MONTHLY PROGRESS REPORT - pdf.usaid.govpdf.usaid.gov/pdf_docs/PA00N43Q.pdf · TRAFFIC CONTROL...
Transcript of MONTHLY PROGRESS REPORT - pdf.usaid.govpdf.usaid.gov/pdf_docs/PA00N43Q.pdf · TRAFFIC CONTROL...
-
Prepared by: The Morganti Group, Inc.
September, 2017
Contract No.: AID-294-I-00-12-00002
Task Order No.: AID-294-TO-15-00008
Gaza-Construction of Reservoirs and Pumping Facilities Package I
MONTHLY PROGRESS REPORT
-
TO-15-00008 Construction Monthly Progress Report September 2017
Construction Monthly Progress Report
Reporting Period: September 1, 2017 September 30, 2017
Contractor: The Morganti Group, Inc.
DISCLAIMER "This report is made possible by the support of the American People through the United States Agency for International Development (USAID.) The contents of this report are the sole responsibility of The Morganti Group, Inc. and do not necessarily reflect the views of USAID or the United States Government."
Contract No.: AID-294-I-00-12-00002
Task Order No.: AID-294-TO-15-00008
Gaza - Construction of Reservoirs and Pumping Facilities Package I
-
TO-15-00008 Construction Monthly Progress Report September 2017
Table of Contents
ABBREVIATION ................................................................................................................................................... 1
1. TASK ORDER OVERVIEW ........................................................................................................................... 2
2. SCOPE OF WORK: ......................................................................................................................................... 3
3. SAFETY .......................................................................................................................................................... 9
4. ENVIRONMENTAL COMPLIANCE .......................................................................................................... 9
5. TRAFFIC CONTROL MEASURES ............................................................................................................ 10
6. RISK MANAGEMENT & MITIGATION MEASURES ............................................................................. 10
7. COMMUNITY OUTREACH ....................................................................................................................... 10
8. GENDER ACTION PLAN .......................................................................................................................... 10
9. COORDINATION AND MEETINGS . ....................................................................................................... 11
10. SITE VISITORS ............................................................................................................................................ 11
11. PROGRESS AND SCHEDULING .............................................................................................................. 11
12. INDICATORS............................................................................................................................................... 15
13. WORKING / NON WORKING DAYS .................................................................................................... 15
14. MATERIAL & EQUIPMENT DELIVERED TO SITE ............................................................................. 16
15. SITE MEMOS ............................................................................................................................................... 16
16. INSPECTION REQUESTS ......................................................................................................................... 17
17. QUALITY CONTROL ................................................................................................................................. 18
18. TESTS RESULTS: ........................................................................................................................................ 18
19. SUBMITTALS . ............................................................................................................................................. 19
20. REQUEST FOR INFORMATION . ............................................................................................................ 19
21. TRANSMITTALS ........................................................................................................................................ 19
22. TASK ORDER GENERAL STATISTICS . .................................................................................................. 31
23. PAYMENTS . ............................................................................................................................................... 31
24. VARIATION ORDERS ............................................................................................................................... 33
25. VARIATION ORDER REQUESTS . ........................................................................................................... 33
26. OBSTACLES AND CHALLENGES . .......................................................................................................... 38
27. PROGRESS PHOTOS . ................................................................................................................................ 39
-
TO-15-00008 Construction Monthly Progress Report September 2017
ANNEXES ............................................................................................................................................................ 59
ANNEX A - MATERIALS- EQUIPMENT RECEIVING LOG . .................................................................................... 60 ANNEX B UPDATED SCHEDULE ...................................................................................................................... 63 ANNEX C - PROGRESS S - CURVE . ..................................................................................................................... 103 ANNEX D - ONE MONTH LOOK AHEAD . .......................................................................................................... 105 ANNEX E - INSPECTION REQUEST LOG ............................................................................................................ 112 ANNEX F - SUBMITTAL LOG ............................................................................................................................. 278 ANNEX G REQUEST FOR INFORMATION LOG . ............................................................................................... 337 ANNEX H - GEO-MIS DATA . ............................................................................................................................ 349 ANNEX I - RISK REGISTER LOG . ....................................................................................................................... 354 ANNEX J SITE MEMOS LOG (ENGINEER TO CONTRACTOR) .......................................................................... 357 ANNEX K SITE MEMOS LOG (CONTRACTOR TO ENGINEER) ......................................................................... 366 ANNEX L QC SUBMITTALS LOG...................................................................................................................... 371 ANNEX M ACCIDENT INVESTIGATION REPORT LOG . .................................................................................... 427 ANNEX N NONE COMPLIANCE REPORT LOG ...................................................................................... 429
-
TO-15-00008 Construction Monthly Progress Report September 2017
Abbreviation
ACOTR Alternate Contracting Officer Technical Representative CD Calendar Day
CE Chief Engineer
CEng Contracts Engineer
CMC Construction Management Contractor
CMWU SAK SAK
Coastal Municipalities Water Utility Saqqa and Khoudary General Contracting Co. Ltd.CO Contracting Officer
COB Close of Business
COP Chief of Party
COR Contracting Officer Representative
CQC Contractor Quality Control
CQCP Contractor Quality Control Program
CRMP Construction Risk Management Plan
CV Curriculum Vita
DCL District Civil Liaison
FO Field Order
HR High Risk
HSE Health & Safety Engineer
IQC Indefinite Quantities Contract
LR Low Risk
M Moderate Risk
MH Medium-High Risk
ML Medium-Low Risk
MRR Material Receiving Report
NCN Non Compliance Notice
NUC Notice of Unsafe Conditions
O&M Operation and Maintenance
OSHA Occupational Safety and Health Act (both Federal and State)
PA Palestinian Authority
PCO Project Control Officer
PIO Public Information Officer
PM Project Manager
PSU Program Support Unit
PWA Palestinian Water Authority
QA Quality Assurance
QC Quality Control RE Resident Engineers
RFI Request for Information
RFTOP Request for Task Order Proposal
SAK Saqqa and Khoudary
SC Sup-Contractor
SOP Standard Operating Procedure
TMGI The Morganti group Inc.
TO Task Order TOL Task Order Leader
TOM Task Order Manager
USAID United States Agency for International Development
VO Variation Order
VOR Variation Order Request
WBG West Bank Gaza
WBWD West Bank Water Department
Page 1 of 430
https://www.facebook.com/SAKCONTRACTING/?fref=nf
-
TO-15-00008 Construction Monthly Progress Report September 2017
1. Task Order Overview 1.1. Description of the Task Order:
Infrastructure in Gaza suffers from years of neglect and lack of investment. The USAID Mission
Infrastructure Needs Program II (INP II) focuses on the rehabilitation and construction of roads,
schools, and water & wastewater projects. The USAID objective is to help the Palestinian economy
by improving Palestinians access to basic infrastructure and services.
The objective of this Task Order is to construct two new water reservoirs, two new booster pump
stations, and their associated supply and distribution pipelines, in order to improve distribution and
increase access to clean drinking water to the population of Gaza, the first is Al Atatrah area located
north of the Gaza Strip, the project at Al Atatrah area includes the construction of a 3800m3 ground
reservoir that will be constructed in place of Al Atatrah abandoned elevated water tank deteriorated
to be demolished, and also includes the supply and installation of a Skid Mounted Booster Pump
Station and the supply and installation of a new Booster Pump Station connected to a new UPVC
distribution network with an approximate total length of 6.3 KLM varying in diameter. The second
area is Nuseirat, located in the heart of the Gaza Strip, the Nuseirat project includes the construction
of a 3800m3 ground reservoir and a new Booster Pump Station connected to a new UPVC distribution
network with an approximate total length of 5.2 KLM varying in diameter.
1.2. Task Order Information
Project Name: Gaza - Construction of Reservoirs and Pumping Facilities Package I
Indefinite Quantity Contract No. AID-294-I-00-12-00002
Task Order No. AID-294-TO-15-00008
Award Date September 21, 2015
NTP Date October 26, 2015
Contract Value USD 10,275,276.16
Modified Contact Value USD 10,425,276.16
BOQ Line Item Amount USD 9,527,437.56
Modified BOQ Line Item Amount USD 10,274,916.32
Day Work Amount USD 747,838.60
Modified Day Work Amount USD 150,359.84
Start Date of Construction Activity January 21, 2016
Contractual Period of Performance: 610 Calendar Days
Modified Contractual Period of Per-formance:
748 Calendar Days
Contractual End Date: June 26, 2017
Modified Contractual End Date: November 11, 2017
Project Location (Area and governorate)
The project is located in Gaza Strip (Al Atatrah & Nuseirat).
1.3. Task Order Key Personnel: No. Name Position
1 Samir Arafat Task Order Manager
2 Swilam Mosalem Quality Control Manager
3 Salim Abu Rafea' Safety and Environmental Compliance Officer
4 Mohye Naeim Project Control Engineer
5 Osama Abo Moussa Surveyor
Page 2 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
2. Scope of Work: 2.1. Project 1: Construction of Al Atatrah Reservoir and Pumping Facilities
2.1.1. Project General Information Project Name: Al Atatrah Reservoir and Pumping Facilities
Indefinite Quantity Contract No AID-294-I-00-12-00002
Task Order No AID-294-TO-15-00008
Award Date September 21, 2015
NTP Date October 26, 2015
Contract Value USD 4,698,583.73
Modified Contract Value USD 5,009,628.38
Start Date of Construction Activity January 21, 2016
Contractual Period of Performance: 610 Calendar Days
Modified Period of Performance 748 Calendar Days
Contractual End Date: June 26, 2017
Modified Contractual End Date: November 11, 2017
Project Location (Area and governorate)
Bait Lahia - North Governorate.
