STATE BANK OF PATIALA - India Electronics & · PDF fileRFP for Elevator Works at...
Transcript of STATE BANK OF PATIALA - India Electronics & · PDF fileRFP for Elevator Works at...
RFP for Elevator Works at Electropreneur Park, UDSC 1
Electropreneur Park
Electropreneur Park
Electropreneur Park
Electropreneur Park
Electropreneur Park
Electroprenur Park
Electropreneur Park
Electropreneur Park
Electropur Park
Electropreneur Park
Electropreneur Park
Electropreneur Park
Electropreneur Park
Electropreneur Park
Electropreneur Park
University of Delhi, South Campus, Library Building,
Benito Juarez Road, New Delhi 110021
TENDER FOR
“Elevator Works at Electropreneur Park, University of Delhi South
Campus”
Tender No.: STPI/EPP/DU/IESA/015 dated 05/06/2015
Pre-bid meeting 10.06.2015 at 12:30 hrs.
Last date of submission of bids 15.06.2015 up to 15.00 hrs.
Date of opening of the technical bids 15.06.2015 up to 15.30 hrs.
Time and date of opening of financial bids 19.06.2015 at 11:00 hrs.
PLANNERS GROUP- SCO 4, Sector 17-E, Chandigarh, www.plannersgroup.net
Request for further information: [email protected]
OR CALL - (0172) 2703917, 2741010
RFP for Elevator Works at Electropreneur Park, UDSC 2
CONTENTS
SECTION-1 : NOTICE INVITING TENDERS
SECTION-2 : FORM OF TENDER
SECTION-3 : GENERAL CONDITIONS
SECTION-4 : ARTICLES OF AGREEMENT
SECTION-5 : TECHNICAL SPECIFICATIONS
SECTION-6 : DIMENSIONAL PARAMETERS
SECTION-7 : PRICE BID
RFP for Elevator Works at Electropreneur Park, UDSC 3
SECTION-I
NOTICE INVITING TENDERS
Name of work Estimated
Cost
Bid
Document
cost
Bid
Security
(EMD)
Contract
Duration
Elevator Works for
Electropreneur Park,
University of Delhi,
South Campus, Library
Building, Benito Juarez
Road, New Delhi
110021. Installation,
Designing, Engineering,
Manufacturing,
Erecting, testing and
commissioning of One
No. Ten Passenger
Elevator.
20 Lacs NIL Rupees
Forty
Thousand
only
16 weeks
1) Officer inviting bids: Project Co-Ordinator– Electropreneur Park, University of Delhi, IIC Lab, DUWA Building, Near Cafeteria, Delhi University South Campus, Benito Juarez Road, New Delhi – 110021.
2) Date of downloading bid document: from the date of publishing to 15.06.2015 up to 15:00 hrs.
3) Last date of receipt of bids 15.06.2015 up to 15.00 hrs.
4) Date of opening of the technical bids: 15.06.2015 Time 15:30 hrs. in the presence of tenderers who may choose to be present at the above address as given in point 1. One authorized representative of the tenderer may be present for the purpose.
5) Time and date of opening of financial bids: 19.06.2015 at 11:00 hrs. in the presence of tenderers who may choose to be present at the above address as given in point 1. One authorized representative of the tenderer may be present for the purpose.
6) Tender Documents can be downloaded from following websites
RFP for Elevator Works at Electropreneur Park, UDSC 4
www.electropreneurpark.com
www.noida.stpi.in
www.stpi.in
www.du.ac.in
www.iesaonline.org
www.cmrindia.com
All the information/ corrigendum/addendum related to the project shall be published on the
above mentioned websites.
7) Place of submission of bid
Project Co-Ordinator– Electropreneur Park
University of Delhi,
IIC Lab, DUWA Building, Near Cafeteria
Delhi University South Campus, Benito Juarez Road, New Delhi – 110021.
o Tender (Bid) documents shall be prepared by typing or writing with inedible black/blue ink, documents must be duly signed at every Stage.
o The tenderers rubber Stamp shall be affixed at required places o The tender (Bid) documents shall be submitted in the duplicate o The sealed cover shall be super scribed as follows o Covering letter, if any, shall be in duplicate and shall be submitted in a separate cover
along with EMD. “TENDER FOR Elevator Works
at
Electropreneur Park”
Tender No.: STPI/EPP/DU/IESA/015 dated 05/06/2015
University of Delhi, South Campus, Library Building, Benito Juarez Road, New Delhi 110021
8) Bid validity: 90 days
9) The time allowed for the completion of the work is 16 weeks from the 7th day after the date of
written order to commence work. The time shall be considered the essence of contract.
Liquidated damages @1% per week of contract value subject to maximum of 10% per week.
RFP for Elevator Works at Electropreneur Park, UDSC 5
10) Submission of Tender:
i) Every tender shall be accompanied by Earnest Money of Rs. 40,000/- (Rupees Forty
Thousand) only in the form of Demand Draft of Schedule Bank drawn in favor of
Electropreneur Park, University of Delhi South Campus payable at New Delhi. No interest
will be payable on E.M.D.
ii) The following shall be adopted for submission and opening of tender. The sealed
envelopes shall be submitted as follows:
Envelope No. 1:
Part-I containing the earnest money deposit will be opened first and if the earnest money deposit
is not found as prescribed the tender shall be rejected and other sealed envelope will be returned
unopened to representative of the concerned tenderer is present.
Part-II: containing the covering letter depicting terms and conditions.
ALONG WITH Technical bid shall be opened if earnest money is in order. The same will be
scrutinized and comments/conditions which have financial implications will be evaluated and
discussed with the tenderer if deemed necessary.
Envelope No. 2:
Containing the price bid shall be opened on a separate date which will be intimated to the tenders
subsequently.
Delay in submission of any part arising out of postal irregularities or for any reason, whatsoever
at any stage, will not be considered. There will be no consideration for damage in transit in case
of postal delivery.
11) The Earnest Money will be retained in the case of the successful tenderer as part of the security
for the due fulfillment of the contract. In case the successful tenderer does not accept work order
or does not start the work physically within 10 days from the work order, the Earnest Money will
be forfeited.
12) The tenderer will submit his tender after carefully examining the whole of the tender documents
and the conditions of tender, and of contract, the drawing and specifications, the bill of quantities.
13) The Notice Inviting Tenders, the conditions of tender and the duly completed form of tender will
form part of the agreement to be executed by the successful tenderer with the Employer.
RFP for Elevator Works at Electropreneur Park, UDSC 6
14) The tender shall be kept valid for a period of 90 days from the date of opening of tender.
15) LANGUAGE OF THE BID
All information in the bid shall be in English failure to comply with this may disqualify a tender.
