Time at Large

2
X Network Access Message: The page cannot be displayed  Explanation: There is a problem with the page yo u are trying to reach and it cannot be displayed. Tr t h e f o l l o win: You are here: Related Articles Construction La w  All Answers Answers by Expert: Ask Experts Volunteer  Alina Valentina Oprea Expertise I can answer to questions regarding FIDIC 1999 contracts, including practical use of these conditions of contract, as well as to questions regarding dispute boards, both from theoretical and practical point of view. I cannot answer to questions related to procurement process, except to some (limited) extent. Experience implementation of works contracts (FIDIC 1999) financed by different financial institutions, including European Union; dispute boards Publications  see http://alina.oprea.v.googlepag es.com/publications ; DRBF Forum Newsletter; Drumuri si Poduri; Revista Constructiilor; SIDiR Newsletter Education/ Credentials  Graduated the University of Civil Engineering Bucharest, Faculty of Railways, Roads and Bridges (1985-1990); Trained under Mr. Gwyn Owen’s pupilage scheme for arbitrators/adjudicators under Ho me Indu st ry Co ns tr uc ti on Indu st ry Co ns tr uc ti on Law Time at large Advertisement Construction Law / Time at large Expert: Alina Valentina Oprea - 7/9/2010  Question Dear, 1. Please explain me the basic concept of "Time at large"? 2. Secondly, if the contractual time of completion or Time of completion after giving Extension of time has passed. Also maximum Liquidated Damages has been levied. Than what to do, if Employer donot want to terminate the contractor as work left is less? Answer  Dear Zafar, Here are the answer to your questions, sent previously, as well. 1. “Time at large” concept deals with waiving the obligation of the Contractor to comply with the Time for Completion when the Employer prevented the Contractor to finalize the works within the Time for Completion. It was used first in the Common Law area, when the mechanism of contract did not al low for extension of time when the Employer did not fulfil l its obligations.  “Time at large” allows the Contractor to finalize the works within reasonable time, instead within the Time for Completion time, when the actions or inactions of the Employer prevented the Contractor to finalize in time the works. For example, if the Employer did not grant the access to the site at the time foreseen in the contract, but later, and the works were delayed because of this, and in the contract there is no mechanism which allows the Contractor to obtain extension of time for completion because of this late possession of site, then the time for completion, in case the Contractor demonstrates the incurred delay and that no mechanism f or granting extension of time because of the Employer’s failure, becomes “time at large”, and the Contractor is allowed to finalize the works within a reasonable time. 2. So, what to do when the works are not finali zed, the time for completion has passed and the maximum amount of Liquidated Damages has been levied… Many Employers ask themselves this question, when they do not want to terminate the Contract, especially when there is not much works to be done. The answer is in the negotiating abilities of the Employer and Engineer mainly, and in the wisdom of the Contractor, all of them being interested in keeping their good name and reputation by finalizing a good piece of work. Another method, which could be complementary to the first one, could be to find the actual reason of not finalizing the works by the Contractor – could be claims not resolved, lack of resources or financial means from the Contractor. Discussions between the Parties, with the help of a mediator or other neutral person, or even with the help of the Engineer – if the Parties do not have bad feelings against him – could lead to agreed solutions to finalize the works in agreed conditions. Best regards, Alina X Network Access Message: Th e page cannot be displayed  Explanation: There is a problem with the page you and it cannot be displayed. Try the following:  Refresh page: Search for the page again by cli button. The timeout may have occurred due to I Check spelling: Check that you typed the Web correctly. The address may have been mistyped.  Access from a link: If there is a link to the pag for, try accessing the page from that link. If you are still not able to view the requested page, try c administrator or Helpdesk. Add to thi s Answer Ask a Questi on Excuses for Not Going to Work - Excuses for Missing Work for a Job Interview Facing Discrimination - Migraines Surgery Questions Work - Questions to Ask at Work Before Surgery Work Leaves and Career Changes - Pregnancy Over 35 Job Interview Answers: Questions About Co-Workers and Supervisors kifle semu Alina Valentina Oprea Daniel Kazado Florin NICULESCU Shan Greer John Dowse Nasir Gilani Syed Senthil Kumar Sellamuthu Bogdan Oprea Liaqat Hayat Peter M. Elliott Pa ge 1 of 2 Construction Law: Time at large, concept of time, zafar 3/16/2011 http://en.allexperts.com/q/Construction-Law-914/2010/7/Time-large-5.htm

Transcript of Time at Large

Page 1: Time at Large

8/4/2019 Time at Large

http://slidepdf.com/reader/full/time-at-large 1/2

X Network Access Message: The page cannot be displayed 

Explanation: There is a problem with the page you are trying to reach

and it cannot be displayed.