2.1.2. Vantage photo:
Page 3 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
2.1.3. Project Key Map
2.1.4. Project Description This project includes constructing a new water reservoir and booster pump station along with supply and distribution piping. Project elements consist of the following: 2.1.5. Statement of Work (SOW) The project consists of the following constructions
A. Construction of Facilities 1. Al Atatrah Reservoir Construct new 3,800 m3 2. Al Atatrah Booster Pump Station Construct new. 3. Al Atatrah Skid Mounted Booster Pump Station Furnish & Install new. B. Construction of New Supply & Distribution Pipelines 1. Supply Line TS1 (280 mm x 0.386 km, 225 mm x 0.355 km and 160 mm x 1 km) 2. Supply Line TS2 (225 mm x 0.536 km) 3. Supply Line TS3 & TS2a (280 mm x 1.23 km and 225 mm x 0.747 km) 4. Distribution Line TD1 (355 mm x 0.156 km and 225 mm x 0.762 km) 5. Distribution Line TD2 (315 mm x 1.020 km)
Al Atatrah Reservoir and Pumping Facilities
Page 4 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
2.1.6. Project Dashboard Status Contract Elapsed Time as of September 30, 2017 [%] 94.39 % *
Planned Percentage of Completion through September 30, 2017 [%] 100 % **
Actual Percentage of Completion through September 30, 2017 [%] 91.97 % **
Float (Days) -140 ***
* According to the approved Extension of Time variation order ** Actual and Planned percentages of work progress based on approved revised CPM schedule Novem-
ber 30, 2016. *** The indicated total float is based on the updated approved CPM schedule November 30, 2016, this update reflects the actual project status up to September 30, 2017. The revised CPM schedule will be prepared and submitted for approval to reflect revised completion date " November 11, 2017" per contract modification No. 3.
2.1.6.1. Progress Chart (September -2017)
2.1.6.2. Time Elapsed (September - 2017)
Remainig Construction Period
5.61%
Contract Elapsed Time
94.39%
Time Elapsed Up to September 30, 2017
Remaining Construction Period Contract Elapsed Time
Planned % of Completion Actual % of Completion
100.00%
91.97%
Project 1 ATA Progress Status %
Page 5 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
2.2. Project 2: Construction of Nuseirat Reservoir and Pumping Facilities 2.2.1. Project 2 General Information
Project Name: Nuseirat Reservoir and Pumping Facilities
Indefinite Quantity Contract No AID-294-I-00-12-00002
Task Order No AID-294-TO-15-00008
Award Date September 21, 2015
NTP Date October 26, 2015
Contract Value USD 4,828,853.83
Modified Contract Value USD 5,265,287.94
Start Date of Construction Activity January 21, 2016
Contractual Period of Performance: 610 Calendar Days
Modified Period of Performance 748 Calendar Days
Contractual End Date: June 26, 2017
Modified Contractual End Date: November 11, 2017
Project Location (Area and governorate) Nuseirat - Middle Governorate.
2.2.2. Vantage photo:
Page 6 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
2.2.3. Project 2 Key Map
2.2.4. Project Description This project includes constructing a new water reservoir and booster pump station along with supply and distribution piping. Project elements consist of the following:
2.2.5. Statement of Work (SOW)
A. Construction of Facilities 1. Nuseirat Reservoir Construct new 3,800 m3 2. Nuseirat Booster Pump Station Construct new.
B. Construction of New Supply & Distribution Pipelines 1. Supply Line NS1 (315 mm x 1.872 km) 2. Supply Line NS2 (280 mm x 0.272 km) 3. Supply Line NS3 (110 mm x 0.133 km) 4. Distribution Line ND1 (500 mm x 0.207 km and 280 mm x 0.244 km ) 5. Distribution Line ND2 (500 mm x 0.227 km) 6. Distribution Line ND3 (355 mm x 0.551 km and 280 mm x 0.275 km) 7. Distribution Line ND4 (400 mm x 0.668 km and 315 mm x 0.659 km)
Nuseirat Reservoir and Pumping Facilities
Page 7 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
2.2.6. Project Dashboard Status Contract Elapsed Time as of September 30, 2017 [%] 94.38 % *
Planned Percentage of Completion through September 30, 2017 [%] 100 % **
Actual Percentage of Completion through September 30, 2017 [%] 90.25 % **
Float (Days) -154 ***
* The Extension of Time variation order is under process ** Actual and Planned percentages of work progress based on approved revised CPM schedule November
30, 2016. *** The indicated total float is based on the updated approved CPM schedule November 30, 2016, this update reflects the actual project status up to September 30, 2017.
The revised CPM schedule will be prepared and submitted for approval to reflect revised completion date " November 11, 2017" per contract modification No. 3.
2.2.6.1. Progress Chart (September - 2017)
2.2.6.2. Time Elapsed (September - 2017)
Planned % of Completion Actual % of Completion
100.00%
90.25%
Project 2 NUS Progress Status %
5.61%Remaining Construction
PeriodContract Elapsed
Time 94.39%
Time Elapsed Up to September 30, 2017
Remaining Construction Period Contract Elapsed Time
Page 8 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
3. Safety TMGI has submitted the updated safety Plan for the month of July, 2017 to the CMC on
September 13, 2017 for review and approval and returned back with action A on September 17,
2017. TMGI has submitted the updated safety Plan for the month of August, 2017 to the CMC
on September 14, 2017 for review and approval and returned back with action A on September
17, 2017.Safety plan for month of September 2017 will be submitted during the next month report
period.
Moreover, safety plan will be updated on monthly basis.
3.1. Safety Toolbox Meetings 3.1.1. Project 1 (ATA)
Three safety toolboxes talk with subcontractor staff and labors were conducted as shown in
the below table:
Date of Meeting
Tool Box No. Location Description
September 7, 2017 STBM-15-00008-ATA-046 ATA Reservoir yard Electrical Works (Connections between VFD & MCC & PLC)
September 10, 2017 STBM-15-00008-ATA-047 ATA Reservoir yard Working Inside Reservoir (Installation Works for Launder)
September 17, 2017 STBM-15-00008-ATA-048 ATA Reservoir yard Confined space (working inside reservoir) internal painting works
3.1.2. Project 2 (NUS) No toolbox meeting was conducted during this reporting period.
3.2. Accident Status 3.2.1. Project 1 (ATA)
No accidents were reported during this reporting period.
3.2.2. Project 2 (NUS) No accidents were reported during this reporting period.
3.3. Notice of Unsafe Condition 3.3.1. Project 1 (ATA)
Zero notice was issued during this reporting period.
3.3.2. Project 2 (NUS) Zero notice was issued during this reporting period.
4. Environmental Compliance TMGI has submitted the updated Environmental Monitoring & Mitigation Plan (EMMP) for the
months of June and July, 2017 to CMC on September 16, 2017 for review and approval and
returned back with action A on September 17, 2017.
Environmental Mitigation Plan (EMMP) update for month of August was not submitted, update
will be submitted during the next month report period.
TMGI will update the Environmental Monitoring and Mitigation Plan on monthly basis.
Page 9 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
4.1.1. Project 1 (ATA) Environmental compliance checklist for the month of July 2017 was received on August 16,
2017, TMGI work on closing it, and it will be submitted during the next reporting period.
Environmental compliance checklist for the month of August 2017 was received on Septem-
ber 26, 2017, TMGI work on closing it, and it will be submitted during the next reporting
period.
4.1.2. Project 2 (NUS) Environmental compliance checklist for the month of July 2017 was received on August 16,
2017, TMGI work on closing it, and it will be submitted during the next reporting period.
Environmental compliance checklist for the month of August 2017 was received on Septem-
ber 26, 2017, TMGI work on closing it, and it will be submitted during the next reporting
period.
5. Traffic Control Measures TMGI implemented the approved traffic plan on reservoir site according to the approved sub-
mittals and shall be updated upon condition changes.
5.1.1. Project 1 (ATA) No update on Al Atatrah pipeline traffic plan during this reporting period.
Traffic signs and barriers are installed onsite according to approved TCP.
5.1.2. Project 2 (NUS) No update on Nuseirat pipeline traffic plan during this reporting period.
Traffic signs and barriers are installed onsite according to approved TCP.
6. Risk Management & Mitigation Measures TMGI has submitted the updated Construction Risk Management Program (CRMP) for the
months of June and July to CMC on September 13, 2017 for review and approval and
returned back with action A on September 14, 2017.
Construction Risk Management Program (CRMP) update for the month of August was not
submitted, update will be submitted during the next month report period.
TMGI will update the Risk Management Program on monthly basis.
Tough restrictions on travel permits between Gaza and West Bank and borders closure are project
risks concerns (Closure and GRAMM system impede delivery of project materials).
For more information, please refer to Annex I.
7. Community Outreach 7.1.1. Project 1 (ATA)
None issued during this reporting period.
7.1.2. Project 2 (NUS) None issued during this reporting period.
8. Gender Action Plan Morganti employed one female Office manager. The Subcontractor SAK also hired a female office
engineer. Morganti provided sanitary facilities and facilitated the sites for females.
* No new employments during this reporting period.
Page 10 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
9. Coordination and Meetings
Two meetings were held during the month of September as below:
Coordination Meeting
Date Attendees Subject Description Location
September 5, 2017
BV, TMGI & SAK
Coordination Meeting No. 097
To Discuss required of startup
GAZII AL-Berkah office
September 19, 2017
USAID, BV & TMGI
Coordination Meeting No. 98
To Disscus Pending Issue BV Main Office, Ramallah
Several internal meetings were held by Morganti in the main office for safety orientation and forthe progress of construction and preparation works.