16) FURTHER INFORMATION
Any further information queries or concerns may be mailed to
[email protected], [email protected] and copy to
17) SIGNATURE OF TENDERS
i. The Tenderers must contain the name, residence and place of business of the person or persons
making the Tender and must be signed and sealed by the Tenderer with his usual signature. The
names of all persons signing should also be typed or printed below the signature.
ii. Tender by a partnership firm must accompany a list of full names of all partners and a copy of
partnership deed and tender shall be separated by each partner thereof or in the event of absence
of any partner, it must be signed on his behalf by a person holding a power of attorney. The power
of attorney shall be enclosed with the tender.
iii. Tenderers by Corporation / Company must be signed with the legal name of the Corporation /
Company by the President / Managing Director or by the Secretary or other person or persons
authorized to tender on behalf of such Corporation / Company in the matter.
iv. Tender by a person who affixed to his signature the word President, Managing Director, Secretary,
Agent or other designation without disclosing his principal will be liable to be rejected.
v. Satisfactory evidence of authority such as power of attorney of the person signing on behalf of
the Tenderer shall be furnished with the bid.
vi. The tenderers name stated on the proposal shall be the exact legal name of the person.
vii. Erasure or other changes in the Tender Documents shall be attested with the initials of the
persons signing the Tender.
viii. Tenders not conforming to the above requirements of signing the tenders may be disqualified.
18) UNDERSTANDING & CLARIFICATION ON DOCUMENTS & SPECIFICATIONS
i. The tenderer is required to carefully examine the specifications and documents and fully inform
himself so as to all the conditions and matter which may in any way affect the works or the cost
thereof. In any case Tenderer finds discrepancies or omissions in the specifications and
documents or is in doubt as to the true meaning of any part, he shall at once request in writing
RFP for Elevator Works at Electropreneur Park, UDSC 7
for an interpretation/ clarifications from the Architect. The Architect will furnish clarification in
writing within 4 days of receipt of such request to all the tenderers. All such interpretations and
clarifications shall form a part of the specifications and documents and accompany the Tender.
ii. Verbal clarification and information giving Architect or his employee(s) or his representative(s)
shall not in any way be binding on the Architect/Employer.
19) The employer does not bind itself to accept the lowest tender and reserves to itself the right to
reject any or all the tenders received without assigning any reason/s thereof. The notification of
award of contract will be made to successful tenderer by the Architect.
20) Eligibility Criteria and conditions:-
a) Proof of approval/Registration with appropriate authority. b) The firm should have satisfactorily completed similar works, as stated below during the last 5 years ending last day of the month of May 2015. (Similar work Means: - DESIGN, SUPPLY, INSTALLATION, TESTING AND COMMISSIONING OF PASSENGER LIFT (8 or more passengers) & COMPREHENSIVE MAINTENANCE)
(i) The firm shall have at least 6 similar installations in any city in India for any Central / State Government, Central Autonomous Body, Central Public Sector undertaking with satisfactory. Proof from appropriate authority for having successfully completed the Installation in last 3 years.
(ii) Maintenance record for the past 3 years and adequate, Bidder should submit at least 6 No. similar O & M Contracts successfully completed during last Five years
(iii) Maintenance/service setup in Delhi / NCR.
c) The bidder should have average turn-over (gross) of Rs. 10 CR for installation of elevator /maintenance work during last five years ending March, 2015. The copy of the duly audited statement checked by chartered Accountant be added.
d) Proof of registration under Delhi/ NCR value added Tax (D-VAT) Act 2004 and undertaking that up-to-date returns submitted to Trade and Taxes Deptt. Delhi/NCR. The bidders registered with other Govts. at the time of tendering shall produce the proof of same. However, successful bidder has to get himself registered with Trade and Taxes Deptt. Delhi/NCR before any payment is made to the agency.
e) The bidder should not be black-listed by any govt./PSU/Autonomous bodies/banks etc. An undertaking in this regard should be furnished on the company letter head duly signed and stamped by the authorized signatory.
f) The bidder should have sufficient T & P to cope up with heavy duty elevator work & must submit the list of such T & P.
g) The bidder should submit the structure of his organization including details of technical, administrative & Maintenance personnel to be employed for work.
h) Registered under EPF, ESI Act
RFP for Elevator Works at Electropreneur Park, UDSC 8
21) Performance guarantee:
i) The contractor shall submit an irrevocable PEFRORMANCE GUARANTEE of 5% (Five percent) of the contract amount in addition to other deposits mentioned elsewhere in the contract for his performance of the contract agreement, (not withstanding and/or without prejudice to any other provisions in the contract) within 7 days of issue of letter of intent. This period can be further extended by Electropreneur Park, UDSC up to a maximum period of 7 days on written request of the contractor stating the reason for delays in procuring the Performance Guarantee, to the satisfaction of the Electropreneur Park, UDSC. This guarantee shall be in the form of fixed deposit receipts or Guarantee Bonds of any Scheduled Bank in accordance with the form annexed hereto.
ii) A letter of intent shall be issued in the first instance informing the successful bidder of the decision of the competent authority to accept his tender and the award letter shall be issued only after the Performance Guarantee in any of the prescribed form is received. In case of failure by the contractor to furnish the performance guarantee within the specified period, the Electropreneur Park shall without prejudice to any other right or remedy available in law, be at liberty to forfeit the earnest money absolutely.
iii) The Performance Guarantee shall be initially valid up to the stipulated date of warranty and AMC period plus 120 days beyond that. In case the time for completion of work gets enlarged, the contractor shall get the validity of performance Guarantee extended to cover such enlarged time for completion of work. After recording of the completion certificate for the work by the competent authority and after furnishing Statutory approvals to be submitted by the contractor after obtaining from the concerned department, the performance guarantee shall be returned to the contractor, without any interest.
iv) Electropreneur Park, UDSC shall not make a claim under the Performance Guarantee except for amounts to which the Electropreneur Park is entitled under the contract (notwithstanding and/or without prejudice to any other provisions in the contract agreement) in the event of :
(a) Failure by the contractor to extend the validity of the Performance Guarantee as described herein above, in which event Electropreneur Park may claim the full amount of the Performance Guarantee. (b) Failure by the contractor to pay the Electropreneur Park any amount due, either as agreed by the contractor or determined under any of the Clauses/Conditions of the agreement, within 30 days of the service of notice to this effect by Engineer in Charge. (c) In the event of the contract being determined or rescinded under provisions of any of the clause/condition of the agreement, the performance guarantee shall stand forfeited in full and shall be absolutely at the disposal of Electropreneur Park
Yours faithfully,
For: Electropreneur Park
Project Co-Ordinator– Electropreneur Park
RFP for Elevator Works at Electropreneur Park, UDSC 9
SECTION -2
FORM OF TENDER Dated:……………………
Project Co-ordinator– Electropreneur Park University of Delhi, IIC Lab, DUWA Building, Near Cafeteria Delhi University South Campus, Benito Juarez Road, New Delhi – 110021. Dear Sir,
Reg: Tender for installation of One No. Ten Passenger Elevators at Electropreneur Park,
University of Delhi, South Campus, Library Building, Benito Juarez Road, New Delhi 110021
1. I/We refer to the tender notice issued on behalf of Project Coordinator– Electropreneur Park,
University of Delhi, IIC Lab, DUWA Building, Near Cafeteria, Delhi University South Campus, Benito
Juarez Road, New Delhi – 110021.
