Talimarjan Clean Power Project
Transcript of Talimarjan Clean Power Project
1
Environmental Monitoring Report
Revised: August 2014
Reporting Period of January – June 2014
№ 2629-UZB и № 2630-UZB:
Talimarjan Clean Power Project.
Prepared by PMU «Talimarjan ТPР»
for the Asian Development Bank.
2
ABBREVIATIONS
TPP – Talimarjan Power Plant
CCGT
PMU
–
-
Combined Cycle Gas Turbine
Project Management Unit
SPS
EIA
NPC
EMP
SEMP
NES
IES
CDM
KMK
PDD
UNFCCC
–
-
-
-
-
-
-
-
-
-
-
Safeguards policy statement
Environmental impact assessment
Nature Protection Committee
Environmental Management Plan
Site Environmental Management Plan
National environmental specialist
International environmental specialist
Clean Development Mechanism
Karshi Main Canal
Project design document
Framework Convention on Climate Change of the
United Nations
CSMM - Corporate Solutions и Mott MacDonald Team
HDEC - Hyundai Engineering and Construction and Daewoo
International Consortium
HSE plan - Health, Safety and Environmental Plan
WEIGHTS AND MEASURES
MW – Megawatt
km – Kilometer
°C – Celsius degree
3
GLOSSARY
I Section. Introduction………………..………………………………. 5
1.1 General information on environment protection………. 5
1.2 Description of the construction works under the project… 8
1.3 Changes in the organization or composition of the
Environment Department …………………………………… 9
II Section. Environmental Management ………………………………… 11
2.1 Status of Environmental Management ………………….. 11
2.2 Ecological monitoring..…………………………….…….. 11
Appendix
1.
Decree Cabinet of Ministry of Republic of Uzbekistan
№ 491 «On government ecological expertise»……………..
Appendix
2.
The environmental clearance from Nature Protection
Committee…………………………………………………...
Appendix
3.
Results of environmental inspection (report prepared by the
Supervision consultant of Corporate Solutions и Mott
MacDonald, May 2014)…………..……………..
Appendix
4.
Monthly Environmental Monitoring Report (report was
prepared by «Hyundai Engineering and Construction and
Daewoo International Consortium», June 2014)……………….
Appendix
5.
Site Based Environmental Management Plan (SBEMP)
(prepared by «Hyundai Engineering and Construction and
Daewoo International Consortium», July
2014)……………………………………… …
Appendix
6.
Public complaints-handling mechanism on the Project
“Expansion of Talimarjan TPP with the construction of two
CCGT with a capacity of 450 MW" (PMU, July
2014)………………………………….................
4
NOTE
In this report, "$" refers to US dollars. This environmental monitoring report is a document of the borrower. The views
expressed herein do not necessarily represent those of ADB's Board of Directors,
Management, or staff, and may be preliminary in nature.
In preparing any country program or strategy, financing any project, or by making
any designation of or reference to a particular territory or geographic area in this
document, the Asian Development Bank does not intend to make any judgments as to
the legal or other status of any territory or area.
Company authorized representative
I certify that the data contained in this report completely and accurately represents
operations during this reporting period:
Signature: Yuliya Yakubova
Title: Safeguard Specialist of “Talimarjan TPP” PMU
Date: August 2014
Contact Details:
Telephone: (+998 71) 233-24-30
Mobile: (+998 93) 530-46-21
E-mail: [email protected] , [email protected]
5
1. INTRODUCTION
The project is implemented in accordance with the Decree of the President of the
Republic of Uzbekistan dated 7 March 2013 No.ПП-1933 "On the measures to
ensure the implementation of the investment project “Expansion of Talimarjan TPP
with the construction of two CCGT with a capacity of 450 MW". The site is an
existing gas fired power plant, which currently generates 800 megawatts (MW). The
project will install two additional combined cycle gas turbine (CCGT) units of about
450 MW each at the site.
Based on ADB's safeguards policy statement (SPS), the Project is classified as
follows: (i) environment (category A) – environmental impact assessment (EIA), (ii)
involuntary resettlement (category C) – no actions, and (iii) indigenous peoples
(category C) – no actions. Therefore, an environmental clearance from ADB was
obtained in December 2009.
According of Decree Cabinet of Ministry of Republic of Uzbekistan № 491 «On government ecological expertise» the Project is classified as a class 1 Project (is attached in appendix 1) Under the Uzbekistan Environmental Legislation. The environmental clearance was obtained from Nature Protection Committee (NPC) on 5 October 2009. According to the legislation of the Republic of Uzbekistan the correction is made after 3 years, a new Conclusion of Ecological Expertise № 18/768 dated 13 August 2013 is received (attached in appendix 2).
The objective of this report is to provide a progress in implementing
Environmental Management Plan and Environmental Monitoring Plan (EMP) as
stated in the Environmental impact. This Report was prepared to cover the period of
January – June 2014
1.1. OVERALL ENVIRONMENTAL INFORMATION
Is the project materially
compliant with all relevant
ADB Requirements
Yes �
No �
Is the project materially
compliant with all
Yes �
6
applicable environmental
and social laws and
regulations?
No �
Have there been any
accidents or incidents that
have caused damage to the
environment, brought
about injuries or fatalities,
affected project labour or
local communities,
affected cultural property,
or created liabilities for
the company?
Yes �
No �
Have there been any
changes to environment,
social, labour or health
and safety laws or
regulations that have
materially affected the
company?
Yes �
No �
How many inspections did
Uzbekenergo perform
during the reporting
period?
1 On May 2 2014 the Monitoring of
compliance with environmental measures
was conducted at the construction site of
CCGT by Yuliya Yakubova, PMU Safeguard
Specialist. Visual inspection on the main
environmental indicators was conducted.
Violations of environmental legislation and
safety regulations were not revealed.
Construction works are mostly in compliance
with the agreed Environmental Management
Plan.
Environmental Specialist at the plant Nizom
Rakhimov conducts a Monitoring of
compliance with environmental measures on
7
a monthly basis.
How many inspections
have been conducted by
the Supervision
Consultant during the
reporting period?
6 Natasha Sim, Supervision Consultant has
visited construction site: on 21-22, 28
January; 25-26 February; 5-6, 12-13 March;
8-9, 15-16 April; 5-8, 13 May; and 17-19, 26-
27 June 2014.
According to results of the conducted
inspections the Consultant provided the PMU
with reports. The environmental inspection
results from May 2014 is presented in
Appendix 3.
How many inspections
have been conducted by
local ecological bodies
during the reporting
period?
0 Due to the fact that the Talimarjan TPP is
restricted access enterprise, the Karshi
Regional Committee for the Nature
Protection conducts the coordination
inspection 1 time in 3 years.
The latest actions inspection at EU
Talimarjan TPP was held in March 2014.
However that inspection did not involve
construction site since the Contractor and
Subcontractor are separate legal entities, thus
inspection of their activities shall be
conducted on individual basis, as per
prescribed rules.
Have these visits resulted
in any penalties, fines
and/or corrective action
plans?
Yes �
No �
Has the Company engaged
any contractors for
project-related work in the
Yes �
No �
Contract Agreement
No.SJSC/UzbekEnergo/ICB-2010-001
between the UE "Talimarjan TPP", SJSC
"Uzbekenergo" and the Consortium of the
8
reporting period? foreign companies «Hyundai Engineering
and Construction and Daewoo International
Consortium» for the “turnkey” construction
of two combined-cycle plants with a capacity
of 450 MW was signed on 07 March 2013.
Were any of the violations
stated above the
responsibility of
contractors?
Yes �
No �
Have any operations been
reduced, temporarily
suspended or closed down
due to environmental,
health, safety or labour
reasons?
Yes �
No �
Please describe any environment or social programmes, initiatives or sub-projects
undertaking during the reporting period to improve the company’s environmental or
social performance and/or management systems:
Within the framework of the project Capacity development program is
implemented under Loan # 2630). Selection of Consultant for environmental and
social Safeguards and Gender is implemented under this program as one of the
subcomponents.
Over a reporting period the bids have been invited on this subcomponent and on
June 12, 2014 shortlist of consultants approved.
1.2. DESCRIPTION OF CONSTRUCTION WORK
During the period under review the project is at the stage of construction works. According to the report on project implementation for June 2014, submitted by Hyundai Engineering and Construction and Daewoo International Consortium (HDEC), on June 30 2014, the project overall progress is 22,26%.
9
1.3. ORGANIZATION OF ENVIRONMENTAL WORK
There are no changes in the composition of the Environment Department. PMU Environment Specialist - Yuliya Yakubova Station Ecologist - Nizom Rakhimov
Since 1 July 2013 the International Environmental Specialist of "Corporate
Solutions Consulting Limited" Natasha Sim has commenced the work. Also from the
party of Corporate Solutions and Mott MacDonald Team (CSMM) the local
consultant on Social, Gender and Environmental issues Lyudmila Khegay is
involved.
Since 10 October 2013 the Contractor's representative Mr. Jeong Hyeon Kim
works at the construction site, who provides active support and regular inspections on
HSE in accordance with the Environmental Management Plan, as well as his assistant
Khusan Khidirov, Environmental and Safety Specialist. Since June 2014 a safety and
environmental engineer – Amanov Oybek has also been working on construction site.
In April 2014 Shaybalov Oybek- subcontractor (Tupolang) ecologist was
employed.
10
Regarding environmental works: The Contractor shall (a) establish an operational system for managing environmental impacts, (b) carry out all of the monitoring and mitigation measures set out in the Environmental Management Plan (EMP).
The Contractor shall submit to the Employer monthly reports on the carrying out
of such measures.
As of today HDEC provides PMU with monthly progress reports, which includes
a chapter "HSE Management", as well as separate monthly report on « environmental
protection and safety code » (attached in appendix 4).
The consultant also provides PMU with a quarterly report, that includes a section
on HSE, the report on monitoring the implementation of the Environment Work Plan
after visiting the construction site, as well as monthly and semi-annual reports on the
results of an environmental inspection.
All these reports PMU reviews, analyzes and takes corrective measures if needed.
According to the results of joint activities Contractor - Consultant - PMU the semi-
annual Environmental reports for the ADB are carried out.
Also according to ADB policy, the PMU sends the semi-annual Environmental
reports to the Karshi Regional Committee for the Nature Protection for reference.
ADB
Ms. Dewi Utami
PMU
Yuliya Yakubova
CSMM
Natasha Sim
Hundai
Mr. Jeong Hyeon Kim
Hundai
Khusan Khidirov
CSMM
Lyudmila Khegay
Talimarjan TPP
Nizom Rakhimov
Hundai
Oybek Amanov
Tupolang
Oybek Shaybalov
11
II. ENVIRONMENTAL MANAGEMENT PLAN (EMP)
2. 1 STATUS OF ENVIRONMENTAL MANAGEMENT PLAN.
In September 2013, HDEC has provided the HSE plan, which includes the Site
Environmental Management Plan (SEMP) and Environmental Protection Plan. This
plan has been reviewed by the PMU and the Consultant and sent to the Contractor for
updating. When updating the HSE plan the Contractor was recommended to base
upon the environmental impact assessment (2009), Environmental Action Plan
(2009).
This plan was under updating 2 more times and the final third version of the EMP,
which was acceptable to PMU and Consultant, was completed in January 2013.
It was also agreed, that every 6 months the SЕМР will be revised for continual
improvement. In May 2014, HDEC, PMU, and CS-MM revised and checked SЕМР
to reflect current conditions and status of site. The objective is to ensure continual
improvement (ISO 14000).
The new Site Based Environmental Management Plan (SВЕМР) was finally
updated by the Contractor and submitted to the PMU (attached in appendix 5).
The new plan is convenient for the ongoing project and guarantees minimum
negative impacts on the environment. SBEMP will be observed by the Contractor
and monitored by SJSC “Uzbekenergo” and the Consultant.
2. 2 ECOLOGICAL MONITORING.
Based on EIA, the PMU with the Station ecologist has carried out the Monitoring
of compliance with the requirements of the Environmental Management Plan
(SEMP) at the construction site. By the PMU the monitoring was conducted one time
in May 2014, but station ecologist conducts a visual inspection of the construction
site on a monthly basis. The main violation detected during inspections is insufficient
watering of green spaces. During the construction works the watering system has
been damaged. Therefore the trees growing on the surrounding grounds need
additional watering.
The Chemical Analysis Laboratory of the station also carries out monthly
analyzes of water samples from the Karshi Main Canal and sewage treatment plants.
12
All violations detected would be recorded and eliminated as work proceeds. In
the accounting period no material breaches of operational code for electrical
installations requirements, which may negatively influence the state of environment
has been recorded. Preoperational and construction works are being conducted in
accordance with environmental legislation of the Republic of Uzbekistan.
Monitoring of the implementation of SEMP on a regular basis is conducted by the
Consultant. In the accounting period Consultant has conducted six environmental
audits. Audit findings are described in (attached in appendix 3).
HDEC engineers conduct daily tours and site surveys. All environmental
indicators are monitored: quality of the water, open air, warehousing and recycling of
household and industrial waste, noise level, means of transport, safety code etc. More
detailed information on the Contractor’s activities can be found in monthly reports by
HDEC on environmental protection and safety code (attached in appendix 4).
Instrumental gauging of noise levels in June are as follows:
Table 2.2.1
13
The EPC Contractor also has concluded a contract with the company for waste
disposal and carries out regular HSE trainings.
According to the recommendations of Co ltd «Nazar Business Technology»,
which in October 2013 conducted ecological audit on the project, the Contractor has
been carrying out systematic trainings on environmental protection and safety code
(on 30th of each month).
For the purpose of project information release semi-annual reports by PMU are
submitted to local agency on conservation of nature and local authority.
Labour and human population complaints mechanism is also implemented as part
of the project. For this purpose there is available free a « book of complaints and
suggestions » in the staff office (attached in appendix 6). In the accounting period no
human population claims have been noted.
The PMU is attentive to recommendations of the CSMM-consultant to improve
the monitoring of the implementation of SEMP and to improve the rating of the
project. The consultant recommended that the Contractor (HDEC) is to develop a
regulatory environmental documentation for the period of construction works and to
provide the local authority for the nature protection with statistical reports. The final
decision on the implementation of these recommendations is still pending. The PMU
and HDEC continue consultations with experts of the State Nature Protection
Committee of Uzbekistan about the feasibility of developing additional
documentation and the statistical reporting procedure.
Monitoring shows that the environmental requirements at the stage of construction
works are fulfilled satisfactorily. In the accounting period no violation of
environmental regulation, or claims from the human population have been noted.
This semi-annual report on the monitoring of environment protection covers the
period of January – June 2014.
1
Environmental Monitoring Report
Revised: August 2014
Reporting Period of January – June 2014
№ 2629-UZB и № 2630-UZB:
Talimarjan Clean Power Project.
Prepared by PMU «Talimarjan ТPР»
for the Asian Development Bank.
2
ABBREVIATIONS
TPP – Talimarjan Power Plant
CCGT
PMU
–
-
Combined Cycle Gas Turbine
Project Management Unit
SPS
EIA
NPC
EMP
SEMP
NES
IES
CDM
KMK
PDD
UNFCCC
–
-
-
-
-
-
-
-
-
-
-
Safeguards policy statement
Environmental impact assessment
Nature Protection Committee
Environmental Management Plan
Site Environmental Management Plan
National environmental specialist
International environmental specialist
Clean Development Mechanism
Karshi Main Canal
Project design document
Framework Convention on Climate Change of the
United Nations
CSMM - Corporate Solutions и Mott MacDonald Team
HDEC - Hyundai Engineering and Construction and Daewoo
International Consortium
HSE plan - Health, Safety and Environmental Plan
WEIGHTS AND MEASURES
MW – Megawatt
km – Kilometer
°C – Celsius degree
3
GLOSSARY
I Section. Introduction………………..………………………………. 5
1.1 General information on environment protection………. 5
1.2 Description of the construction works under the project… 8
1.3 Changes in the organization or composition of the
Environment Department …………………………………… 9
II Section. Environmental Management ………………………………… 11
2.1 Status of Environmental Management ………………….. 11
2.2 Ecological monitoring..…………………………….…….. 11
Appendix
1.
Decree Cabinet of Ministry of Republic of Uzbekistan
№ 491 «On government ecological expertise»……………..
Appendix
2.
The environmental clearance from Nature Protection
Committee…………………………………………………...
Appendix
3.
Results of environmental inspection (report prepared by the
Supervision consultant of Corporate Solutions и Mott
MacDonald, May 2014)…………..……………..
Appendix
4.
Monthly Environmental Monitoring Report (report was
prepared by «Hyundai Engineering and Construction and
Daewoo International Consortium», June 2014)……………….
Appendix
5.
Site Based Environmental Management Plan (SBEMP)
(prepared by «Hyundai Engineering and Construction and
Daewoo International Consortium», July
2014)……………………………………… …
Appendix
6.
Public complaints-handling mechanism on the Project
“Expansion of Talimarjan TPP with the construction of two
CCGT with a capacity of 450 MW" (PMU, July
2014)………………………………….................
4
NOTE
In this report, "$" refers to US dollars. This environmental monitoring report is a document of the borrower. The views
expressed herein do not necessarily represent those of ADB's Board of Directors,
Management, or staff, and may be preliminary in nature.
In preparing any country program or strategy, financing any project, or by making
any designation of or reference to a particular territory or geographic area in this
document, the Asian Development Bank does not intend to make any judgments as to
the legal or other status of any territory or area.
Company authorized representative
I certify that the data contained in this report completely and accurately represents
operations during this reporting period:
Signature: Yuliya Yakubova
Title: Safeguard Specialist of “Talimarjan TPP” PMU
Date: August 2014
Contact Details:
Telephone: (+998 71) 233-24-30
Mobile: (+998 93) 530-46-21
E-mail: [email protected] , [email protected]
5
1. INTRODUCTION
The project is implemented in accordance with the Decree of the President of the
Republic of Uzbekistan dated 7 March 2013 No.ПП-1933 "On the measures to
ensure the implementation of the investment project “Expansion of Talimarjan TPP
with the construction of two CCGT with a capacity of 450 MW". The site is an
existing gas fired power plant, which currently generates 800 megawatts (MW). The
project will install two additional combined cycle gas turbine (CCGT) units of about
450 MW each at the site.
Based on ADB's safeguards policy statement (SPS), the Project is classified as
follows: (i) environment (category A) – environmental impact assessment (EIA), (ii)
involuntary resettlement (category C) – no actions, and (iii) indigenous peoples
(category C) – no actions. Therefore, an environmental clearance from ADB was
obtained in December 2009.
According of Decree Cabinet of Ministry of Republic of Uzbekistan № 491 «On government ecological expertise» the Project is classified as a class 1 Project (is attached in appendix 1) Under the Uzbekistan Environmental Legislation. The environmental clearance was obtained from Nature Protection Committee (NPC) on 5 October 2009. According to the legislation of the Republic of Uzbekistan the correction is made after 3 years, a new Conclusion of Ecological Expertise № 18/768 dated 13 August 2013 is received (attached in appendix 2).
The objective of this report is to provide a progress in implementing
Environmental Management Plan and Environmental Monitoring Plan (EMP) as
stated in the Environmental impact. This Report was prepared to cover the period of
January – June 2014
1.1. OVERALL ENVIRONMENTAL INFORMATION
Is the project materially
compliant with all relevant
ADB Requirements
Yes �
No �
Is the project materially
compliant with all
Yes �
6
applicable environmental
and social laws and
regulations?
No �
Have there been any
accidents or incidents that
have caused damage to the
environment, brought
about injuries or fatalities,
affected project labour or
local communities,
affected cultural property,
or created liabilities for
the company?
Yes �
No �
Have there been any
changes to environment,
social, labour or health
and safety laws or
regulations that have
materially affected the
company?
Yes �
No �
How many inspections did
Uzbekenergo perform
during the reporting
period?
1 On May 2 2014 the Monitoring of
compliance with environmental measures
was conducted at the construction site of
CCGT by Yuliya Yakubova, PMU Safeguard
Specialist. Visual inspection on the main
environmental indicators was conducted.
Violations of environmental legislation and
safety regulations were not revealed.
Construction works are mostly in compliance
with the agreed Environmental Management
Plan.
Environmental Specialist at the plant Nizom
Rakhimov conducts a Monitoring of
compliance with environmental measures on
7
a monthly basis.
How many inspections
have been conducted by
the Supervision
Consultant during the
reporting period?
6 Natasha Sim, Supervision Consultant has
visited construction site: on 21-22, 28
January; 25-26 February; 5-6, 12-13 March;
8-9, 15-16 April; 5-8, 13 May; and 17-19, 26-
27 June 2014.
According to results of the conducted
inspections the Consultant provided the PMU
with reports. The environmental inspection
results from May 2014 is presented in
Appendix 3.
How many inspections
have been conducted by
local ecological bodies
during the reporting
period?
0 Due to the fact that the Talimarjan TPP is
restricted access enterprise, the Karshi
Regional Committee for the Nature
Protection conducts the coordination
inspection 1 time in 3 years.
The latest actions inspection at EU
Talimarjan TPP was held in March 2014.
However that inspection did not involve
construction site since the Contractor and
Subcontractor are separate legal entities, thus
inspection of their activities shall be
conducted on individual basis, as per
prescribed rules.
Have these visits resulted
in any penalties, fines
and/or corrective action
plans?
Yes �
No �
Has the Company engaged
any contractors for
project-related work in the
Yes �
No �
Contract Agreement
No.SJSC/UzbekEnergo/ICB-2010-001
between the UE "Talimarjan TPP", SJSC
"Uzbekenergo" and the Consortium of the
8
reporting period? foreign companies «Hyundai Engineering
and Construction and Daewoo International
Consortium» for the “turnkey” construction
of two combined-cycle plants with a capacity
of 450 MW was signed on 07 March 2013.
Were any of the violations
stated above the
responsibility of
contractors?
Yes �
No �
Have any operations been
reduced, temporarily
suspended or closed down
due to environmental,
health, safety or labour
reasons?
Yes �
No �
Please describe any environment or social programmes, initiatives or sub-projects
undertaking during the reporting period to improve the company’s environmental or
social performance and/or management systems:
Within the framework of the project Capacity development program is
implemented under Loan # 2630). Selection of Consultant for environmental and
social Safeguards and Gender is implemented under this program as one of the
subcomponents.
Over a reporting period the bids have been invited on this subcomponent and on
June 12, 2014 shortlist of consultants approved.
1.2. DESCRIPTION OF CONSTRUCTION WORK
During the period under review the project is at the stage of construction works. According to the report on project implementation for June 2014, submitted by Hyundai Engineering and Construction and Daewoo International Consortium (HDEC), on June 30 2014, the project overall progress is 22,26%.
9
1.3. ORGANIZATION OF ENVIRONMENTAL WORK
There are no changes in the composition of the Environment Department. PMU Environment Specialist - Yuliya Yakubova Station Ecologist - Nizom Rakhimov
Since 1 July 2013 the International Environmental Specialist of "Corporate
Solutions Consulting Limited" Natasha Sim has commenced the work. Also from the
party of Corporate Solutions and Mott MacDonald Team (CSMM) the local
consultant on Social, Gender and Environmental issues Lyudmila Khegay is
involved.
Since 10 October 2013 the Contractor's representative Mr. Jeong Hyeon Kim
works at the construction site, who provides active support and regular inspections on
HSE in accordance with the Environmental Management Plan, as well as his assistant
Khusan Khidirov, Environmental and Safety Specialist. Since June 2014 a safety and
environmental engineer – Amanov Oybek has also been working on construction site.
In April 2014 Shaybalov Oybek- subcontractor (Tupolang) ecologist was
employed.
10
Regarding environmental works: The Contractor shall (a) establish an operational system for managing environmental impacts, (b) carry out all of the monitoring and mitigation measures set out in the Environmental Management Plan (EMP).
The Contractor shall submit to the Employer monthly reports on the carrying out
of such measures.
As of today HDEC provides PMU with monthly progress reports, which includes
a chapter "HSE Management", as well as separate monthly report on « environmental
protection and safety code » (attached in appendix 4).
The consultant also provides PMU with a quarterly report, that includes a section
on HSE, the report on monitoring the implementation of the Environment Work Plan
after visiting the construction site, as well as monthly and semi-annual reports on the
results of an environmental inspection.
All these reports PMU reviews, analyzes and takes corrective measures if needed.
According to the results of joint activities Contractor - Consultant - PMU the semi-
annual Environmental reports for the ADB are carried out.
Also according to ADB policy, the PMU sends the semi-annual Environmental
reports to the Karshi Regional Committee for the Nature Protection for reference.
ADB
Ms. Dewi Utami
PMU
Yuliya Yakubova
CSMM
Natasha Sim
Hundai
Mr. Jeong Hyeon Kim
Hundai
Khusan Khidirov
CSMM
Lyudmila Khegay
Talimarjan TPP
Nizom Rakhimov
Hundai
Oybek Amanov
Tupolang
Oybek Shaybalov
11
II. ENVIRONMENTAL MANAGEMENT PLAN (EMP)
2. 1 STATUS OF ENVIRONMENTAL MANAGEMENT PLAN.
In September 2013, HDEC has provided the HSE plan, which includes the Site
Environmental Management Plan (SEMP) and Environmental Protection Plan. This
plan has been reviewed by the PMU and the Consultant and sent to the Contractor for
updating. When updating the HSE plan the Contractor was recommended to base
upon the environmental impact assessment (2009), Environmental Action Plan
(2009).