10. Site Visitors
The following table shows the site visitors during this reporting period:
Date Time Representative Representing Remarks
Project 1 (ATA)
September 20, 2017 04:30 PM Mr. Ghassan Alami TMGI Reservoir Yard
September 24, 2017 11:50 AM Mr. Peter Lister Black & Veatch Reservoir Yard
Project 2 (NUS)
September 6, 2017 11:00 AM Eng. Amran El-Kharouby USAID Reservoir Yard
September 20, 2017 03:50 PM Mr. Ghassan Alami TMGI Reservoir Yard
September 24, 2017 03:00 PM Mr. Peter Lister Black & Veatch Reservoir Yard
September 24, 2017 03:00 PM Mr. Ghassan Alami TMGI Reservoir Yard
11. Progress and Scheduling
The Construction phase started on January 21, 2016, preconstruction submittals were closed. Fur-thermore, Materials and Shop drawings submittals are ongoing. TMGI has submitted the Updated CPM Construction Schedule August 31, 2017 Rev. A on Sep-tember 13, 2017 and returned back with action B on September 20, 2017. Furthermore, Materials, Shop drawings and as built drawing submittals are ongoing. TMGI will update the CPM Schedule on monthly basis For more details, please refer to Annex B
11.1. Activities During This Reporting Period 11.1.1. Project 1 (ATA)
11.1.1.1. Reservoir Yard 11.1.1.1.1. Continue preparation and submit the construction submittals. 11.1.1.1.2. Continue backfilling works around the facilities buildings for leveling the
site. 11.1.1.1.3. Applying the external paint coat for the reservoir walls. 11.1.1.1.4. Preparing, welding and installing the stainless-steel launder for the reser-
voir
11.1.1.1.5. Installing the float switch and intrusion switch. 11.1.1.1.6. Installing the fire alarm system at the facilities buildings. 11.1.1.1.7. Installing connections between the VFD, PLC & MCC.
Page 11 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
11.1.1.1.8. Continue conducting training courses 11.1.1.1.9. Installing electrical and mechanical works at the pump station and the
diesel generator
11.1.1.1.10. Preparing, welding, connecting and installing the skid mounted pump. 11.1.1.1.11. Installing the instrument devices at the booster station and the reservoir. 11.1.1.1.12. Installing the stainless-steel ladders inside the reservoir 11.1.1.1.13. Applying the internal coating at the reservoir by using the cementitious
material Nito Cote CM210
11.1.1.1.14. Continue painting works for all exposed steel pipes at booster station and the reservoir.
11.1.1.1.15. Casting concrete for base mounted elbow support. 11.1.1.1.16. Fixing/installing mechanicals works for the skid mounted pump 11.1.1.1.17. Conducting a walkthrough for road works outside the reservoir yard in
the presence of the CMWU
11.1.1.1.18. Insulation work for reservoir foundation 11.1.1.1.19. Installing the external ladder of the reservoir 11.1.1.1.20. Continue leveling & compaction of the concrete sidewalk around the
booster pump station, facilities building and reservoir.
11.1.1.1.21. Continue formwork, steel reinforcement and concrete casting for side-walk around the booster pump station, facilities building and reservoir
11.1.1.1.22. Complete installing of the booster station shed. 11.1.1.1.23. Filling the construction joint for reservoir floor by using Thioflex 600
GG
11.1.1.1.24. Continue electrical work for RIO panel at the disinfection building (ca-bles connection)
11.1.1.1.25. Coordination with the CMWU & PWA. 11.1.1.1.26. Continue procurement orders for construction requirements and ABC
material.
11.1.1.2. New construction of supply & distribution Pipelines
11.1.1.2.1. Cleaning and flushing works for the following pipelines. TS1, TS2, TS2a, TS3, TD1 & TD2
11.1.1.2.2. Performing the disinfection process for the following pipeline TS1, TS2, TS2a, TS3, TD1 & TD2
11.1.1.2.3. Performing the neutralization and cleaning after disinfection process for the following pipelines:
TS1, TS2, TS2a, TS3, TD1 & TD2
11.1.1.2.4. Performing the bacteriological tests for the following pipelines: TS1, TS2, TS2a, TS3, TD1 & TD2
11.1.1.2.5. Continue finishing works inside chambers
11.1.2. Project 2 (NUS) 11.1.2.1. Reservoir Yard
11.1.2.1.1. Continue preparation and submit the construction submittals.
Page 12 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
11.1.2.1.2. Continue installing the chlorination system at disinfection building 11.1.2.1.3. Installing, welding for all steel pipes at the booster station and the reser-
voir.
11.1.2.1.4. Pulling wires and installing the fire system at the facilities building 11.1.2.1.5. Pulling wires for instruments from VFD panel to the pump station 11.1.2.1.6. Casting concrete for the pipe support pad 11.1.2.1.7. Continue conducting training courses 11.1.2.1.8. Surface preparation for the reservoir walls and foundation from outside 11.1.2.1.9. Pulling wires and control cables at the reservoir yard. 11.1.2.1.10. Pulling the control cables and preparing connection between the discon-
nect switch and pump motors
11.1.2.1.11. Lubricating works for gate valves at the sustaining line, discharge pipe & flow meter pipe
11.1.2.1.12. Isolation works for the reservoir foundation and the buried part of the reservoir wall
11.1.2.1.13. Installing the flow meter at supply pipes. 11.1.2.1.14. Applying the external painting works at the reservoir. 11.1.2.1.15. Installing the chlorination system at the disinfection building. 11.1.2.1.16. Performing the function test for cables insulation at the pump station,
diesel generator and the facilities buildings
11.1.2.1.17. Installing connections between the VFD, PLC & MCC. 11.1.2.1.18. Continue painting works for all exposed steel pipes at booster station and
the reservoir.
11.1.2.1.19. Installing electrical and mechanical works at the pump station and the diesel generator
11.1.2.1.20. Continue leveling & compaction of the concrete sidewalk around the booster pump station, facilities building and reservoir.
11.1.2.1.21. Continue formwork, steel reinforcement and concrete casting for side-walk around the booster pump station, facilities building and reservoir
11.1.2.1.22. Continue electrical work for RIO panel at the disinfection building (ca-bles connection)
11.1.2.1.23. Installing the instrument devices at the booster station and the reservoir. 11.1.2.1.24. Coordination with the CMWU & PWA. 11.1.2.1.25. Continue procurement orders for construction requirements and ABC
material.
11.1.2.2. New construction of supply & distribution Pipelines
11.1.2.2.1. Cleaning and flushing works for the following pipelines. NS1, NS2, NS3, NS4, ND1, ND2, ND3 & ND4
11.1.2.2.2. Performing the disinfection process for the following pipeline NS1, NS2, NS3, NS4
11.1.2.2.3. Performing the neutralization and cleaning after disinfection process for the following pipelines NS1, NS2, NS3, NS4
11.1.2.2.4. Performing the bacteriological tests for the following pipelines
Page 13 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
NS1, NS2, NS3, NS4 11.1.2.2.5. Continue finishing works inside chambers
11.2. Planned Activities for Next Month 11.2.1. Project 1 (ATA)
The following are the main activities planned for next reporting period:
11.2.1.1. Reservoir Yard: 11.2.1.1.1. Continue preparation and submit the construction submittals. 11.2.1.1.2. Continue furnish and Installation of grounding system for the reservoir. 11.2.1.1.3. Start installation and fixation of the reservoir air vents and level indicator. 11.2.1.1.4. Checkered plate installation for electrical and control building and for
booster pump station
11.2.1.1.5. Start performing the string test and functional tests (start-up process) 11.2.1.1.6. Applying final painting coats for all buildings 11.2.1.1.7. Continue casting concrete for the remaining sidewalk 11.2.1.1.8. Laying the asphalt layer for the road inside the reservoir yard. 11.2.1.1.9. Performing the disinfection process inside the reservoir. 11.2.1.1.10. Coordination with the CMWU & PWA. 11.2.1.1.11. Continue procurement orders for construction requirements and ABC
material.
11.2.1.2. New construction of supply & distribution Pipelines: 11.2.1.2.1. Continue laying asphalt layer including 200mm base course layer for the
road front the reservoir and inside the reservoir yard.
11.2.2. Project 2 (NUS) 11.2.2.1. Reservoir Yard:
11.2.2.1.1. Continue preparation and submit the construction submittals. 11.2.2.1.2. Start installation and fixation of the external ladders for the reservoir 11.2.2.1.3. Start installation and fixation of the internal ladders for the reservoir. 11.2.2.1.4. Start installation and fixation of the reservoir air vents and level indicator
and SS launder. 11.2.2.1.5. Start applying the cementitious coating inside reservoir 11.2.2.1.6. Checkered plate installation for electrical and control building and for
booster pump station 11.2.2.1.7. Start installation of the booster shed 11.2.2.1.8. Continue casting concrete for the remaining sidewalk 11.2.2.1.9. Conducting the functional tests (start-up process) 11.2.2.1.10. Performing the disinfection process inside the reservoir. 11.2.2.1.11. Applying final painting coats for all buildings. 11.2.2.1.12. Coordination with the CMWU & PWA. 11.2.2.1.13. Continue procurement orders for construction requirements and ABC
material.
11.2.2.2. New construction of supply & distribution Pipelines 11.2.2.2.1. Continue the disinfection for the entire pipelines and connections for the
distribution pipeline. For more details, refer to Annex D.
Page 14 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
12. Indicators
12.1. Project 1 (ATA)
12.1.1. Indicator 1: Quantity of drinking water available as a result of USG Assistance Project 1: Al Atatrah
Total number of Beneficiaries
Male Female
No. % No. % Target 59,444 30,316 51% 29,128 49%
Actual 0 0 0% 0 0%
12.1.2. Indicator 2: Person Days of employment generated for this reporting period Project 1: Al Atatrah
Total number (Person Days)
Male Female
No. No.