2. I/We do hereby offer to perform, provide, execute, complete and maintain the work in conformity
with drawings, conditions of contract, specifications, bill of quantities at the respective rates
quoted in the bill of quantities.
3. I/We have satisfied myself/ourselves as to the site conditions, examined the drawings and all
aspects of the tender conditions. Subject to above, I/We do hereby agree, should this tender be
accepted in whole or in part.
a) Abide by and fulfill all the terms and provisions of the said conditions annexed here to:
b) Complete the work within 16 weeks, as stipulated in two or three shifts if considered necessary
by the consultant at no extra cost to the Owner.
4. I/We have deposited earnest money of Rupees 40,000/- (Rupees Forty Thousand only) in the
form of DD and PBG of 5% (to be received from successful bidder) which I/We note, will not bear
any interest and is subject to forfeiture solely at Electropreneur Park’s discretion.
a) If the work is not commenced by me/us within 7 (seven) days from the date of issue of formal
work order.
b) If the offer is withdrawn within the validity period of acceptance.
Or
c) If the contract is not executed within 30 days from award of contract
RFP for Elevator Works at Electropreneur Park, UDSC 10
5. I/We understand that Electropreneur Park, UDSC is not bound to accept the lowest or any tender
received.
6. The acceptance of this tender shall constitute a binding of contract and any failure as mentioned
in item 4, above shall constitute a breach of contract by us and the tender accepting authority
shall be entitled to have the work executed at our risk and cost and to claim extra cost
/expenditure incurred by then from us.
7. Our Bankers are:
8. Name of partners/directors of our firm:
i)
ii)
iii)
iv)
Yours faithfully,
Signature _____________ Name of Partner/Director of the: firm authorized to
Name___________________ sign or Name of person having power of attorney to
Designation____________ sign the contract. (Certified true copy of power of attorney
should be attached)
Signature & Addresses of Witnesses:
a) Signature _____________
Name __________________
Address _______________
b) Signature _____________
Name __________________
Address _______________
RFP for Elevator Works at Electropreneur Park, UDSC 11
SECTION-3
GENERAL CONDITIONS
1.0 GENERAL
1.1 These conditions & specifications are intended to cover the complete installation of elevator plant in first
class workman like manner & shall include all work and materials in accordance with drawings and as per
specifications.
2.0 CODES/REGULATIONS
2.1 The work shall be carried out in accordance with regulations of any local codes/bye- laws & IS codes which
may govern the requirements of the elevators. The following codes/specifications shall be generally
adhered to:
a) IS: 1860 Code of practice for installation, operation and maintenance of electric passengers &
goods lifts.
b) IS: 3534 Outline dimensions of electric lifts.
C) IS: 4666 Specifications for electric passenger and goods lifts.
3.0 SINGULAR/PLURAL
3.1 In all cases where a device or a part of equipment is herein referred to in singular number, it is intended
that such reference shall apply to as many such devices as required to complete the installation.
4.0 DRAWINGS
4.1 Tender Drawing: The tender drawing enclosed with the tender is essentially diagrammatic & indicates the
lift well arrangement & sectional view. This drawing is intended only as guide to the tenderer for offering
his quotation.
4.2 Working Drawing: The lift well has already been constructed. (The elevator contractor shall prepare
detailed general arrangement drawing of the elevator plant including detailed machine room layout, cabling
and mechanical equipment layout, brackets, etc. and submit the same to the Architects within 14 days after
the award of work. All the drawings shall be submitted in quadruplicate).
4.3 The approval of elevator contractor’s drawings by the Architect shall not absolve the contractor from any
of his obligations as per this contract. The contractor shall point out any discrepancies in the approved
drawings within two weeks from the date of receipt of the approved drawing failing which the contractor
will be held responsible for any alterations, modifications or additions that may be required to be carried
out to the elevator well, machine room or pit.
5.0 LICENSE/ PERMIT/INSPECTION
RFP for Elevator Works at Electropreneur Park, UDSC 12
5.1 It shall be the elevator contractor's responsibility to arrange for inspection of elevator plant by the Inspector
or Local Authority. The owners/employer will only complete the application for inspection & deposit the
fees, if any, for the inspection. The contractor shall also be responsible for follow up action & obtain and
deliver to the Owner/ Employer the necessary license/ permit required under the local/provincial/national
regulations/byelaws.
5.2 The elevator contractor shall also carry out any tests/operations as required by the Inspector or Local
Authorities to obtain the approval of elevator installation and operation of the elevator plant. All such tests,
follow up action and liaison shall be included in the prices quoted and no extra payment on these accounts
will be made to the Contractor.
6.0. POWER SUPPLY
6.1 The entire plant & apparatus shall be designed to operate on 433 volts, 3 phase, 4 wire, 50 Hz AC supply.
6.2 The equipment shall be able to function satisfactorily under the following variations of power supply.
a) Voltage : ± 10%
b) Frequency : ± 3%
C) Combined voltage: ± 10%
& frequency
7.0 DUTIES/TAXES/OCTROI
7.1 The tenderer shall include all duties & taxes such as excise duty and sales tax in his prices at the prevailing
rates. The quantum of all such taxes & duties included shall be clearly indicated. It may be noted that if
prices are quoted exclusive of such taxes & duties, the owner/employer reserves his right to reject all such
tenders.
7.2 OCTROI
The quoted prices shall be inclusive of octroi charges & no extra claim on this account will be entertained.
8.0 PACKING/FORWARDING FREIGHT/TRANSIT INSURANCE
8.1 The prices shall be inclusive of all packing, forwarding freight & transit insurance charges. The extra claim
on this account will not be entertained.
9.0 RECEIVING/UNLOADING/HANDLING/STORING/SAFE CUSTODY
9.1 Receiving/Unloading/Handling: The contractor shall receive all the materials, dispatched from his works, at
site & unload, handle and store them in his site storage.
9.2 Storage: The elevator contractor shall arrange to construct his own storage at the site on the space
earmarked for the purpose. The owner/employer will only provide space, all partitions, doors, ventilation,
lighting etc. shall be arranged by the contractor at his own cost.
