may act as a mere facilitator, there purely to assist communications.
Alternatively the mediator acts as a deal maker, to assist the parties in finding overlap in their
bargaining positions or encouraging concession and compromise. Perhaps the mediator acts
more as a problem solver assisting the parties in designing and searching for creative
solutions. The mediator may act as transformer transforming the dispute by allowing the
parties a fresh in-sight into the issues and their positions. The final role of the mediator maybe
as an adjudicator or assessor to provide the parties with an appraisal of the merits of the cases
on a legal, technical or even common sense standpoint.
Frequently Asked Questions: Mediation
How does it work?
Mediation involves a third party neutral taking the role of facilitator, evaluator or transformer
in helping parties to reach a settlement to a dispute
What is the process at a mediation?
There is no set procedure but the typical stages in a mediation could be:
A brief written summary of the dispute submitted in advance by the parties to
the mediator ;
An initial joint meeting where the parties make an oral presentation;
The mediator holds private meetings with the parties; this is often likened to
shuttle diplomacy with a mediator shuttling back and forward to clarify issues and
clarify settlement possibilities. Sometimes these sessions are known as caucuses;
Further joint meetings either to continue negotiations directly or draw up an
agreement or to conclude the mediation.
122
What is the role of the mediator?
Mediators play a variety of roles:
Facilitator - assisting communications and negotiations;
Dealmaker - assisting the parties by comparing bargaining positions or outlining
concessions;
Problem solver - assisting the parties by suggesting creative alternatives, options and
solutions;
Transformer - transforming the dispute by allowing the parties to develop a fresh in-
sight into the issues and their positions.
Evaluator - an adjudicator or an assessor providing the parties with an evaluation
either: legal; technical; or commercial, by way of an appraisal of their cases and
positions.
Does the mediator produce an enforceable award?
Most mediators act as facilitator and any settlement is the parties' own settlement, it is unusual
for mediators to produce awards. The process is thought to be non-binding, consensual and
non-adjudicative.
How can it work if it is not enforceable?
Mediation works because the presence of an independent third party neutral helps all parties
concentrate on reaching a settlement. Once a settlement is agreed it can be converted into an
enforceable contract like any other settlement agreement. Mediators can help in the process
of formalizing in the settlement.
How are mediators trained?
A variety of organizations provide training for mediators. The leaders in commercial
mediation are:
International: The Chartered Institute of Arbitrators www.arbitrators.org and the Centre for
Effective Dispute Resolution (CEDR)
USA: the American Arbitration Association
Formal training for mediators has historically been a two-stage process. The first stage is an
academic treatment of mediation practice and procedure followed by assessment during role-
play and scenarios. After successful completion of the first stage mediators then go on to
undertake a pupillage, where they take part in a number of mediation under the supervision of
an experience mediator. The pupil mediators are again assessed by the experienced mediators
for entry on to a panel of mediators when they can then take referrals in their own right.
Who are the mediators?
123
One school of thought says that good mediators are trained in dispute resolution, and
therefore need not necessarily know or understand the details of the dispute. Proponents of
this school point to America where undergraduate and postgraduate courses in dispute
resolution and in mediation exists. In the UK most mediators are drawn from a broad range of
disciplines and will have received a special training in mediation. Mediators can therefore
bring with them the specialisms of architecture, construction, the law, surveying etc to help
with construction disputes.
What about confidentiality?
It is normal for mediation providers and the mediators to require the parties and the mediator
to sign a confidentiality agreement. This ensures the process is treated as a without prejudice
negotiation on a strictly confidential basis. The mediator cannot be called afterwards to give
evidence of what took place. Where parties are particularly concerned about confidentiality in
joint meetings, the mediation can be conducted by means of separate meetings between the
mediator and each party.
An example of the confidentiality clause common in mediation agreements is shown below:
The mediation is to be conducted on a confidential basis and on a without prejudice
basis unless and until, and to the extent that, the parties otherwise jointly agree.2
Proposing mediation indicates a negotiating weakness?
Proposing mediation is not a sign of weakness but a suggestion of confidence on the
proposing party's ability to put their cards on the table and negotiate a positive commercial
solution. The effect a neutral third party mediator has on dispute negotiations is often
underestimated. However the initiation of getting mediation going can be difficult because
parties are often unfamiliar with mediation. This can be alleviated by including mediation
clauses in commercial contracts, and or allowing the first approach for mediation to come
from an ADR provider.
When is the best time to suggest mediation?