Target 18,350 16,384 1,966
Actual Previously 19532.22 18961.44 570.78
Actual during this reporting period 833 805.50 27.50
Total actual 20365.22 19766.94 598.28
12.2. Project 2 (NUS) 12.2.1. Indicator 1: Quantity of drinking water available as a result of USG Assistance
Project 2: Nuseirat
Total number of Beneficiaries
Male Female
No. % No. %
Target 104,622 53,357 51% 51,265 49%
Actual 0 0 0% 0 0%
12.2.2. Indicator 2: Person Days of employment generated for this reporting period Project 2: Nuseirat
Total number (Person Days)
Male Female
No. No.
Target 18,350 16,384 1,966
Actual Previously 19425.57 18856.82 568.75
Actual during this reporting period 750.38 722.88 27.50
Total actual 20175.95 19579.70 596.25
13. Working / Non Working Days13.1. Project 1 (ATA)1 Total Period of Performance (Original) 610
2 Total Excusable delays/approved extensions 138
3 Modified Period of Performance 748
4 Modified Completion Date November 11,
2017
5 No. of Working Days during this reporting Period 22
6 Accumulated Working Days 578.155
7 Total No. of non-working days (Holidays and weekends) during this reporting Period
8
8 Accumulated non-working days (Holidays and weekends) 107.5
9 No. of non-working days (Due to Weather) during this month 0
10 Accumulated non-working days (Due to Weather) 14.875
Page 15 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
11 No. of non-working days (Due to Objections) during this month 0
12 Accumulated non-working days (Due to Objections) 5
13 No. of non-working days (Due to unstable security situation in Gaza) during this month
0
14 Accumulated non-working days (Due to unstable security situation in Gaza)
0.47
13.2. Project 2 (NUS) 1 Total Period of Performance (Original) 610
2 Total Excusable delays/approved extensions 138
3 Modified Period of Performance 748
4 Modified Completion Date November 11,
2017
5 No. of Working Days during this reporting Period 24
6 Accumulated Working Days 579.905
7 No. of non-working days (Holidays and weekends) during this month 6
8 Accumulated non-working days (Holidays and weekends) 101
9 No. of non-working days (Due to Weather) during this month 0
10 Accumulated non-working days (Due to Weather) 17.375
11 No. of non-working days (Due to Objections) during this month 0
12 Accumulated non-working days (Due to Objections) 7.5
13 No. of non-working days (Due to unstable security situation in Gaza) during this month
0
14 Accumulated non-working days (Due to unstable security situation in Gaza)
0.22
14. Material & equipment delivered to site
14.1 Project 1 (ATA) * Please refer to Annex A Material and Equipment delivered to the site.
14.2 Project 2 (NUS)* Please refer to Annex A Material and Equipment delivered to the site.
15. Site Memos
15.1. TMGI received three site memos from CMC/B&V, for GAZI project About:
Response for SM-15-00008-GAZI-C-E-032: Response for Site Memo no. SM-15-00008-GAZI-E-C-095 (Welding Works for Reservoir and Pump Station Steel Pipes without Con-tractor's CWI Presence/Inspection.)
Revised Site Layouts for the Reservoirs Sites Stainless Steel Pipe for Level Float Indicator
15.1.1. Project 1 (ATA) TMGI received one site memo from CMC/B&V for Al Atatrah project about:
Pump Station Shed at Al Atatrah Project.15.1.2. Project 2 (NUS)
TMGI received five site memos from CMC/B&V for Nuseirat project about:
Third-Party Test Reports for Nuseirat Project-Satisfactory Test Results Third-Party Test Reports for Nuseirat Project-Unsatisfactory Test Results
Page 16 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
15.2. No site memo was issued to CMC/B&V for GAZI project during this reporting period
15.2.1. Project 1 (ATA) TMGI issued three site memos to CMC/B&V for Al Atatrah project about:
Response for Site Memo no. SM-15-00008-ATA-E-C-094 Response for Site Memo no. SM-15-00008-ATA-E-C-036 Al Atatrah asphalt works
15.2.2. Project 2 (NUS) No site memo was issued to CMC/B&V for Nuseirat project during this reporting period.
16. Inspection Requests
During this reporting period, 13 inspection requests for both projects under GAZI task order
were issued:
No. IR Number REV. Description Inspection
Date Actual
Return Date 1st
Inspection
1 IR-15-00008-GAZI-130-A B Inspection request of the materials in the at-
tached MRR (VFD Panel). September 6, 2017 September 7, 2017 A
2 IR-15-00008-GAZI-131-A B Inspection request of the materials in the at-
tached MRR (Skid Mounted Booster Pump).
At SAK ware house.
September 6, 2017 September 6, 2017 C
3 IR-15-00008-GAZI-131-B A Inspection request of the materials in the at-
tached MRR (Skid Mounted Booster Pump).
At SAK ware house.
September 14, 2017 September 14, 2017 A
4 IR-15-00008-GAZI-132-A A
Inspection request of the materials in the fol-
lowing attached MRR:
CONTROL CABLE 5X2.5 (TELDOR)
CONTROL CABLE 12X2.5 (TELDOR)
FIRE CABLE 2 PAIR (TELDOR)
FIRE CABLE 4 PAIR (TELDOR)
At SAK ware house.
September 6, 2017 September 6, 2017 A
5 IR-15-00008-GAZI-133-A B Inspection request for the external ladder for
reservoir before painting. September 6, 2017 September 9, 2017 C
6 IR-15-00008-GAZI-133-B A Inspection request for the external ladder for
reservoir before painting. September 12, 2017 September 13, 2017 A
7 IR-15-00008-GAZI-134-A A Inspection request of the materials in the at-
tached MRR (PLC Panel). September 7, 2017 September 10, 2017 A
8 IR-15-00008-GAZI-135-A A
Inspection request of the materials in the fol-
lowing attached MRR:
Pipe Stainless Steel 75mm
Pipe Stainless Steel 50mm
Pipe Stainless Steel 32mm
Cable Stainless Steel 8mm
At SAK ware house.
September 11, 2017 September 12, 2017 C
9 IR-15-00008-GAZI-136-A A Inspection request of the materials in the at-
tached MRR (THIOFLEX600 GG).
At SAK ware house.
September 14, 2017 September 14, 2017 A
10 IR-15-00008-GAZI-137-A A Inspection request of the materials in the at-
tached MRR (Copper Tube).At Al Atatrah
Storage Yard.
September 19, 2017 September 20, 2017 C
Page 17 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
11 IR-15-00008-GAZI-137-B A Inspection request of the materials in the at-
tached MRR (Copper Tube).
At Al Atatrah Storage Yard.
September 24, 2017 September 27, 2017 C
12 IR-15-00008-GAZI-138-A A
Inspection request of the materials in the fol-
lowing attached MRR:
Electrical Enclosure Tekpan Type
(60x40x20) cm for flow meter
Electrical Enclosure Tekpan Type
(40x30x15) cm for Booster control valve
At SAK ware house.
September 20, 2017 September 21, 2017 A
13 IR-15-00008-GAZI-139-A A
Inspection request of the materials in the fol-
lowing attached MRR:
Soap Holder
Liquid Soap Bottle 500 ML
Towel bar
Towel ring
Mirror
At Al Atatrah Storage Yard.
September 20, 2017 September 21, 2017 A
16.1. Project 1 (ATA) During this reporting period, 63 inspection requests were issued.
16.2. Project 2 (NUS) During this reporting period, 67 inspection requests were issued.
For more details, please refer to Annex E.
17. Quality Control
Updated Quality Control Plan for months of April, May, June, July, August & September will be
submitted in the next reporting period.
Quality Control Plan shall be updated on monthly basis.
17.1. NONE COMPLIANCE REPORT Zero notice was issued during this reporting period
17.1.1. Project 1 (ATA) Zero notice was issued during this reporting period
17.1.2. Project 2 (NUS) Zero notice was issued during this reporting period
For more information, please refer to Annex N.
18. Tests Results:
1 test result was issued for GAZI during this reporting period.
18.1. Project 1 (ATA) During this reporting period, 8 tests were issued.
18.2. Project 2 (NUS) During this reporting period, 14 tests were issued.
For more details, please refer to Annex K.
Page 18 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
19. Submittals
During this reporting period, 95 submittals for GAZI were issued.
19.1. Project 1 (ATA) During this reporting period, 14 submittals for Al Atatrah project were issued.
19.2. Project 2 (NUS) During this reporting period, 13 submittals for Nuseirat project were issued.
* TMGI Continue on submitting construction submittals.
For more details, please refer to Annex F.
20. Request for Information
During this reporting period, two RFIs for GAZI were issued about:
Drainage Piping for Air Release valves Level indicator 75mm SS pipe
20.1. Project 1 (ATA)None issued during this reporting period for Al Atatrah project.
20.2. Project 2 (NUS) None issued during this reporting period for Nuseirat project.
For more details, please refer to Annex G.
21. Transmittals
21.1. Outgoing / Incoming USAID Transmittals (TMGI/ USAID)
Date Contractor Trans. No.
Sender / Recipient
Subject
September 5, 2017 By Email TMGI/USAID
USAID COR APPROVAL - TO-15-00008-GAZI Con-struction Monthly Progress Report No.22 August , 2017
September 18, 2017 By Email USAID/TMGI
September 19, 2017 By Email TMGI/USAID
September 27, 2017 By Email USAID/TMGI
September 11, 2017 By Email TMGI/USAID Project 1295 -GRAMMS update of the pending items
stage 15, stage 17 and Cohen office September 11, 2017
September 15, 2017 By Email USAID/TMGI Re: TO 15-0008/9 GAZA I&II: Project 1295 -GRAMMS update - Critical September 16, 2017 By Email TMGI/USAID
September 17, 2017 By Email TMGI/USAID GAZI- Vetting Request- Renewal
Page 19 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
21.2. Transmittals from Contractor to Engineers Contractors to
Engineer Description Issued Date Response Date
TRS. 00008.C-E-622
TEST - Factory test results for Al Atatrah VFD September 5,
2017 September 6,
2017
TEST - Factory test results for Nuseirat VFD September 5,
2017 September 6,
2017
Manufacturers Field Services Representative for Gate Valve- Option II
September 5, 2017
Retracted
TRS. 00008.C-E-623 RFI - Drainage Piping for Air Release valves September 6,
2017 September 26,
2017
TRS. 00008.C-E-624
TEST - 7 Days Results for 21 MPa-Cylinder for encasement of the building next to asphalt road outside the reservoir yard.