9.3 SAFE CUSTODY: The elevator contractor shall be responsible for storage & safe custody of materials brought
to the site till the entire elevator plant is completed, tested & handed over to the employer/owners. The
RFP for Elevator Works at Electropreneur Park, UDSC 13
elevator contractor shall arrange for security guard to protect the materials stored in his stores/installed at
the site from pilferage, damage, etc. at his own cost.
10.0 COMPLETION TIME
10.1 The entire elevator plant/installation shall be completed within 16 weeks from the 7th day after the date
of written order to commence the work.
11.0 LIQUIDATED DAMAGES
11.1 A liquidated damages of 1 % per week subject to a maximum of 10% of the value of work shall be paid by
the Contractor to the employer if the completion of the work is delayed beyond the agreed completion
date and authorized extension of time if any.
12.0 EXTENSION OF TIME
12.1 Extension of time for completion of the work will be granted in case the work is delayed due to reasons
beyond the control of the contractor such as:
i) Force majeure
ii) Delays on the part of the owner
13.0 LIABILITY FOR ACCIDENTS/DAMAGES
13.1 This contract, the contractor shall be responsible for loss or damage to the plant/equipment/materials
unless the installation is taken over by the Employer/owner
14.0 CONTRACTOR LIABLE FOR DAMAGE DONE
14.1 Any damage done to the property/life/structure due to contractor's operation or neglect will be charged to
the contractor
15.0 INSURANCE
15.1 The contractor shall arrange, secure and maintain insurance as may be necessary and for all such amounts
to protect his interests and the interests of the employer against all risks as detailed herein
The form and the limit of such insurance as defined herein together with the underwritten thereof in each
case shall be acceptable to the employer.
However, irrespective of such acceptance, the responsibility to maintain adequate insurance coverage on
comprehensive all risks basis at all times during the period of contract or extended period if any.
16.0 DAMAGE TO PERSONS AND PROPERTY, INSURANCE, ETC.
16.1 The Contractor shall be responsible for all injury to the work or workmen to persons, animals or things and
for all damages to the structural and/or decorative part of property which may arise from the operations
or neglect of himself or of any Sub contractor or of any of his or a Sub Contractor's employees, whether
such injury or damage arise from carelessness, accident or any other cause whatsoever, in any way
RFP for Elevator Works at Electropreneur Park, UDSC 14
connected with the carrying out of this contract. The clause shall be held to include inter-alia, any damage
to buildings whether immediately adjacent or otherwise, and any damage to roads, streets, foot-paths or
pathways as well as damage caused to the buildings and the work forming the subject of this contract by
rain, wind or any other inclemency of the weather. The contractor shall indemnify the Employer and hold
harmless in respect of all and any expenses arising from any such injury or damages to persons or property
as aforesaid and also in respect of any claim made in respect of injury or damage under any acts of
compensation or damage consequent upon such claim.
16.2 The contractor shall reinstate all damage of every sort mentioned in this clause, so as to deliver the whole
of the contract work, complete and perfect in every respect and so as to make good or otherwise satisfy all
claims for damages to the property or third parties.
16.3 The contractor shall obtain a policy covering under Workmen Compensation Act, a third party insurance as
well as any other insurance and indemnify the Employer entirely from all responsibility in this respect. The
insurance must be placed with a company approved by the Employer and must be effected jointly in the
name of the contractor and the Employer and the policy lodged with the latter. The scope of insurance is
to include damage or loss to the contractor itself till this is made over in complete state.
16.4 Insurance is compulsory and must be effective from the very initial stage. The Contractor shall also be
responsible for anything which may be excluded from damage to any property arising out of incident
occurrence or defective carrying out of this contract.
16.5 The Employer shall be at liberty and is hereby empowered to deduct the amount of any damages,
compensations, costs. Charges and expenses arising or accruing from or in respect of any such claim or
damages from any sums due or to become due to the contractor.
16.6 INSURANCE: All risk Insurance Policy and Workman's Compensation Policy.
Unless otherwise instructed the Contractor shall insure the work and keep the insured until the virtual
completion of the contract against loss or damage by fire and/or earth quake, flood or damages from
whatever cause by an All Risk Insurance Policy for the full value of the contract and Workmen's
Compensation Policy of adequate value. The insurance must be placed with a company approved by the
Employer, in the joint names of the Employer and the contractor for such amount and for any further sum
being allowed to the Contractor as an authorize extra.
16.7 The Contractor shall deposit the policy and receipt for premiums paid with the Employer within 21 days
(Twenty one days) from the date of issue of work order unless otherwise instructed. In default of the
contractor insuring as provided above, the Employer on his behalf may so insure and may deduct the
premiums paid from any money due, or which may become due to the contractor. The contractor shall as
soon as the claim under the policy is settled or the work reinstated by the Insurance Company should they
elect to do so, proceed with due diligence with the completion of work in the same manner as though the
fire has not occurred and in all respects under the conditions of the contract. The Contractor in case of
rebinding or reinstatement after fire shall be entitled to extension of time for completion as the Employer
may deem fit.
17.0 VARIATIONS/RESTRICTIONS OF WORK
RFP for Elevator Works at Electropreneur Park, UDSC 15
Employers/ owners reserve their rights to alter/ delete any item of work as also restrict or increase the
quantum of work to the carried out by the contractor. Such variations shall not vitiate the contract. The
contractor shall not be eligible for any compensation for such variations. However, the quantum of work
carried out will be paid the contract rates.
18.0 PRICE VARIATION
18.1 Prices quoted shall be held firm throughout the period of contract. No price variation on any account, shall
be allowed.
19. PERFORMANCE
19.1a) The Elevator contractor shall guarantee that all the machines/plants/ installations covered under this
contract will yield contract rating and results.
b) The elevator contractor upon the completion of the work shall perform all the tests required to establish,
that the elevator plant is performing as per the contract rating, especially with regards to the load, speed,
systems and controls.
c) If the performance tests do not yield the contract ratings, then the elevator contractor shall rectify/ replaces
free of cost such equipment/materials/ plants and re-conduct the tests to demonstrate their correctness
within one month from the date of written notice from the employer/architect
d) If the elevator contractor fails to carry out modifications required and establish the contract rating of the
plant, the owner/employer reserves the right to get the work done at risk and cost.
19.2 DEFECTS LIABILITY
The elevator contractor shall guarantee that the entire plant/ materials are of brand new quality and the
plant/ materials and workmanship of the apparatus installed by him under this contract are first class in
every respect, and that the plant/material and workmanship shall be free from all the defects. The elevator
contractor also guarantee that he shall rectify/replace free of cost all defective material/plant/
apparatus/workmanship for a period of one year from the date of handing over of the plant. If the
performance of the plant is found to be unsatisfactory during the period of defects/liability, the guarantee
shall be extended till the plant is rectified and satisfactory performance is established for a period of not
less than 6 months.