This plan was under updating 2 more times and the final third version of the EMP,
which was acceptable to PMU and Consultant, was completed in January 2013.
It was also agreed, that every 6 months the SЕМР will be revised for continual
improvement. In May 2014, HDEC, PMU, and CS-MM revised and checked SЕМР
to reflect current conditions and status of site. The objective is to ensure continual
improvement (ISO 14000).
The new Site Based Environmental Management Plan (SВЕМР) was finally
updated by the Contractor and submitted to the PMU (attached in appendix 5).
The new plan is convenient for the ongoing project and guarantees minimum
negative impacts on the environment. SBEMP will be observed by the Contractor
and monitored by SJSC “Uzbekenergo” and the Consultant.
2. 2 ECOLOGICAL MONITORING.
Based on EIA, the PMU with the Station ecologist has carried out the Monitoring
of compliance with the requirements of the Environmental Management Plan
(SEMP) at the construction site. By the PMU the monitoring was conducted one time
in May 2014, but station ecologist conducts a visual inspection of the construction
site on a monthly basis. The main violation detected during inspections is insufficient
watering of green spaces. During the construction works the watering system has
been damaged. Therefore the trees growing on the surrounding grounds need
additional watering.
The Chemical Analysis Laboratory of the station also carries out monthly
analyzes of water samples from the Karshi Main Canal and sewage treatment plants.
12
All violations detected would be recorded and eliminated as work proceeds. In
the accounting period no material breaches of operational code for electrical
installations requirements, which may negatively influence the state of environment
has been recorded. Preoperational and construction works are being conducted in
accordance with environmental legislation of the Republic of Uzbekistan.
Monitoring of the implementation of SEMP on a regular basis is conducted by the
Consultant. In the accounting period Consultant has conducted six environmental
audits. Audit findings are described in (attached in appendix 3).
HDEC engineers conduct daily tours and site surveys. All environmental
indicators are monitored: quality of the water, open air, warehousing and recycling of
household and industrial waste, noise level, means of transport, safety code etc. More
detailed information on the Contractor’s activities can be found in monthly reports by
HDEC on environmental protection and safety code (attached in appendix 4).
Instrumental gauging of noise levels in June are as follows:
Table 2.2.1
13
The EPC Contractor also has concluded a contract with the company for waste
disposal and carries out regular HSE trainings.
According to the recommendations of Co ltd «Nazar Business Technology»,
which in October 2013 conducted ecological audit on the project, the Contractor has
been carrying out systematic trainings on environmental protection and safety code
(on 30th of each month).
For the purpose of project information release semi-annual reports by PMU are
submitted to local agency on conservation of nature and local authority.
Labour and human population complaints mechanism is also implemented as part
of the project. For this purpose there is available free a « book of complaints and
suggestions » in the staff office (attached in appendix 6). In the accounting period no
human population claims have been noted.
The PMU is attentive to recommendations of the CSMM-consultant to improve
the monitoring of the implementation of SEMP and to improve the rating of the
project. The consultant recommended that the Contractor (HDEC) is to develop a
regulatory environmental documentation for the period of construction works and to
provide the local authority for the nature protection with statistical reports. The final
decision on the implementation of these recommendations is still pending. The PMU
and HDEC continue consultations with experts of the State Nature Protection
Committee of Uzbekistan about the feasibility of developing additional
documentation and the statistical reporting procedure.
Monitoring shows that the environmental requirements at the stage of construction
works are fulfilled satisfactorily. In the accounting period no violation of
environmental regulation, or claims from the human population have been noted.
This semi-annual report on the monitoring of environment protection covers the
period of January – June 2014.
Appendix N 1
Decree of
Cabinet of Ministry of Republic of Uzbekistan.
On Confirmation of Government Ecological Expertise in Republic of Uzbekistan
In accordance with Action program for executing the of Decree of President of
Republic of Uzbekistan dated 2 June of 2000 N UP – 6 Measures for
implementing of Program of Liberalization and deepening of reforms in political,
economic and spiritual areas of society and providing of the safety of country and
also for purposed of i ple e ti g the La of Repu li of Uz ekista o E ologi al expertise a d i ple e ti g easures for de elop e t of legal-normative basis of
providing of ecological safety Cabinet of Ministry approves:
1. To confirm:
Regulation on government ecological expertise of Republic Uzbekistan accorind the
appendix 1.
List of activities according which is government ecological expertise is being carried
out according the № .
2. Control for executing of this decree is on responsibility of deputy of Prime Minister
of Republic of Uzbekistan T.H. Haltaeva.
Prime- Minister of Republic of Uzbekistan U.Sultanov.
Tashkent city
31 December 2001
№ 49
Appendix N 2
To decree of Cabinet of Minister dated 31 December 2001
№ 49
List
Of Types of Activities for which is government ecological expertise is made on.
Types of activities which at 1 category of influencing the environment (high risk)
1. Auto roads, subways railways, high speed roads and loading terminals of
republican status.
2. Airports.
3. Base oil and oil products I category.
4. Reservoir with a capacity of over 200 million cubic meters.
5. Mining and processing plant capacity of over one million tons of ore per year.
6. Municipal waste landfills (for cities with populations of more than 200 thousand
people.).
7. Hydroelectric power plants with a capacity of 30 MW.
8. Production of mining and mining-chemical raw materials to the volume of the rock
mass production 2 million cubic meters. M / year or more,
reclamation pits formed during extraction.
9. Extraction of fuel resources (oil, gas, coal, etc.).
10. Plants of ferrous and nonferrous metallurgy.
11. Leather-tanning business.
12. Sewage treatment plant capacity of more than 280 thousand cubic meters. m /
day.
13. Power lines of republican status and national interstate status.
15. Machine-building Industry (Aircraft, Automotive, Tractor, motor building, etc.).
16. Designated storage or disposal of toxic wastes and tailings pond.
17. Incinerators.
18. Oil and gas pipelines of national importance.
19. Oil and gas refineries.
20. Dams.
21. Underground gas storage facilities.
22. Landfills leaching.
23. Enterprises using heap leach technology.
24. Enterprises Waste Processing I and II hazard classes.
26. Manufacture of accumulators, galvanic batteries and components.
27. The production of asbestos and asbestos products.
28. Manufacture of explosives.
29. Production of equipment or devices containing toxic substances regulated by
international agreements.
30. Production, use and storage of radioactive materials (isotopes).
31. Manufacture of rubber and rubber products.
32. Production of glass containing toxic contaminants.
33. Manufacture of tobacco products.
34. Production of cement.
35. Reclamation of tailings ponds of toxic waste.
36. The warehouses of toxic chemicals of national importance.
37. Thermal power station and other installation for burring with thermal capacity
300 MW or more and also facilities with nuclear reactors.
39. Pharmaceutical factories (with the exception of enterprises on packaging of
finished drugs).
40. Chemical complexes and factories.
1
Letterhead of the State Committee for Nature Protection of the Republic of Uzbekistan
13 August 2013 No. 18/768
C O N C L U S I O N
of Government Ecological Expertise
Subject: Environmental impact assessment of the "Expansion of
Talimarjan TPP with the construction of two CCGT with a
capacity of 450 MW" project
Employer: UE “Talimarjan TPP”
Designer: OJSC “Teploelectroproect”
Mr. NORMUMINOV A.A.
Director of UE “Talimarjan TPP”
cc: Mr. MAMANAZAROV M.KH.
Chairman of Kashkadaryaoblkomprirody
Ms.BAYMATOVA T.B.
Technical director of OJSC “Teploelectroproect”
Materials of the first stage of Environmental impact assessment of the
"Expansion of Talimarjan TPP with the construction of two CCGT with a capacity
of 450 MW" has been submitted for the Government Ecological Expertise.
The enterprise is located at Nuristan settlement, Nishan area, Kashkadarya
region in 18 km from the Nishan area center. The nearest residential buildings are
in 700 m to the north-east from the enterprise, in 1.0 km from priority sources of
pollutant emissions to atmosphere. To the east from TPP at a distance of 1.0 km
there is the rail road Karshi-Termez-Dushanbe.
The station is located on the right bank of the Karshi Main Kanal, which is
connected with Talimarjan reservoir (in 7 km).
Talimarjan TPP is focused on power generation; the installed capacity - 800
MW. The power generation in 2012 is amounted to 5516308.8 thousand kWh.
Natural gas is used as a main and reserve fuel at TPP, gas flow rate in 2012 is
2
amounted to 1323074.4 knm³, at that, specific reference fuel consumption for
electrical supply is determined in a value of 313.25 g/kWh, heat-167.99 kg/Gcal.
At existing situation the process equipment of TPP is presented by one
power unit comprising:
- steam turbine К-800-20-5 with a capacity of 800 MW with generator ТВВ
-800-2.
- boiler ТG-805-С3 with steam producing capacity of 2650 ton per hour
The structure of block station includes also a starting heating boiler house
equipped by four boilers U-50-3.9-440GM with steam producing capacity of 50
ton per hour and two water-heating boilers PTVM-30 with heat producing capacity
of 30 Gcal per hour.
The industrial and agricultural enterprises of a southern part of the republic
are experiencing a deficiency in the electric energy as at Talimarjan TPP with the
designed capacity of 3200 MW there is only one power unit with a capacity of 800
MW and being the basic source of electricity generation, thermal power plant is
not able to meet the needs of the served region.
In pursuance of the Resolution of the President of the Republic of
Uzbekistan #ПП-1933 dated 7 March 2013, Talimarjan TPP expansion project
with the construction of two CCGT is developed with increasing its capacity to
1,700 MW. The structure of CCGT includes gas turbine unit with the electrical
capacity of 314 MW, waste-heat steam boiler and steam-turbine condensing unit
with the electrical capacity of 157.7 MW. Natural gas flow rate will make 1267.38
mln.nm³ per year (162.964 nm³/h). Emission of smoke gases from new units is
provided through two individual pipes with a height of 85 m and diameter of 7.2
m.
Management of CCGT is planned through an automated system that allows
ensuring of the control of the process parameters and execution of tasks for
regulation, alarm and blocking of fuel supply in a case of any violations of the
production cycle.
Accommodation of two projected CCGT is planned at the territory of
existing TPP from the main building without additional land acquisition. For
stabilization of natural gas supply with the required parameters of pressure (up to
39.5 bars) the construction of booster compressor station equipped with three gas
compressor is planned.
Water supply of CCGT is provided from existing networks of Talimarjan
TPP (Karshi Main Canal) with consumption for technical needs, taking into
3
account the available capacities 591182 thousand m³/year. Water for the CCGT
will be used in a cooling water system and chemical water treatment.
Wastewater in the turbines under the straight-through arrangement is
removed into the Karshi Main Canal below the water abstraction point. Losses
replenishment in the process water circulation system is carried out by a fresh
water supply from the additional water intake structures, located at the initial KMC
area (from the Talimarjan reservoir). Considering a high mineralization, rigidity
and turbidity of surface waters under the expansion of TPP the organization of
additional (make-up) water pre-treatment with the arrangement of intake chamber
and drilling waste disposal site is provided. For prevention of deposition and salts
scaling formation as well as for disinfection the water is treated with the inhibitor
and sodium hypochlorite.
Number of wastewaters and sewage waters outlet in Karshi Main Canal
remains unchanged:
- Outlet No.1, through which the sanitary sewage is discharged after
cleaning and drain of the water treatment plant in the manifold (collector) K-3-2 at
a rate of 527.2 m3/h;
- Outlet No.2, directing the partially clean waters of turbine condenser
cooling system of power unit No.1 and two CCGT, as well as brine of distillation
desalination plant in the discharge canal of KMC at a rate of 144243.5 m3/h.
Analysis of the manufacturing parameters of installed equipment shows that
at its design the requirements of water-saving technologies are taken into account:
for comparison - the discharge of sewage waters from two combined cycle gas
turbine will reach 45220 m/h while from the power unit No.1 - 93162 m/h.
Thermal pollution of the Karshi Main Canal water as the result of partially
clean waters discharge after coils cooling shall not exceed 3°C in the summer.
The main source of sewage waters pollution with oil products is oil
lubrication system of turbines. Oily sewage waters to be cleaned at the Integrated
treatment of production waste waters. Under the expansion of thermal power
plant to 1700 MW from 800 MW it is necessary to provide the reconstruction
of facilities on the cleaning of oily sewage waters by adjusting the
concentration of petroleum products to the background values that
characterize the quality of water in Karshi Main Canal at the outlet from the
Talimarjan reservoir.
During the plant operation a carbon and nitrogen oxides, nitrogen and sulfur
dioxides and benzo(a)pyrene get into the atmosphere currently, the bulk is
accounted for the nitrogen dioxide - 2847.6 tons/year and nitrogen oxide - 441.3
4
tons/year. Gross emission of pollutants is 3289.4 tons/year. Flue gases from power
unit are exhausted through a pipe with 270 m height and with a diameter of 6.6 m.
Atmospheric air in this region is characterized by a moderate content of
pollutants; Talimarjan TPP and motor transport brings the main contribution to the
contamination of the atmosphere with nitrogen dioxide. With TPP emissions the
nitrogen dioxide are generated outside of TPP reaching 0.19 of maximum
permissible concentration (MPC) that is do not exceed the established limits (0.25
MPC).
After the expansion of TPP at developing of its capacity to 1700 MW
from 800 MW the pollutant emissions increase to 4431.29 tons/year (by
1141.89 tons/year), and the maximum concentrations of nitrogen dioxide,
generating with TPP emissions outside of TPP will make 0.24 MPC (without
taking into account a background) at the territory of Nuristan settlement -
0.21 MPC. On other substances – they do not reach the values of 0.1 MPC.
Specific emission rate of pollutants per unit of capacity (MW) are
significantly reduced: from 4.11 tons till 2.6 tons.
The generation of additional types of wastes during the construction of two
CCGTs is not predicted, their quantity is increasing due to high consumption of
lubricants, mercury-containing lamps, work clothing, etc., but standards of wastes
generation will remain at the same level.
For the purpose of noise reduction, CCGTs are equipped with acoustic
enclosure, an Air Filtering and Conditioning System (AFCS) is installed, equipped
with a filtration system and air heating that will provide effective cleaning of the
air flowing to the suction pipe of CCGT.
Environmental expertise of the submitted materials has shown their
compliance with the requirements of the environmental laws on the scope and
content of the first stage of the EIA and considers it necessary to develop the final
stage - Statement of environmental effects (SEE) for the purpose of regulatory
actions on emissions and discharges of pollutants into the environment, waste
generation and emplacement of industrial waste separately by years in view of
the commissioning schedule of CCGTs with a capacity of 450 MW.
For the regulatory actions on discharges of pollutants to surface-stream flow
under the SEE it is necessary to perform schemes of water disposal separately by
discharges and the identifying the sources of pollutants supply in baseline
characteristics. Prediction of water pollution of Karshi Main Canal with sewage
5
waters of TPP should be calculated depending on the mode of water flow in the
canal.
The draft of environmental impact statement of Talimarjan TPP expansion
project with the construction of two CCGT with a capacity of 450 MW and
increasing the plant capacity to 1700 MW is under the coordination of
Government Ecological Expertise of the State Committee for Nature protection the
Republic of Uzbekistan.
Kashkadarya Regional Committee for Nature Protection should take
under control the compliance with the requirements of environmental laws when
placing the combined cycle gas turbines at the territory of Talimarjan TPP. Prior
to the development and submission of the Statement of environmental effects
by the Government Ecological Expertise it is necessary to submit to the State
Committee for Nature protection the results of status monitoring of the
Karshi Main Canal surface waters before and after discharge of Talimarjan
TPP sewage waters.
Deputy Chairman (signature) K. Sadykov
Action by: Ishmukhamedova T.R.
Tel: 230-16-99
Uzbekistan
Environmental Report Bi-Annual Audit
May 2014
EXPANSION OF TALIMARJAN POWER PLANT | IMPLEMENTATION CONSULTANTS |
| LOAN NO. 2629-UZB |
FINANCED BY: The Asian Development Bank |
MAY 2014 |
• IN ASSOCIATION WITH:• SUBMITTED BY:
DOCUMENT CONTROL AND VERIFICATION SHEET
Job Title: Expansion of Talimarjan Power Plant with the construction of two combined-cycle plants with a capacity of 450 MW Project
Contract No: ADB LOAN NO. 2629-UZB
Document Name: Environmental Report – Bi-Annual Audit – May 2014
Document History:
Version Date Prepared Checked Approved
1.0 27 May 2014 Natasha Sim Terry Foote
1.1
1.2
ABBREVIATIONS
ADB Asian Development Bank
CS-MM Corporate Solutions and Mott MacDonald Team
CCGT Combined Cycle Gas Turbine
DMF Design and Monitoring Framework
EA Executing Agency
EPC Engineering Procurement Construction
GoU Government of Uzbekistan
HDEC Consortium of Hyundai and Daewoo
H&S Health & Safety
HSE Health, Safety, and Environment
IA Implementing Agency
IC Implementation Consultant
IAS International Accounting Standards
IFI International Financial Institution
JICA Japan International Cooperation Agency
PAM Project Administration Manual
PFS Project Financial Statements
PMU Project Implementation Unit
TPP Talimarjan Power Project
UFRD Fund for Reconstruction and Development of the Republic of Uzbekistan
UZS Uzbekistan Som (currency unit)
VAT Value Added Tax
WA Withdrawal Application
CONTENTS
1. INTRODUCTION ................................................................................................................ 6
2. RESULTS ........................................................................................................................... 9
1.1. STATUS OF THE EMP ..................................................................................................... 9 1.2. EMP REVISION .............................................................................................................. 9 1.3. RECOMMENDATIONS ...................................................................................................... 9 1.4. SITE PHOTOGRAPHS .................................................................................................... 10
FIGURES AND TABLES
Table 1: Key Environmental Issues ........................................................................................... 7 Table 2: Companies Working during April 2014 ........................................................................ 8 Table 3: Contact Information ..................................................................................................... 8 Table 4: EMP from Annex 7.3 of the Environmental Management Plan (HDEC, January 2014)
with CS-MM Status May 2014 ........................................................................................ 12
1. INTRODUCTION
CS-MM plans to performs environmental audit reports bi-annually (November and May of each year) and monthly observations records. This report is the bi-annual audit for May 2014.
GENERAL
Monthly Check: May 2014
Site visit dates: 7, 8, 14 May 2014
Date of next monthly check: June 2014
Site inspections by:
1) Natasha Sim 2) Lyudmila Khegay
ADB visit (8 May 2014)
Documents reviewed/used:
� EMP � HDEC environmental monthly report April
2014 � MoM of the weekly construction meetings
provided by HDEC.
Method of environmental checks Location of audit:
� Visual inspections � Site walk around with Topalang
Environmental Officer � Discussions with site supervisors � Attendance of a HSE weekly meeting (7
May 2014)
� Power block area � Cooling tower area � Administration building and canteen � Batch plant and vehicle washing area � Workers accommodation camps � Vehicle repair shop and fuelling area � Customs warehouse
Progress details as of mid May 2014:
� Vehicle workshop and fuelling station are in operation. Offices have been completed. � Cooling tower excavations are complete and backfilling has begun � Power block backfilling in area A & C1 is near completion � The control room/admin building foundation soil has been compacted and blinded. � Administration building work is still not 100% complete � Canteen building is in operation although remodelling is not yet complete � Workers camp construction (Topalang and HDEC) is ongoing
Completed this month:
� Review of the EMP with HDEC, Topalang and the PMU – revisions have been made
� Environmental permitting and records continues to be discussed with the PMU and HDEC
� Bi-annual environmental review
Achievements for June 2014:
� ADB environmental audit will take place in June 2014
� PMU to start to compile their semi-annual environmental report for ADB
� Environmental officer from Topalang to improved monitoring measures – CS-MM will review these in June.
Date 31 May 2014
Signed – Environmental and Social Expert
CS-MM, Natasha Sim
Table 1: Key Environmental Issues
Issue Responsible Party
Deadline Status
Companies are required to give statistical reports (стат. отчетность) annually.
One does not need an Environmental impact assessment/ZEP (Заявление экологические последствие) to give statistics reports. But if there is no ZEP, compensation fees will have to be paid in place of this.
PMU – Yulia Yakoba
HDEC
May 2014 Open. The PMU has sent a letter to HDEC stating that they will have to pay annual environmental compensation fees and the procedure for this can be found in the Cabinet of Ministers of the Republic of Uzbekistan No 199. HDEC may either obtain a ZEP for the construction period or do the environmental calculations for emissions and discharges themselves.
CS-MM have advised HDEC that the ZEP would be better.
Resource records need to be improved.
Topalang
HDEC must monitor this
June 2014 Open. Monitoring resources has been discussed with the Topalang Environmental expert and the Existing power station environmental expert. The issue has also been raised with HDEC.
Waste management on site still needs to be improved with more accessible and appropriate waste bins and a waste management plan for various waste types.
HDEC
Topalang
End of April 2014
Open. The waste management situation has only slightly improved.
More bins should be provided and more waste separation should take place.
There are no Environmental induction sessions, although the H&S induction covers some environmental aspects. This needs to be started now so that all employees are made aware of the EMP and their responsibilities towards implementing it.
Topalang under HDEC supervision
Mid June 2014 Open.
At the site construction meeting CS-MM brought up the need for HDEC to have a Project Execution Plan (POS - plan organizatsiya stroitelstvo). Once this is obtained Topalang can create the required Statements of Work (PPR - plan proizvodstvo raboti). The PPRs are important for environmental aspects as well as they should state how much water they are going to use, electricity, etc. It also includes where they will get permissions, where they will dispose of wastewater, waste, etc.
HDEC
Topalang
PMU
ASAP Open.
Update - Statements of work (PPR) are being prepared and submitted to the Employer/CS-MM for approval.
At the moment they do not contain any environmental measures.
The EMP should be reviewed and potentially revised in order for it to reflect the current situation at the construction site.
HDEC Topalang
PMU
End of May 2014
Closed. The EMP was reviewed by CS-MM, the PMU, and HDEC. HDEC will submit a revised version with short justifications. The revised EMP should be submitted to the ADB so they can use this for the audit in June.
Table 2: Companies Working during April 2014
Company Position
HDEC EPC Contractor
PGU Tupalang Sub-Contractor
KS & Technology Sub-Contractor
H&S Sub-Contractor
Table 3: Contact Information
Name Company Position Contact (email and/or tel.)
Jeong-Hyeon Kim Hyundai HSE Engineer [email protected]
+99 890 444 1239
Husan Khidirov Hyundai HSE Engineer [email protected]
+9989 34 23 31 14
Bazzarov Irkin Nazomutdiyouvich
PGU Tupalang H&S Engineer 91 218 65 33
Nizom Rakhimov Talimarjan Environment +9989 39 00 19 36
Oybek Shaybalov PGU Tupalang Environmental Engineer
+9989 36 97 11 12
2. RESULTS
1.1. Status of the EMP
The status of the EMP implementation is shown in Table 4.
Most of the measures are being implemented, however improvements need to be made specifically in record keeping, waste management, and dust control.
1.2. EMP Revision
It has been agreed that every 6 months the EMP will be reviewed for continual improvement. During May 2014, HDEC, the PMU, and CS-MM reviewed and revised the EMP to reflect the current site conditions and status. The purpose of the revision is to ensure continual improvement (ISO 14000).
1.3. Recommendations
Recommendations for the PMU
� The PMU should submit the revised site-based EMP to the ADB so the updated version is used during their environmental audit in June 2014
� Ensure that the normative documents (ZEP for the construction site) are created to ensure that the appropriate statistics reports are submitted to the environmental authorities.
� The next semi-annual report for the ADB should address the environmental recommendations from the ADB audit in November 2013.
Recommendations for the Topalang Environmental Officer
The PMU should recommend the following to HDEC for the Topalang Environmental Officer:
� Compile the quarterly environmental statistics report for the 1st quarter of 2014. By doing this HDEC will understand the environmental priorities and environmental measures needed during the construction work.
� Complete the site map indicating the areas of environmental risk (waste management, water intakes, sources of pollution, etc.)
� Create and approve standardized reporting forms for monitoring (noise, water consumption, electricity consumption, fuel usage, etc.). These forms should be approved by HDEC. They should be able to get assistance from the existing power station or the Regional Committee for Nature Protection.
� Hold an environmental meeting with site managers explaining the purpose for the EMP and their responsibilities.
1.4. Site Photographs
Photograph 1: Cement arrival area by the batch plant (13/05/2014)
Photograph 2: No smoking sign near in the refuelling area (7/05/2014)
Photograph 3: Stockpile water in the cooling tower area (7/05/2014)
Photograph 4: Slope textile in the power block area (7/05/2014)
Photograph 5: The Topalang Environmental expert is creating maps indicating areas of environmental risk (7/05/2014).
Photograph 6: Some of the vehicles are not in good technical condition (this noisy bulldozer was observed and the driver did not have appropriate PPE) (7/05/2014)
Photograph 7: Settling tank near the vehicle washing area. Oil filters will be installed. (7/05/2014).
Photograph 8: Waste separation near the administration building (7/05/2014).
Photograph 9: Waste bin near the customs warehouse (7/05/2014).
Table 4: EMP from Annex 7.3 of the Environmental Management Plan (HDEC, January 2014) with CS-MM Status May 2014
Aspect
Аспект
Mitigation
Меры по снижению воздействия
Location
Место
Monitoring
Контроль
Responsible
Ответственные
CS-MM Status for May 2014
Management
Informing a) Inform local residents schedule of
the construction activities
b) Introduce types of emissions and
counter measures
HSE
Training
Centre
Officially a) EPC Contractor
b) PMU
a) No activities completed as of yet.
b) Measures in this plan have been
introduced.
