MERC, Order in Case No 44 of 2013 Page 1 Before the ...
Transcript of MERC, Order in Case No 44 of 2013 Page 1 Before the ...
MERC, Order in Case No 44 of 2013 Page 1
Before the
MAHARASHTRA ELECTRICITY REGULATORY COMMISSION
World Trade Centre, Centre No.1, 13th Floor, Cuffe Parade, Mumbai – 400 005
Email: [email protected]
Website: www.mercindia.org.in/www.merc.gov.in
Case No.44 of 2013
IN THE MATTER OF
Maharashtra State Power Generation Company Limited’s (MSPGCL’s) Petition
for determination of Capital Cost and Tariff of Khaperkheda Unit # 5 for FY
2012-13
Shri V. P. Raja, Chairman
Shri Vijay L. Sonavane, Member
Smt Chandra Iyengar, Member
Date: 4 September, 2013
ORDER
The Maharashtra State Power Generation Company Limited (MSPGCL or
Mahagenco) submitted a Petition under Sections 61, 62 and 86 (1)(a)(b) of the
Electricity Act, 2003 and Part E of MERC (Terms and Conditions of Tariff)
Regulations, 2005 before the Maharashtra Electricity Regulatory Commission
(MERC or the Commission) on 22 March, 2013 for determination of Capital Cost and
Tariff of its Khaperkheda Thermal Power Station Unit # 5 for FY 2012-13. The
Commission, in exercise of the powers vested in it under Section 61 and Section 62 of
the Electricity Act, 2003 (EA 2003) and all other powers enabling it in this behalf,
and after taking into consideration all the submissions made by MSPGCL, all the
suggestions and objections of the public, responses of MSPGCL, issues raised during
the Public Hearing, and all other relevant material, determines the Capital Cost and
Tariff of Khaperkheda Unit # 5 for FY 2012-13 as under.
MERC, Order in Case No 44 of 2013 Page 2
Table of Contents
1 BACKGROUND AND BRIEF HISTORY ......................................................... 11
1.1 Background ................................................................................................... 11
1.2 Admission of the current Petition and Public Hearing process .................... 12
1.3 Organisation of the Order .................................................................................. 14
2 OBJECTIONS RAISED, RESPONSE FROM MSPGCL AND
COMMISSION’S VIEW ............................................................................................. 16
2.1 Capital Cost ................................................................................................... 16
MSPGCL’s reply ........................................................................................................ 18
Commission’s view ..................................................................................................... 19
2.2 Tariff ............................................................................................................. 20
MSPGCL’s reply ........................................................................................................ 22
Commission’s view ..................................................................................................... 22
2.3 Merit Order Despatch ................................................................................... 23
MSPGCL’s reply ........................................................................................................ 23
Commission’s view ..................................................................................................... 24
2.4 Project Management ..................................................................................... 24
MSPGCL’s reply ........................................................................................................ 24
Commission’s view ..................................................................................................... 24
3 APPROACH OF THIS ORDER .......................................................................... 25
4 CAPITAL COST OF KHAPERKHEDA UNIT # 5 ............................................ 26
4.1 Capital Cost of Khaperkheda Unit # 5 .......................................................... 26
4.2 Background to Project Commissioning ........................................................ 28
4.3 Comparison of capital cost ........................................................................... 37
4.4 Hard cost ....................................................................................................... 48
Land & Site Development ................................................................................... 48
Commission’s Analysis .............................................................................................. 48
BTG Package ....................................................................................................... 49
Commission’s Analysis .............................................................................................. 50
BoP Electrical and Mechanical Package ............................................................. 52
MERC, Order in Case No 44 of 2013 Page 3
Commission’s Analysis .............................................................................................. 53
Civil Works .......................................................................................................... 53
Commission’s Analysis .............................................................................................. 54
Construction and Pre-Commissioning activities .................................................. 59
Commission’s Analysis .............................................................................................. 59
Overheads 61
Commission’s Analysis .............................................................................................. 61
Initial Spares ........................................................................................................ 62
4.5 Interest During Construction ........................................................................ 63
Commission’s Analysis .............................................................................................. 66
4.6 Liquidated Damages ..................................................................................... 69
Commission’s Analysis .............................................................................................. 69
4.7 MEANS OF FINANCE ................................................................................ 72
Commission’s Analysis .............................................................................................. 72
5 Tariff of Khaperkheda Unit # 5 for FY 2012-13 ................................................. 75
5.1 Energy Charges ............................................................................................. 75
Fuel Supply Agreement ....................................................................................... 75
Commission’s Analysis .............................................................................................. 76
Calorific Value and Price of Fuel ........................................................................ 79
Commission’s Analysis .............................................................................................. 80
Operational Parameters ........................................................................................ 81
Commission’s Analysis .............................................................................................. 84
5.2 Additional capitalisation ............................................................................... 90
Commission’s Analysis .............................................................................................. 90
5.3 Annual Fixed Charges .................................................................................. 94
Operation and Maintenance Expenses ................................................................. 94
Commission’s Analysis .............................................................................................. 95
Depreciation ......................................................................................................... 98