20.0 MAINTENANCE
20.1 After completion of the installation of the elevator plant by the elevator contractor, he shall furnish, free of
cost, maintenance service for the entire plant for a period of 12 months from the date of handing over. The
maintenance service shall include regular examination of the plant during the regular working hours by
trained personnel, and shall include all necessary adjustments, greasing, oiling, cleaning, supplies and
genuine standard parts to keep the equipment/plant in proper operation.
21.0 PAINTING
RFP for Elevator Works at Electropreneur Park, UDSC 16
21.1 All exposed metal work finished under these specifications shall be properly spray painted after installation
to the entire satisfaction of the employer.
22. PROVISION BY ELEVATOR CONTRACTOR
22.1 Elevator contractor shall provide/carryout the following works at his own cost.
a) Necessary scaffolding in the hoist-way required during the erection of the elevators. It shall be responsibility
of the contractor to provide safe and strong scaffolding duly fastened/ securely fixed to building to prevent
it from swaying.
b) Minor builders work comprising of cutting holes and making good for car and counter weight rail brackets,
hall buttons and indicators including laying of sill in position.
C) Steel items such as machine beams, bearing plates, buffer support channels, and any insert plates/sleeves
etc. required for installation of these items.
d) Hoisting beam in the machine room
e) Necessary sill projection in aluminum / steel at all landings. The contractor shall provide any other work as
may be required to complete the work.
f) The scaffolding constructed by the lift contractor, shall be made available to the electrical contractor and
other contractors, involved in providing other services in the lift shaft.
23.0 PROVISION BY CLIENT
23.1 The following work shall be excluded from scope of work of elevator contractor.
a) A hoist-way, properly framed, enclosed and plastered and painted including a pit of proper depth with
drains and water proofing, if required.
b) Vertical iron ladder for access to the pit.
C) Properly lighted ventilated shaft, including floors, access door, ladders, trap doors and guards as required.
d) Pouring and finishing of shaft floor after the machine and relevant equipment have been set in place by
elevator contractor.
e) Guard for hoist way & temporary barricades at hoist way openings.
f) Main electric supply to machine room including wiring up to the elevator machine controllers, lights in the
midpoint of hoist way, light with switch in the pit & hoist way etc. as required.
g) Electric power for erection, testing & commissioning of the elevator plant.
h) Architraves & door frames at all hoist way entrances.
24.0 TERMINATION OF CONTRACT
24.1 Owners/Employers may terminate the contract if the contractor commits any act of insolvency or shall be
adjudged insolvent or if he suffers any payment under this contractor be attached by or on behalf of any
creditors of the contractor or has abandoned the contract or has filed to commence the work or had without
RFP for Elevator Works at Electropreneur Park, UDSC 17
any lawful excuse under the conditions suspended the progress of work for 14 days after receiving
instructions from the employer to proceed with the work or has failed to proceed with work with the
diligence & failed persistently to observe & perform all or any of the acts required for performance of the
contract.
25.0 ELECTRICITY FOR ERECTION
It shall be the elevator contractor's responsibility to arrange for electricity required for erection work. He
shall also arrange to pay for the electricity consumed by him for the erection work, directly to the electricity
supplier.
26.0 24 HOUR CALL BACK SERVICE
The contractor shall be able to provide to the owner 24 hours emergency call back service at installation
site.
27. The proposed work covered under this tender during its progress can also be inspected by the Chief
Technical Examiner or Technical Examiner or by an Officer of Vigilance cell of the authority on behalf of
Engineer-in-charge/ Architect.
28. AGREEMENT:
The successful tenderer will be required to enter into an agreement, draft of which is attached and shall
pay for all stamps and legal expenses incidental thereto.
29. VALIDITY:
The tenderer shall note that his tender shall remain open for consideration for a period of 90 days from the
date of opening of tender.
30. LAW GOVERNING CONTRACT:
This shall be governed by Indian Law for the time being enforce. All dispute arising out of this work shall be
subject to jurisdiction of Delhi Courts only.
31. EARNEST MONEY
The tenderers will have to deposit an amount of Rs. 40,000/- (Rupees Forty Thousand only) in the form of
DD in favor of Electropreneur Park, University of Delhi South Campus New Delhi at the time of submission
of tender as an earnest money.
32. PAYMENT TERMS
Against supply of Material at site - 50%
Erection - 10%
Commission - 10%
End of installation & satisfactory performance &
Statuary approval – 20%
On Expiry of warranty period & AMC - 10%
RFP for Elevator Works at Electropreneur Park, UDSC 18
On successful expiry of the defect liability period and the contractor having removed all the defects from
the work to the satisfaction of employer, the Architect shall on demand from the contractor, recommend
to the Employer to refund performance bank guarantee provided that there is no other demand
outstanding against the contractor. The contractor shall also have to give in writing while applying for
refund that he has no claim against the employer in connection with the work completed by him, failing
Bank Guarantee may be withheld.
33. ARBITRATION SETTLEMENT OF DISPUTES
ARBITRATION:
33.1 All disputes or differences of any kind whatsoever which shall at any time arise between the parties hereto touching or concerning the works or the execution or maintenance thereof of this contract or the construction remaining operation or effect thereof or to the rights or liabilities of the parties or arising out of or in relation foreclosure or breach of the contract (other than those in respect of which the decision of any person is by the contract expressed to be final and binding) shall after written notice by either party to the contract to the other of them and to the Appointing Authority who shall be appointed for this purpose by the Employer be referred for adjudication to a sole arbitrator to be appointed as hereinafter provided.
33.2 For the purpose of appointing the sole arbitrator referred to above, the Appointing Authority will send within thirty days of receipt by him of the written notice aforesaid to the contractor a panel of three names of persons who shall be presently unconnected with the organization for which the work is executed.
33.3 The contractor shall on receipt by him of the names as aforesaid, select any one of the persons named to be appointed as a sole arbitrator and communicate his name to the Appointing Authority within thirty days of receipt by him of the names. The Appointing Authority shall thereupon without any delay appoint the said person as the sole arbitrator. If the contractor fails to communicate such selection as provided above within the period specified, the Appointing Authority shall make the selection and appoint the selected person as the sole arbitrator.
33.4 If the Appointing Authority fails to send to the contractor the panel of three names as aforesaid within the period specified, the contractor shall send to the Appointing Authority a panel of three names of persons who shall all be unconnected with either party. The appointing Authority shall on receipt by him of the names as aforesaid select any one of the persons named & appoint him as the sole arbitrator. If the Appointing Authority fails to select the person and appoint him as the sole arbitrator within 30 days of receipt by him of the panel and inform the contractor accordingly, the contractor shall be entitled to appoint one of the persons from the panel as the sole arbitrator and communicate his name to the Appointing Authority.