Emergency a) Compile and implement an
emergency situation control plan
b) Every six months have emergency
drills
c) Confirms the role of individual
Project
Site
Observatio
n of
emergency
a) Contractor
b) Subcontractor
a) This is in place, HDEC standard
procedures. A site-specific plan is being
compiled.
b) They have implemented an emergency
signal system and have regular drills
Traffic a) All traffic signs, signals, and road
markings must be obeyed
b) Authorized transportation of
equipment and materials ON entry to
the site
c) Speed of transport vehicles should
be strictly controlled in the access
road to TPP
Project
Site
Inspection
of traffic
conditions
a) Contractor
b) Subcontractor
a) Traffic signals and road signs are
present on site. Drivers are occasionally
seen driving too fast or talking on their
phones while working however it is being
controlled by HDEC.
b) Checks are made on a random basis
c) Yes
Monitoring a) Monthly monitoring of the following
should take place:
� Fuel (m3)
Project
Site
Observatio
n use of
sources
a) Contractor
b) Subcontractor
a) Not completely. Monitoring still needs to
be improved on site. Fuel and electricity are
being monitored but water meters still need
� Electricity (kWh)
� Water (m3)
to be installed on site.
Overall more environmental report
monitoring needs to take place. See Table
1 for more information on this.
Air / Воздух
Plan /
План
a) Identify all possible air pollution
sources related to construction
activities
Определить все возможные
источники загрязнения воздуха
b) Compile and implement air control
plan
Составить и применить план
контроля воздуха
Project
Site
Площад
ка
проекта
Examinatio
n
Оценка
a)Contractor
Подрядчик
b)PMU
ГРП
a) The Topalang environmental OFFICER has
identified the air pollution sources.
b) This should be part of the ZEP for
construction (Environmental impact
statement). This document should be
produced by an accredited design engineering
institute. It will be required to report on this
quarterly.
Exhaust
fumes
Выхлопны
е газы
a) Regularly serviced and maintained
to be in good condition vehicles and
Equipment
Транспортные средства и
оборудование постоянно
обслуживаются и поддерживаются
в хорошем состоянии
b) Forbid the burning of coal, waste,
or wood on site
c) Reduce idle time of all vehicles
Maintenanc
e Area
Зона
обслужива
ния
Inspection
Проверка
a) Subcontractor
Субподрядчик
b) Appropriate
manager
Соответствующий
менеджер
a) Vehicles in bad condition are sent off
site. The vehicle rental company needs to
supply vehicles in good condition.
b) Yes
c) Yes
Dust / Пыль
Plan /
План
a)Identify all possible dust pollution
sources related to construction
Project
Site
Examinatio
n
a) Contractor
Подрядчик
a) The Topalang environmental OFFICER has
identified the dust pollution sources unofficially.
activities
Определить все возможные
источники загрязнения пылью,
связанные со строительными
работами
b)Compile and implement dust
control plan
Составить и применить план
контроля запыленности
Площад
ка
проекта
Оценка b) PMU
ГРП
b) They are implementing dust control
measures according to their own internal
procedures plan. A formal plan should be part
of the ZEP for construction (Environmental
impact statement). This document should be
produced by an accredited design engineering
institute. It will be required to report on this
quarterly.
Watering /
Увлажнен
ие
Watering shall be implemented to
control dust where
Увлажнение должно быть
применено для контроля
запыленности:
a)Working areas
Рабочие зоны
b)Exposed areas
Открытые зоны
c)Active cuts excavation and fill sites
Действующие срезы выемки и
засыпки
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a,b,c) Watering of the roads is happening
up to six times per day in the working
areas, exposed areas, stockpiles, etc.
Watering /
Увлажнен
ие
Watering shall be implemented to
control dust when
Увлажнение должно быть
применено для контроля
запыленности:
a)Before and after operation
До и после работ
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a,b,c) Adequate watering is taking place on the
construction site. On dry, hot days, frequency
should be increased.
b)Breaking of rock/concrete work
Работы по разлому камней/бетона
c)Drilling of rock work
Работы по сверлению камней
Site control
Контроль
площадки
a) Minimize size and duration of
exposed areas
Минимизировать размер и
продолжительность открытых зон
b) Keep hauling roads in good
condition
a)Projec
t Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
b) However no engineering of the access
roads has taken place.
Material
control
Контроль
материало
в
a) Minimize size and duration of
materials stockpiles
Минимизировать размер и
продолжительность склада
материалов.
Laydow
n
Складск
ая
площад
ка
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
Material
control
Контроль
материало
в
a) Minimum practical height to limit
the fugitive dust generation from
unloading excavated materials
Высота, с которой выкопанные
материалы сбрасываются, должна
контролироваться до минимальной
практической высоты для
ограничения образования
сдуваемой пыли от разгрузки.
b) Cement debagging should take
place in a sheltered area
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Training on dust control related to
loading of excavated materials has taken
place.
b) Cement debagging is taking place in the
warehouse near the batch plant. Once the
batch plant is in full operation the cement
will be delivered by train and deposited
directly into the bunkers.
Vehicle a) Limiting vehicle-entrained dust Project Observatio a)Contractor a) All roads are currently unpaved, dust is
control
Контроль
транспорт
ных
средств
from unpaved roads
Ограничивать пыль, поднимаемую
транспортными средствами, с
грунтовых дорог
b) Limiting vehicle speeds (20 km/h
in Project Site) and restricting traffic
volumes
Ограничение скорости
транспортных средств и
ограничения объемов
транспортных потоков
c)Trucks have proper fitting side and
tail boards
Грузовики должны иметь
подходящие боковые и задние
откидные стенки
d)Materials shall also be dampened,
if necessary, before transportation
Материалы также должны быть
увлажнены, если необходимо,
перед транспортировкой
e)Covering trucks during transport of
materials
Накрывать грузовики во время
транспортировки материалов
Site
road
Дорога
площад
ки
проекта
n
Наблюден
ие
Подрядчик
b)Subcontractor
Субподрядчик
being controlled.
b) There are signs on the road and drivers
are trained and monitored.
c) Yes
d) Yes
e) It is not necessary
Noise / Шум
Plan /
План
a)Identify all possible noise pollution
sources related to construction
Project
Site
Examinatio
n
a)Contractor
Подрядчик
a) Not identified in a systematic way – this is a
task for the environmental officer of Topalang.
activities
Определить все возможные
источники шума, относящиеся к
строительным работам
b)Compile and implement a noise
control plan
Составить и применить план
контроля шума
c) Posting Signboards on contruction
sites and/or stickers on equipment
outlining how affected parties can
lodge complaints
Площад
ка
проекта
Оценка b)PMU
ГРП
b) HDEC are implementing noise control
measures according to their own internal
procedures plan. A formal plan should be part
of the ZEP for construction (Environmental
impact statement). This document should be
produced by an accredited design engineering
institute. It will be required to report on this
quarterly.
Noise level
Уровень
шума
a) Inspect noise level using the
construction equipment
Проверить уровень шума с
использованием строительного
оборудования
b) Equipment noise limit will complly
with Item 223 of EIA. For example.
Direction of Nuristan are limited to 80
dba 1 m.
c) Use appropriate PPE (earplug,
earmuff) if exceeds noise limits
Project
Site
Площад
ка
проекта
Inspection
Проверка
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a, b) Records are supplied in the monthly
environmental reports
c) Not everyone is wearing appropriate PPE
for high-level noise, Site staff have been
instructed to wear ear protection.
Vehicle
control
Контроль
транспорт
ных
a)Limiting vehicle speeds (20 km/h at
Project Site)
Ограничение скорости
транспортных средств
b)Restrict truck movements to day
Project
Site
road
Дорога
площад
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) there are some violations. Speed limit
signs are posted on site and drivers are
trained and monitored.
b) Trucks are now working night shifts.
They need a work permit for this. This
средств time and restrict truck movements to
major transport routes
Ограничить передвижение
грузовиков только в дневные часы
и ограничить передвижение
грузовиков к основным
транспортным маршрутам.
ки
проекта
should not cause any complaints, as
settlements are not close by.
Vehicle
control
Контроль
транспорт
ных
средств
a)Regularly serviced and maintained
to be in good condition vehicles and
Equipment
Транспортные средства и
оборудование постоянно
обслуживаются и поддерживаются
в хорошем состоянии
Maintenanc
e area
Зона
обслуживан
ия
Inspection
Проверка
a)Subcontractor
Субподрядчик
b)Appropriate
manager
Соответствующий
менеджер
a) Random checks are carried out and
inadequate vehicles are removed. The
environmental officer should have a plan for
checking the maintenance plans of vehicles
and be able to carry out spot checks.
Noise
barrier
Звуковые
барьеры
a)Use of temporary acoustic barriers
or exhaust mufflers
Использовать временные звуковые
барьеры или глушители
b)Noise barriers located between
noisy construction activities and
noise sensitive receivers
Шумовые ограждения,
расположенные между шумными
строительными работами и
чувствительными к шуму
приемниками
c) Noise maininted at 70 dB at
outside of nearest building from
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Not necessary
b) Not necessary as there are not close to
sensitive receivers
c) This is being tested and records are
included in the monthly environmental
reports
power plant
Equipment
control
Контроль
оборудова
ния
a)Equipment shall be operated within
specifications and capacity
Оборудование должно
использоваться в пределах
спецификаций и мощности
b)Equipment shall be operated in as
diversified a manner as possible
Оборудование должно
использоваться максимально
диверсифицировано
c)Equipment shall be turned off when
not in use
Оборудование должно
выключаться, когда не
используется
d)Works using machines or vehicles
shall be prohibited in the midnight
and the dawn
Работы с использованием машин
или транспортных средств должны
быть запрещены в ночное время и
на рассвете.
e) Air intakes, vents, and stacks
should be fitted with suitable noise
attenuating equipment (if required)
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a, b, c) Yes
d) Should be prohibited unless they have
work permit. Work has started at night on
the construction site to catch up with
construction delays. In this case night work
is permitted.
e) Vendor packages are being examined to
ensure they have the appropriate devices.
Equipment
control
a)Select the time when the
environment is least sensitive to
Project
Site
Inspection
Проверка
a)Contractor
Подрядчик
a) Yes
Контроль
оборудова
ния
noise impact using pile drivers, jack
hammers, and rock drills
Выбрать время, когда окружающая
среда наименее чувствительна к
воздействию шума при
использовании сваебойных
каперов, отбойных молотков и
буров
Площад
ка
проекта
b)Subcontractor
Субподрядчик
Wastewater / Сточные воды
Plan /
План
a)Identify all possible wastewater
pollution sources related to
construction activities
Определить все возможные
источники сточных вод,
относящиеся к строительным
работам
b)Compile and implement a
wastewater control plan
Составить и применить план
контроля сточных вод
Project
Site
Площад
ка
проекта
Examinatio
n
Оценка
a)Contractor
Подрядчик
b)PMU
ГРП
a) Not identified in a systematic way – this is a
task for the environmental OFFICER of
Topalang.
b) They are implementing wastewater control
measures according to their own internal
procedures plan. A formal plan should be part
of the ZEP for construction (Environmental
impact statement). This document should be
produced by an accredited design engineering
institute. It will be required to report on this
quarterly.
Batch plant
control
Контроль
РБУ
a)Wastewater from concrete batching
plant operation and shall not be
discharged overland
Сточные воды, образованные от
работы РБУ, не должны
сбрасываться на поверхность
земли
Batchin
g Plant
area
Зона
РБУ
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Drainage at the concrete batch plant is not
adequate. Proper drainage in the batch plant
area will be installed along with adequate
wastewater treatment.
Washing
water
Промывоч
ная вода
a)Undertake settling and
neutralization of alkaline washing
water containing excessive cement
prior to discharge
Произвести осадку и
нейтрализацию воды щелочения,
содержащей большое количество
цемента, до утилизации
b)Water from washing large
concrete-mixing equipment
Вода после очистки крупного
оборудования для смешивания
бетона
Batchin
g Plant
area
Зона
РБУ
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a, b) Not currently being done although the
batch plant is not in full operation. Proper
drainage in the batch plant area will be
installed along with adequate wastewater
treatment.
Washing
water
Промывоч
ная вода
a)All washing of equipment or
machinery shall be undertaken in
designated areas
Мойка всего оборудования и
машин должна производиться в
обозначенных зонах
b)Washing of equipment areas must
be equipped with a suitable
impermeable floor and sump/oil trap
Зоны мойки должны быть
оборудованы подходящими
водонепроницаемыми полами и
сточными колодцами /
маслоуловителями.
Washin
g area
Зона
промыв
ки
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) There is a specific vehicle washing area,
however the process can be improved.
They have two settling tanks and they plan
on installing an oil filter. Then the water will
be reused on site. It should be confirmed
whether or not a permit for discharge is
needed.
b) This needs to be improved and there are
plans in place.
Wastewate a)Wastewater collected within Fuelling Observatio a)Contractor a) Not at the moment. There are plans for
r emission
Выделени
е сточных
вод
bunded area around the fuelling area
be disposed of as hazardous waste
Сточные воды, собранные внутри
зоны обваловки вокруг
заправочной зоны, должны быть
утилизированы как опасные
отходы
area
Зона
заправк
и
n
Наблюден
ие
Подрядчик
b)Subcontractor
Субподрядчик
adequate drainage.
Natural
water
Естествен
ные воды
a)Natural run-off diverted away from
any camps
Естественный сток должен быть
отведен от строительного городка
Camp
area
Зона
строительн
ого городка
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
Rain water
Дождевая
вода
a)Heavy rainwater plan to be and
implemented for the construction
phase of the Project
План дождевых вод должен быть
применен для строительной фазы
Проекта.
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) No heavy rain. Rain plan is being
developed.
Contaminat
ed water
Загрязнен
ная вода
a)Sand, silt and silt-laden water do
not enter the heavy rainwater drain
system or any surface watercourse
Песок, осадок и вода, насыщенная
взвешенными наносами не должны
попадать в систему дренажа
сильных дождевых вод или любые
поверхностные водные потоки
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
Material
control
a)All hazardous material storage
areas designed to reduce risk of
Material
storage
Observatio
n
a)Contractor
Подрядчик
a) There is minimal hazardous material on
site at the moment
Контроль
материало
в
spillages
Все зоны хранения опасных
материалов должны быть
спроектированы для уменьшения
риска утечек
b)All materials covered during
transport to prevent them from
spilling
Все материалы должны быть
накрыты во время
транспортировки для
предотвращения утечки
c) Store all liquid/solid waste properly
above ground to avoid spills/leaks
d) Develop a hazardous materials
and handling plan. Provid spill
response kits at all HazMat storage
areas and work site
e) Chemicals and fuels on site should
be kept to a minimum
areas
Зоны
хранения
материало
в
Наблюден
ие
b)Subcontractor
Субподрядчик
b) Not necessary to cover materials.
c) Yes
d) A plan is in place, however not all
working areas have spill response kits and
not all workers are not aware of what a spill
response kit is.
e) Yes
Straining
Фильтрова
ние
a)Construction of dirt trap, interceptor
pond and the attenuation dam
commenced as early as possible in
the construction phase
Строительство грязеуловителя,
отстойника коллектора сточных
вод и сдерживающей плотины
должно быть произведено как
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) No
можно раньше до начала фазы
строительства.
Undergrou
nd water
Подземны
е воды
a)Monitoring the underground water
by sampling of underground water at
site around four(4) points
Контроль подземных вод путем
отбора проб грунтовых вод на
площадке вокруг 4 (четырех) точек.
Местоположение будет
определено и будет
использоваться для
периодического отбора проб
b)The location will be qualified and used
for periodic sampling.
Местоположение будет определено и
будет использоваться для
периодического отбора проб.
Project
Site
Площад
ка
проекта
Experimentatio
n
Эксперимент
a)Laboratory
Лаборатория
a, b) Groundwater levels are very low and
after further discussions it has been
decided that groundwater will not be
monitored.
However they will be monitoring the quality
of incoming potable water and wastewater
using the existing power station’s
laboratory. The exact spots for samples are
still to be determined.
Barrier
Огражден
ия
a)Channels, earth bund walls or
sandbag barriers be provided on site
to direct storm water to silt removal
facilities
Каналы, стены земляной
обваловки или ограждения из
мешков с песком должны быть
предусмотрены на площадке для
направления ливневых вод к
сооружениям удаления осадка
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Not necessary at this time.
Hazardous
Waste
Storage of hazardous waste in
bunded areas to avoid leaks
escaping to the ground or nearby
surface waters
a) Yes
Monitoring a) Monitoring water quality
b) Water samples, sent to local
laboratory to be tested for water
quality ph, oil, debris, and etc.
a, b) Wastewater goes to Talimarjan
wastewater plant and the quality is
monitored there. The incoming potable
water will be sampled and examined using
the existing station’s laboratory.
Soil / Почва
Plan /
План
a)Identify all possible soil pollution
sources related to construction
activities
Определить все возможные
источники загрязнения почвы,
относящиеся к строительным
работам
b)Compile and implement a soil
control plan
Составить и применить план
контроля почвы
Project
Site
Площад
ка
проекта
Examinatio
n
Оценка
a)Contractor
Подрядчик
b)PMU
ГРП
a) Not identified in a systematic way – this is a
task for the environmental officer of Topalang.
b) They are implementing soil control
measures according to their own internal
procedures plan. A formal plan should be part
of the ZEP for construction (Environmental
impact statement). This document should be
produced by an accredited design engineering
institute. It will be required to report on this
quarterly.
Site control
Контроль
площадки
a)Minimize size and duration of
exposed areas
Минимизировать размер и
продолжительность открытых зон
b)Minimize the excavation during
construction of fuel oil
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
b) This point is unclear and fuel oil is not being
constructed.
c) Some excavation slopes are too vertical.
d) Yes
Минимизировать экскаваторные
работы во время строительства
дамбы топливного масла и
известняка
c) Minimize the overall slope of the site
Минимизировать общий откос
площадки
d) Ensure good landscaping and erosion
control
Site control
Контроль
площадки
a)Deposited silt and grit removed
regularly and disposed of by
spreading evenly over stable
Накопленный осадок и песок
должны удаляться регулярно и
утилизироваться путем
равномерного распределения
между постоянными зонами
растительности
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Not applicable
Covering
Накрытие
a)Exposed slope surface shall be
covered during the rainy day
Открытая поверхность скоса
должна быть накрыта в дождливые
дни
b)Open stockpiles of construction
materials covered during rainy day
Открытые склады строительных
материалов должны быть накрыты
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Not applicable
b) Not applicable at the moment but plans
are in place for the future.
во время ливней
Road
control
Дорожный
контроль
a)Trafficked areas and access roads
protected by coarse stone ballast
Все проезжие части и дороги доступа
должны быть защищены крупно-
щебеночным балластом
Project
Site
road
Дорога
площад
ки
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) No. There has been no engineering of
the site access roads. They remain dirt
raods.
Sediment
Осадок
a)Sediment tanks can be used for
settling wastewater prior to disposal
Грязеуловители достаточной могут
быть использованы для осаждения
сточных вод до утилизации
Project
Site
Площад
ка
проекта
Inspection
Проверка
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) In the vehicle washing area this is taking
place. Howeve the treatment needs to be
improved and plans are in place for an oil filter.
The water will not be disposed of in the
wastewater system and is planned to be
reused.
Drainage
facilities
Дренажны
е
устройств
а
a)All drainage facilities, erosion and
sediment control structures shall be
regularly inspected and maintained
Все дренажные осушение
сооружения, конструкции контроля
осаждения и эрозии должны
постоянно проверяться и
обслуживаться
Project
Site
Площад
ка
проекта
Inspection
Проверка
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
Vehicle
control
Контроль
транспорт
ных
средств
a)All vehicles and plant cleaned
before leaving a construction site
Все транспортные средства и
станции должны быть очищены до
выезда за пределы строительной
площадки
Exits of
the
project
site gate
Выезды
с
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) No, because all vehicles are hired
b) Yes
c) Not applicable
b)Ensure no earth, mud, debris and
the like is deposited by them on
roads
Обеспечить, чтобы земля, грязь,
строительный мусор и тому
подобное не скапливались на
дорогах
c)Adequately designed and sited
wheel washing bay shall be provided
at every site exits
Разработанная и расположенная
надлежащим образом площадка
очистки колес должна быть
предусмотрена на каждом выезде
с площадки
площад
ки
Road
control
Дорожный
контроль
a)All road works separated from
surface waters
Все дорожные работы должны
быть отделены от поверхностных
вод
b)All roads shall be properly sloped
and have adequate culverts to
manage runoff
Все дороги должны быть скошены
надлежащим образом и иметь
соответствующие водоспуски для
управления стоками
c)Earthworks to construct drainage
Project
Site
road
Дорога
площад
ки
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) No road works as of yet
b) No road works as of yet
ditches and to lay subsurface
drainage conduits
Земляные работы для
строительства дренажных канав и
для прокладки каналов
подпочвенного дренажа
Excavated
material
Материал
ы выемки
a)Excavated materials possible to
used reclamation fill
Материалы выемки могут быть
использованы для повторного
заполнения
b)Surplus excavated materials quarry
overburden, rock rejected for
aggregate, aggregate surplus to the
requirements and the like not
discarded indiscriminately
Излишние материалы выемки,
избыточные камни, камни, не
принятые для заполнения,
излишние заполнители и тому
подобное не должны
беспорядочно списываться
c)Different types of surplus
excavated materials deposited
separately in the spoil dumps
designated for the purpose outside
the Project site
Различные типы материалов
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
a) Yes
b) Yes
c) Some soil is being deposited within
project boundaries due to a PMU request
выемки могут накапливаться
отдельно в отвалах вынутого
грунта, предназначенных для
данной цели за пределами
площадки
Spill control
Manageme
nt
Управлени
е
a)Any spillage of fuel shall straight
away be absorbed using sand or
other absorbent materials
Любая утечка топлива должна
быть незамедлительно впитана с
использованием песка или других
впитывающих материалов.
b) Develop a spill response plan
c) Only people with adequate training
and knowledge should handle fuel
and chemicals to avoid spills
d) Fuelling shoudl be done on
concrete surface provided with spill
catch tank that can be easily cleaned
and all spilled fuel recovered/safety
disposed
e) All repair and maintenance work to
be done either on concrete surface
with oil spill catch basisn or oil catch
pants provided at all service areas
f) Routinely inspect all equipment
handling hazardous materials for
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) The number of spill kits should be
increased and workers should be informed
of how to use them.
b) Yes
c) Yes
d) No spill catch tank
e) This is being done in the vehicle
maintenance area near the batch plant.
f) Yes
g) No
h) Yes
i) Yes
leaks and spills
g) All fuel where spills and leakage is
possible e.g. the generator, must
have basins installed to prevent
leakage
h) The recovered matierals must be
recycled
i) Fuelling equipment must be fitted
with proper fuel nozzles and devices
to avoid accidental spills
Storing
Хранение
a)All fuel stored on site shall be kept
in drums or in bulk tanks
Все топливо, хранимое на
площадке, должно держаться в
металлических бочках или
наливных цистернах
b)Fuel storage area be located at a
designated place away from any
source of ignition or open drain
Зоны хранения топлива должны
быть расположены в
определенном месте вдали от
любых источников возгорания или
открытого дренажа
c)“No Smoking” sign displayed at the
storage location and a charged fire
extinguisher of the correct type
Знак «Не курить» должен быть
Fuel
Storage
area
Зона
хранени
я
топлива
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
b) Yes – there is a designated refueling
area near the batch plant.
c) Yes
d) No – but there are plans to improve this.
повешен в месте хранения и
заряженный огнетушитель
соответствующего типа должен
быть готов к использованию.
d)All fuel tanks and storage areas
provided with concrete embankments
to readily contain spills
Все топливные баки и зоны
хранения должны быть
предусмотрены с бетонным
защитными дамбами для
удержания утечек
Oil
emission
Выброс
масла
a)Treat oily wastewater in
coalescence separator prior to
discharge
Обрабатывать нефтезагрязненные
промстоки в сепараторе-
коагуляторе до слива.
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) At the vehicle washing area there are
plans to install an oil filter to treat the
wastewater
Refueling Refueling of vehicles shall take place
only in designated areas
a) Yes
Training Fuel handling training shall include
chemical handling in the training
program for assigned personnel
a) Yes
Waste
Plan /
План
a)Identify all possible waste pollution
sources
Определить все возможные
источники отходов
Project
Site
Площад
ка
Examinatio
n
Оценка
a)Contractor
Подрядчик
b)PMU
ГРП
a) Not identified in a systematic way – this is a
task for the environmental officer of Topalang.
b) They are implementing waste control
measures according to their own internal
b)Compile and implement a waste
control plan
Составить и применить план
контроля отходов
c)Procedures detailed in the Material
Safety Data Sheet (MSDS) for
hazardous materials included in
pollutants spillage control plan and
followed in the event of an
emergency situation
Процедуры, детально описанные в
Листах данных безопасности
материалов для опасных
материалов, должны быть
включены в план контроля утечки
загрязнителей и соблюдаться в
случае чрезвычайной ситуации.