Commission’s Analysis .............................................................................................. 98
Interest on Long Term Loan .............................................................................. 100
MERC, Order in Case No 44 of 2013 Page 4
Commission’s Analysis ............................................................................................ 100
Advance Against Depreciation .......................................................................... 103
Commission’s Analysis ............................................................................................ 104
Return on Equity ................................................................................................ 104
Commission’s Analysis ............................................................................................ 104
Income Tax ........................................................................................................ 105
Commission’s Analysis ............................................................................................ 106
Interest on Working Capital ............................................................................... 106
Commission’s Analysis ............................................................................................ 106
Non Tariff Income ............................................................................................. 107
Annual Fixed Charges ....................................................................................... 107
MERC, Order in Case No 44 of 2013 Page 5
List of Tables
Table 1.1: Newspaper Notice of Public Hearing ......................................................... 14
Table 4.1: Comparison of Ordering Cost and Cost as on COD submitted by MSPGCL
(Rs. Crore) ................................................................................................................... 27
Table 4.2: Award of BoP Package submitted by MSPGCL ........................................ 29
Table 4.3: Award of other Packages submitted by MSPGCL ..................................... 29
Table 4.4: Letters written to M/s BHEL and M/s BGR submitted by MSPGCL ........ 33
Table 4.5: Delay in milestone activities submitted by MSPGCL ................................ 34
Table 4.6: Key milestones ........................................................................................... 37
Table 4.7: Comparison of Capital Cost submitted by MSPGCL (Rs. Crore/MW) ..... 38
Table 4.8: Item wise comparison of Capital Cost submitted by MSPGCL (Rs. Crore)
..................................................................................................................................... 39
Table 4.9: Land & Site Development Cost as on COD approved by the Commission
(Rs. Crore) ................................................................................................................... 49
Table 4.10: Comparison of Ex-works supply price of BTG submitted by MSPGCL . 49
Table 4.11: Comparison of price for Erection, Testing and Commissioning submitted
by MSPGCL ................................................................................................................ 50
Table 4.12: Cost of BTG as on COD approved by the Commission (Rs. Crore) ........ 52
Table 4.13: Cost of BoP Electrical and Mechanical as on COD approved by the
Commission ................................................................................................................. 53
Table 4.14: Details of Miscellaneous Civil Works submitted by MSPGCL ............... 54
Table 4.15: Cost of Civil Works as on COD approved by the Commission (Rs. Crore)
..................................................................................................................................... 59
Table 4.16: Cost of Construction and pre commissioning activities as on COD
approved by the Commission (Rs. Crore) ................................................................... 61
Table 4.17: Overheads as on COD approved by the Commission (Rs. Crore) ........... 62
Table 4.18: Initial Spares as on COD approved by the Commission .......................... 63
Table 4.19: Hard Cost as on COD approved by the Commission (Rs. Crore) ............ 63
Table 4.20: Loan Drawdown Schedule submitted by MSPGCL (Rs. Crore) .............. 64
Table 4.21: Assumptions for IDC Computation submitted by MSPGCL ................... 65
Table 4.22: Project Cost including IDC approved by the Commission (Rs. Crore) .... 69
Table 4.24: Capital Cost as on COD approved by the Commission (Rs. Crore) ......... 71
Table 4.26: Details of Internal Accruals submitted by MSPGCL (Rs. Crore) ............ 73
Table 4.27: Debt and Equity as on COD submitted by MSPGCL .............................. 74
Table 4.28: Means of Finance considered by the Commission (Rs. Crore) ................ 74
Table 5.1: Imported Coal supply schedule submitted by MSPGCL ............................ 75
Table 5.2: Study on usage of coal submitted by MSPGCL ......................................... 78
Table 5.3: Calorific Value and Price of Fuel submitted by MSPGCL ........................ 79
Table 5.4: Landed Price and Calorific Value of Fuel considered by the Commission 80
MERC, Order in Case No 44 of 2013 Page 6
Table 5.5: Comparison of Bunkered Calorific Value and Weighted Average Calorific
Value ............................................................................................................................ 81
Table 5.6: Actual Realisation of coal during FY 2012-13 submitted by MSPGCL .... 86
Table 5.7: Impact on performance parameters submitted by MSPGCL ...................... 87
Table 5.8: Performance parameters approved by the Commission ............................. 89
Table 5.9: Energy Charge approved by the Commission for FY 2012-13 .................. 89
Table 5.10: Details of Additional Capitalisation submitted by MSPGCL .................. 91
Table 5.11: Quantum of Spares after COD and upto cut-off date approved by the
Commission (Rs. Crore) .............................................................................................. 93
Table 5.12: Additional Capitalisation for FY 2012-13 approved by the Commission 93
Table 5.13: O&M expenses for FY 2012-13 submitted by MSPGCL ........................ 95
Table 5.14: Computation of escalation rate for FY 2008-09 submitted by MSPGCL 95
Table 5.15: Basis for Escalation rates submitted by MSPGCL ................................... 96
Table 5.16: WPI data submitted by MSPGCL ............................................................ 96
Table 5.17: CPI data submitted by MSPGCL .............................................................. 96
Table 5.18: WPI Inflation submitted by MSPGCL ..................................................... 96
Table 5.19: CPI Inflation submitted by MSPGCL ...................................................... 96
Table 5.20: Computation of escalation rate for FY 2012-13 submitted by MSPGCL 97
Table 5.21: O&M expenses approved by the Commission for FY 2012-13 (Rs. Crore)
..................................................................................................................................... 98
Table 5.22: Depreciation for FY 2012-13 approved by the Commission ................... 99
Table 5.23: Loan Drawal considered by the Commission for FY 2012-13 (Rs. Crore)
................................................................................................................................... 102
Table 5.24: Loan repayment submitted by MSPGCL ............................................... 102
Table 5.25: Interest on Loan approved by the Commission (Rs. Crore) ................... 103
Table 5.26: Advance Against Depreciation approved by the Commission (Rs. Crore)
................................................................................................................................... 104
Table 5.27: Return on Equity for FY 2012-13 approved by the Commission (Rs.