33.5 If the arbitrator so appointed is unable or unwilling to act or resign his appointment or vacates his office due to any reason whatsoever another sole arbitrator shall be appointed as aforesaid.
33.6 The work under the contract, shall however, continue during the arbitration proceedings & on payment due or payable to the contractor shall be withheld on account of such proceedings.
33.7 The arbitrator shall be deemed to have entered on the reference on the date he issued notice to both the parties fixing the date of the first hearing.
33.8 The arbitrator may from time to time with the consent of the parties, enlarge the time for making and publishing the award.
RFP for Elevator Works at Electropreneur Park, UDSC 19
33.9 The arbitrator shall give a separate award in respect of each dispute or difference referred to him. The arbitrator shall decide each dispute in accordance with the terms of the contract and give a reasoned award. The venue of arbitration shall be such place as may be fixed by the Arbitrator in his sole discretion.
33.10 The fees, if any, of the Arbitrator shall, if required to be paid before the award is made and published, be paid half and half by each of the parties. The costs of the reference and of the award including the fees, if any, of the Arbitrator who may direct to and by whom and in what manner, such costs or any part thereof shall be paid and may fix or settle the amount of costs to be so paid.
33.11 The award of the Arbitrator shall be final and binding on both the parties.
33.12 Subject to aforesaid the provisions of the Arbitration Act 1940 or any statutory modification of reenactment thereof and the rules made thereunder, and for the time being in force, shall apply to the Arbitration proceeding under this clause.
RFP for Elevator Works at Electropreneur Park, UDSC 20
SECTION – 4
ARTICLES OF AGREEMENT
ARTICLES OF AGREEMENT made this .......................................................... day of
................................................. between Electropreneur Park, University of Delhi, IIC Lab, DUWA Building,
Near Cafeteria a company incorporated under the Act, 1955 and having its Local Head Office at New Delhi,
160 017, (hereinafter referred to as the “EMPLOYER” which expression shall include its successor or
successors and assigns) of the ONE PART.
AND
M/s.................................................................................................................................................................
having its registered office at .............................................................................(hereinafter referred to as
the ‘CONTRACTOR’ of the OTHER PART,
WHEREAS the Employer is desirous of executing Elevator Works for EP, University of Delhi, South
Campus, Library Building, Benito Juarez Road, New Delhi 110021 as stated to the General
Conditions (hereinafter called the WORK).
AND WHEREAS the Employer in order to effectively carry out the said work at University of Delhi, South Campus, Library Building, Benito Juarez Road, New Delhi 110021, engaged. M/s. PLANNERS GROUP, SCO-4, Sector -17-E, Chandigarh 160 017 hereinafter referred to as (the ARCHITECT/CONSULTANT) to prepare plans, drawings and specifications describing the to be executed for Employer, to call for tenders from contractors for the job, to open tenders received at the office of the employer, to scrutinize and recommend to the Employer the name or names of the Contractor or Contractors from whom the tenders were received.
AND WHEREAS the Employer has caused the plans, drawings as per list attached. Specifications, priced schedule of quantities for the Work as per instruction to tenderers, general conditions of contract and special conditions of contract prepared with the assistance of the said Architect/Consultant, subject to which the offer of the Contractor shall be accepted.
AND WHEREAS the tender of the Contractor for Elevator WORKS of the said work at New Delhi has been approved by the Employer.
RFP for Elevator Works at Electropreneur Park, UDSC 21
AND WHEREAS the contractor has deposited with the owner Rs. _____________________
(Rupees ____________________ only) (PBG of 5%) as security deposit for the due performance
of the Agreement.
AND WHEREAS work order has been released to the Contractor.
AND WHEREAS the relevant drawings inclusive of the specifications. priced schedule of quantities,
instruction to tenderer, general conditions of contract and Special Conditions and letters exchanged by &
between the parties from submission of tender up to acceptance including letter of order (hereinafter
collectively referred to as "the said conditions') have been signed by the parties hereto and the contractor
has agreed to execute upon and subject to the said conditions.
NOW IT IS HEREBY AGREED AS FOLLOWS:
1: In consideration of the payments to be made to the Contractor as hereinafter provided the
Contractor shall upon and subject to the said conditions execute and complete the work as
described in the said specifications and the said priced Schedule of Quantities.
2: The Employer will pay to the Contractor the sum of Rs.................................. (Rupees
…………....................................................................................................) (Hereinafter called the
‘Contract Sum’) or such other sum as shall become payable hereunder at the times and in the
manner specified in the said conditions.
3: The terms 'Architect/Consultant' in the said conditions shall mean the said M/s. PLANNERS
GROUP and in the event of the said Architect/Consultant ceasing to be the Architect/Consultant
for the purpose of this contract such other person or persons as shall be nominated for the
purpose by the Employer, provided always that no person subsequently appointed to be the
Architect/Consultant under this contract shall be entitled to disregard or over rule any decision
or approval expressed in writing by the outgoing Architect/Consultant for the time being if the
same had been done under instruction from the Employer.
4: The agreement and documents mentioned above shall form the basis of this contract and all
disputes to be decided in the manner prescribed in the conditions attached hereto.
RFP for Elevator Works at Electropreneur Park, UDSC 22
5: The said contract comprises Elevator Works as mentioned above and in the tender documents
and all subsidiary work connected therewith within the same site as may be ordered to be done
from time to time by the said Employer through the Architect/Consultant or other Archi-
tect/Consultants the case may be even though the said work may not be shown on the drawings
or described in the said specifications or the priced schedule of quantities.
6: Notwithstanding what is stated herein before or hereinafter or in the instruction to the tenderer,
general conditions of contract, special conditions, the Employer through the Architect/ Consultant
reserves to himself the right to alter the nature of the work and of adding to or, omitting any
items of work from the contract or of having portions of the same carried out departmentally or
otherwise and such alterations or variations shall be carried out without prejudice to this contract.
7. The above conditions shall be read and be treated as forming part of this agreement and the parties
hereto will respectively be bound hereby and to abide by themselves to the conditions and
stipulations and perform the same on their parts to be respectively observed and preferred.
8: Any dispute arising under this agreement between the parties hereto shall be referred for
adjudication to a sole arbitrator in New Delhi in the manner and in terms of the provisions laid
down in Clause 45 of the General Conditions of Contract. The award of the arbitrator shall be final
and binding on both the parties.
9. The time allowed for the completion of the work is 16 weeks from the 7th day after the date of
written order to commence work. The time shall be considered the essence of contract. Liquidated
damages @1% per week of contract value subject to maximum of 10%.