проекта procedures plan. A formal plan should be part
of the ZEP for construction (Environmental
impact statement). This document should be
produced by an accredited design engineering
institute. It will be required to report on this
quarterly.
c) Yes
Waste
Disposal
Утилизаци
я отходов
a)Dispose unusable waste streams at
permitted waste disposal facilities
Утилизировать непригодные потоки
отходов в разрешенных местах
утилизации отходов
Disposal
facilities
Установки
утилизаци
и
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes, there is a contract with a local waste
management company. Waste is deposited
approximately 4 km from site.
Waste from the vehicle maintenance area is
taken away and deposited by the vehicle
rental company.
Waste
disposal
Утилизаци
я отходов
a)Separate waste disposal area shall
be designated on the construction
site
Отдельная зона утилизации
отходов должна быть разработана
Disposal
area
Зона
утилизаци
и
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
c)disposal company
a) Yes, although this should be increased
b) Yes, although this can be improved
c) Yes
d) Some waste is separated although this
can be improved. There are separate
на строительной площадке
b)Separate waste disposal area
contains clearly demarcated skips
and bins to allow different types of
waste
Отдельная зона утилизации
отходов содержит разграниченные
контейнеры и мусорные баки для
разделения различных типов
отходов
c)Waste is separated into
nonhazardous and
hazardous/potentially hazardous
prior to reuse, recycling or transport
to Landfill
Разделение отходов на неопасные
и опасные / потенциально опасные
перед повторным использованием,
переработкой или
транспортировкой на свалку.
d)Domestic, metal scrap, used oil,
paper, hazardous etc.
Бытовые, металлолом,
использованное масло, бумага,
опасные отходы и т.д.
e) Disposal of all waste appropriately
(with formal contracts with waste
management companies)
Утилизирующая
компания
disposal areas at the HDEC workers camp
and the canteen.
e) Yes
Waste
disposal
Утилизаци
я отходов
a)The wide range of materials and
chemicals involved such as oil,
lubricants, cutting oils, sludge, paints
etc.
Широкий ассортимент материалов
и химических веществ, таких как
масло, смазки, охлаждающее
масло, эмульсия, лакокрасочные
материалы и пр.
b)Hazardous waste shall be
identified, classified, handled and
disposed of safely
Опасные отходы должны быть
определены, классифицированы,
обработаны и утилизированы
безопасно
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
Contractor
Подрядчик
a) Not applicable
b) At this time there are not many
hazardous wastes on site. Increased
training on how to identify and dispose of
hazardous waste should be given to
employees of all levels.
hazardous
waste
Опасные
отходы
Identify types of hazardous waste:
Определить типы опасных отходов
a)Fuel, waste oil, paints and
contaminated material with oil
Топливо, отработанное масло, краски
и маслозагрязненные материалы
b)Sludge contaminated with heavy
metals
Буровая грязь, загрязненная
тяжелыми металлами
c)Corrosives, including acids and alkalis
Корродирующие вещества, включая
Project
Site
Площад
ка
проекта
Examinatio
n
Оценка
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a, b, c, d) The Topalang Environmental officer
should put together a list of all the hazardous
wastes that will be generated and understand
how to dispose of them adequately.
кислоты и щелочь
d)Other hazardous substances
Прочие опасные вещества
Reuse
Вторичное
использов
ание
a)Re-use the waste during construction Вторично использовать отходы во время строительства
b)Re-use or recycle waste streams to
other users at other locations
Вторично использовать потоки
отходов к другим пользователям в
других местах
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a, b) Where possible waste is being reused
Reuse
Вторичное
использов
ание
a)The design of formwork could
maximize the use of standard
wooden panels
Проект опалубки может увеличить
использование стандартных
деревянных панелей
b)Alternatives such as steel formwork
or plastic facing could be considered
to increase the potential for re-use
Альтернативы, такие как стальная
опалубка или пластмассовая
облицовка, могут быть учтены для
увеличения возможного
повторного использования
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
Contractor
Подрядчик
a) Where possible this is taking place
b) Where possible this is taking place
Recycle
Waste
Переработ
a) Develop dedicated area for
sale of recycled material
away from active
Out of
the
project
Training
Обучение
a)Contractor
Подрядчик
b)Subcontractor
a) Some designated areas on site have
been set aside for recyclable materials. For
example behind the rebar workshop on the
ка construction works and near
site access point
Разработать отдельную
зону для продажи
переработанных
материалов от
действующих
строительных работ и
около места доступа на
площадку.
site
Вне
площад
ки
Субподрядчик cooling tower there is an area for scrap
metal. However these areas are not yet
permanent.
Rubbish
bins
Мусорные
баки
a)Provide sufficient bins with lids to
store the solid waste produced on a
daily basis
Предоставить достаточное
количество баков с крышками для
хранения твердых отходов,
производимых ежедневно.
b)Bins not allowed to become overfull
and shall be emptied as a minimum
on a weekly basis
Баки не должны быть переполнены
и должны опустошаться как
минимум еженедельно.
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
c)disposal company
Утилизирующая
компания
a) The number of bins has been increasing,
however more are required. Some of the bins
are very heavy and difficult to empty.
b) Yes, bins are emptied at frequently (usually
weekly or bi-weekly)
Rubbish
bins
Мусорные
баки
a)Implement adequate numbers of
rubbish bins around construction site
and in construction camps
Применить достаточное количество
мусорных баков вокруг строительной
a)Projec
t Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
c)disposal company
a) The number of bins has been increasing,
however more will be required. Some of the
bins are very heavy and difficult to empty.
They are emptied by hand currently.
b) Most of the bins have accurate signage
площадки и в строительном городке
b)Install signage encouraging use of
rubbish bins on site and in construction
camps
Установить знаки, рекомендующие
использование мусорных баков на
площадке и в строительном городке
b)Camp Утилизирующая
компания
although separation should be encouraged
more.
Discharge
Сброс
a)Prohibit dumping of dredge material in
canal or elsewhere on site
Запретить сброс вынутого грунта в
КМК, канал и прочие районы на
площадке
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
Storing
Хранение
a)Design and implement a temporary
waste storage area for domestic
waste
Разработать и применить место
временного хранения отходов для
бытовых отходов
b)Located away from living and
eating areas
Располагаться вдали от жилых
мест и мест употребления пищи
c)Separation of storage of hazardous
and non-hazardous waste
Отдельное хранение опасных и
неопасных отходов
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes, in the future there are plans for
more adequate areas
b) Yes
c) Yes
Storing a) Containers used for the storage of Storage Observatio a)Contractor a) Yes
Хранение chemical wastes shall be suitable for
the substance they are holding,
resistant to corrosion, maintained in a
good condition, and securely closed
Контейнеры, используемые для
хранения химических отходов,
должны Подходить для веществ,
которые в них хранятся, быть
устойчивыми к коррозии,
содержать в хорошем состоянии, и
плотно закрываться
b)Stored chemical in roofed areas with
concrete flooring.
Хранить химикаты в местах с крышей
и бетонным полом.
area
Зона
хранени
я
n
Наблюден
ие
Подрядчик
b)Subcontractor
Субподрядчик
b) Yes, there is a designated chemical
storage area
storing
Хранение
The storage area for chemical waste
shall
Зона хранения химических отходов
должна
a)Be located away from surface water
bodies.
Находиться вдали от поверхностных
вод
b)Be constructed with a weatherproof
cover, concrete floor with bunding, and
with adequate securable storage bins for
waste.
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) The chemical storage area is located
near the batch plant and at the HDEC
temporary camp
b) Yes
c) Adequate signs and sign training has
been provided
d) Yes
e) Yes, it is enclosed on 4 sides
f) Yes
Быть построена с устойчивой к погоде
крышей, бетонным полом с
обваловкой и с соответствующими
закрепляющимися баками для
отходов
c)Have appropriate signage and signage
system
Иметь соответствующие знаки
d)Be clearly labeled and used solely for
the storage of chemical waste.
Быть четко промаркированной и
использоваться исключительно для
хранения химических отходов
e)Be enclosed on at least 3 sides.
Быть закрытой как минимум с трех
сторон
f)Be arranged such as to separate
incompatible materials
Быть организованной таким
образом, чтобы разделять
несовместимые материалы
Training
Обучение
a)Include information on solid waste
management in construction worker
training program
Включить информацию об
управлении твердыми отходами в
программу обучения строительных
рабочих
Training
center
Учебны
й центр
Training
Обучение
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Information is included in the HSE
induction session for workers
Separating
Сортировк
а
a)Wood and other scrap material with
a commercial value shall be
separated and stored in segregated
areas prior to removal
Дерево и прочие отходы с
коммерческой ценностью должны
быть отделены и храниться в
раздельных зонах до удаления
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
Battery
Батареи
a)Batteries drained and flushed
before disposal and the residual acid
diluted and neutralized discharged
into the sewerage plant
Батареи должны быть разряжены
и промыты до утилизации, а
остаточная кислота должна быть
растворена и нейтрализована и
утилизирована в канализационную
систему
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Batteries are removed by the vehicle
rental company
Chemical
waste
Химически
е отходы
Disposal of chemical waste shall
Утилизация химических отходов
должна
a)Treated by a licensed waste collector.
Обрабатываться лицензированным
коллектором отходов
b)Be to a facility licensed to receive
chemical waste, such as the chemical
waste treatment
Быть учреждением, лицензированным
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
c)Waste collector
Коллектор
отходов
a, b) There are plans in place for this
c) Yes
d) Local legislation allows for 6 months
storage on site
e) Yes
на получение химических отходов,
таким как учреждение обработки
химических отходов
c)Hazardous and toxic waste shall not
be disposed of on the canal
Опасные и токсичные отходы не
должны утилизироваться в канал
d)Hazardous waste shall be removed
from the site property within 60 days.
Опасные отходы должны быть
удалены с площадки в течение 60
дней
e)Hazardous waste shall not be dumped
onto the ground, into storm sewers or
into sanitary sewer system
Опасные отходы не должны
сбрасываться на землю, ливневые
стоки или санитарные стоки
Waste of
catering
Кухонные
отходы
a)Catering wastes is divided into food
waste and non-food waste
Кухонные отходы подразделяются
на пищевые и непищевые отходы
b)All organic food waste generated
by kitchen facilities to be disposed of
at the landfill
Все органические пищевые
отходы, производимые на кухнях
должны утилизироваться на
Catering
Места
общественн
ого питания
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
c)Catering
company
Компания
общественного
питания
a) This is being done
b) Food waste is taken by local workers and
fed to animals. In the future it will be given
to a nearby farm.
свалке
c)Food waste daily removed from the
kitchen
Пищевые отходы должны
ежедневно удаляться с кухни
d)Food waste always contained in
plastic bags for disposal
Пищевые отходы должны всегда
храниться в пластиковых мешках
для утилизации
e)Non-food waste collected in
separate containers as beverage
cans, packing materials, etc.
Непищевые отходы должны
собираться в отдельные
контейнеры, например, банки из-
под напитков, упаковочные
материалы и пр.
Oily waste
water
Маслосод
ержащие
сточные
воды
a)Oily wastewater and oil-
contaminated material generated
from the construction machinery will
be collected and transferred back
onshore for treatment/disposal
Маслосодержащая вода и
маслозагрязненные материалы,
произведенные строительной
техникой в процессе
строительства, будут собираться и
Project
Site
Площад
ка
проекта
Observatio
n
Наблюден
ие
a)Contractor
Подрядчик
b)Subcontractor
Субподрядчик
a) Yes
передаваться обратно на сушу для
обработки/утилизации
A 30.June .2014 Monthly Report O.Amanov J.H.KIM J.H.KIM
REV. DATE DESCRIPTION DSGN CHKD APPD
. . EMPLOYER/ :
CONSULTANT
:
CONTRACTOR/ :
PROJECT/ :
TALIMARJANTHERMAL POWER PLANT EXPANSION PROJECT
TITLE/ :
Monthly Environmental Report
SCALE
DOCUMENT NUMBER
Rev.
.
NONE / A
Report Отчет
TALIMARJAN TPP UNITARY ENTERPRIZE of SJSC UZBEKENERGO
Я « Я Э »
« Э »
`
2
ENVIRONMENTAL REPORT
1. Purpose The purpose of report is to minimize the adverse impacts on the environment by establishing and maintaining the effective mitigation plans against environmental issues.
.
2. Environmental Issues
2.1 Air Emission
2.2 Dust control
2.3 Noise control
2.4 Wastewater quality control . 2.5 Waste management control
2.6 Pollutants Spillage control, etc. .
3. Environmental Meeting
3.1 Date/ : Thursday, 10:00 AM , 10:00
3.2 Location/ : Talimarjan HDEC conference room -
3.3 Attendants/ : HDEC HSE Team, Subcontractor HSE Team and Management/
( ) HDEC, .
4. Environmental Training
4.1 On the first day of duty – Induction -
4.2 Subject
Project HSE (Environmental) policy and objectives (Annex 1)
HSE ( ) ( 1)
Environmental management program
Significant environmental aspects identified.
Emergency preparedness and response plan / drill in environmental incident such as oil, chemical
spillage.
, , .
Dust control plan
Noise control plan
Wastewater control plan
Solid waste management and on how to identify hazardous or potentially hazardous wastes
`
3
Pollutants spillage control plan
Current applicable environmental laws and regulations
MSDS contents of hazardous materials, etc for concerned operational peoples.
. .
5. Environmental Performance Monitoring sheet
Aspect
Mitigation
Location
Monitoring
Responsible
Frequency
Risk Status
Management
Informing
a) Inform local residents schedule of the
construction activities.
b) Introduce types of emission and
countermeasures.
.
HSE
Training
center
HSE
Officially
Contractor
PMU
Yearly (if required)
(
)
a) Low
Management is
informed on
schedule of
construction
activities.
b) Medium
Emission type
and
countermeasures
regular
Emergency
A
a) Compile and implement an emergency situation
control plan.
.
b) Every three months have emergency drills.
.
c) Confirms the role of individual
.
Project Site
Observation of
emergency
Contractor
Subcontractor
Quarterly
E
a) Medium
Regular training
on Emergency
and accident is
going on
quarterly.
.
b)Medium
`
5
Regular drill
conducted in HSE
HSE c) Medium
HSE
manager,officers
and the other
persons have role
in Emergency
plan
HSE ,
Traffic
T
a) All traffic signs, signals, and road markings
must be obeyed.
, .
b) Authorized transportation of equipments and
materials entry to the site
c)Speed of transport vehicles should be strictly
controlled in the access road to TPP
Э .
Project Site
Inspection of
traffic conditions
Contractor
Subcontractor
Daily
a) Medium
The employees
are having
trainings on signs
and signals
description.
b) Low
Only authorized
vehicles can enter
in Site.
`
6
c) Medium
The speed limit
signs are posted
and drivers are
being trained for
speed limits
(20km/h).
(20
/ ). Monitoring
M a)Monthly monitoring of the following should take place:
:
Fuel (m3)/
Electricity (KWh)/ Э
Water (m3)/
Project Site
Observation
use of sources
Contractor
Subcontractor
Monthly
a) Low
Electricity, Fuel
and usage of
Water is being
monitored.
Э ,
. Air
Plan / a)Identify all possible air pollution sources related
to construction activities
b)Compile and implement an air control plan
Project Site
Examination of
air plan
Contractor
PMU
In the
construction
process
a) Low
There is no air
emission except
dust but is under
control
H
`
7
, ,
b) N/A
Exhaust fumes
a) Regularly serviced and maintained to be in
good condition vehicles and Equipment
b) Forbid the burning of waste, wood on site
,
c) Reduce idle time of all vehicles
Maintenanc
e Area
Project Site
Inspection of
air emission
Observation of
air pollution
Subcontractor
Appropriate
manager
Monthly
a) Low
All transports are
being serviced
and maintained.
. b) Low
Any burnings are
not allowed on
Sites.
c)Low
All vehicles are
under control.
.
Dust
`
8
Plan / a) Identify all possible dust pollution sources
related to construction activities
,
b) Compile and implement dust control plan
Project Site
Examination
dust plan
Contractor
PMU
In the
construction
process
a) Low
Dust pollution
sources are
identified and
being controlled.
. b) Low
The dust control
plan has been
implemented.
. Watering
Watering should be implemented to control dust
where
:
a)Working areas
b)Exposed areas
c)Active cuts excavation and fill sites
Project Site
Observation of
watering
Contractor
Subcontractor
1) Daily
2) Windy Days
Low
The schedule of
watering is
prepared and
work process is
followed by the
schedule.
Watering
Watering should be implemented to control dust
when
:
a)Before and after operation
b)Breaking of rock/concrete work
/
c)Drilling of rock work
Project Site
Observation of
watering
Contractor
Subcontractor
During
construction
activity
Low
The schedule of
watering is
prepared and
work process is
followed by the
schedule.
`
9
Site control
a) Minimize size and duration of exposed areas
b)Keep hauling roads in good condition
.
Project Site
Observation
dust control
Contractor
Subcontractor
Daily
a)Medium
Watering
exposed areas
b) Medium
Main roads are
kept clean.
.
Material control
Minimize size and duration of materials stockpiles
.
Lay down
yard
Observation
material storage
Contractor
Subcontractor
Daily
Low
All material are
under control
Material control
a)Minimum practical height to limit the fugitive
dust generation from unloading excavated
materials
,
,
.
b) Cement debagging should take place in a
sheltered area.
Project Site
Batching
Plant area
Observation of
work
Contractor
Subcontractor
Daily
a) Low
Loading and
Unloading works
are being
controlled not to
dump dust.
-
.
b) Low
The cement
debagging is
`
10
holding inside
temporary
warehouse.
Vehicle control
a)Limiting vehicle-entrained dust from unpaved
roads
, ,
b)Limiting vehicle speeds (20 km/h in Project Site)
and restricting traffic volumes
c)Trucks have proper fitting side and tail boards
d)Materials shall also be dampened, if necessary,
before transportation
, ,
e)Covering trucks during transport of materials
Project Site
road
Observation of
traffic condition
Contractor
Subcontractor
Daily
a) Low
Watering of main
roads is going on
6 times per day.
6
. b) Low
The signs
describing speed
limits are posted
on Site roads.
. c) Low
All trucks have
fitting side and tail
boards.
.
`
11
d)Low
Materials are
being moistened
during loading
time
e) N/A
No need to cover
the materials
during
transportation /
,
Noise
Plan / a)Identify all possible noise pollution sources
related to construction activities
,
b)Compile and implement a noise control plan
c)Posting Signboards on construction sites and/or
stickers on equipment outlining how affected
parties can lodge complaint
/
.
Project Site
Examination of
noise plan
Contractor
PMU
In the
construction
process
a) Low
All noise pollution
sources related to
construction
activities are
identified.
,
. b) Low
The control plan
is being used.
`
12
c) Low
Controlled by
Contractor and
Subcontractor
Noise level
a) Inspect noise level of the construction
equipment
b) Equipment Noise limit will comply with Item 223
of EIA.
For example. Direction of Nuristan are limited to
80 dba 1m
223 .
.
80 1
c)Use appropriate PPE (earplug, earmuff) if
exceeds noise limits
( , ),
Project Site
Inspection of
noise level
Contractor
Subcontractor
During
construction
activity
a) Low Noise level is
being inspected.
b) Low Equipment Noise
Limit conform with
Item 223 of EIA.
223
c) Low
The employees
use earplugs at
noisy workplaces.
.
Vehicle control
a)Limiting vehicle speeds (20 km/h at Project Site)
Project Site
road
Observation of
traffic control
Contractor
Daily
a) Low
Speed limit signs
`
13
b) Restrict truck movements to day time and
restrict truck movements to major transport routes
.
Subcontractor
are posted on Site
roads.
b) Medium
The restriction
movement of
transport routes
are controlled
Vehicle control
Regularly serviced and maintained to be in good
condition vehicles and Equipment
Maintenanc
e area
Inspection of
repair records
Subcontractor
Appropriate
manager
Monthly
Low
All vehicles are
being serviced
and maintained
periodically.
Noise barrier
a)Use of temporary acoustic barriers or exhaust
mufflers
b)Noise barriers located between noisy
construction activities and noise sensitive
receivers
,
Project Site
Observation
use of noise
protector.
Contractor
Subcontractor
Daily
a) Low
No need to use
temporary
acoustic barriers
or exhaust
mufflers so far
`
14
c)Noise maintained at 70 dB at outside of nearest
building from power plant
70
b) N/A
There is no
noise barriers and
noise sensitive
receivers /
H
c) Low
The noise
maintained lower
than 70 dB at
outside of nearest
building from
power plant
70
Equipment
control
a)Equipment shall be operated within
specifications and capacity
b)Equipment shall be operated in as diversified
manner as possible
c)Equipment shall be turned off when not in use
,
d)Work using machines or vehicles shall be
Project Site
Observation
work of
equipment
Contractor
Subcontractor
Daily
a) Low
Equipments are
being used within
specifications and
capacity.
. b) Low
`
15
prohibited in the midnight and the dawn
. e)Air intakes, vents, and stacks should be fitted
with suitable noise attenuating equipment (if
required)
,
(
)
The operation of
equipment is
controlled.
. c) Low
Equipments are
turned off if not
used .
,
d) Medium
Only heavy trucks
are working in day
time.
.
e) N/A
/
Equipment
control
Select the time when the environment is least
sensitive to noise impact using pile drivers, jack
hammers, and rock drills
,
,
Project Site
Inspection of
noise level
Contractor
Subcontractor
During
construction
activity
Low
The noisy work
processes are
held at suitable
time.
.
Wastewater
Plan / a)Identify all possible wastewater pollution
sources related to construction activities
Project Site
Examination of
wastewater plan
Contractor
In the
construction
a) Low
Under the
`
16
,
b)Compile and implement a wastewater control
plan
PMU
process
control by
contractor.
.
b) Low
The wastewater
control plan is
being
implemented.
. Batch plant
control
Wastewater from concrete batching plant
operation and shall not be discharged overland
, ,
Batching
Plant area
Observation of
wastewater
Contractor
Subcontractor
Operation of
batching plant
Э
N/A
Batch Plant has
not started
working yet. /
.
Washing water
a)Undertake settling and neutralization of alkaline
washing water containing excessive cement prior
to discharge
,
,
b)Water from washing large concrete-mixing
equipment
Batching
Plant area
Observation of
washing water
Contractor
Subcontractor
Operation of
batching plant
Э
a) N/A
/
b) Low
Controlled
wastewater
procedure of
Batch plant.
Washing water
a)All washing of equipment or machinery shall be
undertaken in designated areas
b)Washing of equipment areas must be equipped
with a suitable impermeable floor and sump/oil
trap
Washing
area
Observation of
washing area
Contractor
Subcontractor
Daily
a) Medium
Heavy vehicles
are being washed
in designated
area.
`
17
/ .
. b) Low
Install wastewater
disposal system.
.
Wastewater
emission
Wastewater collected within bunded area around
the fuelling area be disposed of as hazardous
waste
, ,
Fuelling area
Observation of
wastewater
Contractor
Subcontractor
Daily
Low
Install wastewater
disposal system.
.
Natural water
Natural run-off diverted away from any camps
Camp area
Observation of
natural water
Contractor
Subcontractor
Daily
N/A /
Rain water
Heavy rain water plan to be and implemented for
the construction phase of the Project
.
Project
Site
Observation of
rain water
Contractor
Subcontractor
During
Heavy rain
Low
The heavy rain
plan is being
implemented
Contaminated
Water
Sand, silt and silt-laden water do not enter the
water drain system or KMC
, ,
Project
Site
Observation of
water system
Contractor
Subcontractor
During
Heavy rain
Low
Water drain
system and KMC
are protected
from any
pollution.
`
18
. Material control
a)All hazardous material storage areas designed
to reduce risk of spillages
b) All materials covered during transport to
prevent them from spilling
c)Store all liquid/solid waste properly above
ground to avoid spills/leaks
/ /
d)Develop a hazardous materials and handling
plan provide spill response kits at all HazMat
storage areas and work site
.
. e) Chemicals and fuels on site should be kept to a
minimum
Material
storage
areas
Observation of
material storage
condition
Contractor
Subcontractor
Daily
a) Low
Hazardous
material storage
is protected from
spillage
. b) Medium
Materials are
watered before
loading
. c) Low
All liquid/solid
wastes are
properly stored.
/
.
d) Medium
Hazardous
materials and
handling plan is
created.
`
19
e)Medium
Chemicals and
fuels
on Site are kept
depending on
requirement
Straining
Construct of dirt trap, intercept or pond and the
attenuation dam (if required) commenced as early
as possible in the construction phase
,
( )
.
Project
Site
Observation of
strain system.
Contractor
Subcontractor
Weekly
N/A
/
Barrier
Channels, earth bund walls or sandbag barriers
be provided on site to direct rain water to silt
removal facilities
,
Project
Site
Observation of
silt removal
facilities
Contractor
Subcontractor
Daily
N/A
/
Hazardous
waste
Storage of hazardous waste in bunded areas to
avoid leaks escaping to the ground or nearby
surface waters
,
Hazardous
waste
bunded area
Observation of
hazardous
waste
Contractor
Subcontractor
Weekly
N/A
/
There is no any
hazardous waste
on Sites
Monitoring
a)Monitoring water quality
b)Water samples, sent to local laboratory to be
tested for Water quality ph, oil, debris and etc
,
Project
Site
Experimentation
of wastewater
Э
Laboratory
Monthly
a)Low Laboratory
test for water is
being held
periodically.
`
20
, , , . .
b) Low
Water samples
from potable, non
potable and
sewage are
tested monthly
,
Soil
Plan / a)Identify all possible soil pollution sources related
to construction activities
,
b)Compile and implement a soil control plan
Project Site
Examination of
soil plan.