September 6, 2017
September 12, 2017
TEST - 7 Days Results for 21 MPa-Cylinder for encasement around 6 sleeves PVC pipes for external electrical (MV) Network.
September 6, 2017
September 12, 2017
TEST - Test Results for the asphalt layer (7.0cm) for road outside & inside the reservoir yard.
September 6, 2017
September 12, 2017
TEST - Factory test results for Al Atatrah Skid Mounted Booster Pump
September 6, 2017
September 13, 2017
TRS. 00008.C-E-625
TEST - 28 Days Results for 30 MPa-Cylinder for electrical pull manhole for the external electrical cable.
September 7, 2017
September 25, 2017
AS BUILT DRAWINGS: Nuseirat Architectural and Struc-tural Retaining & Boundary Walls
September 7, 2017
September 20, 2017
Electrical AS BUILT DRAWINGS: Metering Panel -AL-Ata-trah
September 7, 2017
September 12, 2017
Electrical AS BUILT DRAWINGS: Metering Panel -Nusei-rat
September 7, 2017
September 12, 2017
Electrical AS BUILT DRAWINGS: Guard House -Al Ata-trah
September 7, 2017
September 19, 2017
Electrical AS BUILT DRAWINGS: Guard House -Nuseirat September 7,
2017 September 19,
2017
Mechanical AS BUILT DRAWINGS: Pump Station Al Atatrah
September 7, 2017
September 20, 2017
TRS. 00008.C-E-626
Section 4H: Lightning and Earthing System Final Operation & Maintenance Manual
September 10, 2017
September 13, 2017
Section 4D: Lighting Fixture Final Operation & Maintenance Manual.
September 10, 2017
September 13, 2017
Section 4L: Photovoltaic system Final Operation & Mainte-nance Manual
September 10, 2017
September 13, 2017
Section 4E: 400V Distribution Boards Final Operation & Maintenance Manual
September 10, 2017
September 19, 2017
Section 1A: Vertical Booster Pumps and 400V Electric Mo-tors Final Operation & Maintenance Manual
September 10, 2017
September 27, 2017
Section 4F: 600V Motor Control Center Final Operation & Maintenance Manual
September 10, 2017
September 20, 2017
Section 7D: Flow Switches [Pump Station] Final Operation & Maintenance Manual
September 10, 2017
September 12, 2017
Page 20 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Section 4G: Fire Alarm System Final Operation & Mainte-nance Manual
September 10, 2017
September 12, 2017
TRS. 00008.C-E-627
Training for VFD Operator September 10,
2017 Retracted
Training for VFD Programmer September 10,
2017 Retracted
Training for HMI Programmer September 10,
2017 Retracted
Training for HMI Operator September 10,
2017 Retracted
Training for PLC Operator September 10,
2017 Retracted
Training for PLC Programmer September 10,
2017 Retracted
Section 7H: Ultrasonic Level Transmitter Final Operation & Maintenance Manual
September 10, 2017
September 13, 2017
String Test Method Statement for Vertical Pumps September 10,
2017 September 13,
2017
Nuseirat Site Layout Revised Shop Drawing September 10,
2017 Retracted
Section 4A: Engine Generators Final Operation & Mainte-nance Manual
September 10, 2017
September 12, 2017
TRS. 00008.C-E-628
Section 8C: Eyewash & Emergency Shower with Remote Tank Final Operation & Maintenance Manual
September 11, 2017
September 13, 2017
Section 4K: Disconnect Switch Final Operation & Mainte-nance Manual
September 11, 2017
September 12, 2017
Section 7G: Proximity Switch Final Operation & Mainte-nance Manual
September 11, 2017
September 20, 2017
Section 10B: Steel Mesh fences and Gate Final Operation & Maintenance Manual
September 11, 2017
September 12, 2017
Section 7B: Level Pressure Transmitters Final Operation & Maintenance Manual
September 11, 2017
September 12, 2017
TEST - 28 Days Results for 21 MPa-Cylinder for encasement of discharge header.
September 11, 2017
September 12, 2017
TRS. 00008.C-E-629 Al Atatrah Site Layout Revised Shop Drawing September 11,
2017 Retracted
TRS. 00008.C-E-630 VOR - Changes to Task Orders' Permanent Signs September 12,
2017 Retracted
TRS. 00008.C-E-631
AS BUILT DRAWINGS: Disinfection Building (Architec-tural & Structural)-Nuseirat
September 12, 2017
September 21, 2017
Galvanized Steel Clamp- With Sample September 12,
2017 September 13,
2017
Section 4C: LV Cable Final Operation & Maintenance Man-ual
September 12, 2017
September 13, 2017
Section 7F: Premium Accuracy Pressure Transmitters Final Operation & Maintenance Manual
September 12, 2017
September 13, 2017
Section 4B: Transformer Final Operation & Maintenance Manual
September 12, 2017
September 19, 2017
Page 21 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
TRS. 00008.C-E-632 Updated CPM Construction Schedule August 31, 2017 September 13,
2017 September 20,
2017
TRS. 00008.C-E-633
AS BUILT DRAWINGS: Disinfection Building (Architec-tural & Structural)-Al Atatrah
September 13, 2017
September 25, 2017
Section 6K: Strainers Final Operation & Maintenance Manual September 13,
2017 September 19,
2017
Section 4I: Communication and control cable Final Opera-tion & Maintenance Manual
September 13, 2017
September 19, 2017
Section 7C: Float Type Level Switches Final Operation & Maintenance Manual
September 13, 2017
September 19, 2017
Enclosure for Flow meter September 13,
2017 September 17,
2017
Updated Construction Risk Management Program (CRMP) June 2017
September 13, 2017
September 14, 2017
Updated Construction Risk Management Program (CRMP) July 2017
September 13, 2017
September 14, 2017
Updated Construction Risk Management Program (CRMP) August 2017
September 13, 2017
September 25, 2017
Update Safety Plan July 2017 September 13,
2017 September 17,
2017
TRS. 00008.C-E-634
Training for Control Valves September 14,
2017 September 17,
2017
Nuseirat Site Layout Revised Shop Drawing September 14,
2017 Under Review
Al Atatrah Site Layout Revised Shop Drawing September 14,
2017 Under Review
Update Safety Plan August 2017 September 14,
2017 September 17,
2017
Section 1B Variable Frequency Drive Final Operation & Maintenance Manual
September 14, 2017
September 19, 2017
Section 6L: Backflow Preventer Valve Final Operation & Maintenance Manual
September 14, 2017
September 19, 2017
Section 14A & 15A: Short circuit & coordination and study protective device studies Final Operation & Maintenance Manual
September 14, 2017
September 19, 2017
Start Up and Function Test Schedule September 14,
2017 September 19,
2017
TRS. 00008.C-E-635
Electrical AS BUILT DRAWINGS: Main Distribution Board (MCC) for Nuseirat Reservoir
September 16, 2017
September 27, 2017
Electrical AS BUILT DRAWINGS: Sub Distribution Board September 16,
2017 Under Review
AS BUILT DRAWINGS: Nuseirat Pipe Line Shop Drawing September 16,
2017 September 28,
2017
Electrical AS BUILT DRAWINGS: Main Distribution Board (MCC) Al Atatrah
September 16, 2017
September 27, 2017
Booster Pump Station Shed Revised Column Location Shop Drawings - Al Atatrah
September 16, 2017
September 27, 2017
Updated Environmental Monitoring & Mitigation Plan (June 2017)
September 16, 2017
September 17, 2017
Updated Environmental Monitoring & Mitigation Plan (July 2017)
September 16, 2017
September 17, 2017
Material and Method Statement for Repair the irregular con-crete surface
September 16, 2017
Under Review
Page 22 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Material and Method Statement for Placing New SS Anchor Bolts
September 16, 2017
September 27, 2017
TRS. 00008.C-E-636
Section 10C: Manholes and Manholes Covers Final Opera-tion & Maintenance Manual
September 17, 2017
September 17, 2017
Section 5: PLC and Control Systems Final Operation & Maintenance Manual
September 17, 2017
September 19, 2017
Section 7A: Electromagnetic Flow Meter Final Operation & Maintenance Manual
September 17, 2017
September 19, 2017
Section 11-A: Water heating System Final Operation & Maintenance Manual
September 17, 2017
September 27, 2017
Section 7E: Pressure Switch Final Operation & Maintenance Manual
September 17, 2017
September 19, 2017
Section 7L: Pressure Gauges Final Operation & Maintenance Manual
September 17, 2017
September 19, 2017
TRS. 00008.C-E-637
Section 4M: Reservoir LCP Level Panel Final Operation & Maintenance Manual
September 18, 2017
September 20, 2017
Section 11-E: Wall Mounted Exhaust Fans Final Operation & Maintenance Manual
September 18, 2017
September 21, 2017
Mechanical AS BUILT DRAWINGS: Disinfection Building September 18,
2017 September 27,
2017
Section 3: Grinder Pump Package Lift Station Final Opera-tion & Maintenance Manual
September 18, 2017
September 20, 2017
Section 7J: Electrode/Conductance Relay Level Switches Fi-nal Operation & Maintenance Manual
September 18, 2017
September 20, 2017
TEST - Core Test Results for the asphalt layer for road out-side & inside the reservoir yard.
September 18, 2017
Under Review
TEST - 7 Days Results for 35 MPa-Cylinder for pipe support pad - foundation.