Crore) ......................................................................................................................... 105
Table 5.28: Income Tax approved by the Commission for FY 2012-13 (Rs. Crore) 106
Table 5.29: Interest on Working Capital approved by the Commission for FY 2012-13
(Rs. Crore) ................................................................................................................. 107
Table 5.30: AFC approved by the Commission for Khaperkheda Unit # 5 for FY
2012-13 (Rs. Crore) ................................................................................................... 108
Table 5.31: Tariff approved by the Commission for FY 2012-13 ............................. 108
MERC, Order in Case No 44 of 2013 Page 7
List of Figures
Figure 1: Timeline for development of 500 MW Units by Central Utilities submitted
by MSPGCL ................................................................................................................ 35
Figure 2: Timeline for development of 500 MW Units by State Sector Utilities
submitted by MSPGCL ................................................................................................ 35
MERC, Order in Case No 44 of 2013 Page 8
List of Abbreviations
AAD Advance Against Depreciation
ABT Availability Based Tariff
AFC Annual Fixed Cost
AHP Ash Handling Plant
APH Air Pre Heater
ARR Aggregate Revenue Requirement
ATE Appellate Tribunal for Electricity
A&G Administrative & General
BHEL Bharat Heavy Electricals Ltd.
BTG Boiler, Turbine and Generator
CEA Central Electricity Authority
CERC Central Electricity Regulatory Commission
CHP Coal Handling Plant
COD Commercial Operation Date
CPI Consumer Price Index
CPRI Central Power Research Institute
CV Calorific Value
CIL Coal India Limited
CPRI Central Power Research Institute
DCB Domestic Competitive Bidding
DPR Detailed Project Report
EA 2003 Electricity Act, 2003
FC Financing Charges
FD Forced Draft
FO Furnace Oil
FSA Fuel Supply Agreement
FY Financial Year
GAAP Generally Accepted Accounting Principles
GCV Gross Calorific Value
GFA Gross Fixed Assets
GoM Government of Maharashtra
IBPL India Bulls Power Ltd.
ICB International Competitive Bidding
ID Induced Draft
IWC Interest on Working Capital
kcal kilo calories
MERC, Order in Case No 44 of 2013 Page 9
kg Kilogram
kV kilo Volt
kW Kilo Watt
kWh kiloWatt hour
LD Liquidated Damages
LDO Light Diesel Oil
MAT Minimum Alternative Tax
MDBFP Motor Driven Boiler Feed Pump
MERC Maharashtra Electricity Regulatory Commission
MGR Merry-Go-Round
Mkcal Million kilo calories
MMT Million Metric Tonne
MoU Memorandum of Understanding
MSEB Maharashtra State Electricity Board
MSEDCL/
MAHADISCOM
Maharashtra State Electricity Distribution Co. Ltd.
MSETCL Maharashtra State Electricity Transmission Company
Ltd.
MSLDC/SLDC Maharashtra State Load Despatch Centre
MSPGCL Maharashtra State Power Generation Company Limited
MT Metric Tonnes
MTPA Million Tonne per Annum
MU Million Units
MW Mega Watt
NTPC National Thermal Power Corporation
O&M Operations and Maintenance
PLF Plant Load Factor
PLR Prime Lending Rate
PPA Power Purchase Agreement
R&M Repair & Maintenance
RoE Return on Equity
RTD Resistance Temperature Detector
SFO Secondary Fuel Oil
SFOC Secondary Fuel Oil Consumption
SHR Station Heat Rate
STPP Super Thermal Power Plant
STPS Super Thermal Power Station
MERC, Order in Case No 44 of 2013 Page 10
TDBFP Turbine Driven Boiler Feed Pump
Th.MT Thousand Metric Ton
TPS Thermal Power Station
TVS Technical Validation Session
WCL Western Coalfields Ltd.
WPI Wholesale Price Index
MERC, Order in Case No 44 of 2013 Page 11
1 BACKGROUND AND BRIEF HISTORY
1.1 Background
1.1.1 This Order relates to the Petition filed by Maharashtra State Power Generation
Company Limited (MSPGCL) for determination of Capital Cost and Tariff for
FY 2012-13 for the newly commissioned Khaperkheda Unit # 5 of 500 MW
capacity. MSPGCL is a Company formed under the Government of
Maharashtra General Resolution No. ELA-1003/P.K.8588/Bhag-2/Urja-5
dated 24 January, 2005 with effect from 6 June, 2005 according to the
provisions envisaged in Part XIII of the EA 2003. MSPGCL is a Company
registered under the Companies Act, 1956.
1.1.2 MSPGCL, in its Petition, has prayed as under:
“
a. Approve the Capital Cost and Tariff of the unit for FY 2012-13 as
computed.
b. Allow any additional submission of MSPGCL for approval of Tariff for
Khaperkheda Unit # 5 for FY 2012-13.
c. Provide the Petitioner with the workable excel model used to determine
the final tariff of the unit.
d. Condone any shortcomings in the petition and allow the Petitioner to
submit additional information as may be required by the Commission at a
later stage.
e. Allow MSPGCL to recover fixed cost and energy charges as per the tariff
to be approved from MSEDCL through Energy Bills from the date of
order.
f. Issue appropriate directives to MSEDCL for payment of the dues to
MSPGCL with respective financial year of the date of the order.
g. Allow MSPGCL to recover the difference in the current tariff/provisional
tariff vis-a-vis the final tariff to be approved in this petition from the date
of issue of order.
h. Issue any such further orders as the Commission may deem fit.”