AS WITNESS our hand this day of
SIGNED by the said Employer in the presence of
SIGNED by the said Contractor in the presence of
RFP for Elevator Works at Electropreneur Park, UDSC 23
SECTION -5
TECHNICAL SPECIFICATIONS
01 Passenger Elevator:
Passenger elevators shall include all elements conforming to specifications or as amended herein. Elevators
covered by this specification shall be provided, installed, tested, commissioned, certified, approved by all
agencies having jurisdiction including insurance carriers. Each agency having jurisdiction shall certify each
elevator fit for public use.
02 Service Elevators:
Elevator contractor shall provide short duration emergency lighting in each car which shall be supported by
central or local dry cell rechargeable battery and necessary relays.
03 Hoisting Machine
Hoisting machines for passenger elevators will normally be of the gearless traction with Machine room less
type based on the principle of A.C. Variable Voltage Variable Frequency. The unit should consist of an A.C.
Motor, reduction gear and traction sheave operating at 1.0m/sec.
Hoist Motor The hoist motor shall be a single speed, 3 phase A.C. motor of reversible type and designed for elevator service, repeated starts, high starting Torque & low starting current characteristics & within the limits acceptable to the electric supply Co. and E. 1. rates. All cater winding put be heaviest insulated adequately in pre-generated for tropical climate and mechanically strength. (Any structural steel required for installation in existing lift well will be provided by the Agency)
04 Construction:
The A.C. motor, reduction gear, Traction sheave and brake shall form a single compact unit. The stator core
design should be so to give efficient commutation in the most demanding operating conditions and
extended service life with minimum maintenance.
Substantially dimensioned roller bearings with good maintenance access should be provided for longer
bearing life and trouble free operation.
Bed plates with anti-vibration mountings should also be included for quiet and vibration free operation.
Motor windings:
The normal insulation class of the motor is 'F' Thermal protection of the motor should be provided by four
thermistors embedded in the stator of the winding. The motor should be cooled by an externally mounted
fan.
Brake: The D.C. operated brake should have two independent brake arms and should be capable of holding
a car stationery even at 100 percent over load.
05 Emergency Cranking
The hoisting machines shall be provided with a set of special tools including a hand crank or its equal to
allow release of hoist brake and provide for manual movement of the car in case of emergency. The elevator
system supplier shall qualify his bid with respect to manual cracking.
RFP for Elevator Works at Electropreneur Park, UDSC 24
06 Automatic Self Leveling
The elevator shall be provided with automatic self-leveling feature that shall bring the elevator car level to
with ± 3mm of the landing floor regardless of load or direction of travel. The automatic self-leveling feature
shall correct for over travel and rope stretch.
07 Car Top Station
A car top operating station comprised of Key operated switch and constant pressure up/down buttons shall
be provided on each elevator. Car shall respond to up/down command at inspection speed. The elevator
contractor shall provide with CFL type fixtures.
08 Sheaves
Sheaves shall be machined, balanced and shall maintain cable sheave ratio well within requirements.
Lubrication points shall be extended to a location that is easily accessible.
09 Car frame and Safety
A car frame fabricated from cold rolled formed steel numbers shall be provided with adequate bracing to
support the platform and car enclosures. The car safety shall be integral with car frame, or shall be mounted
on the bottom members of the car frame, and shall be of the flexible guide clamp type designed to stop
and hold a fully loaded car which exceeds descending safeties shall conform to local codes.
10 Speed Governor
Speed Governor operating the safety gear in case of over speeding of car in the down ward direction.
11 Wiring
All wiring and electrical intern connections shall comply with governing codes. Insulated wiring shall have
frame retardant and moisture proof outer covering, and shall be run in conduit, tubing or approved
electrical raceways. Travelling cables shall be flexible and suspended to relieve strain on individual
conductors. A minimum of 10% spare conductors shall be provided in travelling cable.
12 Pit Switch
An emergency stop switch shall be located in the pit accessible from the pit access door which when
operated shall stop the car regardless of position in the hoistway.
13 Buffers
Buffer shall be installed in the pit as a means for slowing and stopping the car and counter weight at the
bottom limits of travel, in compliance with local code.
14 Guide Rails
Steel elevator guide shall be installed to guide the car and counter weight, erected plumb and securely
fastened to the building structure, filled and field to ensure smooth joints.
15 Guide
Rubber encased oil spring tension adjusted roller guides shall be provided for passenger elevators with
speed of 1.00 MPS or greater, mounted on top and bottom of the car frame, and top and bottom of the
counter weight frame to engage their respective guide rails.
16 Travelling Cable
RFP for Elevator Works at Electropreneur Park, UDSC 25
Travelling cable shall be flat & flexible.
17 Inter locks
Hoist way shall be provided with electro mechanical locks.
18 Counter Weight
A structure steel frame with cast iron filler weights shall be furnished to provide proper counter balance for
smooth and economical operation.
19 Counterweight Guard
A metal counterweight guard shall be finished and installed at the bottom of the hoistway, and shall wrap
around counterweight rails for a height of no less than 1.80m in order to protect accidental contact.
20 Ropes
The hoist ropes shall be traction steel of size, construction and number of insure proper, operation of the
elevator and give satisfactory and safety assurance. Governor ropes shall be of steel. All ropes shall consist
of at least eight strands wound about a hemp core centre. All ropes shall conform to IS 2365-1963.
21 Acceleration /Deceleration
Shall be linear and smooth. Stops shall be without cable oscillations.
22 Sound Reduction
The contractor shall provide necessary sound insulation material, preferably neoprene pads of adequate
density to effectively absorb and isolate the machine from the beams and flooring.
23 Emergency Car Lighting
Provision shall be made in the car operation station. Necessary wires shall be included in the car travelling
cable. Communications equipment and connections to the building service system shall be furnished and
installed by others.
24 Elevator Movement
The traffic display should also include car position and car direction, car call registered, call allocations.
25 Hall Buttons
For elevators these shall be provided at each landing. A feather touch luminous button shall be provided at
top most and ground floor and basement landing, two feather touch luminous on a single plate shall be
provided at each intermediate floor. When a hall call is registered by momentary pressure on a landing
button, that button shall become illuminated and remain illuminated until the call is answered.
26 Call Button
Call button for elevator shall be as per Architect selection. Selection for service elevator shall be as per
manufacturer's standard selection. Emergency operation shall return the elevator's to a designated floor,
most commonly, the Lobby, by means of a signal from the automatic fire alarm system by and key operated
switch in the lobby panel.
RFP for Elevator Works at Electropreneur Park, UDSC 26
Car traveling toward lobby shall express to lobby ignoring all car and hall calls. Car parked on intermediate
floors shall close their doors and express to lobby. Car parked at lobby shall open their doors ignoring car
and hall calls. All hall and car buttons shall extinguish and shall accept no further hall or car registration.