September 18, 2017
September 25, 2017
TRS. 00008.C-E-638
Instrumentation and control system (PLC and Automation) Trainers
September 19, 2017
September 27, 2017
Variable Frequency Drive (VFD)Trainers September 19,
2017 September 27,
2017
Mechanical AS BUILT DRAWINGS: Electrical & Control Building
September 19, 2017
September 27, 2017
Page 23 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Training for Control Valves September 19,
2017 September 21,
2017
Mechanical AS BUILT DRAWINGS: Pump Station Nusei-rat
September 19, 2017
September 25, 2017
Training for HMI Operator September 19,
2017 September 20,
2017
Section III: Plant Description and general layout Final Oper-ation & Maintenance Manual
September 19, 2017
September 20, 2017
Section 8D: Chemical Storage Tank Final Operation & Maintenance Manual
September 19, 2017
September 21, 2017
Training for HMI Programmer September 19,
2017 September 20,
2017
Training for PLC Operator September 19,
2017 September 20,
2017
AS BUILT DRAWINGS: Nuseirat 3800M3 Reservoir Struc-tural & Architectural Drawing's
September 19, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for TS2a pipeline at Al Atatrah project
September 19, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for TS3 pipeline at Al Atatrah project
September 19, 2017
Under Review
TEST - 28 Days Results for 21 MPa-Cylinder for encasement of the building next to asphalt road outside the reservoir yard.
September 19, 2017
September 25, 2017
TRS. 00008.C-E-639
Nuseirat Electrical & Control Building Checkered Plate Shop Drawings
September 20, 2017
September 27, 2017
AL - Atatrah Electrical & Control Building Checkered Plate Shop Drawings
September 20, 2017
September 27, 2017
AS BUILT DRAWINGS: Al Atatrah 3800M3 Reservoir Structural & Architectural Drawing's
September 20, 2017
Under Review
Mechanical AS BUILT DRAWINGS: Pump Station Al Atatrah
September 20, 2017
September 21, 2017
Electrical AS BUILT DRAWINGS: Disinfection Building September 20,
2017 Under Review
Galvanized PVC coated flexible - Option II September 20,
2017 September 27,
2017
TRS. 00008.C-E-640
TEST - Fire and control cables - Test certificate September 21,
2017 September 25,
2017
TEST - Flushing, disinfection & bacteriological test result for TS2 pipeline at Al Atatrah project
September 21, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for supply pipeline TS1 from St. 1+000 to St. 1+630 at Al Ata-trah project
September 21, 2017
Under Review
Page 24 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
TEST - Flushing, disinfection & bacteriological test result for supply pipeline TS1 from St. 1+630 to St. 2+960 at Al Ata-trah project
September 21, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for distribution pipelines TD1 & TD2 at Al Atatrah project
September 21, 2017
Under Review
Training for VFD Operator September 21,
2017 September 21,
2017
Guard House Furniture September 21,
2017 Under Review
TRS. 00008.C-E-641 VOR - Electrical Installation deficiencies at Al Atatrah and Nuseirat Projects-Item No.04-Rio Panel
September 21, 2017
September 21, 2017
TRS. 00008.C-E-642
Training for VFD Operator September 24,
2017 September 25,
2017
Training for VFD Programmer September 24,
2017 September 25,
2017
Section 11H: Portable Fire Extinguishers Final Operation & Maintenance Manual
September 24, 2017
September 25, 2017
Section 8B: Free Chlorine Analyzer Final Operation & Maintenance Manual
September 24, 2017
September 27, 2017
Section 8A: Dosing Pump Final Operation & Maintenance Manual
September 24, 2017
September 27, 2017
TRS. 00008.C-E-643
Training for PLC Programmer September 24,
2017 September 25,
2017
Electrical AS BUILT DRAWINGS: Electrical & Control Building - Al Atatrah
September 24, 2017
Under Review
TRS. 00008.C-E-644 VOR - Storage Costs of Dual Use Materials that Arrived to Gaza up to July 11, 2017
September 25, 2017
Under Review
TRS. 00008.C-E-645 RFI - Level indicator 75mm SS pipe September 25,
2017 Under Review
TRS. 00008.C-E-646
Toilet Accessories With Sample September 25,
2017 September 27,
2017
Reservoir External Ladder Shop Drawings September 25,
2017 September 27,
2017
Steel Pipes Painting Prepare Method Statement September 25,
2017 September 27,
2017
Local Representative for Vertical Turbines Pumps September 25,
2017 September 27,
2017
Local Representative for Engine Generator September 25,
2017 September 27,
2017
Local Representative for Variable Frequency Drive (VFD) September 25,
2017 September 27,
2017
Local Representative for Control Valves September 25,
2017 September 27,
2017
Local Representative for Motor Control Center (MCC) September 25,
2017 September 27,
2017
Local Representative for Chlorine System September 25,
2017 September 27,
2017
Local Representative for Photo-Voltaic System September 25,
2017 September 27,
2017
Local Representative for PLC September 25,
2017 September 27,
2017
Page 25 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Local Representative for Skid Mounted Booster Pump September 25,
2017 September 27,
2017
AS BUILT DRAWINGS: Guard House (Architectural & Structural)-Nuseirat
September 25, 2017
Under Review
AS BUILT DRAWINGS: Guard House (Architectural & Structural)-Al Atatrah
September 25, 2017
Under Review
TRS. 00008.C-E-647 VOR - Changes to Task Orders' Permanent Signs September 26,
2017 September 26,
2017
TRS. 00008.C-E-648
RFI - Replace manual pressure gauge calibrator by PVC pres-sure pipes
September 26, 2017
Retracted
Mechanical AS BUILT DRAWINGS: Skid Mounted Booster Pump Al Atatrah
September 26, 2017
September 28, 2017
AS BUILT DRAWINGS: Nuseirat Chambers September 26,
2017 Under Review
TRS. 00008.C-E-649
Mechanical AS BUILT DRAWINGS: Pump Station Nusei-rat
September 27, 2017
Under Review
Section 6I: Dismantling Joint Final Operation & Maintenance Manual
September 27, 2017
Under Review
Section 12D: PP-R Pipe for Disinfection Building Final Op-eration & Maintenance Manual
September 27, 2017
Under Review
Section 11-J: Expansion Joint Final Operation & Mainte-nance Manual
September 27, 2017
Under Review
TEST - Soil field density for leveling & compaction under side walk area around the facilities buildings.
September 27, 2017
Under Review
TEST - 28 Days Results for 21 MPa-Cylinder for encasement around 6 sleeves PVC pipes for external electrical (MV) Network.
September 27, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for Supply pipeline NS1 at Nuseirat project
September 27, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for Supply pipeline NS2 at Nuseirat project
September 27, 2017
Under Review
TEST - Flushing, disinfection & bacteriological test result for Supply pipeline NS3 at Nuseirat project
September 27, 2017
Under Review
TRS. 00008.C-E-650
Training for VFD Programmer September 28,
2017 Under Review
Training for PLC Programmer September 28,
2017 Under Review
Training for HMI Operator September 28,
2017 Under Review
Training for HMI Programmer September 28,
2017 Under Review
Training for PLC Operator September 28,
2017 Under Review
Section 6E: Gate Valve Final Operation & Maintenance Manual
September 28, 2017
Under Review
Section 9B: Steel Pipe & Fitting Final Operation & Mainte-nance Manual
September 28, 2017
Under Review
Section 11-I: Ultraviolet (UV) Water Purifier Final Operation & Maintenance Manual
September 28, 2017
Under Review
Section 12C: PVC and HDPE Pipes Final Operation & Maintenance Manual
September 28, 2017
Under Review
Mechanical AS BUILT DRAWINGS: Guard House September 28,
2017 Under Review
Page 26 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
TRS. 00008.C-E-651 Painted G.S corrugated sheet 0.6mm - With Sample September 30,
2017 Under Review
21.3. Transmittals from Engineers to Contractor Engineers to Contractor
Description Received Date
TRS-15-00008-E-C-525
TEST - Certified Factory Pump Performance Test Result Al Atatrah. September 5, 2017
TEST - Certified Factory Pump Performance Test Result Nuseirat September 5, 2017
TEST - 28 Days Results for 35 MPa-Cylinder for flow meter - (booster pump station) and external ladder pad at the guard house.
September 5, 2017
TRS-15-00008-E-C-526
Manufacturers Field Services Representative for Air Release Valve September 6, 2017
PVC Support for disinfection wet panel September 6, 2017
Certificate of Test for Grounding system September 6, 2017
Factory test results for Al Atatrah VFD September 6, 2017
Factory test results for Nuseirat VFD September 6, 2017
TRS-15-00008-E-C-527 Section 12C: PVC and HDPE Pipes Preliminary Operation & Maintenance Manual
September 10, 2017
TRS-15-00008-E-C-528 TEST - Certificate of Test for Grounding system September 11, 2017
TRS-15-00008-E-C-529
TEST - 7 Days Results for 21 MPa-Cylinder for encasement of the building next to asphalt road outside the reservoir yard.
September 12, 2017
TEST - 7 Days Results for 21 MPa-Cylinder for encasement around 6 sleeves PVC pipes for external electrical (MV) Network.
September 12, 2017
TEST - Test Results for the asphalt layer (7.0cm) for road outside & inside the reservoir yard.
September 12, 2017
TEST - 28 Days Results for 21 MPa-Cylinder for encasement of discharge header.