1.1.3 The Petitioner submitted that it owns eight thermal Power Stations including
one Gas Power Station, and also operates and maintains hydro Stations located
in the State of Maharashtra. The Petitioner submitted that having added four
Units of 250 MW each (Paras Unit # 3, Paras Unit # 4, Parli Unit # 6 & Parli
Unit # 7), the Company, in its endeavour to increase the power generating
MERC, Order in Case No 44 of 2013 Page 12
capacity in the State of Maharashtra, commissioned Khaperkheda Unit # 5 on
16 April, 2012 with an installed capacity of 500 MW.
1.1.4 The Petitioner submitted that it has entered into a Power Purchase Agreement
(PPA) with Maharashtra State Electricity Distribution Company Limited
(MSEDCL) for supply of power from the said Unit for a period of 25 years.
1.1.5 The Petitioner submitted that the Commission vide its MYT Regulations, 2011
dated 4 February, 2011 introduced the second MYT Control Period regime in
the State of Maharashtra with effect from 1 April, 2011. The Petitioner
submitted that it was granted two years exemption from MYT second Control
Period regime by the Commission vide its Order dated 23 August, 2011 in
Case No. 44 of 2011 and accordingly, the second Control Period regime for it
would be applicable from FY 2013-14 to FY 2015-16. The Petitioner
submitted that in light of the aforesaid Order, it has filed the present Petition
for determination of Tariff for Khaperkheda Unit # 5 for the period 16 April,
2012 to 31 March, 2013 based on MERC (Terms and Conditions of Tariff)
Regulations, 2005.
1.2 Admission of the current Petition and Public Hearing process
1.2.1 A set of data gaps were forwarded to MSPGCL on 12 April, 2013. Further, the
Commission raised additional data gaps to ensure adequacy of information for
processing the Petition. The data gaps raised by the Commission can be
grouped under the following heads:
a. Methodology of arriving at original cost estimates as shown in DPR
submitted
b. Details of Competitive Bidding process conducted for award of various
Packages
c. Board approval at various levels of execution
d. Justification for revision in Cost Estimates
e. Verification of actual expenditure incurred
f. Justification for increase in Cost under various heads
g. Fuel related issues.
1.2.2 The first Technical Validation Session (TVS) was held on 17 April, 2013.
During the TVS, the Petitioner made a presentation focusing on salient
features of the Petition. The Petitioner also highlighted issues such as increase
MERC, Order in Case No 44 of 2013 Page 13
in Capital Cost of the Unit as compared to original estimated cost, delays in
implementation, reasons for delay, and measures taken by MSPGCL to
minimize the increase in Project Cost due to time overruns. The list of
individuals, who participated in the TVS held on 17 April, 2013 is provided at
Appendix-1.
1.2.3 The second TVS was held on 9 May, 2013. During the TVS, MSPGCL
presented the comparison of Capital Cost of Khaperkheda Unit # 5 with other
similar projects of 500 MW Unit size. MSPGCL also presented the
comparison of Capital Cost of Khaperkheda Unit # 5 with benchmarking of
Capital Cost (Hard Cost) for Thermal Power Stations with Coal as fuel
notified by CERC vide its Order dated 4 June, 2012. MSPGCL also presented
the Fuel Supply Agreement (FSA) details of Khaperkheda Unit # 5 and
performance parameters during FY 2012-13. In the second TVS, the
Commission directed MSPGCL and Officers of the Commission to hold
meetings for joint inspection of the internal files related to Khaperkheda Unit
# 5. The list of individuals, who participated in the TVS held on 9 May, 2013
is provided at Appendix-2.
1.2.4 The Officers of the Commission held meetings in this regard with MSPGCL
on 14 May, 2013, 17 May, 2013, 21 May, 2013 and 6 June, 2013.
1.2.5 The third TVS was held on 23 May, 2013. In the third TVS, MSPGCL
presented the comparison of Capital Cost of Khaperkheda Unit # 5 with Power
Stations of NTPC and CERC benchmarks on Capital Cost (Hard Cost).
Further, MSPGCL presented the analysis of factors impacting the IDC. The
list of individuals, who participated in the TVS held on 23 May, 2013 is
provided at Appendix-3.
1.2.6 MSPGCL submitted the replies to data gaps raised vide its letters dated 26
April, 2013, 7 May, 2013, 15 May, 2013, 30 May, 2013, 7 June, 2013 and 1
August, 2013.
1.2.7 The Commission admitted MSPGCL’s Petition on 12 June, 2013. In
accordance with Section 64 of the Electricity Act, 2003, the Commission
directed MSPGCL to publish its Petition in the abridged form to ensure due
public participation. The Public Notice was published in the following
newspapers inviting suggestions/objections from the stakeholders.
MERC, Order in Case No 44 of 2013 Page 14
Table 1.1: Newspaper Notice of Public Hearing
Name of the Newspaper Date of Publication
Free Press journal (English)
20 June, 2013 Saamna (Marathi)
Pudhari (Marathi)
Times of India (English)
1.2.8 The copies of MSPGCL’s Petition and its Executive Summary were made
available at MSPGCL’s offices and on MSPGCL’s website
(www.mahagenco.in). The copy of the Public Notice and Executive Summary
of the Petition was also available on the website of the Commission
(www.mercindia.org.in) in downloadable format. The Public Notice specified
that the objections and comments, either in English or Marathi, may be filed
along with the proof of service on MSGPCL.