As there is no single process of mediation there is no single correct time in the dispute to
suggest mediation. However the earlier the process can begin the more likely the parties are to
achieve savings in costs and time; and notably the less likely is that the parties will have
become entrenched in their positions and into the adversity of dispute. It might be appropriate
to delay suggesting mediation where one party suspects that the other party is not seriously
interested in reaching a solution, or if a party still needs time to gather information for its
case. The following points are worth considering
A mediator may be able to help the parties in managing the information
gathering and case evaluation process;
2 JCT 98, PN 28/95.
124
Mediation does not ordinarily involve the examination or cross-
examination of witnesses, but takes an overall commercial approach given the
need to arrive settlement;
Mediation can be used not only for the initial attempt settlement but it
can be tried again later when circumstances change;
There are few risks in attempting mediation and the parties can always
abandon the process if it proves unproductive;
Most mediations, and most mediators, will only last a day at very most
three days to assess settlement possibilities.
How much does mediation costs?
How long is a piece of string. The service of trained experience mediators can be secured
from the leading ADR providers at reasonable commercial costs (starting at £50 per party per
hour). It is normal that the parties bear their own costs of the mediation proceedings and
share the fees of the mediator. There are often few additional costs in preparing for mediation,
and mediation can assists in the information gathering process so that any costs are marginal.
The benefits of mediation
The benefits of mediation are often summarised under the six C's
Consensual - parties agree to seek business solutions assisted by their advisers and a neutral
mediator.
Control - the parties agree a timetable, procedure, and the agenda. The outcome is a
contractual agreement or consent award.
Cost savings - the emphasis is on key issues not on exhausting every avenue to substantiate a
case or to refute the other side's evidence before the tribunal.
Continuing business relations - the emphasis is on the communication of interests between the
parties, on solving the problem, and on commercial business solutions.
Confidentiality - ADR meetings are private, and should be used to explore creative solutions
and agree pragmatic settlements.
Creative - in ADR commercial and business solutions are not limited by legal rules. Current
and future interests and any other aspects can be explored to achieve a solution.
How to work with a mediator
Prepare
Prepare your case in sufficient detail to allow you to negotiate effectively while concentrating
on essentials. Mediation is not a binding adjudicative process, you do not need to explore
every eventuality in case it might be relevant.
125
Summarise the core issues
Prepare a brief written summary of the dispute and your case, summarised the core issues and
evidence. Include documents which are essential to the case, if there are tricky legal or
technical question as part of the dispute agree upon an independent assessment by a third
party. The Mediator a can help in appointing the independent assessor, or by using the parties'
expert reports point the parties towards a settlement.
Recognise the various roles mediators may have to play
Mediators play a variety of roles to assist the parties:
Facilitator - there to purely assist communication;
Deal maker - helping parties find overlap in their bargaining positions or
encouraging concessions;
Problem solver - assisting in the search for creative options;
Transformer - to transform the dispute and open up creative avenues for
settlement;
Adjudicator assessor - providing the parties with legal technical appraisal of
the merits of their case.
It is important to the parties work closely with a mediator in private sessions in order to make
best use of the mediator's skills.
Confidentiality
Indicate clearly which information you expect a mediator to keep confidential in discussions
with other party. The mediator will normally assume that communications in a caucus; are
confidential unless otherwise indicated.
Limit those attending
Limit the numbers of staff and representatives attending the mediation; to those decision-
makers and professional advisers who can contribute to the settlement of the dispute. If
evidence or input from others is required, particularly experts, they can be brought in as and
when necessary.
Complex issues
If the case involves many parties or complex technical and legal issues, considering agreeing
with the other party to the use co-mediators or to an assessor working with mediator.
Flexibility
Be prepared to be flexible. The mediation will only reach a settlement if the parties bring a
genuine willingness on for new solutions take and give concessions, in the interests of
achieving a settlement. Argue your best case to protect your rights but do so with an open
mind and a view towards pragmatic alternatives by a mediated settlement. If you're looking
for a third party to adjudicate or give an award you should not be in mediation.
126
Self-Appraisal Questions
1) Am I able to demonstrate that I can now meet the objectives set out at the start of this
section
Looking at my responses to the exercises, can I:
2) Explain the different mediation styles and models
i) Facilitative
ii) Evaluative
iii) Settlement
iv) Transformative
3) Discuss the arguments for and against the different mediation styles and models
i) Facilitative
ii) Evaluative
iii) Settlement
iv) Transformative
4) Evaluate the use of the different mediation styles and models
i) Facilitative
ii) Evaluative
iii) Settlement
iv) Transformative
v) Discuss the contingent model of the mediation