Contractor
PMU
In the
construction
process
a) Low
All possible soil
pollution sources
are under
control
b) Low
Soil control plan is
being
implemented.
.
Site control
a)Minimize size and duration of exposed areas
Project
Site
Observation of
soil emission
Contractor
During
construction
a) N/A /
`
21
b) Minimize excavation during construction of the
dam fuel oil and limestone
c) Minimize the overall slope of the site
d)Ensure good landscaping and erosion control
Subcontractor
activity
b) N/A
/
c) Low
There are no
much slope areas
at Sites
d) Low
Landscaping
trees are planted
to prevent
erosion around
working site
,
Site control
Deposited silt and grit removed regularly and
disposed of by spreading evenly over stable
Project
Site
Observation of
silt and grit
Contractor
Subcontractor
Monthly
N/A
/
Covering
a)Exposed slope surface shall be covered during
the rainy day
b)Open stockpiles of construction materials
covered during rainy day
Project
Site
Observation of
material store
Contractor
Subcontractor
During rainy
day
a) Medium
Barricades are
posted around
slopes.
,
`
22
b) N/A
/
Road control
Trafficked areas and access roads protected by
coarse stone ballast
-
Project
Site road
Observation of
traffic
Contractor
Subcontractor
Monthly
N/A
/
Sediment
Sediment tanks can be used for settling
wastewater prior to disposal
Project
Site
Inspection of
sediment tank
ability
Contractor
Subcontractor
Install
sediment tank
N/A
/
Drainage
facilities
All drainage facilities, erosion and sediment
control structures shall be regularly inspected and
maintained
,
Project
Site
Inspection for
maintenance
Contractor
Subcontractor
Monthly
Low
Planned where to
install the
drainage system.
,
.
Vehicle control
a)All vehicles and plant cleaned before leaving a
construction site
b)Ensure no earth, mud, debris and the like is
deposited by the mud roads
, , ,
Exits of the
project site
gate
Observation of
traffic condition
Contractor
Subcontractor
Weekly
a) Medium
Heavy vehicles
are being
cleaned.
.
b) Medium
The roads are
being cleaned
from mud after
rain.
.
Road control a)All road works separated from surface waters Project Observation of Contractor Daily a) Low
`
23
b)All roads shall be properly sloped and have
adequate culverts to manage runoff
c)Earth works to construct drainage ditch sand to
lay sub surface drainage conducts
Site road
traffic condition
Subcontractor
The road works
made as required
,
b)Low
All roads are
sloped as
required
c) N/A /
Excavated
material
a)Excavated materials possible to used
reclamation fill
b)Surplus excavated materials quarry over
burden, rock rejected for aggregate, aggregate
surplus to the requirements and the like not
discarded in discriminately
, , , ,
c)Different types of surplus excavated materials
deposited separately in the spoil dumps
designated for the purpose outside the Project site
,
Project
Site
Observation of
excavated
material
Contractor
Daily
a) Medium
Excavated soil is
being used for
backfilling.
.
b) Low
All rocks are
removed from
Sites.
.
c) Medium
Big stones,
hammered
concretes
removed
separately in the
`
24
designated spoil
dumps
,
Spill Control
Management
a)Any spillage of fuel shall straight away be
absorbed using sand or other absorbent materials
. b)Develop spill response plan
. c)Only people with adequate training and
knowledge should handle fuel and chemicals to
avoid spills
, .
d) Fuelling should be one on concrete surface
provided with spill catch tank that can be easily
cleaned and all spilled fuel recovered/safety
disposed
,
/
e) All repair and maintenance work to be done
either on concrete surface with oil spill catch
basins or oil catch pans provided at all service
areas
Project
Site
Observation
spill
Examination of
spill plan
Observation of
spilling
Contractor
Subcontractor
Daily
Prior to fuel
bulk storage
a) Low
All spillages are
eliminated
immediately
.
b) Low
Spill response
plan is being
used.
.
c) Low
Only authorized
employees work
with fuel and
chemicals.
`
25
-
,
f) Routinely inspect all equipment handling
hazardous materials for leaks and spills
g) All fuel where spills and leakage area possible
e.g. the generator, must have basins installed to
prevent leakage
, ,
h) The recovered materials must be recycled
i) Fuelling equipment must be fitted with proper
fuel nozzles and devices to avoid accidental spills
. d) Medium
The fuelling
process is being
taken on gravel
surfaced fuel
point.
.
e) Low
All maintenance
works are held in
maintenance
shop with
concrete surface.
.
f) Low
All hazardous
materials are
under control.
. g) Low
The fuel point has
spill response kit
and water
reservoir.
`
26
h) Low
Recycling's are
used where
needed.
,
. i) Low
Used only proper
fuel nozzles and
device.
.
Storing
a)All fuel stored on site shall be kept in drums or
in bulk tanks
, ,
b)Fuel storage area be located at a designated
place away from any source of ignition or open
drain
c)“No Smoking” sign displayed at the storage
location and a charged fire extinguisher of the
correct type
Fuel Storage
area
Observation of
oil storage
Contractor
Subcontractor
Daily
a) Low
All fuel is stored in
fuel point.
b) Low
The fuel point has
been built in
designated place
`
27
« »
.
d)All fuel tanks and storage areas provided with
concrete embankment store a daily contain spills
e) Provide spill kits at all working areas
. c) Low
Proper signs are
posted and fire
extinguisher
exists at fuel
point.
.
d) Low
All fuel tanks and
storage areas are
safe from spills.
. e) Low
Oil spillage kits
are provided at all
working areas
. Oil emission
Treat oily wastewater in coagulant separator
prior to discharge
- .
Project
Site
Observation of
oily water
Contractor
Subcontractor
Daily
NA
/
Refueling
Refueling of vehicles shall take place only in
designated areas
Fuel Storage
area
Observation of
refueling
Contractor
Subcontractor
Daily
Low
The fuelling
process is being
`
28
.
taken only in
designated area.
. Training
Fuel handling training shall include chemical
handling in the training program for assigned
personnel.
.
Training
Center
Training of oil
handling
Contractor
As needed
Low
The employee,
who works with
fuel or chemicals,
passes by special
training.
,
,
.
Waste
Plan / a)Identify all possible waste pollution sources
b)Compile and implement a waste control plan
c)Procedures detailed in the Material Safety Data
Sheet (MSDS) for hazardous materials included in
pollutants spillage control plan and followed in the
even to fan emergency situation
,
,
.
Project Site
Examination of
waste plan
Contractor
PMU
In the
construction
process
a) Low
All waste pollution
sources are
identified.
. b) Low
Waste control
plan is on
process.
`
29
. c) Low
The MSDS is
plan is on
process.
Waste
Disposal
Dispose unusable waste streams at permitted
waste disposal facilities
Disposal
facilities
Observation of
waste facility
Contractor
Subcontractor
Weekly
Low
Waste disposal
company takes
out all type of
wastes
.
Waste disposal
a)Separate waste disposal area shall be
designated on the construction site
b)Separate waste disposal area contains clearly
demarcated skips and bins to allow different types
of waste
c) Waste is separated into non-hazardous and
hazardous / potentially hazardous prior to reuse,
recycling or transport to Landfill
/
,
.
d)Domestic, metal scrap, used oil, paper,
hazardous etc.
, , , , . .
e) Disposal of all waste appropriately (with formal
contracts with waste management companies)
Disposal
area
Observation of
waste control
Contractor
Subcontractor
Disposal
company
Daily
a)Low
Planned to place
waste separation
dumpsters in
designated area.
. b)Low
Waste bins are
located for
separation in
designated area.
`
30
( )
c) Medium
Waste is being
separated into
non-hazardous
and hazardous.
.
d) Low
Waste is being
separated.
e) Low
Waste disposal
company takes
out all type of
wastes and
disposes.
.
Waste disposal
a)The wide range of materials and chemicals
involved such as oil, lubricants, cutting oils,
sludge, paints etc.
, , ,
, , .
b)Hazardous waste shall be identified, classified,
handled and disposed of safely
, ,
Project
Site
Observation of
waste
Contractor
Daily
a) Low
Waste disposal
company takes
out all type of
wastes
.
b) Medium
Hazardous
`
31
wastes are
controlled. .
.
Hazardous
waste
Identify types of hazardous waste:
a)Fuel, waste oil, paints and contaminated
material with oil
, ,
b)Sludge contaminated with heavy metals
,
c)Corrosives, including acids and alkalis
,
d)Other hazardous substances
e)Appointment of approved contractor for the
removal of hazardous and solid waste to existing
incineration and landfill areas approved by
Hokimiyat and SES
,
Э
Project
Site
Examination of
hazardous
waste
Contractor
Subcontractor
In the
construction
process
Low
All types of
wastes are
identified.
a) Low
Identified
b) N/A
/
c) N/A
/
d) All types of
wastes are
identified.
e) N/A
/
Reuse
a)Re-use the waste during construction
b)Re-use or recycle waste streams to other users
at other locations
Project
Site
Observation of
reuse waste.
Contractor
Subcontractor
Daily
a) N/A
Waste disposal
company takes
out all type of
wastes /
.
`
32
b) N/A
/
Reuse
a)The design of formwork could maximize the use
of standard wooden panels
b)Alternatives such as steel formwork or plastic
facing could be considered to increase the
potential for re-use
,
,
Project
Site
Observation of
reuse material.
Contractor
Daily
a) Low
There are used
standard metal
casings.
b) Low
Only steel
formworks are
reused.
.
Recycle Waste
Develop dedicated area for storage of recycled
material away from active construction works and
near site access point
.
Out of the
project site
Training of
waste disposal
Contractor
Subcontractor
Monthly
N/A /
Rubbish bins
a) Provide sufficient bins with lids to store the
solid waste produced on a daily basis
,
.
b) Bins not allowed to become overfull and shall
be emptied as a minimum on a weekly basis
.
Project
Site
Observation of
waste disposal
Contractor
Subcontractor
Disposal
company
Weekly
a) Low
Standard waste
bins are placed at
Sites
b) Bins are being
cleaned before
overfull.
`
33
Rubbish bins
a)Implement adequate numbers of rubbish bins
around construction site and in construction
camps
b)Install signage encouraging use of rubbish bins
on site and in construction camps
,
a)Project
Site
b)Camp
Observation of
waste disposal
Contractor
Subcontractor
Disposal
company
Daily
a) Medium
Providing with
sufficient waste
bins is ongoing.
b) Low
Waste bins are
marked with
proper signs.
,
. Discharge
Prohibit dumping of discharge material in canal or
elsewhere on site
,
Project
Site
Observation of
dumping
Contractor
Subcontractor
Daily
Low
Dumping dredge
in canal is
prohibited
. Storing
a)Design and implement a temporary waste
storage area for domestic waste
b)Located away from living and eating areas
c)Separation of storage of hazardous and non-
hazardous waste
Project
Site
Observation of
waste store
area
Contractor
Subcontractor
Daily
a) N/A
Waste disposal
company takes
out all type of
wastes /
.
b) N/A
/
c) Low
Hazardous
`
34
materials are
stored in
designated area
Storing
Containers used for the storage of chemical
wastes shall
,
,
a)Be suitable for the substance they are holding,
resistant to corrosion, maintained in a good
condition, and securely closed
,
, ,
,
b)Stored chemical in roofed areas with concrete
flooring.
.
Storage area
Observation of
waste store
area
Contractor
Subcontractor
Daily
a) N/A
Placed proper
waste bins in
Sites. /
b) Low
Chemical are
stored in special
chemical storage
area.
Storing
The storage area for chemical waste shall
a) Be located away from surface water bodies.
b) Be constructed with a weatherproof cover,
concrete floor with bunding, and with adequate
securable storage bins for waste.
,
c) Have appropriate signage and signage system.
Project Site
Observation of
waste store
area
Contractor
Subcontractor
Daily
a) Low
Chemical storage
area is located
away from water.
b) Low
Chemical storage
is Located in
`
35
. d) Be clearly labeled and used solely for the
storage of chemical waste.
e) Be enclosed on at least 3 sides.
f) Be arranged such as to separate in compatible
materials
,
concrete building.
. c) Medium
The signs
describing
chemical storage
area are posted.
d) N/A
/
e) Low
Chemical storage
area is closed
from all sides.
.
f)Low
Materials
separation
arranged as
properly.
, .
Training Include information on solid waste management in Training Training of Contractor a)Monthly Low
`
36
construction worker training program
center
waste disposal
Subcontractor
b)Random
The information
on solid is
included in
training program.
. Separating
Wood and other scrap material with a commercial
value shall be separated and stored in segregated
areas prior to removal
Project
Site
Observation of
waste control
Contractor
Subcontractor
Daily
Low
Wood and other
scrap are
separated in
specified place
Battery
The dead batteries will be given to specialized
organizations for reuse
Project
Site
Observation of
battery
Contractor
Subcontractor
Daily
N/A
/
5.1 Definition
A. High: The activity shall be carried out. Adequate control measures shall be established to bring
the risk levels to medium before the activity can be performed. : .
. B. Medium: The Activity shall be further analyzed to determine if any additional control measure
are required. If required, such additional control measures shall be established before the activity can be performed.
: . ,
. C. Low: No additional control measures will be required.
: .
6. Noise Level
Sound Level (dBA) ( )
Location
Test Date Limits
Remark
4.June.2014 11.June.2014 18.June.2014 25.June.2014
Contractor Office
45.3 46.3 49.4 43.5
85 dBA
Approve
Contractor Camp
47.1 47.9 51.6 47.7
Approve
Power Block Gate
54.1 55.7 60.1 51.7
Approve
Power Bock Area
55.2 60.3 67.2 55.1
Approve
Cooling Tower Gate
46.3 44.6 43.4 46.7
Approve
Batch plant
50.3 49.5 45.9 52.6
Approve
Subcontractor
Camp area
51.1 51.0 53.6 51.1 Approve
Existing Power Plant Gate
51.4 56.4 54.2 52.8 Approve
Nuristan 55.9 55.9 54.8 47.9 Approve
The Greenhouse of
Existing TPP
54.3 45.9 43.9 56.1
Approve
Customs Warehouse
48.6 56.4 44.1 50.6
Approve
Parking lot
48.2 48.4 52.1 49.8
Approve
`
38
7. Environmental Status
Description
This Month
Cumulative
No. of Training
33 155
No. Of Persons
336 1233
Training Man Hours
-
672 2462
8. The Monitoring of Usage
The Monitoring of:
: This Month
Cumulative
Fuel (l) ( )
Diesel 31200 418232
Benzin 1140 1860
Electricity (kv/h) ( / ) 25240 149557
Disposed Waste (tons) 33291 125702
Water
( ) Non-potable water (m
3) 8272 16544
Potable water (m
3) 2111 4112
`
39
9. Construction Site map
Site map indicates Assembly points, Waste Storage area, Water Sampling points, Sound Level Sampling points, Access roads.
D 05.Aug.2014 Issue for Approval / O.Amanov H.Khidirov K.H.KIM
C 25.Jan.2014 Issue for Approval / J.H.KIM Y.H.Jeong T.H.Jung
B 07.Jan.2014 Issue for Approval / J.H.KIM Y.H.Jeong T.H.Jung
07.Nov.2013 Issue for Approval / J.H.KIM Y.H.Jeong T.H.Jung
REV. DATE DESCRIPTION DSGN CHKD APPD
. EMPLOYER/ :
CONSULTANT :
CONTRACTOR/ :
PROJECT/ :
TALIMARJANTHERMAL POWER PLANT EXPANSION PROJECT
TITLE/ :
SITE BASED ENVIRONMENTAL MANAGEMENT PLAN
SCALE
DOCUMENT NUMBER
Rev.
.
NONE / B-000-W-64-001 D
FOR APPROVAL
TALIMARJAN TPP UNITARY ENTERPRIZE of SJSC
UZBEKENERGO
Я « Я Э » « Э »
Site Based Environmental Management Plan Rev. D
1
Revision Control Table
Rev. Date Rev. No. Description of Revision Remarks
-July-2014 4 Fourth Issue
The title "Environmental Management
Plan" is changed to "Site Based
Environmental Management Plan".
Section 5.1 Part 1 Construction, Clause 2
(Inform community of duration and schedule
of construction activities) was removed. The
Construction activities are away from local
community.
Section 5.1 Part 2 Admin. Clause 5
(Regularly backfill and re-dig toilets) was
removed. All WC facilities are connected to
sewage system.
SОМЭТШЧ 5.2 “EЧЯТrШЧЦОЧЭКХ PОrПШrЦКЧМО
MШЧТЭШrТЧР PrШРrКЦ” ЭКЛХО аКЬ rОЦШЯОН. TСО
Monitoring was included on the table of
Annex 7.3
Section 5.3 Part 3. The аШrН “CШЧЭrКМЭШr”
аКЬ МСКЧРОН ЭШ “SuЛМШЧЭrКМЭШr” КЬ ЭСО
Contractor does not have its own
equipments.
Section 5.5.2 Part 1The article (Inform
community of duration and schedule of
construction activities) was removed. The
Construction activities are away from local
community.
SОМЭТШЧ 5.5.3.2 “TОЦЩШrКrв ЧШТЬО ЛКrrТОrЬ”
was removed as there is no need to use
Noise barriers at Site.
Section 5.5.3.3 Part 4 (Inform community of
duration and schedule of construction
activities) was removed. The Construction
activities are away from community.
Site Based Environmental Management Plan Rev. D
2
Section 5.6.1 Part 2 was modified. The word
“РrШuЧН аКЭОr” аКЬ rОЦШЯОН КЬ РrШuЧН
water exists over than 16 m deeper and it
cannot be deteriorated.
Section 5.6.2 Part 2 Clause 3 was modified.
TСО аШrН “HОКЯв rКТЧ” аКЬ rОЦШЯОН КЬ
there no any heavy rains.
Section 5.6.2 Part 3 was removed as
underground water exists over than 16 m
deeper.
Section 5.6.3.3 Part 2 was removed. The
Excavation works are not being held in Fuel
point.
Section 5.6.3.3 Part 5 was modified (the
ЬОЧЭОЧМО “КХХ ЭrКППТМФОН КrОКЬ КЧН КММОЬЬ
rШКНЬ ЩrШЭОМЭОН Лв МШКrЬО ЬЭШЧО ЛКХХКЬЭ” аКЬ
removed) as coarse stone ballasts do not
exist on Site roads.
Section 5.6.3.3 Part 6 was modified (the
ЬОЧЭОЧМО “НТЬЩШЬОН ШП Лв ЬЩrОКНТЧР ОЯОЧХв
ШЯОr ЬЭКЛХО” аКЬ rОЦШЯОН) КЬ НОЩШЬТЭОН ЬТХЭ
and grit do not exist at Site.
Section 5.6.3.3 Part 8 was modified (the
ЬОЧЭОЧМО “аСООХ аКЬСТЧР ЛКв” аКЬ
removed) as wheel washing point is set in
Car wash point.
Section 5.7.2 Part 6 was modified. All
wastes shall be disposed by Waste Disposal
Company.
SОМЭТШЧ 5.7.3.3” АКЬЭО ПrШЦ Wessel” аКЬ
removed. The wastes from Wessel do not
exist on Site.
Section 5.7.3.2 "Noise Enclosure" removed.
The "Noise Enclosure" is not usable for this
project.
Section 5.7.3.5 Part 2 was modified. All food
wastes shall be disposed by Waste Disposal
Site Based Environmental Management Plan Rev. D
3
Company.
Annex 7.3 SОМЭТШЧ “MКЧКРОЦОЧЭ”, TКЛХО
“IЧПШrЦТЧР” PКrЭ A (Inform local residents with
the schedule of the construction activities
was removed.
Annex 7.3 SОМЭТШЧ “MКЧКРОЦОЧЭ”, TКЛХО
“Emergency” PКrЭ A (Compile and implement
ОЦОrРОЧМв ЬТЭuКЭТШЧ МШЧЭrШХ ЩХКЧ” аКЬ
removed as the plan exists and being
implemented.
AЧЧОб 7.3 SОМЭТШЧ “MКЧКРОЦОЧЭ” TКЛХО
“EЦОrРОЧМв” PКrЭ C (CШЧПТrЦЬ ЭСО rШХО ШП
individual) was removed.
AЧЧОб 7.3 SОМЭТШЧ “DuЬЭ” TКЛХО “VОСТМХО
МШЧЭrШХ” PКrЭ E аКЬ ЦШНТПТОН: CШЯОrТЧР ЭruМФЬ
during transport of materials (if required).
AЧЧОб 7.3 SОМЭТШЧ “NШТЬО”, TКЛХО “NШТЬО
ЛКrrТОr” аКЬ rОЦШЯОН КЬ ЭСОrО ТЬ ЧШЭ ЛОТЧР
used noise barriers.
AЧЧОб 7.3 SОМЭТШЧ “NШТЬО”, TКЛХО “PХКЧ” PКrЭ
B (Compile and implement emergency
ЬТЭuКЭТШЧ МШЧЭrШХ ЩХКЧ” аКЬ rОЦШЯОН КЬ ЭСО
plan exists and being implemented.
AЧЧОб 7.3 SОМЭТШЧ “NШТЬО”, TКЛХО “EquТЩЦОЧЭ
МШЧЭrШХ” PКrЭ D аКЬ ЦШНТПТОН: АШrФ uЬТЧР
machines or vehicles shall be prohibited in
nightshift works
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭОаКЭОr”, TКЛХО
“АКЬЭОаКЭОr ОЦТЬЬТШЧ” PКrЭ A аКЬ ЦШНТПТОН
as wastewater around the fuelling area does
not exist.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭОаКЭОr”, TКЛХО
“PХКЧ” PКrЭ B (CШЦЩile and implement
ОЦОrРОЧМв ЬТЭuКЭТШЧ МШЧЭrШХ ЩХКЧ” аКЬ
removed as the plan exists and being
implemented.
Site Based Environmental Management Plan Rev. D
4
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭОаКЭОr”, TКЛХО
“UЧНОrРrШuЧН аКЭОr” аКЬ rОЦШЯОН. TСО
underground water exists more than 16 m
deeper.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭОаКЭОr” TКЛХО
“BКrrТОrЬ” аКЬ rОЦШЯОН. TСОrО КrО ЧШ КЧв
channels near the Construction area and
there is not heavy rain season in this region.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭОаКЭОr”, TКЛХО
“HКгКrНШuЬ аКЬЭО” PКrЭ A аКЬ ЦШНТПТОН:
Monitoring incoming and outgoing water
quality.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭОаКЭОr”, TКЛХО
“HКгКrНШuЬ аКЬЭО” PКrЭ B аКЬ ЦШНТПТОН:
Water samples, sent to Talimarjan TPP
laboratory to be tested for water quality.
AЧЧОб 7.3 SОМЭТШЧ “SШТХ”, TКЛХО “PХКЧ” PКrЭ B
(Compile and implement emergency situation
МШЧЭrШХ ЩХКЧ” аКЬ rОЦШЯОН КЬ ЭСО ЩХКЧ ОбТЬЭЬ
and being implemented.
AЧЧОб 7.3 SОМЭТШЧ “SШТХ” TКЛХО “SТЭО МШЧЭrШХ”
was removed. There is no any deposited silt
and grit on Site.
AЧЧОб 7.3 SОМЭТШЧ “SШТХ” TКЛХО “SОНТЦОЧЭ”
was modified: The location was changed from
Project Site to Equipment Maintenance
shop.
AЧЧОб 7.3 SОМЭТШЧ “SШТХ” TКЛХО “VОСТМХО
МШЧЭrШХ” PКrЭ A аКЬ ЦШНТПТОН: AХХ ЯОСТМХОЬ КЧН
plant cleaned once in a week. The location
was changed from Exits of the Project Site
Gate to Equipment Maintenance Shop.
AЧЧОб 7.3 SОМЭТШЧ “SШТХ” TКЛХО “VОСТМХО
МШЧЭrШХ” PКrЭ C аКЬ rОЦШЯОН. АСОel washing
point exists in Car Wash area.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО”, TКЛХО “PХКЧ” PКrЭ
B (Compile and implement emergency
situation control plКЧ” аКЬ rОЦШЯОН КЬ ЭСО
Site Based Environmental Management Plan Rev. D
5
plan exists and being implemented.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО” TКЛХО “АКЬЭО
НТЬЩШЬКХ” аКЬ ЦШНТПТОН. TСО RОЬЩШЧЬТЛТХТЭв
was changed to Waste Disposal Company
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО” TКЛХО “АКЬЭО
НТЬЩШЬКХ” PКrЭ E аКЬ rОЦШЯОН. All wastes
shall be disposed by Waste disposal
company.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО” TКЛХО “HКгКrНШuЬ
аКЬЭО” аКЬ rОЦШЯОН. HКгКrНШuЬ аКЬЭОЬ НШ
not exist in Construction Site.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО” TКЛХО “АКЬЭО
НТЬЩШЬКХ” TКЛХО “RuЛЛТЬС ЛТЧЬ” PКrЭ A аas
removed.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО” TКЛХО “CСОЦТМКХ
аКЬЭО”, PКrЭ D аКЬ ЦШНТПТОН: HКгКrНШuЬ
waste shall be removed from the Site
property within 6 month.
AЧЧОб 7.3 SОМЭТШЧ “АКЬЭО” TКЛХО “АКЬЭО ШП
МКЭОrТЧР” PКrЭ B аКЬ ЦШНТПТОН: AХХ ШrРКЧТМ
food wastes generated by kitchen facilities to
be disposed of at the farm.