1.2.9 The Commission received objections/suggestions/comments from 6
stakeholders in writing on the Petition filed by MSPGCL for determination of
Capital Cost and Tariff of Khaperkheda Unit # 5 for FY 2012-13.
1.2.10 The public Hearing in the matter was held on16 July, 2013 at 11:00 hrs. at the
Commission’s Office. The list of individuals who participated in the Public
hearing is provided in Appendix – 4. The Commission has ensured that the
due process as contemplated under the law to ensure transparency and public
participation was followed at every stage meticulously and adequate
opportunity was given to all the persons concerned to file their say in the
matter.
1.3 Organisation of the Order
This Order is organised in the following six Sections:
Section 1 of the Order provides a brief history of the quasi-judicial regulatory
process undertaken by the Commission. For the sake of convenience, a list of
abbreviations with their expanded forms has been included.
Section 2 of the Order lists out the various suggestions and objections raised by
the objectors in writing as well as during the Public Hearing before the
Commission. Various suggestions and objections have been summarized,
MERC, Order in Case No 44 of 2013 Page 15
followed by the response of MSPGCL and the rulings of the Commission on each
of the issues.
Section 3 of the Order deals with the approach of this Order.
Section 4 deals with approval of Capital Cost of Khaperkheda Unit # 5.
Section 5 deals with the determination of Tariff for Khaperkheda Unit # 5 for FY
2012-13.
MERC, Order in Case No 44 of 2013 Page 16
2 OBJECTIONS RAISED, RESPONSE FROM MSPGCL
AND COMMISSION’S VIEW
2.1 CAPITAL COST
2.1.1 Shri. Pratap Hogade, Maharashtra Veej Grahak Sanghatana, submitted that the
Capital Cost of Khaperkheda Unit # 5 of 500 MW is Rs. 3376.90 Crore, i.e.,
Rs. 6.7538 Crore per MW while the Capital Cost of the recently
commissioned other Units is Rs. 4.5 Crore/MW to Rs. 5 Crore/MW. He
submitted that the Capital Cost of Khaperkheda Unit # 5 is almost 1.5 times
higher as compared to other Units and the submission of MSPGCL should be
carefully scrutinised.
2.1.2 Shri. R. B. Goenka, Vidarbha Industries Association, submitted that the capital
cost approved on March 28, 2006 for Khaperkheda Unit # 5 was Rs. 2169.88
Crore, which was inclusive of the IDC amounting to Rs.147.88 Crore. He
submitted that the BTG and BoP contracts awarded to M/s. BHEL on 23
January, 2007 and M/s. BGR on 3 July, 2007, respectively, totalled up to Rs.
2708.93 Crore, which is an increase of Rs. 539.05 Crore in a span of 10 to 12
months. He suggested that the Commission should enquire about this
escalation in the price within a span of only 10 to 12 months.
2.1.3 Shri. R. B. Goenka submitted that the contracts do not include Liquidated
Damages (LD) clause, but include Price Variation Clause (PVC). He further
submitted that the delay in the project and cost escalation was due to the use of
poor quality material, which was rejected by quality control of MSPGCL and
delay in erection by contractors and in such a case, PVC cannot be applied and
LD clause should have been invoked. He also submitted that apart from PVC
Clause, MSPGCL incurred additional cost on IDC, which increased from Rs.
147.88 Crore to Rs. 667.35 Crore.
2.1.4 Shri. R. B. Goenka submitted that the final project cost approved by the Board
of MPSGCL on 24 May, 2010 is Rs. 3219.66 Crore but the cost as on COD is
Rs. 3376.90 Crore which works out to be Rs. 6.753 Crore/MW and in today’s
market cost per MW cost for coal based super critical thermal power plants is
between Rs. 4.75 Crore/MW to Rs. 5 Crore/MW. He further submitted that the
capital cost of MSPGCL is almost 35 to 40% higher than market rates and the
Commission should initiate an enquiry and should not approve purchase of
power through this project.
MERC, Order in Case No 44 of 2013 Page 17
2.1.5 Shri. Babanrao Chaure, Maharashtra Chamber of Commerce, Industry &
Agriculture, requested the Commission to refer to the Petition of Korba Super
Thermal Power Station Stage-III of 500 MW capacity for comparison and
evaluation of various parameters of Khaperkheda Unit # 5. He submitted that
the order for Main Plant equipment of Khaperkheda Unit # 5 was placed on
BHEL in January, 2007 while that of Korba project was placed in March,
2006 and BTG equipments in both the projects were ordered from BHEL but
BHEL had completed Korba Project within stipulated time as compared to
Khaperkheda Unit # 5. He requested the Commission to conduct the hearing
on this Petition in front of all the contractors/stakeholders as MSPGCL has
submitted that the cause of delay is due to BHEL and other
contractors/agencies. He further submitted that the proposal should be
evaluated and reviewed considering the Petition filed by Korba Stage III
project and Public Private Partnership based Indiabulls owned project of
Nasik/Amravati of 1300 MW as the said Project had already been completed
before time by BHEL and other contractors and is waiting for fuel linkage/rail
linkage.