September 12, 2017
Electrical AS BUILT DRAWINGS: Metering Panel -AL-Atatrah September 12, 2017
Electrical AS BUILT DRAWINGS: Metering Panel -Nuseirat September 12, 2017
Section 7D: Flow Switches [Pump Station] Final Operation & Maintenance Manual
September 12, 2017
Section 4G: Fire Alarm System Final Operation & Maintenance Manual September 12, 2017
Section 4A: Engine Generators Final Operation & Maintenance Manual September 12, 2017
Section 4K: Disconnect Switch Final Operation & Maintenance Manual September 12, 2017
Section 10B: Steel Mesh fences and Gate Final Operation & Maintenance Manual
September 12, 2017
Section 7B: Level Pressure Transmitters Final Operation & Maintenance Manual
September 12, 2017
TRS-15-00008-E-C-530
Section 4H: Lightning and Earthing System Final Operation & Mainte-nance Manual
September 13, 2017
Section 4D: Lighting Fixture Final Operation & Maintenance Manual. September 13, 2017
Section 4L: Photovoltaic system Final Operation & Maintenance Manual September 13, 2017
Section 7H: Ultrasonic Level Transmitter Final Operation & Maintenance Manual
September 13, 2017
String Test Method Statement for Vertical Pumps September 13, 2017
Section 8C: Eyewash & Emergency Shower with Remote Tank Final Oper-ation & Maintenance Manual
September 13, 2017
Galvanized Steel Clamp- With Sample September 13, 2017
Page 27 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Section 4C: LV Cable Final Operation & Maintenance Manual September 13, 2017
Section 7F: Premium Accuracy Pressure Transmitters Final Operation & Maintenance Manual
September 13, 2017
TEST - Factory test results for Al Atatrah Skid Mounted Booster Pump September 13, 2017
VOR - Storage Costs of Dual Use Materials that Arrived to Gaza up to July 11, 2017
September 13, 2017
TRS-15-00008-E-C-531
AS BUILT DRAWINGS: Guard House (Architectural & Structural)-Nuseirat
September 14, 2017
AS BUILT DRAWINGS: Al Atatrah Pipe Line Shop Drawing September 14, 2017
Updated Construction Risk Management Program (CRMP) June 2017 September 14, 2017
Updated Construction Risk Management Program (CRMP) July 2017 September 14, 2017
TRS-15-00008-E-C-532
AS BUILT DRAWINGS: Guard House (Architectural & Structural)-Al Atatrah
September 17, 2017
Training for Control Valves September 17, 2017
Al Atatrah Asphalt works Shop Drawing September 17, 2017
Enclosure for Flow meter September 17, 2017
Update Safety Plan July 2017 September 17, 2017
Update Safety Plan August 2017 September 17, 2017
Updated Environmental Monitoring & Mitigation Plan (June 2017) September 17, 2017
Updated Environmental Monitoring & Mitigation Plan (July 2017) September 17, 2017
Section 10C: Manholes and Manholes Covers Final Operation & Mainte-nance Manual
September 17, 2017
TRS-15-00008-E-C-533
TEST - 7 Days Results for 30 MPa-Cylinder for electrical pull manhole for the external electrical cable.
September 18, 2017
Nuseirat Pump Station Checkered Plate Shop Drawings September 18, 2017
TRS-15-00008-E-C-534
Electrical AS BUILT DRAWINGS: Guard House -Al Atatrah September 19, 2017
Electrical AS BUILT DRAWINGS: Guard House -Nuseirat September 19, 2017
Section 4E: 400V Distribution Boards Final Operation & Maintenance Manual
September 19, 2017
Section 4B: Transformer Final Operation & Maintenance Manual September 19, 2017
Section 6K: Strainers Final Operation & Maintenance Manual September 19, 2017
Section 4I: Communication and control cable Final Operation & Mainte-nance Manual
September 19, 2017
Section 7C: Float Type Level Switches Final Operation & Maintenance Manual
September 19, 2017
Section 1B Variable Frequency Drive Final Operation & Maintenance Man-ual
September 19, 2017
Section 6L: Backflow Preventer Valve Final Operation & Maintenance Manual
September 19, 2017
Section 14A & 15A: Short circuit & coordination and study protective de-vice studies Final Operation & Maintenance Manual
September 19, 2017
Start Up and Function Test Schedule September 19, 2017
Section 5: PLC and Control Systems Final Operation & Maintenance Man-ual
September 19, 2017
Section 7A: Electromagnetic Flow Meter Final Operation & Maintenance Manual
September 19, 2017
Section 7E: Pressure Switch Final Operation & Maintenance Manual September 19, 2017
Page 28 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Section 7L: Pressure Gauges Final Operation & Maintenance Manual September 19, 2017
TRS-15-00008-E-C-535
AS BUILT DRAWINGS: Nuseirat Architectural and Structural Retaining & Boundary Walls
September 20, 2017
Mechanical AS BUILT DRAWINGS: Pump Station Al Atatrah September 20, 2017
Section 4F: 600V Motor Control Center Final Operation & Maintenance Manual
September 20, 2017
Updated CPM Construction Schedule August 31, 2017 September 20, 2017
Section 4M: Reservoir LCP Level Panel Final Operation & Maintenance Manual
September 20, 2017
Section 3: Grinder Pump Package Lift Station Final Operation & Mainte-nance Manual
September 20, 2017
Section 7J: Electrode/Conductance Relay Level Switches Final Operation & Maintenance Manual
September 20, 2017
TRS-15-00008-E-C-536
Section 7G: Proximity Switch Final Operation & Maintenance Manual September 20, 2017
Training for HMI Operator September 20, 2017
Section III: Plant Description and general layout Final Operation & Maintenance Manual
September 20, 2017
Training for HMI Programmer September 20, 2017
Training for PLC Operator September 20, 2017
TRS-15-00008-E-C-537
AS BUILT DRAWINGS: Disinfection Building (Architectural & Struc-tural)-Nuseirat
September 21, 2017
Training for Control Valves September 21, 2017
Mechanical AS BUILT DRAWINGS: Pump Station Al Atatrah September 21, 2017
Training for VFD Operator September 21, 2017
Section 11-E: Wall Mounted Exhaust Fans Final Operation & Maintenance Manual
September 21, 2017
Section 8D: Chemical Storage Tank Final Operation & Maintenance Man-ual
September 21, 2017
TRS-15-00008-E-C-538 VOR - Electrical Installation deficiencies at Al Atatrah and Nuseirat Pro-jects-Item No.04-Rio Panel
September 21, 2017
TRS-15-00008-E-C-539
TEST - Fire and control cables - Test certificate September 25, 2017
TEST - 28 Days Results for 30 MPa-Cylinder for electrical pull manhole for the external electrical cable.
September 25, 2017
TEST - 7 Days Results for 35 MPa-Cylinder for pipe support pad - founda-tion.
September 25, 2017
TEST - 28 Days Results for 21 MPa-Cylinder for encasement of the build-ing next to asphalt road outside the reservoir yard.
September 25, 2017
TEST - AS BUILT DRAWINGS: Disinfection Building (Architectural & Structural)-Al Atatrah
September 25, 2017
Training for VFD Operator September 25, 2017
Training for VFD Programmer September 25, 2017
Training for PLC Programmer September 25, 2017
Updated Construction Risk Management Program (CRMP) August 2017 September 25, 2017
Mechanical AS BUILT DRAWINGS: Pump Station Nuseirat September 25, 2017
Section 11H: Portable Fire Extinguishers Final Operation & Maintenance Manual
September 25, 2017
TRS-15-00008-E-C-540 RFI - Drainage Piping for Air Release valves September 26, 2017
Page 29 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
Changes to Task Orders' Permanent Signs September 26, 2017
TRS-15-00008-E-C-541
Toilet Accessories With Sample September 27, 2017
Reservoir External Ladder Shop Drawings September 27, 2017
Nuseirat Electrical & Control Building Checkered Plate Shop Drawings September 27, 2017
AL - Atatrah Electrical & Control Building Checkered Plate Shop Drawings September 27, 2017
Steel Pipes Painting Prepare Method Statement September 27, 2017
Instrumentation and control system (PLC and Automation) Trainers
September 27, 2017
Variable Frequency Drive (VFD)Trainers September 27, 2017
Local Representative for Vertical Turbines Pumps September 27, 2017
Local Representative for Engine Generator September 27, 2017
Local Representative for Variable Frequency Drive (VFD) September 27, 2017
Local Representative for Control Valves September 27, 2017
Local Representative for Motor Control Center (MCC) September 27, 2017
Local Representative for Chlorine System September 27, 2017
Local Representative for Photo-Voltaic System September 27, 2017
Local Representative for PLC September 27, 2017
Local Representative for Skid Mounted Booster Pump September 27, 2017
Electrical AS BUILT DRAWINGS: Main Distribution Board (MCC) for Nuseirat Reservoir
September 27, 2017
Electrical AS BUILT DRAWINGS: Main Distribution Board (MCC) Al Atatrah
September 27, 2017
Mechanical AS BUILT DRAWINGS: Electrical & Control Building September 27, 2017
Section 1A: Vertical Booster Pumps and 400V Electric Motors Final Oper-ation & Maintenance Manual
September 27, 2017