Site Based Environmental Management Plan Rev. D
6
TABLE OF CONTENTS
1. INTRODUCTION / ................................................................................................................ 9
1.1 PURPOSE / ................................................................................................................ 9
1.2 SCOPE / .................................................................................... 9
1.3 PROJECT SITE MAP ................................................................................................................ 10
2. DEFINITIONS / .......................................................................................................... 11
3. RESPONSIBILITIES / ..................................................................................... 12
3.1 PROJECT MANAGER (PM) / ( ) ............................................. 12
3.2 HSE MANAGER / HSE .............................................................................. 12
3.3 ENVIRONMENTAL OFFICER (EO) /
(EO) .............................................................................................................................................. 13
3.4 SECTION MANAGERS (SM) / ( ) ................................. 15
4. ENVIRONMENTAL MANAGEMENT / .................................................................................................... 16
4.1 OVERVIEW / ...................................................................................... 16
4.2 ENVIRONMENTAL POLICY & OBJECTIVES/ .............................................................................. 16
4.3 PROJECT ENVIRONMENTAL MANAGEMENT SYSTEM (PEMS) / ................................................ 16
4.4 ENVIRONMENTAL ORGANIZATION / ......................................................................................... 17
4.5 COMPLIANCE WITH LEGAL REQUIREMENTS / .......................................................................... 18
4.6 ENVIRONMENTAL ASPECTS IDENTIFICATION & ASSESSMENT / .............................................. 18
4.7 EVALUATION, SELECTION & CONTROL OF SUB-CONTRACTORS / .......................................... 19
4.8 ENVIRONMENTAL MEETING / ................................................................................................... 20
4.9 ENVIRONMENTAL TRAINING / ..................................... 21
4.10 EMERGENCY PREPAREDNESS / .............................................................................................. 23
Site Based Environmental Management Plan Rev. D
7
4.11 ENVIRONMENTAL INCIDENT INVESTIGATION, ANALYSIS & REPORTING / ................................ 24
4.12 ENVIRONMENTAL INSPECTION / .......................................... 24
4.13 ENVIRONMENTAL AUDIT / .............................................................. 26
4.14 ENVIRONMENTAL IMPROVEMENT PLAN /................................................................................. 27
4.15 ENVIRONMENTAL REPORTING ................................................................................................ 27
5. ENVIRONMENTALCONTROLANDMONITORING / ............................................................................ 28
5.1 SPECIFIC ENVIRONMENTAL MITIGATION MEASURES / ........................................................... 28
5.2 ENVIRONMENTAL PERFORMANCE MONITORING / ................................................................. 31
5.3 AIR EMISSIONS / ................................................................... 31
5.4 DUST CONTROL / ...................................................................... 31
5.4.1 objectives / ................................................................................................ 31
5.4.2 dust control plan / ...................................... 32
5.4.3 specific control action / в ................... 32
5.5 NOISE CONTROL / ...................................................................................... 34
5.5.1 objectives / ................................................................................................ 34
5.5.2 noise control PROCEDURE / ....................... 34
5.5.3 specific control action / в ................... 36
5.6 WASTEWATER CONTROL / ......................................................... 37
5.6.1 objectives / ................................................................................................ 37
5.6.2 wastewatercontrol / в ................................................ 37
5.6.3 specific control action / ................................. 39
5.7 WASTE CONTROL / ..................................................................... 42
5.7.1 objectives / ................................................................................................ 42
5.7.2 wastecontrol / .......................................................... 42
5.7.3 specific control actions / ............................... 44
5.8 POLLUTANTS SPILLAGE CONTROL / ........................................................................................ 48
5.8.1 objectives / ................................................................................................ 48
5.8.2 pollutantsspillagecontrolplan / ............................................................................ 48
6. REFERENCES / .................................................................................. 51
Site Based Environmental Management Plan Rev. D
8
6.1 THE HDEC CORPORATE HSE POLICY DOCUMENT / HDEC
HSE 51
6.2 THE HDEC CORPORATE HSE MANUAL / HDEC
HSE 51
6.3 THE HDEC CORPORATE HSE PROCEDURES / HDEC
HSE 51
6.4 ISO 14001 (ENVIRONMENTAL MANAGEMENT SYSTEM) STANDARDS SPECIFICATIONS /
14001 ( ) ............................................................................... 51
6.5 EHS GUIDELINES FOR THERMAL POWER PLANTS(DEC 19,2008) AND IFC/WB
PERFORMANCE STANDARDS ON SOCIAL AND ENVIRONMENTAL SUSTAINABILITY(APRIL
30,2006) / HSE (19 ., 2008)
/ (30 ., 2008) ..... 51
6.6 EIA (AGREED WITH ADB, DEC 15,2009) / ( , 15
2009 ) 51
7. ANNEXES / .................................................................................................................. 51
7.1 CERTIFICATE OF ISO 14001 / 14001 .................................................. 51
7.2 CONTRACTOR HSE POLICY STATEMENT / HSE ................... 51
7.3 ENVIRONMENTAL MANAGEMENT PLAN CHART /
........................................................................................................................................ 51
[ANNEX 7.1 CERTIFICATE OF ISO 14001 / 7.1 14001] ................... 52
[ANNEX 7.2 CONTRACTOR HSE POLICY STATEMENT / 7.2
HSE] 53
[ANNEX 7.3 ENVIRONMENTAL MANAGEMENT PLAN CHART / 7.3
] ............................................................................................................. 55
Site Based Environmental Management Plan Rev. D
9
1. INTRODUCTION /
1.1 PURPOSE /
The purpose of this plan is to minimize the adverse impacts on the environment by
establishing and maintaining the effective mitigation plans against environmental issues
that may arise during the construction, commissioning up to hand over of plant to the
EMPLOYER.
,
, , .
1.2 SCOPE /
As per work progress, this plan shall be amended and developed every year if necessary.
And this plan will incorporate the conditions and mitigation measures contained in the
environmental Impact Assessment (EIA), Environmental Management Plan (EMP)
provisions, detailed design and the EMP requirements specified in Chapter VI of the Asian
Development Bank (ADB) Environmental Assessment Guidelines, 2003 and ITB
requirement.
, , .
, (EIA), (EMP),
EMP, VI ( ), 2003,
.
The CONTRACTOR shall develop and implement an internationally recognized
Environmental Management System (EMS) for all activities related to the Project
construction activities in line with the The CONTRACTOR Corporate Environmental
Management System and ISO 14001 Standards Requirements (refer to Annex 7.1
Certificate of ISO 14001)
(EMS) ,
, 14001 ( . 7.1 14001).
During the construction period, appropriate measures for environmental conservation and
protection shall be continuously taken. All measures shall be in accordance with the
contract specification and current applicable local laws and regulations.
, .
.
Site Based Environmental Management Plan Rev. D
10
Some important items that shall be considered in order to minimize the environmental
impacts are as follows:
, , :
Air Emission
Dust control
Noise control
Waste water quality control
. Waste management control
Pollutants Spillage control, etc.
.
1.3 PROJECT SITE MAP /
Site Based Environmental Management Plan Rev. D
11
2. DEFINITIONS /
Audit /
Systematic examination to determine whether activities and related results conform to
planned procedures and whether these procedures are implemented effectively and are
suitable for achieving carried the required objectives.
, ,
.
Continual Improvement /
Process of enhancing the environmental management system to achieve improvements in
overall environmental performance in line with environmental policy.
.
Environmental Performances /
Measurable results of the Environmental Management System related to the control of
environmental aspects, based on Environmental policy and objectives.
, ,
.
Environmental Targets /
Detailed performance requirement, quantified wherever practicable, applicable to the
organization or parts thereof, that arises from the environmental objectives and that needs
to be set and met in order to achieve those objectives.
, – , ,
.
Environmental (or HSE) Management System /
(HSE)
Part of the overall management system that facilitates the management of the Health,
Safety and Environmental risks associated with the activities of the CONTRACTOR and
the Sub-Contractors on site.
, , , HDEC,
.
Environmental (or HSE) Policy / (HSE)
Statement by the organization of its intentions and principal in relation to its overall
Environmental (or HSE) performance, which provides a framework for action and for the
setting of its Environmental (or HSE) Objectives and Targets.
(HSE),
Site Based Environmental Management Plan Rev. D
12
(HSE) .
Environment /
Surroundings in which the construction activities to be occurred and created an impact an
air, water, wastewater, dust, noise, etc to related local society.
, , , , , ,
.
3. RESPONSIBILITIES /
3.1 PROJECT MANAGER (PM) / ( )
Environmental responsibilities of PM are given below but not limited to:
,
:
Review and approve strategic Project Environmental (or HSE) Policy and Objectives
(HSE).
Approve the Project environmental protection plan and other procedures
.
Define roles, responsibilities and provide resources for ensuring that environmental
requirements are implemented and maintained in all concerned areas of Project
activities
,
,
.
Ensure that Project Environmental Management System is managed in an adequate
manner throughout the site organization.
, .
Ensure appropriate resources are available to support the implementation of the
Project Environmental Management System
.
Review suitability and effectiveness of the Project Environmental Management
System, etc.
..
3.2 HSE MANAGER / HSE
The HSE Manager shall:
HSE :
Ensure the development and implementation at site on activities described in this
plan and other procedures.
Site Based Environmental Management Plan Rev. D
13
, .
Assist the Project Manager in all environment related matters
, .
Manage the HSE organization at site.
HSE . Ensure that all activities regarding work are carried out in accordance with the
environmental management plan.
, , , .
Ensure that the Project complies with the EIA and EMP provisions and applicable
local environmental laws and regulations.
, EIA EMP .
Ensure preparation of a detailed EMP based on the EIA and detailed design complied
with the requirements specified in Chapter VI of the Asian Development Bank (ADB)
Environmental Assessment Guidelines 2003, covering construction and operation
phases.
EMP, EIA , , VI
( ), 2003, .
3.3 ENVIRONMENTAL OFFICER (EO) / (EO)
The CONTRACTOR shall appoint an Environmental Officer (EO) who has academic
qualifications and having adequate experience in environmental management and
monitoring. EO must be aware of the information and knowledge of Environmental
Management System (EMS) and Environmental Impact Assessment Report (EIA Report)
provided by ADB.
( ), .
(EMS) ( EIA), .
It is the EO function to advise the Project Manager and HSE Manager on the following
main areas:
HSE
:
Proper management and disposal of wastes to the designated area by Uzbekenergo.
, .
Control of noise and dust pollution
Sewage water and drainage control
Site Based Environmental Management Plan Rev. D
14
Air and water pollution control
General housekeeping
Monitoring and report periodically
Environmental responsibilities of EO in general are given below, but not limited to:
,
:
Ensure preparation of a detailed EMP based on the EIA and detailed design complied
with the requirements specified in Chapter VI of the Asian Development Bank (ADB)
Environmental Assessment Guidelines 2003, covering construction and operation
phases.
EMP, EIA , , VI
( ), 2003, .
Ensure that the Project complies with the EIA and EMP provisions and applicable
local environmental laws and regulations.
, EIA EMP .
Ensure that the environmental requirements are established, implemented and
maintained across the Project site activities, specifically including:
, , , : Identification and assessment of environmental aspects.
Environmental objectives, targets and environmental management program.
,
.
Monitor adherence to the Project environmental policy & objectives, alerting
management of non-compliance, and providing advice on remedial actions,
through environmental audits, reviews, inspections etc.
,
, , .
Monitor and verify closeout of actions arising from environmental audits.
, .
Report periodically to the Project management on the performance of the Project
environmental management system.
.
Prepare and submit environmental monitoring reports to Owner.
.
Site Based Environmental Management Plan Rev. D
15
3.4 SECTION MANAGERS (SM) / ( )
Environmental responsibilities of SM are given below, but not limited to:
,
:
Fully aware of Project environmental policy, objective & targets and management
programs.
, , .
Understand and apply responsibilities specified in the environmental management
system documentation.
, .
Ensure that the environmental requirements are established, implemented and
maintained across the responsible section activities, specifically including:
, , , : Identification and assessment of environmental aspects.
Environmental objectives, targets and environmental management program.
,
.
Coordinate Project Environmental Control Supervisor.
.
Support & monitor the implementation, performance and effectiveness of the
environmental management system.
, .
Participate in HSE Committee meetings and take every opportunity to talk to his
team about environmental issues.
HSE ,
. Support & ensure that supervisors or foremen are working to focus attention on
supervising the most hazardous and significant activities.
, .
Ensure all corrective actions assigned to his team arising from audits, incidents
and environmental reviews are implemented on time.
, , ,
, .
Site Based Environmental Management Plan Rev. D
16
4. ENVIRONMENTAL MANAGEMENT /
4.1 OVERVIEW /
The management of all environmental aspects of the Project activities shall be developed
through a comprehensive Project Environmental Management System (PEMS).
(PEMS).
The PEMS is controlled by the CONTRACTOR‟Ь Corporate HSE Management System
providing a required level of environmental standards.
PEMS HSE , .
The PEMS shall be designed and implemented in accordance with the CONTRACTOR„Ь Corporate HSE Management System and aligned to ISO 14000 series principles for
environmental management system.
PEMS HSE
14000 .
The PEMS shall address the management actions and commitments associated with
environmental matters specific to Project.
PEMS , , .
4.2 ENVIRONMENTAL POLICY & OBJECTIVES/
The CONTRACTOR shall establish Project Environmental Policy and Objectives in line
with the CONTRACTOR‟Ь Corporate HSE policy statement. A copy of the
CONTRACTOR„Ь Corporate HSE Policy Statement is provided in Annex 7.2.
HSE
. HSE 7.2.
4.3 PROJECT ENVIRONMENTAL MANAGEMENT SYSTEM (PEMS) /
(PEMS)
The PEMS shall be developed to provide a systematic and structured approach to cover all
significant environmental aspects of the Project. It will be based on the CONTRACTOR‟Ь
Corporate HSE Procedures and cover all local laws and regulations for the protection of
the environment. Essentially the PEMS shall provide Project with the structure for:
PEMS
Site Based Environmental Management Plan Rev. D
17
. HSE
. , PEMS :
Managing the operations in a way that ensures that continual improvement in
environmental performance and compliance with local regulation is achieved.
,
. Establishing and assessing performance against its commitments
Setting environmental objectives and targets
Developing and effectively implementing appropriate plans and procedures.
Primary outcomes of the PEMS are to ensure that all activities associated with the
construction of the Project to be complied with regulation or procedure so that adverse
effects on the environment could be avoided or kept to acceptable requirements.
PEMS , , ,
, .
Obligations to fulfill the responsibilities and accountabilities across all elements of the
PEMS involve the participation of both the CONTRACTOR and various Sub-Contractors
within the Project.
PEMS .
4.4 ENVIRONMENTAL ORGANIZATION /
The CONTRACTOR shall establish Project environment organization and appoint
Environmental Officer to comply with local laws and legislation and to implement
Environmental Management System on site.
.
The Environmental Management System ensures that the Project Environmental
Objectives are met through implementation of technical activities and procedures, a
Project HSE Team shall be appointed to perform all the technical activities included in this
Environmental Protection Plan and the Corporate HSE Manual.
.
HSE
Site Based Environmental Management Plan Rev. D
18
, HSE.
TСО CONTRACTOR‟Ь HОКН OППТМО SКПОЭв КЧН EЧЯТrШЧЦОЧЭ DОЩКrЭЦОЧЭ ЬuЩЩШrЭЬ ЭСО Project Management Team with specialist advice, consultation, inspection, auditing and
directions for the execution of the tasks to comply with relevant laws and legislation and to
implement Project Environmental Management System on site.
,
, ,
.
4.5 COMPLIANCE WITH LEGAL REQUIREMENTS /
The CONTRACTOR shall be responsible for all impacts on the environment which result
from Project construction activities. Such impacts may include dust, waste, noise,
wastewater, etc affecting those outside the site boundary.
, .
, , , , .
The CONTRACTOR shall comply with all relevant local regulations to the Project.
.
Newly legislated and revised environmental laws shall be examined in order to determine
whether those have an influence over Project activities. Environmental laws and other
requirements shall be kept up-to-date.
.
.
The CONTRACTOR shall ensure of the following:
:
To comply with the EIA and the requirements specified in Chapter VI of the ADB
Environmental Assessment Guidelines, 2003.
EIA , VI ( ), 2003.
4.6 ENVIRONMENTAL ASPECTS IDENTIFICATION & ASSESSMENT /
A wide range of potential environmental impacts is foreseeable from the identification of
environmental aspects and assessment of environmental impacts, and many impacts
relate directly to construction activities on site.
Site Based Environmental Management Plan Rev. D
19
,
.
This plan will incorporate the conditions and mitigation measures contained in the
environmental Impact Assessment (EIA)
, ( )
The CONRACTOR will clarify the identification and assessment of environmental aspects
before construction period:
:
:
A ЬТЦТХКr ЬТЭО‟Ь ОЧЯТrШЧЦОЧЭal aspects identification and assessment report.
. Construction methods may arise public complaints or expected to arise during
construction.
.
Construction equipment to be used for construction.
,
Utilities and facilities related to the construction
,
Environmental Impact Assessment, if available
,
Project HSE specification
HSE
Current applicable laws and regulations, work practice, etc.
, .
The expected adverse (significant) environmental impacts are as follows:
( ) :
Dust
Noise
Improper waste disposal
Emissions to atmosphere
ETC
4.7 EVALUATION, SELECTION & CONTROL OF SUB-CONTRACTORS /
,
The CONTRACTOR shall be responsible for ensuring each the Sub-CШЧЭrКМЭШrЬ‟ РШШН
Site Based Environmental Management Plan Rev. D
20
environmental performance. The CONTRACTOR shall:
. :
Conduct meetings before bid submission to address specific environmental
requirements.
.
Include Project specific environmental requirements in bid packages.
.
Request environmental information from each prospective the Sub-Contractor and
evaluate it during the selection process.
.
Stipulate environmental performance in the contractual agreements between the
CONTRACTOR and the Sub-Contractors.
.
Establish specific training requirements for the Sub-Contractors.
. Conduct pre-job meetings to address environmental expectation.
.
Require formal the Sub-Contractor environmental induction course for all new
employments at the site.
.
Review the environmental performance of the Sub-Contractors.
.
4.8 ENVIRONMENTAL MEETING /
The CONTRACTOR shall conduct regular environmental meetings and committee with
internal organization and the Sub-Contractors to ensure that works are carried out on site
with minimum adverse impacts to environment / workers and the public. This
environmental meeting will be incorporated in the safety & committee meeting where
safety, health and environmental matters are to be discussed at the same time.
, ,
. , ,
.
The environmental meeting shall be separately held for the purpose to:
Site Based Environmental Management Plan Rev. D
21
:
Review and discuss environmental incidents and non-conformances generated from
Project activities within one week.
, , .
Review and discuss all site environmental matters.
.
Review environmental performance of environmental protection plan and other
control plans
.
Review training requirement and practice.
4.9 ENVIRONMENTAL TRAINING /
The CONTRACTOR shall establish procedures to ensure that all personnel and in
particular new personnel, or personnel transferred to new assignment are given proper
environmental training relevant to their duties.
, , , ,
, .
Mandatory training shall be provided inappropriate languages to the workforce as follows:
, ,
:
On the first day of duty– Induction
-
Refresh training at regular intervals
When training needs are identified during risk assessments
The CONTRACTOR shall ensure that all personnel are provided with basic training [i.e.
Environmental Induction Course (incorporates environment matters), environmental laws
and regulations, Project rules on working at site, emergency evacuation procedures]. And
the CONTRACTOR shall keep signed records of training attendance.
, ( . . ( ),
, , ).
.
The CONTRACTOR shall ensure that all managers, supervisory personnel including those
of Sub-Contractors are trained in environmental management system. The CONTRACTOR
Site Based Environmental Management Plan Rev. D
22
shall be responsible for identifying environmental training which may be required for the
performance of the work and ensure that such training is provided for the personnel
concerned to mitigate adverse environmental impact.
, , , ,
. ,
, .
Environmental training will include but are not limited to:
, , : Project HSE (Environmental) policy and objectives
HSE ( )
Environmental management program
Significant environmental aspects identified.
Emergency preparedness and response plan / drill in environmental incident such as
oil, chemical spillage.
, , .
Dust control plan
Noise control plan
Wastewater control plan
Solid waste management and on how to identify hazardous or potentially hazardous
wastes
Pollutants spillage control plan
Current applicable environmental laws and regulations
MSDS contents of hazardous materials, etc for concerned operational peoples.
. .
All training information, records and certificates shall be properly documented, kept and
made available for verification.
, , .
Site Based Environmental Management Plan Rev. D
23
4.10 EMERGENCY PREPAREDNESS /
The CONTRACTOR shall establish an emergency plan to respond effectively to
emergency situations on the site to include but not limited to fire, spills, etc.
, , , , .
The emergency plan shall be:
:
Establish evacuation procedures.
Assign responsibilities to specific individuals.
Provide notification to the Authority and outside agencies such as fire station, hospital,
etc.
, , .
Establish means of communications.
Assign locations for emergency centers.
Provide in-house emergency responses
Include site security and controlled access
The information developed shall be documented and communicated appropriately within
the site to ensure that the site organization can respond to emergency situations.
,
.
The CONTRACTOR shall establish a program of training, drills and exercises to test and
evaluate the preparedness for emergency actions.
, .
The CONTRACTOR shall, once every six months, organize emergency exercises based
on likely site scenarios in which the key site personnel work through their emergency
response roles.
, ,
.
Site Based Environmental Management Plan Rev. D
24
4.11 ENVIRONMENTAL INCIDENT INVESTIGATION, ANALYSIS & REPORTING /
,
The CONTRACTOR shall establish procedure toidentify,record, investigate and analyze
any environmental incidents that occur on site. The investigation and analysis shall identify
the root cause and contributory causes of the incidents and formulate measures
accordingly to prevent future recurrence of similar incident.
, , , .
.
The investigation of the incident or non-conformance shall include:
:
Identifying and handling any legislative compliance issues associated with the
environmental incident or non-conformance.
, .
Identifying root causes and taking appropriate action to manage the resulting
environmental impact occurring from the incident or non-conformance.
, -
. Initiating any corrective and preventive actions and confirming effectiveness of
actions taken. Any actions taken will be appropriate to the magnitude of problems and
commensurate with the environmental risk.
.
.
The CONTRACTOR shall establish procedures to ensure that all personnel including the
Sub-CШЧЭrКМЭШrЬ‟ аШrФОrЬ СКЯО ЭСО ЬФТХХЬ ЭШ rОЩШrЭ ЬКПОЭв ТЧМТНОЧЭЬ. , ,
, , .
The CONTRACTOR shall keep records of all incidents reports, investigation, analysis and
counter measures taken and shall submit details of this in Monthly Report, if required.
, ,
, .
4.12 ENVIRONMENTAL INSPECTION /
Project key performance indicators shall be developed to monitor environmental
performance prior to construction activities. Monitoring environmental incidents and the
close-out of audit and incident action items will be included. The key performance
Site Based Environmental Management Plan Rev. D
25
indicators will be regularly monitored, recorded, tracked and communicated.
.
.
, , .
The CONTRACTOR shall establish procedure to carry out internal environmental
inspections at least once per shift. In addition, informal spot checks will be carried out
more frequently on critical site activities.
. ,
.
A written record shall be kept of the daily inspection findings and the results of the
inspections should be brought to the attention of the environmental control supervisor and
the section managers having responsibility in the area concerned, together with the
necessary remedial action and due date for completion.
,
, , .
Any corrective action should be immediately implemented by the section manager, and
followed up by the environment staff, with regular monitoring by safety and environment
department at site.
, , ,
.
The CONTRACTOR shall ensure that inspections are carried out at a specified frequency
which will ensure a high level of compliance with the provisions of the EMS.
, , EMS.
Inspections which are requested by the statutory requirements shall be carried out at a
frequency and in accordance with any procedure given in the relevant legislation.
, , ,
.
Inspection records and follow up action plan shall be properly documented. In addition,
following any regulatory inspection, the CONTRACTOR shall submit a written report to the
EMPLOYER which shall provide details of all aspects of the inspection, if required.
. ,
, , ,
Site Based Environmental Management Plan Rev. D
26
.
4.13 ENVIRONMENTAL AUDIT /
The CONTRACTOR‟Ь HОКН OППТМО ЬСКХХ КЩЩШТЧЭ КЧ ТЧНОЩОЧНОЧЭ ТЧЭОrЧКХ ОЧЯТrШЧЦОЧЭКХ audit team to audit the job site an every year.
.
The following items should be inspected during internal audits:
: Current environmental laws & regulations
Responsibilities of Project organization
Results of environmental aspects identification & assessment
Sub-Contractors compliance report
Operational control of environmental protection
Training and competence
Emergency preparedness
Incidents and corrective actions
Audits and inspections
Report of Environmental improvement plan, etc.
.
The CONTRACTOR shall periodically review and evaluate the efficiency of the Project
EMS in place.
EMS .
The audits and possible corrective actions should be carried out in accordance with the
НШМuЦОЧЭОН ЩrШМОНurОЬ ШП ЭСО CONTRACTOR‟Ь HОКН OППТМО HSE AuНТЭ PrШМОНurО. All corrective actions for deficiencies identified during audit shall be implemented by the
site to verify the satisfaction of the requirement. In addition, the results of audits and
corrective actions should be kept and submitted to the EMPLOYER on MER (Monthly
Environmental Report) and MPR (Monthly Progress Report).
– HSE
. , ,
Site Based Environmental Management Plan Rev. D
27
. , .