2.1.6 Shri. Ashok Pendse, Thane Belapur Industries Association, submitted that the
Commission vide its Order dated 30 November, 2011 in Case No. 71 of 2011
has approved the PPA for 7 Units of MSPGCL. Shri. Ashok Pendse submitted
that the PPA for Parli Unit # 7, Parli Unit # 8, Bhusawal Unit # 4, Bhusawal
Unit # 5 and Nasik are yet to be submitted for approval. He submitted that
whatever philosophy, the Commission adopts for approval of tariff for
Khaperkheda Unit # 5, it will have to be repeated for all the stations for which
PPA’s have been signed and hence, the philosophy adopted by the
Commission is crucial. Shri. Ashok Pendse submitted that Paras Unit # 3, Parli
Unit # 6 and Tata Power Company-Generation’s Unit # 8 were synchronised
in a span of about 6 to 8 months of each other and all the three Units got
equipment from BHEL. He submitted that the capital cost per MW of Paras
Unit # 3 and Parli Unit # 6 is 52% higher than capital cost per MW of TPC-G
Unit # 8. Shri. Ashok Pendse submitted that MSPGCL has submitted the
reasons for delay because of BHEL, which is the common supplier for the said
three Units. Shri. Ashok Pendse submitted that the decision of Hon’ble ATE
regarding allowance of pass through 50% of incremental expenses due to
delay to the consumers is an adhoc decision and the Commission should not
consider it in finality.
MERC, Order in Case No 44 of 2013 Page 18
2.1.7 Shri. Ashok Pendse submitted that if MSPGCL can procure 250 MW Units at
Rs. 6.25 Crore/MW as against the cost per MW of Rs. 7.50 Crore/MW of
Khaperkheda Unit # 5 of 500 MW, configuration of 2x250 MW should be
considered as compared to 1x500 MW. He submitted that approved capital
cost per MW of Vindhyachal Super Thermal Power Station is Rs. 5.23
Crore/MW, NTPC Mauda is Rs. 6.92 Crore/MW, Essar Power Gujarat is Rs.
4.80 Crore/MW, Adhunik Power Chhattisgarh is Rs. 6.10 Crore/MW. He
further submitted that while the capital cost per MW for other projects is in the
range of Rs. 5 to 6 Crore/MW, the cost of Rs. 7.50 Crore/MW of Khaperkheda
Unit # 5 is on higher side. He submitted that in case of Paras and Parli new
Units, the reason for high cost was BHEL and in Khaperkheda Unit # 5, the
reason is high interest cost. Shri. Ashok Pendse submitted that the capital cost
per MW should be capped at Rs. 6 Crore/MW as it has implications on other
projects wherein Power Purchase Agreement has been signed.
MSPGCL’s reply
2.1.8 MSPGCL submitted that as per CERC norms on benchmarking of Capital
Cost dated 4 June, 2012, the capital cost for newly commissioned plants of
capacity 1x500 MW is Rs. 5.05 Crore/MW which is exclusive of taxes and
duties, IDC, coal handling, unloading equipment at jetty, wagon rakes, railway
siding, rolling stock, railway engine, etc. MSPGCL replied that the total cost
including the above would be Rs. 5.93 Crore/MW and that of Khaperkheda
Unit # 5 is Rs. 5.42 Crore/MW. MSPGCL replied that the estimates show that
the capital cost of Khaperkheda Unit # 5 is as per the norms specified by
CERC. MSPGCL replied that as per the prevalent industry rates, the
mentioned capital cost of Rs. 4.5 to 5 Crore /MW for a 500 MW plant is not at
all feasible. MSPGCL replied that the Capital Cost per MW of Rihand TPP
(2x500 MW) is Rs. 6.23 Crore/MW, Mauda TPP (2x500 MW) is Rs. 6.01
Crore/MW, and Vallur TPP (2x500 MW) is Rs. 6.06 Crore.
2.1.9 MSPGCL replied that CERC norms indicate that for a 2x500 MW plant, the
capital cost per MW reduces by approximately 16% as compared to 1x500
MW. The cost reduction is dependent on tax on equipment, interest costs, etc.
MSPGCL replied that a Company with a favourable credit rating can avail
loans at a lower interest rate. MSPGCL replied that it being a BBB rated
entity, has higher interest cost as compared to NTPC with AAA rating.
MSPGCL replied that it has put in efforts to reduce the capital cost to a great
extent. MSPGCL replied that orders for BTG and BoP contracts have been
placed with renowned companies under competitive bidding and Contractual
MERC, Order in Case No 44 of 2013 Page 19
agreements with the Companies have been signed to eliminate cost overruns
and time overruns. MSPGCL replied that as compared to other projects,
MSPGCL has given detailed cost calculations for Khaperkheda Unit # 5,
which has been determined by adequate discretion.
Commission’s view
2.1.10 Regulation 30.1 of MERC (Terms and Conditions of Tariff) Regulations, 2005
specifies as under:
“Subject to prudence check by the Commission, the actual expenditure
incurred on completion of the project shall form the basis for determination of
the original cost of project....”
2.1.11 The present Petition is for determination of capital cost and tariff for the newly
commissioned Khaperkheda Unit # 5, for which the Commission has carried
out the prudence check of Capital Cost of Khaperkheda Unit # 5. The Hon’ble
ATE in its order dated 27.04.11 in Appeal No. 72 of 2010 in Para 7.2 of its
order, has explained the scope of prudence check as under:
“The capital cost has to be determined on the basis of actual expenditure
incurred on completion of the project subject to prudence check by the State
Commission. The dictionary meanings of the word ‘prudent’ are “sensible and
careful when you make judgments and decisions and avoiding unnecessary
risk”. The prudence check of the capital cost has to be looked into considering
whether the Appellant has been careful in its judgments and decisions while
executing the project or has been careful and vigilant in executing the
project.”