27 Fireman's Switch:
When the fireman switch is turned on, the lift shall rush to the particular pre-determined floor. The lift shall
also provide the necessary toggle switch facility required.
28 Inspection Operation — All Elevators
A switch shall be provided in the car to permit operation of the elevator from top of the car for inspection
purposes, with car and hall buttons inoperative. Car shall travel at inspection speed not exceeding 0.5 m/sec
29 Car Operating Panel
The car operating panel shall contain a bank of feather touch luminous buttons marked to correspond to
the landing serviced. It shall include a series of push buttons corresponding to the floors served, along with
an emergency stop and switches required. Operating panel shall incorporate the following floor buttons,
door, open/close, emergency stop/alarm, up/down in manual mode, man/auto key switch and fire
operation.
a) Auto/attendant/inspection key operated switch.
b) Up/down button.
C) Light and fan switches.
On sounding of general fire alarm, the elevator shall if in motion, express to the ground floor. If stopped,
the elevator shall open its doors and remain there until reset. Emergency phone shall be provided, installed
in integral cabinet and connected to the PABX by the low tension contractor.
30 Elevator Cab:
Car shall be detailed by the Architect or interior designer. The cab manufacturer shall make provisions for
ventilation inlets at the bottom of the cab (concealed from passenger's view) and blowers at ceiling,
emergency hatch with electrical interlock and anchors for hand rails, or per local code.
The car sill shall be flush with finish floor. Sill to floor space shall not exceed 25mm.
a) Doors shall be arranged to remain open for a time period sufficient to meet handicapped requirements
(Optional)
b) The time interval for which the elevator doors remain open when a car stops at a landing shall be
independently adjustable for response to car calls and response to hall calls.
c) An approved positive interlock shall be provided for each hoist way entrance which shall prevent operation
of the elevator unless all doors for that elevator are secured and shall maintain the doors in their closed
position while the elevator is away from the landing. Emergency access to the hoist way as required by
governing codes shall be provided.
RFP for Elevator Works at Electropreneur Park, UDSC 27
SECTION-6
ELEVATOR SPECIFICATION
TYPE - A
No. of Lifts 1
Type and capacity Machine room less passenger Elevator, Rated load 680 kg, 10 persons
Stops 3, [FLOOR DESIGNATION G,1,3]
Travel Height ~13.5m
Access Sides 2
Speed 1.0 meter per second
Type of Drive A.C. variable voltage variable frequency with 16 - bit microprocessor
Location of Machine room
Permanent magnet synchronous/asynchronous electric traction gearless motor to be hoisted on guide rail within the elevator hoist way.
Serving 3 floors3 stops 3 levels 2 openings (on the opposite side)
Hoist way available 1800mm(wide) x 2000mm (deep) clear dimensions
Car size 1100mm (wide) x 1300mm (deep)x2300 (high)
car enclosure Constructed out of hairline stainless stainless steel 304 grade finish.
Car entrance Center opening automatic doors in hairline stainless steel finish 304 grade with a clear opening of 800mm(wide) x 2100mm (high)
Hoist way entrance Centre Opening Automatic Doors in hairline Stainless Steel Finish 304 grade with provision of emergency Key Opening at all Landings with a clear Opening of 800 MM (wide) x 2100MM (high)
Door operation Automatic D.C. Door Operation with adjustable Door Opening and Closing timings
Control Simplex Full Collective with or without attendant.
Operation Automatic D.C. Door Operation with adjustable Door Opening and Closing timings
RFID RFID based elevator controller
RFP for Elevator Works at Electropreneur Park, UDSC 28
Power supply 415 Volts, 3 Phase, 50 Hertz Alternating Current
Fan Concealed Cross Flow Blowers for Mid Air Flow
Flooring Granite Flooring
Lighting Diffused LED Lighting in car
Indicators Dot Matrix Digital Direction and Position Indicators in both car and at all landings.
other features * Battery Operated emergency Light with Rechargeable Battery
* Battery Operated Emergency Alarm with Rechargeable Battery
* Adjustable Guide Shoes
* Micro Movement L.E.D. based Buttons
* Hands Free Press and Speak Intercom with EPABX for three way communications
* Load Weighing device with overload bypass feature
* Steel items such as Door Frames Sill Angles, Fascia Plates, Spring Buffers.
* Buttons-Call Registration-Red
* Braille Fixtures
* Full Height infrared Safety Curtain.
* System Capable of withstanding + 10% to - 10% Variation in Supply Voltage Fluctuations.
* Lift Announcement System
* Three Side Hand Rails
* Car Platform constructed out of a Cold Rolled Grain Oriented Formed Sheet of Steel
* 2 Phase Device Fire Man Drive
* Fire Man Switch at Main Lobby
* Heavy Duty Door Motor Fire Rating for Two hour as per IS 3809 : 1970
* Car False Ceiling in Stainless Steel in Plain Finish
Pit Ladder
* Motor Compatible for 180 Starts Per Hour
* Automatic Rescue Device to automatically bring the elevator to a landing in case of power failure.
All Signals Fixtures will be in Stainless Steel Face Plates.
RFP for Elevator Works at Electropreneur Park, UDSC 30
SECTION -7 (VOLUME II)
(TO BE PUT IN SEPARATE SEALED ENVELOPE)
PRICE BID INSTALLATION OF TEN PASSENGER ELEVATOR AT I.I.C. BUILDING FOR Electropreneur Park University
of Delhi, South Campus, Library Building, Benito Juarez Road, New Delhi 110021
S.No Item of Work Qty. Amount
(To be quoted by the
contractor)
PART-A:
1 i) Supply, design, installation, testing and commissioning of TEN passenger
(without machine room) Elevator as per the terms and conditions. Technical
specifications and dimensional parameters enclosed in Volume 1 of the
Tender Document including obtaining statuary approval.
(Any structural steel required for installation in existing lift well will be
provided by the Agency)
Technical specifications: as per Elevator Specification TYPE - A
1 No.
ii) Taxes as applicable
TOTAL (Part-A) (includes (i) and (ii))
PART-B:
2 i) Comprehensive parts replacement annual maintenance charges for the
above elevator for a period of ONE year including supply of all spares as
required, after the defects liabilities period of 1 year. (As per clause 20 –
section 3 – General Conditions, first year is already covered under FOC basis,
so we require AMC for next 1 year)
ii) Taxes as applicable
TOTAL (Part B) (includes (i) and (ii))
SUMMARY:
Total of part A+B
GRAND TOTAL
Grand Total (in words) - Note:
1. Evaluation will be done on Grand Total. 2. While evaluation, in case of similar bid value, the contract will be awarded to the bidder
having highest turnover in last 3 years.