4.14 ENVIRONMENTAL IMPROVEMENT PLAN /
The CONTRACTOR shall establish environmental objectives and improvement plans
based on incident analysis, audit results and results of environmental aspects identification
/ assessment, in order to raise the Project EMS.
, , /
EMS .
Project environmental improvement plan will cover at least the following:
:
Achievement of environmental objectives
Corrective actions following environmental incidents
, v
Corrective actions regarding non-conformities observed during internal or external
audits, self and imposed inspections
,
,
Review of training and emergency drills
Environmental aspects identification & assessment and preventive actions
Complaints from local inhabitants or local authorities.
.
The CONTRACTOR shall review Project environmental improvement plan with the
CONTRACTOR‟Ь HОКН OППТМО ЩОrТШНТМКХХв НurТЧР ЭСО МШЧЬЭruМЭТШЧ ЩОrТШН.
.
4.15 ENVIRONMENTAL REPORTING
The CONTRACTOR shall establish environmental reporting of the environmental performance to the EMPLOYER alongside the monthly disposal record.
.
As a minimum, the monthly report shall include:
, :
Incident statistics
Number of Environment audits refer to plan and follow-up and close-out of
Site Based Environmental Management Plan Rev. D
28
corrective actions
Summary of environmental training
Principal Environmental activities performed during the period, etc.
, . .
5. ENVIRONMENTALCONTROLANDMONITORING /
5.1 SPECIFIC ENVIRONMENTAL MITIGATION MEASURES /
TheCONTRACTORshallimplementthespecificenvironmentalmitigationmeasuresasfollows:
:
Construction
Minimize size and duration of exposed areas and materials.
.
Water exposed areas during windy conditions.
.
Confine construction activities to defined construction worksites.
. Store chemicals in roofed areas with concrete flooring (if required).
( ). Ensure sorbents are available in areas where chemicals are stored
, .
Cover all trucks carrying materials off site, if required
, .
As far as possible, restrict truck movements to night time hours.
,
. As far as practical, restrict truck movements to major transport routes as far as
possible.
, , .
Maintain on-site construction vehicles and equipment as well as vehicles travelling
to and from the site in good condition.
, , ,
, .
Site Based Environmental Management Plan Rev. D
29
Program delivery and removal of materials to avoid clashes with peak hours.
.
Maximize use of large trucks (15~20 tons) to transport construction materials.
(15 – 20 ) ,
.
Usetemporarywastestorageareafordomesticwastewiththefollowingcharacteristics :
:
- Located away from living and eating areas.
- Concrete floors with bund to prevent overflow
- Weatherproof roof, Securable bins
,
- Fencing and signage prohibiting entry to authorized personnel
,
- Separation of storage of hazardous and non-hazardous waste
Ensure all waste is separated into non-hazardous and hazardous/potentially
hazardous before reuse, recycling or transport to landfill.
/ ,
. Ensure that fireprotection equipment is present on site during burning and staffs are
trained in its use (if required, but prohibited burning, strictly).
, ,
. Prohibit disposal of waste to KMC (Karshi Main Canal) and other areas of the site.
( ) .
Undertake timely repairs of any malfunctioning construction vehicles and equipment.
..
Confine noisy activities to day time.
. Implement well-organized sanitation using temporary trench latrines.
, .
Locate latrines away from living and eating areas, away from areas with high
ground water table and at least 100m away from KMC.
, 100 .
Develop dedicated area for storage of recycled material away from active
construction works and near site access point.
Site Based Environmental Management Plan Rev. D
30
.
Admin. /
Maintain clean and orderly construction camps.
. Provide a clean water supply at the construction worker camp.
. Provide adequate rubbish bins and regular dispose of waste.
.
Regularly disinfect toilets
. Regularly backfill and re-dig toilets.
. Provide rubbish bins in latrine area for collection of solid waste.
.
Provide Construction workers camps in good condition. (water quality, public health
impacts caused by worker sewage)
( , , )
Batch plant /Workshop / - /
Alkaline wash water containing excessive amounts of cement will be settled and
neutralized before discharge.
, , .
Treat oily wastewater in coalescence separator before discharge.
- .
HSE / HSE
Educate workers on the need to maintain hygienic conditions at the worker camp.
..
Train construction staff in clean up procedures for spills.
. Ensure that truck drivers are educated on road safety requirements.
, .
Install signage encouraging use of rubbish bins on site and in construction camps.
, .
Monitoring the level of noise in site boundary
Control and operation the storage area for flammable materials and chemical
Site Based Environmental Management Plan Rev. D
31
.
5.2 ENVIRONMENTAL PERFORMANCE MONITORING /
The CONTRACTOR shall conduct self-monitoring of its environmental performance in
terms of:
:
Implementation of mitigation measures.
. Monitoring program specified in the table below.
.
5.3 AIR EMISSIONS /
TСО CONTRACTOR‟Ь rОЬЩШЧЬТЛТХТЭТОЬ аТЭС rОРКrН ЭШ КТr ОЦТЬЬТШЧЬ ЬСКХХ ЛО ЭШ: :
Minimize emission of dust, exit flue gases into the atmosphere caused by vehicles
and equipment for construction by reducing idle time
, ,
.
Identify all possible air pollution sources related to construction activities in a method
of statement as well as procedure to minimize emission into air.
, ,
. Ensure the Subcontractor‟Ь ОquТЩЦОЧЭ ТЬ rОРuХКrХв ЬОrЯТМОН КЧН ЦКТЧЭКТЧОН ЭШ ЛО ТЧ
good condition. Report any signs of engine not running efficiently like black smoke,
poor fuel economy and performance to the appropriate manager.
, .
, , , , .
Ensure hazardous materials are identified during works and notify the EMPLOYER
immediately.
.
5.4 DUST CONTROL /
5.4.1 OBJECTIVES /
To minimize the nuisance impact on surrounding communities of dust generation
during construction activities.
Site Based Environmental Management Plan Rev. D
32
.
5.4.2 DUST CONTROL PLAN /
Dust control plan shall be compiled and implemented for the construction phase and the
following key issues included:
, :
Carry out watering of exposed areas and materials during windy conditions.
.
Minimize size and duration of exposed areas and materials.
.
Limiting vehicle-entrained dust from unpaved roads through traffic control measures.
E.g. limiting vehicle speeds and restricting traffic volumes.
, ,
. . . .
Covering trucks during transport of materials and impose speed limits.
.
5.4.3 SPECIFIC CONTROL ACTION /
5.4.3.1 DRILLING & BREAKING /
Where breaking of rock/concrete is required, watering shall be implemented to control
dust, water sprays shall be used during the handling of excavated material at the site
and at active cuts excavation and fill sites where dust is likely to be generated.
, / , ,
, .
Where drilling of rock is required, dust controls, including watering prior to drilling to
wet down the rock face, shall be implemented to control fugitive dust.
, , , ,
.
5.4.3.2 MATERIAL HANDLING / -
The heights from which excavated materials are dropped shall be controlled to a
minimum practical height to limit the fugitive dust generation from unloading.
, ,
Site Based Environmental Management Plan Rev. D
33
.
All stockpiles of aggregate shall be enclosed or covered entirely by impervious
sheeting or sprayed with water so as to maintain the entire surface wet.
.
5.4.3.3 VEHICLE DUST /
As far as possible, restrict truck movements to night time and restrict truck
movements to major transport routes.
, .
Maintain vehicles traveling to and from the site in good condition.
, ,
Effective water sprays shall be used on the site to dampen potential dust emission
sources such as unpaved areas used by site traffic and active construction area.
, ,
. Vehicles transporting materials that have the potential to generate dust shall have
proper fitting side and tail boards.
, , , .
Materials transported by vehicles shall be covered entirely by clean impervious
sheeting, with the cover properly secured and extended over the edges of the side
and tail boards to ensure that the materials do not leak from the vehicle.
, , , ,
, .
Materials shall also be dampened, if necessary, before transportation.
, , .
In order to prevent earth movement from the site due to construction activity and run
off onto public road, drains, the site shall be inspected regularly.
- , ,
. On-site vehicle speeds shall be controlled to reduce dust re-suspension and
dispersion by traffic within the sites.
.
Site Based Environmental Management Plan Rev. D
34
5.4.3.4 EXCAVATION /
The working area of any excavation or earth moving operation shall be
sprayed with water before and after the operation so as to maintain the entire surface
wet
.
The amount of soil exposed and the dust generation potential shall be kept as low as
possible. This can be accomplished by surface compaction, temporary fabric covers,
minimizing the extent of exposed soil and the prompt re-vegetation of completed
earthworks.
. ,
, .
Excavate any ground contaminated by spillage of fuel or leaked oil/hydraulic fluids
and arrange for disposal at the waste disposal site approved by the EMPLOYER.
, /
, , .
5.4.3.5 SITE CLEARANCE /
The working area for the removal of boulders, poles, pillars or temporary or
permanent structures shall be sprayed with water before and after the operation so as
to maintain the entire surface wet.
, , ,
.
5.5 NOISE CONTROL /
5.5.1 OBJECTIVES /
To adhere to the noise regulations as implemented within the noise impacted areas.
, .
To comply with the occupational noise regulations of Local. To minimize noise
impacts on the neighboring residential area (Nuristan town 1km far from project site).
. . (
1 )
5.5.2 NOISE CONTROL PROCEDURE /
Noise Control Procedure will be set in accordance with EIA. Noise Control Procedure shall
Site Based Environmental Management Plan Rev. D
35
include the following measures for good practice:
. :
Consider use of temporary acoustic barriers or exhaust mufflers if disturbance to
surrounding land use is found to be occurring.
, .
Equipment shall be operated within specifications and capacity (eg.
Don‟toverloadmachines)
( . . ).
Equipment shall be operated in as diversified a manner as possible (i.e. if possible,
spread operation of equipment throughout working periods rather than operating
several items simultaneously).
( , ,
, ). Equipment shall be turned off when not in use.
, . As far as possible, restrict truck movements to night time and restrict truck
movements to major transport routes.
,
.
Partly finished buildings shall be used to accommodate pumps, generators,
compressors and saws.
, , .
When using pile drivers, jack hammers, and rock drills for blasting activities, select
the time when the environment is least sensitive to noise impact preferably during
normal working days daytime hours.
, , ,
, .
Arrange proper locations of concrete batching plants, electric power stations, etc. as
ЬШ ЭШ ЦТЧТЦТгО ЧШТЬО‟Ь ТЦЩКМЭЬ ШЧ КММШЦЦШНКЭТШЧ ХТПО ШП ОЦЩХШвООЬ. ,
. Inspect noise level during the construction of construction equipment as so to
determine proper working schedule as so to ensure that noise level is satisfied with
the allowable noise level, referred to the EIA in compliance with local regulation.
,
.
Site Based Environmental Management Plan Rev. D
36
5.5.3 SPECIFIC CONTROL ACTION /
Noise emissions from construction sites can be minimized through good site practice,
selecting quiet plant and quiet working methods and through the use of temporary barriers.
To reduce impact of noise to the residential area from operation of vehicles and equipment
for site, the speed of vehicles and other equipment shall be limited and noise from
operation of the equipment shall be minimized.
, .
, .
5.5.3.1. NOISE-PRODUCING EQUIPMENT CONTROL /
Maintain construction vehicles and equipment in good condition.
.
Undertake timely repairs of any malfunctioning construction vehicles and equipment.
.
Confine noisy activities to day time hours.
. Mobile plant shall be located as far away from noise sensitive receivers as possible.
.
Monitor the levels of noise created by the heavy equipment.
5.5.3.2. SCHEDULING OF CONSTRUCTION ACTIVITY /
Activities may be scheduled to minimize noise generated at certain areas during
periods which may be particularly sensitive to noise
,
,
.
Works using machines or vehicles that generate noise shall be prohibited in the
midnight and the dawn.
, , .
Program delivery and removal of materials to avoid clashes with peak hours.
.
Site Based Environmental Management Plan Rev. D
37
5.6 WASTEWATER CONTROL /
5.6.1 OBJECTIVES /
To minimize of water being contaminated.
To minimize deterioration of surface water quality
.
5.6.2 WASTEWATER CONTROL /
The wastewater control procedure will be set in accordance with the EIA. The wastewater
control shall include the following details:
.
:
Shall identify sources of wastewater, and state the collection facilities that are to be
used to prevent pollution, as well as the method of disposal of the contaminated
water.
, ,
. The control plan for wastewater generated from concrete batching plant operation.
, . Water from washing large concrete-mixing equipment (mixers and the like) shall not
be discharged overland.
( ) .
Undertake settling and neutralization of alkaline washing water containing excessive
cement prior to discharge.
, , .
All washing of equipment or machinery shall be undertaken in designated areas (e.g.
workshop or maintenance areas), and these areas must be equipped with a suitable
impermeable floor and sump/oil trap. The use of detergents for washing shall be
restricted to low phosphate and nitrate containing.
( , ),
/ .
. Workshops, fuelling depots and washing areas shall be bund.
, . Oil collected in grease traps shall be collected by the appointed waste disposal
contractor.
, , .
Any wastewater or spilled fuel collected within bund area around the fuelling area
shall be disposed of as hazardous waste.
Site Based Environmental Management Plan Rev. D
38
, , .
Rainwater control plan is to be designed and implemented for the construction phase of
the Project. This shall be prepared by the CONTRACTOR prior to commencing
construction. Thecontrolplanshallincludethefollowingdetails:
.
. : Actions to address the reduction of surface water run-off and resultant erosion.
.
Natural run-off shall be diverted away from any camps (i.e. office area used by the
CONTRACTOR and Sub-Contractors on site) towards the rain water drains where
these are available.
( . . , )
, . Special care must be taken in areas susceptible to erosion, e.g. steep slopes. The
CONTRACTOR shall ensure that sand, silt and silt-laden water do not enter KMC.
The CONTRACTOR shall appropriate measures to limit erosion and prevent silt and
sand entering drainage or KMC due to construction activities.
, , , . , ,
, .
- . ,
: Temporary fences shall be erected and maintained to ensure that activities
are conducted within the demarcated area, and thus limit impact on the
environment.
,
, .
All hazardous material storage areas shall be designed to reduce risk of
spillages. All materials shall be covered during transport to prevent them
from spilling. If there is a risk of contamination of rainwater, all stockpiles
shall be covered to be kept out of the rain.
.
. ,
. Contaminated rainwater and other run-off from construction site shall be
contained. Construction of dirt trap, interceptor pond and the attenuation
dam (if required) shall be commenced as early as possible in the
Site Based Environmental Management Plan Rev. D
39
construction phase.
. ,
( )
. In the event of a spill which may contaminate rainwater, the spill control
procedures shall be implemented immediately.
, , .
The location will be qualified and used for periodic sampling.
.
5.6.3 SPECIFIC CONTROL ACTION /
5.6.3.1 AT THE START OF SITE ESTABLISHMENT /
Channels, earth bund walls or sandbag barriers shall be provided on site to direct rain
water to silt removal facilities.
,
.
5.6.3.2 DEBRIS IN KMC /
Any oil, solid, noxious or floating materials shall not be discharged into canal. And all
water discharged shall be reasonably free of impurities.
, , .
.
5.6.3.3 SOIL EROSION AND SEDIMENTATION CONTROL /
Minimize size and duration of exposed areas.
. Undertake progressive stabilization of exposed areas.
.
If excavation of soil cannot be avoided during the rainy season, or at any time of year
when rains are likely, exposed slope surface shall be covered.
, ,
.
Site Based Environmental Management Plan Rev. D
40
The overall slope of the site shall be kept to a minimum to reduce the erosive
potential of surface water flows.
.
All drainage facilities, erosion and sediment control structures (if required) shall be
regularly inspected and maintained to ensure proper and efficient operation at all
times and particularly following rains. Deposited silt and grit shall be removed
regularly.
, ( )
, . .
Open stockpiles of construction materials (e.g. aggregates sand and fill material) shall
be covered during rains. Measures shall be taken to prevent the washing away of
construction materials, soil, silt or debris into any drainage system.
( , ) .
, , .
All vehicles and plant shall be cleaned before leaving a construction site to ensure no
earth, mud, debris and the like is deposited by them on roads.
, , ,
.
All road works shall be separated from surface waters with berms or other fencing
materials that will contain loose soils.
,
. All roads shall be properly sloped and have adequate culverts to manage runoff.
.
Plantsiteperimetershouldoccurasmuchaspossibletorestorelostnaturalerosioncontrol.
. Earthworks toconstruct drainage ditches and to lay subsurface drainage conduits (if
required) should separate activityareas from surface waters with the placement of
berms or other fencing material to contain loose soils during construction.
( )
.
5.6.3.4 FUEL TANKS /
All fuel stored on site shall be kept in drums or in bulk tanks which in either case shall
be located at a designated place away from any source of ignition or open drain
Site Based Environmental Management Plan Rev. D
41
аСТМС НШОЬ ЧШЭ ХОКН ЭШ КЧ ТЧЭОrМОЩЭШr, КЧН ЬСКХХ ЛО ЩrШЩОrХв ХКЛОХОН. A “NШ SЦШФТЧР” sign shall be displayed at the storage location and a charged fire extinguisher of the
correct type kept on standby.
, , ,
, ,
. « »
. Any spillage of fuel shall straight away be absorbed using sand or other absorbent
materials, which shall be disposed of as contaminated waste.
, .
All fuel tanks and storage areas shall be provided with concrete embankments to
readily contain spills.
.
Treat oily wastewater in coalescence separator prior to discharge.
- .
5.6.3.5 SEWAGE DISPOSAL/HOLDING TANKS /
/
Sewerage system will be designed and installed to carry all wash and wastewater,
sewage, such as arrangement of pits. Where a public sewer system is available, all
plumbing fixtures and sewers shall be connected to it in accordance with applicable
laws and regulations.
, ,
. ,
,
. Sewage shall be collected prior to disposal. Effluent shall comply with legal guidelines
for emissions into the environment, as appropriate.
. .
Building temporary water treatment works (permeable digestion tank) for construction
workers and defining special waste disposal area in order to avoid defecation and
throwing domestic waste, leading to environmental pollution.
( - )
, , .
Site Based Environmental Management Plan Rev. D
42
5.7 WASTE CONTROL /
5.7.1 OBJECTIVES /
To maximize the internal and external recycling of materials.
. To minimize the volume of solid waste requiring disposal by landfill.
, .
5.7.2 WASTE CONTROL /
Waste Control Procedure will be set in accordance with EIA. Waste Control shall be
implemented for the construction activities. This shall:
. . :
Incorporate the following waste control hierarchy to mitigate environmental impacts:
:
Minimize the generation of waste
Re-use the waste during construction
Re-use or recycle waste streams to other users at other locations
Dispose unusable waste streams at permitted waste disposal facilities.
.
The system for collecting, sorting, disposal and recycling of waste shall be clearly
described in the waste control plan. This shall include:
, , . : A separate waste disposal area shall be designated on the construction site,
which contains clearly demarcated skips and bins to allow different types of
waste to be segregated at source: domestic, metalscrap, usedoil, paper,
hazardous etc.
,
: , , , ,
. . The CONTRACTOR shall provide sufficient bins with lids to store the solid
waste produced on a daily basis. Bins shall not be allowed to become
overfull and shall be emptied as a minimum on a weekly basis.
Site Based Environmental Management Plan Rev. D
43
, .
. Odor, water quality and soil impacts associated with uncontrolled waste disposal
, , .
Implement adequate numbers of rubbish bins around construction site and
in construction camps
.
Install signage encouraging use of rubbish bins on site and in construction
camps
, .
Include information on solid waste management in construction worker
training program including information on how to identify hazardous or
potentially hazardous waste
, ,
. Develop dedicated area for storage of recycled material away from active
construction works and near site access point
. Prohibit disposal of waste to KMC and other areas of the site
.
The waste sorting and temporary storage area shall be permanently controlled by an
environmental officer to ensure compliance with the waste sorting and disposal
requirement.
. The CONTRACTOR shall ensure that the waste control of the Sub-Contractors are
suitably qualified and equipped to manage the waste generated during construction.
, ,
. All wastes shall be disposed by waste disposal company. (as per type of waste)
( ).
The CONTRACTOR and its Sub-Contractors will take all necessary measures to
prevent any discharge of any substances, which may result in pollution or be
deleterious to life or the surrounding environment.
,
.
Site Based Environmental Management Plan Rev. D
44
Solid waste will be stored in predetermined collection points prior to their removal and
disposal by the appointed contractor
.
Wood and other scrap material with a commercial value shall be separated and
stored in segregated areas prior to removal.
.
Oil and other lubricants shall be collected in drums and disposed of in accordance
аТЭС ЭСО CONTRACTOR‟Ь ТЧЬЭruМЭТШЧЬ.
. The dead batteries will be given to specialized organizations for reuse.
.
Sharps containers will be provided for medical facilities (for syringes, suturing kits and
needles) and also clearly identified bagging for infectious or contaminated items.
( , ),
. Adequate drainage and sewerage facilities (if required) designed and installed in
КММШrНКЧМО аТЭС ЭСО CONTRACTOR‟Ь ЬЩОМТПТМКЭТШЧЬ. ( )
. Siting and provision of concrete wash areas and disposal area.
. Identification of disposal areas for non-contaminated materials such as spoil.
, .
Appointment of approved contractor for the removal of hazardous and solid waste to
existing incineration and landfill areas approved by Hokimiyat and SES.
.
5.7.3 SPECIFIC CONTROL ACTIONS /
5.7.3.1 EXCAVATED INERT MATERIALS /
Excavated materials are not considered likely to cause adverse impacts, since they
may be possible to be used as reclamation fill, which is considered a useful reuse of
the material. Any uncontaminated inert material may be delivered to public fill site.
, ,
. .
Surplus excavated material, quarry overburden, rock rejected for aggregate,
aggregate surplus to the requirements and the like shall not be discarded
Site Based Environmental Management Plan Rev. D
45
indiscriminately.
, , , , .
Different types of surplus excavated materials shall be deposited separately in the
spoil dumps designated for the purpose outside the Project site.
, .
5.7.3.2 CONSTRUCTION & DEMOLITION WASTE /
Careful planning and good site management can minimize over ordering and waste of
materials such as concrete, mortars and cement groups. The design of formwork can
maximize the use of standard wooden panels so that high re-use levels can be
achieved. Alternatives such as steel formwork or plastic facing will be considered to
increase the potential for re-use.
,
, .. ,
. , ,
. Disposal of construction waste can either be at a specified landfill, or a public dump.
, .
5.7.3.3 HAZARDOUS (CHEMICAL) WASTE / ( )
For the process which generates chemical waste, it may be possible to fine
alternatives which generate reduced quantities or even no chemical waste, or less
dangerous types of chemical waste. The management of hazardous waste causes
number of problems in practice. The wide range of materials and chemicals involved
such as oil, lubricants, cutting oils, sludge, paints etc. Hazardous waste shall be
identified, classified, handled and disposed of safely.
, , ,
, .
. , , , , ,
. , , .
Types of hazardous waste:
:
Site Based Environmental Management Plan Rev. D
46
Fuel, waste oil, paints and contaminated material with oil
, ,
Sludge contaminated with heavy metals
,
Corrosives, including acids and alkalis
,
Other hazardous substances
Containers used for the storage of chemical wastes shall:
, , :
Be suitable for the substance they are holding, resistant to corrosion,
maintained in a good condition, and securely closed
, ,
, , .
Store chemical in roofed areas with concrete flooring.
. Display a label. Proper labeling is essential.
. . The storage area for chemical waste shall;
:
Be located away from surface water bodies.
. Be constructed with a weatherproof cover, concrete floor with bund, and with
adequate securable storage bins for waste.
,
. Have appropriate signage
Be clearly labeled and used solely for the storage of chemical waste.
.
Be enclosed on at least 3 sides.
. Have adequate ventilation.
. Be arranged such as to separate incompatible materials.
, .
Disposal of chemical waste shall:
:
Treated by a licensed waste collector.
. Be to a facility licensed to receive chemical waste, such as the chemical
waste treatment facility (which offers both a chemical waste collection
service and supply the necessary storage containers).
Site Based Environmental Management Plan Rev. D
47
, , (
, ).
Hazardous and toxic waste shall not be disposed of on the water.
. Hazardous waste shall be removed from the site property within 60 days.
60 . Hazardous waste shall not be dumped onto the ground, into rain water
sewers, or into sanitary sewer system.
,
.
5.7.3.4 FOOD (CATERING) WASTE / ( )
Catering wastes is divided into food waste and non-food waste.
. All organic food waste generated by kitchen facilities to be disposed of at the farm.
, .
Food waste shall be daily removed from the kitchen.
. Food waste shall always be contained in plastic containers for disposal to prevent
pest like flies and rats e.g. from breeding.
, , .
Non-food waste (beverage cans, packing materials, etc.) shall be collected in
separate containers.
( - , .) .
5.7.3.5 GENERAL REFUSE /
General refuse generated on-site shall be stored in enclosed bins or compaction units
separate from construction and chemical waste. A reputable waste hauler shall be
employed to remove general refuse from the site, separately from construction and
chemical wastes, on a daily or every second day basis to minimize odor, pest and
litter impacts.
, ,
. ,
, . General refuse is generated largely by food service activities on site, so reusable
rather than disposable dishware shall be used if feasible. Aluminum cans are often
recovered from the waste stream by individual collectors if they are segregated or
easily accessible, so separate labeled bins shall be provided if feasible.
Site Based Environmental Management Plan Rev. D
48
, ,
, . , , , .