2.1.12 Thus, the scope of prudence check is to examine whether the Petitioner has
been careful and vigilant in taking decisions while executing the project. The
Commission has hence, looked into the justification given by MSPGCL in
respect of any change in scope of items of work, reasons for increase in cost as
compared to estimated cost, reasons for delay in project and process of
awarding various contracts. As regards the comparison of Capital Cost with
other projects, the Commission is of the view that such analysis is important to
analyse the price trends, but such a comparison cannot be absolute in
determining the prudence of cost incurred for a particular project as the cost of
project varies from project to project depending on the ground realties and
project specific features. The prudence check carried out by the Commission
MERC, Order in Case No 44 of 2013 Page 20
in approving the Capital Cost of Khaperkheda Unit # 5 is detailed in further
Sections of this Order.
2.1.13 As regards the increase in Capital Cost in ordering Cost vis a vis Capital Cost
originally approved by the Board, MSPGCL in its submissions has mentioned
that the original estimates of Khaperkheda Unit # 5 were mere estimates while
the Ordering Cost was the cost discovered through Competitive Bidding
Process for the award of respective packages. The Commission has gone
through the details of Contracts Awarded while carrying out the prudence
check of the Capital Cost as detailed in further Sections of this Order.
2.2 TARIFF
2.2.1 Shri. Pratap Hogade submitted that considering the fixed cost of Rs. 596.21
Crore and generation of 1991.93 MU for FY 2012-13, the fixed cost per kWh
is Rs. 2.99. Shri. Pratap Hogade submitted that in future, assuming a PLF of
75%, the generation would be 3285 MU and fixed cost per kWh would be Rs.
1.82 which is also on the higher side. Shri. Pratap Hogade also submitted that
the Energy Charge of Rs. 3.21/kWh during stabilisation period and Rs.
2.84/kWh post stabilisation period is also on the higher side.
2.2.2 Shri. R. B. Goenka submitted that the sum of projected fixed cost for FY
2012-13 of Rs. 2.99/kWh and variable cost of Rs. 2.96/kWh is Rs. 5.95/kWh
and this is very high in today’s market scenario. Shri. R. B. Goenka submitted
that the PLF of 32.85% during the stabilisation period and 51.68% post
stabilisation period indicates inefficient working of MSPGCL. Shri. R. B.
Goenka submitted that for super critical thermal power plant the coal
consumption of E grade coal is about 0.65kg/kWh, and hence the variable cost
at 100% efficiency considering oil consumption should be about Rs.
0.95/kWh. Shri. R. B. Goenka submitted that even at 50% efficiency, the
variable cost should not be more than Rs. 1.8/kWh. He further submitted that
the high cost of power from Khaperkheda Unit # 5 should not be permitted to
be purchased by MSEDCL as cheaper power is available in the market.
2.2.3 Shri. R. B. Goenka submitted that there are number of Captive Power Plants
and private power plants that are kept idle as MSEDCL had denied purchase
of power even at Rs. 3.50 per unit. Shri. R. B. Goenka submitted that in the
Power Exchanges, the average power cost in last 3 months is ranging from Rs.
2/unit to Rs. 2.5/unit. Shri. R. B. Goenka submitted that the Commission had
MERC, Order in Case No 44 of 2013 Page 21
approved power purchase rates of MSEDCL from JSW at Rs. 3.54/kWh,
Adani Power at Rs. 2.55/kWh, EMCO at Rs. 2.87/kWh and IBPL at Rs.
3.26/kWh. Shri. R. B. Goenka requested the Commission to direct MSEDCL
to purchase power in merit order system only.
2.2.4 Shri. Babanrao Chaure submitted that in its Petition, MSPGCL had not shown
the detailed tariff working. Shri. Babanrao Chaure submitted that MSPGCL is
deviating from the principles of determination of Tariff. He submitted that the
Annual Fixed Charges of Khaperkheda Unit # 5 are Rs. 596.21 Crore and rate
of Energy Charge per unit is Rs. 2.96/kWh against 81.867 Paise/kWh of
Korba Project and hence, Khaperkheda Unit 5 rates are 3.61 times higher than
Korba Project.
2.2.5 Shri. Raksh Pal Abrol, Bharatiya Udhami Avam Upbhokta Sangh, submitted
that the Annual Fixed Charges for Khaperkheda Unit # 5 for FY 2012-13 is
Rs. 596.21 Crore and Variable Cost is Rs. 2.96/kWh. He submitted that the
data submitted by MSPGCL for Khaperkheda Unit # 5 for FY 2012-13 is not
comparable with the parameters approved by the Commission for Dahanu
Generating Station of 500 MW of Reliance Infrastructure Company Limited -
Generation for FY 2012-13, which utilises Domestic Coal and Imported Coal.
He submitted that the Commission should carry out the analysis of the figures
provided by MSPGCL for Khaperkheda TPS and of Unit # 5 of 500 MW
capacity.