Tr the follow in :

You are here:

Related Articles

ConstructionLaw  

All Answers

Answers by Expert:

Ask Experts

Volunteer

 Alina Valentina Oprea

Expertise

I can answer to questions

regarding FIDIC 1999

contracts, including practical

use of these conditions of 

contract, as well as to

questions regarding dispute

boards, both from theoretical

and practical point of view. I

cannot answer to questions

related to procurement

process, except to some

(limited) extent.

Experience

implementation of works

contracts (FIDIC 1999)

financed by different financial

institutions, including

European Union; dispute

boards

Publications  

see

http://alina.oprea.v.googlepag

es.com/publications ; DRBF

Forum Newsletter; Drumuri si

Poduri; Revista Constructiilor;

SIDiR Newsletter

Education/ Credentials 

Graduated the University of 

Civil Engineering Bucharest,

Faculty of Railways, Roads

and Bridges (1985-1990);

Trained under Mr. Gwyn

Owen’s pupilage scheme for

arbitrators/adjudicators under

Home Industry Construct ion Industry Construct ion Law Time at large

Advertisement

Construction Law /Time at large

Expert: Alina Valentina Oprea - 7/9/2010

 

Question 

Dear,

1. Please explain me the basic concept of "Time at large"?

2. Secondly, if the contractual time of completion or Time of 

completion after giving Extension of time has passed. Also

maximum Liquidated Damages has been levied. Than what to do,

if Employer donot want to terminate the contractor as work left is

less?

Answer 

Dear Zafar,

Here are the answer to your questions, sent previously, as well.

1. “Time at large” concept deals with waiving the obligation of the

Contractor to comply with the Time for Completion when the

Employer prevented the Contractor to finalize the works within the

Time for Completion. It was used first in the Common Law area, when the mechanism of contract did not al low for

extension of time when the Employer did not fulfil l its obligations.

 “Time at large” allows the Contractor to finalize the works within reasonable time, instead within the Time for

Completion time, when the actions or inactions of the Employer prevented the Contractor to finalize in time the works

For example, if the Employer did not grant the access to the site at the time foreseen in the contract, but later, and

the works were delayed because of this, and in the contract there is no mechanism which allows the Contractor toobtain extension of time for completion because of this late possession of site, then the time for completion, in case

the Contractor demonstrates the incurred delay and that no mechanism for granting extension of time because of the

Employer’s failure, becomes “time at large”, and the Contractor is allowed to finalize the works within a reasonable

time.

2. So, what to do when the works are not finalized, the time for completion has passed and the maximum amount of 

Liquidated Damages has been levied… Many Employers ask themselves this question, when they do not want to

terminate the Contract, especially when there is not much works to be done. The answer is in the negotiating abilities

of the Employer and Engineer mainly, and in the wisdom of the Contractor, all of them being interested in keeping

their good name and reputation by finalizing a good piece of work. Another method, which could be complementary to

the first one, could be to find the actual reason of not finalizing the works by the Contractor – could be claims not

resolved, lack of resources or financial means from the Contractor. Discussions between the Parties, with the help of a

mediator or other neutral person, or even with the help of the Engineer – if the Parties do not have bad feelings

against him – could lead to agreed solutions to finalize the works in agreed conditions.

Best regards,

Alina

XNetwork Access Message: Thepage cannot be displayed 

Explanation: There is a problem with the page you

and it cannot be displayed.

Try the following: 

Refresh page: Search for the page again by clbutton. The timeout may have occurred due to

Check spelling: Check that you typed the Webcorrectly. The address may have been mistyped

 Access from a link: If there is a link to the pafor, try accessing the page from that link.

If you are still not able to view the requested page, try cadministrator or Helpdesk.

Add to this Answ er Ask a Question

Excuses for Not Going to Work - Excuses for Missing Work for a Job Interview•

Facing Discrimination - Migraines•

Surgery Questions Work - Questions to Ask at Work Before Surgery•

Work Leaves and Career Changes - Pregnancy Over 35•

Job Interview Answers: Questions About Co-Workers and Supervisors•

kifle semu

Alina Valentina Oprea

Daniel Kazado

Florin NICULESCU

Shan Greer

John Dowse

Nasir Gilani Syed

Senthil Kumar

Sellamuthu

Bogdan Oprea

Liaqat Hayat

Peter M. Elliott

Page 1 oConstruction Law: Time at large, concept of time, zafar

3/16/20http://en.allexperts.com/q/Construction-Law-914/2010/7/Time-large-5.htm

Page 2: Time at Large

8/4/2019 Time at Large

http://slidepdf.com/reader/full/time-at-large 2/2

FIDIC mentoring scheme

(2006 – 2007)

©2011 About.com, a part of The New York Times Company. All rights reserved.

User Agreement Privacy Policy Encyclopedia

Browse Answers:

About Us Tell Friends How to Ask How to Volunteer FAQ Tech Support Top Experts Expert Login

By Category Alphabetically 

Page 2 oConstruction Law: Time at large, concept of time, zafar

3/16/20http://en.allexperts.com/q/Construction-Law-914/2010/7/Time-large-5.htm