5.8 POLLUTANTS SPILLAGE CONTROL /
5.8.1 OBJECTIVES /
To minimize negative environmental impacts through rapid and effective containment
and clean-up actions.
.
5.8.2 POLLUTANTS SPILLAGE CONTROL PLAN /
The CONTRACTOR shall develop and implement a pollutants spillage control plan prior to
the start of construction activities. Procedures detailed in the Material Safety Data Sheet
(MSDS) for hazardous materials shall be included in this plan and followed in the event of
an emergency situation.
. ,
, .
The CONTRACTOR shall ensure compliance with the following and where necessary,
include details of how this will be achieved in the pollutants spillage plan.
, , , , .
5.8.2.1 CONTAMINANTS OF SPILLAGES /
The CONTRACTOR shall ensure there is no contamination of the soil as a result of
spills from any workshop and other equipment maintenance facilities.
, ,
. Any workshop shall have a smooth impermeable (concrete or thick plastic covered
with ground) floor. The floor shall be bund and sloped towards an oil trap or sump to
contain any spillages.
( , ).
.
Site Based Environmental Management Plan Rev. D
49
Pumps and other machinery requiring oil, diesel, etc. that is to remain in one position
for more than two days shall be placed on drip trays. The drip trays shall be emptied
regularly and the contaminated water disposed of off-site at a facility capable of
handling such wastewater. Drip trays shall be cleaned before any possible rain
events that may result in the drip trays overflowing and before long weekends and
holidays.
, , , ,
. , , ,
. , ,
. All vehicles and equipment shall be kept in good working condition and serviced
regularly.
.
All equipment that leaks onto the ground shall be repaired immediately or removed.
, , .
If servicing and fuelling of vehicles and equipment takes place on site, this shall occur
at dedicated and properly equipped facilities. All waste generated by these activities
shall be managed as per the Waste Control Plan and the Wastewater Control Plan.
/ , . ,
.
If diesel or oil refueling is to take place on the construction site then the surface under
the refueling area shall be protected against pollution to the ground.
,
. When servicing equipment, drip trays shall be used to collect the waste oil and other
lubricants. Drip trays shall also be provided in construction areas for stationary plant
(ЬuМС КЬ МШЦЩrОЬЬШrЬ) КЧН ПШr “ЩКrФОН” ЩХКЧЭ (ЬuМС КЬ ЬМrКЩОrЬ, МrКЧОЬ, ХШКНОrЬ). ,
. ( ,
) « » ( , , , ).
The CONTRACTOR shall not change oil or lubricants anywhere on site except at
designated locations, not unless if there is a breakdown or an emergency repair. If
emergency repairs are required outside of designated areas, the CONTRACTOR
shall take proper control measures prior to commencing such activities and shall
ensure that appropriate absorbent materials and/or drip trays are available to collect
any oil, fluid, etc.
,
Site Based Environmental Management Plan Rev. D
50
, . ,
, /
, .
5.8.2.2 CLEAN-UP SPILLAGE /
Emergency procedures shall be developed and communicated to all personnel such
that they are aware of the procedures to be followed for dealing with spills. The
procedures shall include identification or responsible personnel and reporting
procedures, contact details of emergency services, etc.
, ,
. ,
. Procedures detailed in the MSDS for hazardous materials shall be followed in the
event of an emergency situation.
, ,
. The CONTRACTOR shall ensure that the necessary materials and equipment for
dealing with spills is available on site at all times.
, .
The CONTRACTOR shall ensure that there is always a supply of absorbent materials
readily available to absorb / breakdown or where possible, where encapsulate minor
chemical / oil spillages.
, , / , , / .
Any waste water or spilled fuel collected within the bund around the refueling area
shall be disposed of as hazardous waste.
, , .
The CONTRACTOR shall remove all oil, petrol, and diesel-soaked sand immediately
and shall dispose of it as hazardous waste.
, , , .
Excavate any ground contaminated by spillage of fuel or leaked oil/hydraulic fluids
and arrange for disposal at the waste disposal site approved by competent Authority.
, / ,
, . If spillages of materials occur during transportation, spillages shall be cleaned-up
immediately and transported to the shelter for possible use or disposed of at the
appropriate disposal facilities.
Site Based Environmental Management Plan Rev. D
51
,
.
Train construction staff in clean-up procedures for spills.
.
6. REFERENCES /
6.1 THE HDEC CORPORATE HSE POLICY DOCUMENT /
HDEC HSE
6.2 THE HDEC CORPORATE HSE MANUAL / HDEC
HSE
6.3 THE HDEC CORPORATE HSE PROCEDURES / HDEC
HSE
6.4 ISO 14001 (ENVIRONMENTAL MANAGEMENT SYSTEM) STANDARDS SPECIFICATIONS
/ 14001 ( )
6.5 EHS GUIDELINES FOR THERMAL POWER PLANTS(DEC 19,2008) AND IFC/WB
PERFORMANCE STANDARDS ON SOCIAL AND ENVIRONMENTAL
SUSTAINABILITY(APRIL 30,2006) / HSE
(19 ., 2008)
/ (30 ., 2008)
6.6 EIA (AGREEDWITHADB, DEC 15,2009) / ( , 15 2009 )
7. ANNEXES /
7.1 CERTIFICATE OF ISO 14001 / 14001
7.2 CONTRACTOR HSE POLICY STATEMENT / HSE
7.3 SITE BASED ENVIRONMENTAL MANAGEMENT PLAN CHART /
Site Based Environmental Management Plan Rev. D
52
[ANNEX 7.1 CERTIFICATE OF ISO 14001 / 7.1 14001]
Site Based Environmental Management Plan Rev. D
53
[ANNEX 7.2 CONTRACTOR HSE POLICY STATEMENT / 7.2
HSE]
Site Based Environmental Management Plan Rev. D
54
Site Based Environmental Management Plan Rev. D
55
[ANNEX 7.3 SITE BASED ENVIRONMENTAL MANAGEMENT PLAN CHART / 7.3 ]
No No Aspect
Mitigation
Location
Monitoring
Responsible
Frequency
1 Management/
1.1 Informing Introduce types of emission and countermeasures.
. Officialy
1)PMU
Yearly
(if required)
(
) 1.2 Emergency a)Every three months has emergency drills.
. b)Confirms the role of individual
.
Project Site
Observation
of
emergency
1)Contractor
2)Subcontractor
Quarterly
.
1.3 Traffic a)All traffic signs, signals, and road markings must be obeyed.
, .
b)Authorized transportation of equipments and materials entry to
the site
c)Speed of transport vehicles should be strictly controlled in the
access road to TPP
.
Project Site
Inspection of
traffic
conditions
1)Contractor
2)Subcontractor
Daily
1.4 Monitoring Monthly monitoring of the following should take place:
Fuel (m3)/
Electricity (KWh)/
Water (m3)/
Project Site
Observation
use of
sources
1)Contractor
2)Subcontractor
Monthly
2 Air /
2.1 Plan / Identify all possible air pollution sources related to construction Project Site Examination 1)Contractor In the
Site Based Environmental Management Plan Rev. D
56
activities
.
of air plan
construction process
2.2 Exhaust fumes
a) Regularly serviced and maintained to be in good condition
vehicles and Equipment
b)Forbid the burning of coal, waste, or wood on site
, c)Reduce idle time of all vehicles
Maintenance
Area
Project Site
Inspection of
air emission
Observation
of air polution
1)Subcontractor
2)Appropriate
manager
Monthly
3
Dust /
3.1 Plan / Identify all possible dust pollution sources related to
construction activities
,
Project Site
Examination
dust plan
1)Contractor
2)PMU
In the construction process
3.2 Watering
Watering shall be implemented to control dust where
:
a) Working areas
b) Exposed areas
c) Active cuts excavation and fill sites
Project Site
Observation
of watering
1)Contractor
2)Subcontractor
a) Daily
b)Windy Days
3.3 Site control
a) Minimize size and duration of exposed areas
b)Keep hauling roads in good condition
Project Site
Observation
dust control
1)Contractor
2)Subcontractor
Daily
Site Based Environmental Management Plan Rev. D
57
.
3.4 Material control
Minimize size and duration of materials stockpiles
.
Lay down
Observation
material
storage
1)Contractor
2)Subcontractor
Daily
3.5 Material control
a)Minimum practical height to limit the fugitive dust generation
from unloading excavated materials
, ,
.
b) Cement debagging should take place in a sheltered area.
Project Site
Batching
Plant area
Observation
of work
1)Contractor
2)Subcontractor
Daily
3.6 Vehicle control
a)Limiting vehicle-entrained dust from unpaved roads
, ,
b)Limiting vehicle speeds (20 km/h in Project Site) and
restricting traffic volumes
c)Trucks have proper fitting side and tail boards
d)Materials shall also be dampened, if necessary, before
transportation
, ,
e)Covering trucks during transport of materials (if required)
Project Site
road
Observation
of traffic
condition
1)Contractor
2)Subcontractor
Daily
Site Based Environmental Management Plan Rev. D
58
4
Noise /
4.1 Plan / a)Identify all possible noise pollution sources related to
construction activities
,
b) Posting Signboards on construction sites and/or stickers on
equipment outlining how affected parties can lodge complaint
/
.
Project Site
Examination
of noise plan
1)Contractor
2) Subcontractor
In the
construction
process
4.2 Noise level
a) Inspect noise level of the construction equipment
b) Equipment Noise limit will comply with Item 223 of EIA.
For example. Direction of Nuristan are limited to 80 dba 1m
223 .
. 80 1
c)Use appropriate PPE (earplug, earmuff) if exceeds noise
limits
( , ),
Project Site
Inspection of
noise level
1)Contractor
2)Subcontractor
During
construction
activity
4.3 Vehicle control
a) Limiting vehicle speeds (20 km/h at Project Site )
b) Restrict truck movements at night time and restrict truck
movements to major transport routes
Project Site
road
Observation
of traffic
control
1)Contractor
2)Subcontractor
Daily
Site Based Environmental Management Plan Rev. D
59
. 4.4 Vehicle control
Regularly serviced and maintained to be in good condition
vehicles and Equipment
Maintenance
area
Inspection of
repair
records
1)Subcontractor
2)Appropriate
manager
Monthly
4.5 Equipment
control
a)Equipment shall be operated within specifications and
capacity
b) Equipment shall be operated in as diversified a manner as
possible
c) Equipment shall be turned off when not in use
,
d) Work using machines or vehicles shall be prohibited at night
shift work time.
.
e)Air intakes, vents, and stacks should be fitted with suitable
noise attenuating equipment (if required)
,
( )
Project Site
Observation
work of
equipment
1)Contractor
2)Subcontractor
Daily
4.6 Equipment
control
Select the time when the environment is least sensitive to
noise impact using pile drivers, jack hammers, and rock drills
,
Project Site
Inspection of
noise level
1)Contractor
2)Subcontractor
During
construction
activity
Site Based Environmental Management Plan Rev. D
60
,
5
Waste water /
5.1 Plan / Identify all possible wastewater pollution sources related to
construction activities
,
Project Site
Examination
of
wastewater
plan
1)Contractor
In the construction process
5.2 Batch plant
control
Waste water from concrete batching plant operation and shall
not be discharged overland
, ,
Batching
Plant area
Observation
of
wastewater
1)Contractor
2)Subcontractor
Operation of
batching
plant
5.3 Washing water
Undertake settling and neutralization of alkaline washing water
containing excessive cement prior to discharge
,
,
Batching
Plant area
Observation
of washing
water
1)Contractor
2)Subcontractor
Operation of
batching
plant
5.4 Washing water
a)All washing of equipment or machinery shall be undertaken
in designated areas
b)Washing of equipment areas must be equipped with a
suitable impermeable floor and sump/oil trap
/
.
Truck
washing
area
Observation
of washing
area
1)Contractor
2)Subcontractor
Daily
5.5 Waste water
emission
Waste water collected within bunded area around the fuelling
area be disposed of as hazardous waste
,
Fuelling
area
Observation
of
wastewater
1)Contractor
2)Subcontractor
Daily
Site Based Environmental Management Plan Rev. D
61
,
5.6 Natural water
Natural run-off diverted away from any camps
Camp area
Observation
of natural
water
a)Contractor
b)Subcontractor
Daily
5.7 Rain water
Rain water plan to be and implemented for the construction
phase of the Project
.
Project
Site
Observation
of rain water
a)Contractor
b)Subcontractor
During rain
5.8 Contaminated
water
Sand, silt and silt-laden water do not enter the water drain
system or KMC
, ,
Project
Site
Observation
of water
system
a)Contractor
b)Subcontractor
During rain
.
5.9 Material control
a) All hazardous material storage areas designed to reduce
risk of spillages
b) All materials covered during transport to prevent them from
spilling (if needed).
(
).
c)Store all liquid/solid waste properly above ground to avoid
spills/leaks
/ /
d)Develop a hazardous materials and handling plan .provide
spill response kits at all HazMat storage areas and work site
Material
storage
areas
Observation of material storage condition
a)Contractor
b)Subcontractor
Daily
Site Based Environmental Management Plan Rev. D
62
.
. e) Chemicals and fuels on site should be kept to a minimum
5.10 Straining
Construct of dirt trap, interceptor pond and the attenuation dam
(if required) commenced as early as possible in the
construction phase
,
(
)
.
Project
Site
Observation
of strain
system.
1)Contractor
2)Subcontractor
Weekly
5.11 Hazardous
waste
Storage of hazardous waste in bunded areas to avoid leaks
escaping to the ground or nearby surface waters
,
Hazardous
waste bunded
area
Observation of
harzardous waste
1)Contractor
2)Subcontractor
Weekly
5.12 Monitoring
a) Monitoring water quality according to local standards
.
b) Water samples, sent to Talimarjan TPP laboratory to be tested
for water quality.
, , .
Project
Site
Experimentation
of waste water
1)Laboratory
Quarterly
.
6
Soil /
6.1 Plan / Identify all possible soil pollution sources related to
construction activities
,
Project Site
Examination
of soil plan.
1)Contractor
In the construction process
6.2 Site control
a) Minimize size and duration of exposed areas
Project
Site
Observation
of soil
1)Contractor
During
construction
Site Based Environmental Management Plan Rev. D
63
b) Minimize the excavation during construction of fuel oil
c) Minimize the overall slope of the site
d)Ensure good landscaping and erosion control
emission
2)Subcontractor
activity
6.3 Covering
a)Exposed slope surface shall be covered during the rainy day
b)Open stockpiles of construction materials covered during
rainy day
Project
Site
Observation
of material
store
1)Contractor
2)Subcontractor
During rainy
day
6.4 Sediment
Sediment tanks can be used for settling wastewater prior to
disposal
Equipment
Maintenance,
Batch plant
and Truck
washing areas
Inspection of
sediment
tank ability
1)Contractor
b)Subcontractor
Install
sediment tank
6.5 Drainage
facilities
All drainage facilities, erosion and sediment control structures
shall be regularly inspected and maintained
,
Inspection for
maintenance
a)Contractor
b)Subcontractor
Monthly
6.6 Vehicle control
a) All vehicles must be cleaned once in a week
.
b) Ensure no earth, mud, debris and the like is deposited by
them on roads
Equipment
maintenance
shop
Observation of
traffic condition
1)Contractor
2)Subcontractor
Weekly
.
Site Based Environmental Management Plan Rev. D
64
, , ,
6.7 Road control
a) All road works separated from surface waters
b) All roads shall be properly sloped and have adequate
culverts to manage run off
c) Earth works to construct drainage ditches and to lay
subsurface drainage conduits
Project
Site road
Observation of
traffic condition
1)Contractor
2)Subcontractor
Daily
6.8 Excavated
material
a) Excavated materials possible to used reclamation fill
b)Surplus excavated materials quarry over burden, rock rejected
for aggregate, aggregate surplus to the requirements and the like
not discarded indiscriminately
, , , ,
c)Different types of surplus excavated materials deposited
separately in the spoil dumps designated for the purpose outside
the Project site
,
Project
Site
Observation
of excavated
material
1)Contractor
2) Subcontractor
Daily
7
Overall Spill Control/
7.1 Management a) Any spillage of fuel shall straight away be absorbed using Project Observation 1)Contractor Daily
Site Based Environmental Management Plan Rev. D
65
sand or other absorbent materials
. b)Develop spill response plan
. c)Only people with adequate training and knowledge should
handle fuel and chemicals to avoid spills
,
.
d) Fuelling should be one on concrete surface provided with
spill catch tank that can be easily cleaned and all spilled fuel
recovered/safety disposed
,
/
e) All repair and maintenance work to be done either on
concrete surface with oil spill catch basins or oil catch pans
provided at all service areas
- ,
f) Routinely inspect all equipment handling hazardous
materials for leaks and spills monthly
g) All fuel where spills and leakage area possible e.g. the
generator, must have basins installed to prevent leakage
Site
spill
Examination
of spill plan
Observation
of spilling
2)Subcontractor
Monthly
Monthly
Site Based Environmental Management Plan Rev. D
66
, ,
h) The recovered materials must be recycled monthly
i) Fuelling equipment must be fitted with proper fuel nozzles
and devices to avoid accidental spills
Monthly
7.2 Storing
a) All fuel stored on site shall be kept in drums or in bulk tanks
, ,
b) Fuel storage are a be locate data designated place away
from any source of ignition or open drain
c)“NoSmoking” sign displayed at the storage location and a
charged fire extinguisher of the correct type
« »
. d) All fuel tanks and storage areas provided with concrete
embankments to readily contain spills
e)provide spill response kits at all working areas
Fuel Storage area
Observation
of oil storage
1)Contractor
2)Subcontractor
Daily
7.3 Oil emission Treat oily wastewater in coalescence separator prior to Project Observation 1)Contractor Weekly
Site Based Environmental Management Plan Rev. D
67
discharge
- .
Site
of oily water
2)Subcontractor
7.4 Refueling
Refueling of vehicles shall take place only in designated areas
.
Fuel Storage area
Observation
of refuelling
1)Contractor
2)Subcontractor
Daily
7.5 Training
Fuel handling training shall include chemical handling in the
training program for assigned personnel.
.
Training
Center
Training of oil
handling
Contractor
As needed
8
Waste control/ K Ш
8.1 Plan / a) Identify all possible waste pollution sources
b) Procedures detailed in the Material Safety Data Sheet
(MSDS) for hazardous materials included in pollutants spillage
control plan and followed in the event of an emergency
situation
,
,
.
c) Should have "Keep a waste log" for all type of wastes
produced in construction area.
" »
, .
Project Site
Examination
of waste plan
1)Contractor
In the construction process
8.2 Waste
Disposal
Dispose unusable waste streams at permitted waste disposal
facilities
Disposal
facilities
Observation
of waste
Waste disposal
company
Weekly
Site Based Environmental Management Plan Rev. D
68
facility
8.3 Waste disposal
a)Separate waste disposal area shall be designated on the
construction site
b)Separate waste disposal area contains clearly demarcated
skips and bins to allow different types of waste
c) Waste is separated into non-hazardous and hazardous /
potentially hazardous prior to reuse, recycling or transport to
Landfill
/
,
.
d) Must be separated to the domestic, metal scrap, used oil,
paper, hazardous etc.
, , , , . .
Disposal
area
Observation of
waste control
1)Contractor
2)Subcontractor
3)Disposal
company
Daily
Site Based Environmental Management Plan Rev. D
69
8.4
Reuse
a) Re-use the waste during construction
b) Re-use or recycle waste streams to other users at other
locations
c)The design of formwork will maximize the use of standard
wooden panels
d)Alternatives such as steel formwork or plastic facing can be
considered to increase the potential for re-use
,
,
Project
Site
Observation
of reuse
waste.
1)Contractor
2)Subcontractor
Daily
8.5 Recycle Waste
Develop dedicated area for storage of recycled material away
from active construction works and near site access point
.
Out of the
project site
Training of
waste
disposal
1)Contractor
2)Subcontractor
Monthly
8.6 Rubbish bins
a) Provide sufficient bins with lids to store the solid waste
produced on a daily basis
, .
b) Bins not allowed to become overfull and shall be emptied as
a minimum on a weekly basis
.
Project
Site
Observation
of waste
disposal
1)Contractor
2)Subcontractor
3)Disposal
company
Weekly
8.7 Rubbish bins
Install signage encouraging use of rubbish bins on site and in
construction camps
,
a)Project Site
Observation
of waste
disposal
1)Contractor
2)Subcontractor
Weekly
Site Based Environmental Management Plan Rev. D
70
b)Camp
3)Disposal
company
8.8 Discharge
Prohibit dumping of dredge material in canal or elsewhere on site
,
Project
Site
Observation of
dumping
1)Contractor
2)Subcontractor
Daily
8.9 Storing
a) Design and implement a temporary waste storage area for
domestic waste located away from living and eating areas
b)Separation of storage of hazardous and non-hazardous waste
Project
Site
Observation
of waste
store area
1)Contractor
2)Subcontractor
Monthly
8.10 Storing
Containers used for the storage of chemical wastes shall
,
,
a) Be suitable for the substance they are holding, resistant to
corrosion, maintained in a good condition, and securely closed
, ,
, ,
b)Stored chemical in roofed areas with concrete flooring.
.
Storage
area
Observation
of waste
store area
1)Contractor
2)Subcontractor
Monthly
8.11 Storing
The storage area for chemical waste shall
a) Be located away from surface water bodies.
b) Be constructed with a weatherproof cover, concrete floor with
Project
Site
Observation of
waste store
area
1)Contractor
2)Subcontractor
Weekly
Site Based Environmental Management Plan Rev. D
71
bunding, and with adequate securable storage bins for waste.
,
c) Have appropriate signage and signage system.
. d) Be clearly labeled and used solely for the storage of chemical
waste.
e) Been closed on at least 3 sides.
f) Be arranged such as to separate in compatible materials
,
8.12 Training
Include information on solid waste management in construction
worker training program
Training
center
Training of
waste
disposal
1)Contractor
2)Subcontractor
a)Monthly
b)Random
8.13 Separating
Wood and other scrap material with a commercial value shall
be separated and stored in segregated areas prior to removal
Project
Site
Observation
of waste
control
1)Contractor
2)Subcontractor
Daily
8.14 Battery
a) The dead batteries will be given to specialized organizations
for reuse
Project
Site
Observation
of battery
1)Contractor
2)Subcontractor
Daily
8.15 Chemical waste
Disposal of chemical waste shall
Project
Site
Observation
of chemical
1)Contractor
Daily
Site Based Environmental Management Plan Rev. D
72
a) Be treated by a licensed waste collector.
b)Be to a facility licensed to receive chemical waste, such as the
chemical waste treatment
,
,
c)Hazardous and toxic waste shall not be disposed of on the canal
d) Hazardous waste shall be removed from the site property within
6 month.
6 . e)Hazardous waste shall not be dumped onto the ground, into rain
water sewers or into sanitary sewer system
,
waste
2)Subcontractor
3)Waste
collector
8.16 Waste of
catering
a)Catering wastes is divided into food waste and non-food
waste
b)All organic food waste generated by kitchen facilities to be
disposed of at the farm
,
c)Food waste daily removed from the kitchen
d)Food waste always contained in plastic containers for
disposal
Catering
Observation
of catering
1)Contractor
2)Subcontractor
3)Catering
company
Daily
Site Based Environmental Management Plan Rev. D
73
e) Non-food waste collected in separate containers as
beverage cans, packing materials, etc.
, , - , .
8.17 Oily wastewater
Oil and other lubricants collected in drums and disposed of in
accordance with CONTRACTOR instructions
Project
Site
Observation
of oily waste
water.
1)Contractor
2)Subcontractor
Daily
Механизм рассмотрения жалоб от населения по проекту «Расширение
Талимарджанской ТЭС со строительством двух ПГУ мощностью
по 450 МВт»
Public complaints-handling mechanism on the Project “Expansion of Talimarjan TPP with the
construction of two CCGT with a capacity of 450 MW"
рис.1 Жалобная Книга
pic. 1 Complaint book
рис.2 Жалобная книга находится в отделе кадров в свободном доступе
pic. 2 Complaint book is being kept freely available in HR department.
рис. 3 и рис.4 Жалобная книга прошита и пронумерована
pic. 3 & 4 Complaint have sequentially numbered pages that have been bound securely
рис 5. Жалобная книга пуста, записей нет
pic. 5 Complaint book is empty, there are no entries
рис.6 и рис.7 Отдел кадров, проходная
pic. 6 & 7 HR department, entrance to the Talimarjan TPP
рис. 8 Время приёма руководством УП «Талимарджанская ТЭС» граждан
pic. 8 Visiting hours for citizens to meet with management of Talimarjan TPP
рис. 9 Время приёма руководством ГАК «Узбекэнерго» граждан по личным вопросам
pic. 9 Visiting hours for citizens to meet with management of SJSC “Uzbekenergo” on
personal issues
рис. 10 и рис. 11 Объявление о наличии жалобной книги на пункте пропуска на станцию
pic. 10 & 11 Notification at the entrance of Talimarjan TPP that there is a complaint book
available
рис. 12 и рис 13. Объявление о наличии жалобной книги в посёлке Нуристан, рынок
pic. 12 & 13 Notification at the marketplace in the settlement of Nuristan that there is a
complaint book available
рис. 14 и рис. 15 Объявление о наличии жалобной книги в посёлке Нуристан, здание для
собраний жителей посёлка, медпункт
pic. 14 & 15 Notification at the meeting hall/ first-aid station in the settlement of Nuristan that
there is a complaint book available