Booster Pump Station Shed Revised Column Location Shop Drawings - Al Atatrah
September 27, 2017
Material and Method Statement for Placing New SS Anchor Bolts September 27, 2017
Section 11-A: Water heating System Final Operation & Maintenance Man-ual
September 27, 2017
Mechanical AS BUILT DRAWINGS: Disinfection Building September 27, 2017
Galvanized PVC coated flexible - Option II September 27, 2017
Section 8B: Free Chlorine Analyzer Final Operation & Maintenance Man-ual
September 27, 2017
Section 8A: Dosing Pump Final Operation & Maintenance Manual September 27, 2017
TRS-15-00008-E-C-542
AS BUILT DRAWINGS: Nuseirat Pipe Line Shop Drawing September 28, 2017
Mechanical AS BUILT DRAWINGS: Skid Mounted Booster Pump Al Atatrah
September 28, 2017
Page 30 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
22. Task Order General Statistics
NO. Description This Month Cumulative
1 Preconstruction Submittals 0 93
2 Material Submittals 6 606
3 Shop drawings Submittals
3.1 Mutual for ATA & NUS (GAZI) 1 123
3.2 Project 1 ATA 3 112
3.3 Project 2 NUS 2 92
4 Preliminary Operation & Maintenance Manual 1 87
5 Inspection Request (IR)
5.1 Mutual for ATA & NUS (GAZI) 13 149 5.2 Project 1 ATA 63 1087
5.3 Project 2 NUS 67 883
6 Request for Information (RFI)
6.1 Mutual for ATA & NUS (GAZI) 2 50
6.2 Project 1 ATA 0 4
6.3 Project 2 NUS 0 6
23. Payments
Invoice No. Project Submitted
date Received by
BV on Amount $
Retention Amount
Amount Received
Received Date
PAY-15-00008-GAZI-
001
ATA January 18,
2016 January 21,
2016 263,471.99 - 263,471.99
February 09, 2016
NUS January 18,
2016 January 21,
2016 270,776.85 - 270,776.85
February 09, 2016
GAZI (Total)
January 18, 2016
January 21, 2016
534,248.84 - 534,248.84 February 09,
2016
PAY-15-00008-GAZI-
002
ATA May 29, 2016 May 31, 2016 288,625.54 - 288,625.54 June 16, 2016
NUS May 29, 2016 May 31, 2016 54,907.57 - 54,907.57 June 16, 2016
GAZI (Total)
May 29, 2016 May 31, 2016 343,533.11 - 343,533.11 June 16, 2016
PAY-15-00008-GAZI-
003
ATA June 19, 2016 June 21, 2016 61,941.06 - 61,941.06 June 30, 2016
NUS June 19, 2016 June 21, 2016 24,329.93 - 24,329.93 June 30, 2016
GAZI (Total)
June 19, 2016 June 21, 2016 86,270.99 - 86,270.99 June 30, 2016
Page 31 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
PAY-15-00008-GAZI-
004
ATA September 5,
2016 September 5,
2016 96,420.36 - 96,420.36
September 14, 2016
NUS September 5,
2016 September 5,
2016 207,048.76 - 207,048.76
September 14, 2016
GAZI (Total)
October 5, 2016
September 5, 2016
303,469.12 - 303,469.12 September 14, 2016
PAY-15-00008-GAZI-
005
ATA October 24,
2016 October 24,
2016 515,498.53 - 515,498.53
November 09, 2016
NUS October 24,
2016 October 24,
2016 438,828.04 - 438,828.04
November 09, 2016
GAZI (Total)
October 24, 2016
October 24, 2016
954,326.57 - 954,326.57 November 09, 2016
PAY-15-00008-GAZI-
006
ATA December 6,
2016 December 6,
2016 226,915.42 - 226,915.42
December 14, 2016
NUS December 6,
2016 December 6,
2016 479,259.76 - 479,259.76
December 14, 2016
GAZI (Total)
December 6, 2016
December 6, 2016
706,175.18 - 706,175.18 December 14, 2016
PAY-15-00008-GAZI-
007
ATA February 09,
2017 February 09,
2017 449,104.50 - 449,104.50
March 03, 2017
NUS February 09,
2017 February 09,
2017 539,372.37 - 539,372.37
March 03, 2017
GAZI (Total)
February 09, 2017
February 09, 2017
988,476.87 - 988,476.87 March 03,
2017
PAY-15-00008-GAZI-
008
ATA May 09, 2017 May 15, 2017 546,561.61 - 546,561.61 June 05, 2017
NUS May 09, 2017 May 15, 2017 584,968.77 - 584,968.77 June 05, 2017
GAZI (Total)
May 09, 2017 May 15, 2017 1,131,530.38 - 1,131,530.38 June 05, 2017
PAY-15-00008-GAZI-
009
ATA August 09,
2017 August 09,
2017 779,134.97 - 779,134.97
August 24, 2017
NUS August 09,
2017 August 09,
2017 811,327.30 - 811,327.30
August 24, 2017
GAZI (Total)
August 09, 2017
August 09, 2017
1,590,462.27 - 1,590,462.27 August 24,
2017
Page 32 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
24. Variation Orders
Two variation order was approved during this reporting period.
VO. No. Description VO
Status USAID
Approval date
Variation Order
Amount
Time Extension
Days
VO-15-00008-
GAZI-01
Changes in Requirements, New Items, New Definitive Quantities, Correction of Typo, Sequential and Arithmetic Errors and Time Extension
Approved August 3, 2016 176,084.76 $ 21
VO-15-00008-
GAZI-02
The Use of Steel Pipes In lieu of Ductile Iron Pipes for Reservoir's Yard Piping
Approved August 25, 2016 Zero Zero
VO-15-00008-
GAZI-03
Changes in Requirements, New Definitive Quantities.
Approved January 20, 2016 54,944.11 $ Zero
VO-15-00008-
GAZI-04
Changes in Requirements, New Definitive Quantities.
Approved May 24, 2016 (89,824.41) $ Zero
VO-15-00008-
GAZI-05
Changes in Requirements, New Definitive Quantities.
Approved August 3, 2017 14,352.44 $ Zero
VO-15-00008-
GAZI-06
Extension of Time (Modification No. AID-294-TO-15-00008-02)
Approved July 17, 2017 Zero 31
VO-15-00008-
GAZI-07
Cost Time Extension and New Defini-tive Quantities
Approved September 29,
2017 591,921.86 $ 86
VO-15-00008-
GAZI-08
Contract modification (Modification No. AID-294-TO-15-00008-03)
Approved September 28,
2017 591,921.86 $ 86
25. Variation Order Requests
VOR No. Description VO. No. Variation
Order Amount
Time Extension
Days
VOR-15-00008-GAZI-001-A Purchase and delivered the additional quantities of UPVC pipes fittings, restrained joints and FA
001-A 41,133.00 $ Zero time Extension
VOR-15-00008-GAZI-001-B Purchase and delivered the additional quantities of UPVC pipes fittings, restrained joints and FA
001-B 40,533.00 $ Zero time Extension
VOR-15-00008-GAZI-001-C Purchase and delivered the additional quantities of UPVC pipes fittings, restrained joints and FA
001-C 35,993.00 $ Zero time Extension
VOR-15-00008-GAZI-002-A Use of Steel Mini Guard In lieu of Concrete New Jersey Barriers
002-A Zero Cost Zero time Extension
VOR-15-00008-GAZI-002-B Use of Steel Mini Guard In lieu of Concrete New Jersey Barriers
002-B Zero Cost Zero time Extension
VOR-15-00008-GAZI-002-C Use of Steel Mini Guard In lieu of Concrete New Jersey Barriers
002-C Zero Cost Zero time Extension
Page 33 of 430
-
TO-15-00008 Construction Monthly Progress Report September 2017
VOR-15-00008-GAZI-003-A Use of coloured PVC conduits for embedded installations instead of rigid schedule 40 PVC conduits
003-A Zero Cost Zero time Extension
VOR-15-00008-GAZI-003-B Use of coloured PVC conduits for embedded installations instead of rigid schedule 40 PVC conduits
003-B Zero Cost Zero time Extension
VOR-15-00008-GAZI-003-C Use of coloured PVC conduits for embedded installations instead of rigid schedule 40 PVC conduits
003-C Saving
(1,380.00) $ Zero time Extension
VOR-15-00008-GAZI-004-A GFCI (Ground Fault Circuit Interrupter) Receptacles
004-A Zero Cost Zero time Extension
VOR-15-00008-GAZI-005-A The use of PE pipe PN12.5 instead of PVC-U pipe PN16 for Reservoir Drain Pipe
005-A Zero Cost Zero time Extension
VOR-15-00008-GAZI-005-B The use of HDPE pipe PN12.5 instead of PVC-U pipe PN16 for Reservoir Drain Pipe
005-B Zero Cost Zero time Extension
VOR-15-00008-GAZI-005-C The use of HDPE pipe PN12.5 instead of PVC-U pipe PN16 for Reservoir Drain Pipe
005-C Zero Cost Zero time Extension
VOR-15-00008-GAZI-006-A Impact of Walkthrough for Al Atatrah Supply and Distribution Pipelines
006-A 32,587.5 $ Zero time Extension
VOR-15-00008-GAZI-006-B Impact of Walkthrough for Al Atatrah Supply and Distribution Pipelines
006-B 31337.5 $ Zero time Extension
VOR-15-00008-GAZI-007-A Impact of Walkthrough for Nuseirat Supply and Distribution Pipelines
007-A 127,175.00 $ Zero time Extension
VOR-15-00008-GAZI-007-B Impact of Walkthrough for Nuseirat Supply and Distribution Pipelines
007-B 105,300.00 $ Zero time Extension
VOR-15-00008-GAZI-008-A Request of Time Extension to Compensate Excusable Delays
008-A 11382.93 $ 13 Days
VOR-15-00008-GAZI-008-B Request of Time Extension to Compensate Excusable Delays
008-A 66300.00 $ 13 Days
VOR-15-00008-GAZI-009-A The use of Gaza available sand materials and the calcareous sand material as fill-ing material (Kurkar) under structures.
009-A Zero Cost Zero time Extension
VOR-15-00008-GAZI-010-A Replace Pad-Mount Transformer by Pole Mount Transformer for Al Atatrah Project
010-A 94,784.00 $ 21 Days
VOR-15-00008-GAZI-010-B Replace Pad-Mount Transformer by Pole Mount Transformer for Al Atatrah Project
010-B 89,810.00 $ 21 Days
VOR-15-00008-GAZI-010-C Replace Pad-Mount Transformer by Pole Mount Transformer for Al Atatrah Project
010-C 84,310.00 $ 21 Days
VOR-15-00008-GAZI-010-D Replace Pad-Mount Transformer by Pole Mount Transformer for Al Atatrah Project
010-C 79,170.00 $ 21 Days
VOR-15-00008-GAZI-011-A Replace Pa