2.2.6 Shri. Ashok Pendse submitted that Tata Power Company-Generation can
procure coal from mines in Australia and domestic coal is available to
MSPGCL and hence, MSPGCL has advantage of 20% in respect of energy
cost. He submitted that the fixed cost of Khaperkheda is Rs. 2.38/kWh and
variable cost is Rs. 1.77/kWh at 80% PLF and Rs. 2.52/kWh at 56% PLF and
hence, the total cost is Rs. 4.15-4.90/kWh. He further submitted that the fixed
cost of Khaperkheda Unit # 5 is very high in comparison to that of M/s Adani
at Rs. 1.11/kWh.
2.2.7 Shri. George John submitted that the Fixed Charges for FY 2012-13 is Rs. 596
Crore and considering 3500 MU, the rate of Fixed Charge at Rs. 1.70/kWh is
very high. Shri. George John requested for the following information with
regard to Khaperkheda Unit # 5:
a. MU generated during Stabilisation period
b. MU generated post Stabilisation period
MERC, Order in Case No 44 of 2013 Page 22
c. Rate of depreciation considered and amount on which depreciation is
worked out
d. Working capital, Rate of interest considered for working capital and
duration for which working capital is computed
e. Equity base considered for computation of RoE and rate of return
considered
f. Variable Charge for FY 2012-13
g. Variation in Heat rate during Stabilisation Period and post Stabilisation
period.
MSPGCL’s reply
2.2.8 MSPGCL replied that the components of fixed costs are Depreciation, Interest
on Loan, O&M costs, RoE and income tax as per Regulations. MSPGCL
replied that inadequate coal supply of around 62.59% of the contracted
amount during the stabilization period led to reduced generation. MSPGCL
replied that it is noteworthy to highlight that projects of approximately 15000-
20000 MW capacity have been delayed due to shortage of coal and in view of
the scarcity of coal all over the country, CIL has issued directives of blending
of imported coal with domestic coal; the import of the same has to be
undertaken by the power producers. MSPGCL replied that this would lower
the fixed costs but simultaneously raise the variable cost of generation.
MSPGCL replied that it is making efforts to maximize generation and has
used blended coal as stipulated.
Commission’s view
2.2.9 The Commission has notified the MERC (Terms and Conditions of Tariff)
Regulations, 2005, the applicability of which has been extended till FY 2012-
13 for MSPGCL. In the said Regulations, the Commission has laid out the
principles for determination of Annual Fixed Charges and Energy Charges for
a Generating Station. The Commission had also specified the norms of
Availability, Auxiliary Energy Consumption, Gross Station Heat Rate,
Secondary Oil Consumption and Transit Loss for operation of Thermal
Generating Stations in the Regulations. MERC Tariff Regulations, 2005 also
specifies the mechanism of sharing of gains and losses on account of
controllable and uncontrollable factors. The Commission has approved the
Fixed Charges and Energy Charge of Khaperkheda Unit # 5 for FY 2012-13 in
accordance with the provisions of MERC Tariff Regulations, 2005, as
discussed in detailed in subsequent Sections of the Order.
MERC, Order in Case No 44 of 2013 Page 23
2.3 MERIT ORDER DESPATCH
2.3.1 Shri Pratap Hogade submitted that the power purchase cost of MSEDCL
through medium term/short term sources is Rs. 4/kWh to Rs. 4.25/kWh and
the power purchase cost through long term PPA is much lesser. He submitted
that price of electricity from Adani is Rs. 2.64/kWh, Jindal is Rs. 3.33/kWh,
Mundra is Rs. 2.52/kWh, India Bulls is Rs. 3.28/kWh and from short and
medium term market at Rs. 4/kWh. Shri. Pratap Hogade submitted that in
view of availability from cheaper generation sources, power should not be
bought at higher price from Khaperkheda Unit # 5.
2.3.2 Shri Pratap Hogade submitted that MSEDCL and other Distribution Licensees
are bound to procure power from low cost generation sources in accordance
with the provisions of Merit Order Despatch. He requested the Commission
that power should be bought only from low cost Units of MSPGCL in
accordance with the provisions of Merit Order Despatch. Shri. Pratap Hogade
submitted that allowing procurement of power from sources with high cost of
generation would encourage inefficiency in the form of lower PLF and would
contradict with the spirit of competition envisaged in Electricity Act, 2003 and
consumer protection rights. Shri. Pratap Hogade requested the Commission to
give appropriate directions in this regard.
MSPGCL’s reply
2.3.3 MSPGCL replied that the Commission had approved the PPA between
MSPGCL and MSEDCL after due regulatory process. MSPGCL replied that
as per the principles of tariff determination for actual recovery of costs,
satisfactory performance of the generation as per norms is required and in case
of underperformance, the Commission does not allow recovery of variable
cost and fixed costs recovery is also reduced on a pro-rata basis, which has
been faced by MSPGCL. MSPGCL replied that SLDC is authorized to
determine the load dispatch schedule and the principles of merit order dispatch
is followed and the directive of the SLDC is binding on the utilities. MSPGCL
replied that all new Units of MSPGCL have tariffs determined separately
whereas old Units have cumulative tariff. MSPGCL replied that similarly the
tariff of Khaperkheda Unit # 5 will be determined separately from other Units
and the same will be taken into account in merit order dispatch. MSPGCL
replied that Merit order dispatch is followed in Maharashtra in the strict sense
of the term.
MERC, Order in Case No 44 of 2013 Page 24
Commission’s view
2.3.4 The present ABT mechanism allows MSLDC to schedule energy by applying
merit order to the entire State of Maharashtra. In this mechanism, all the
generating Units of the State are ranked in the order of the variable cost and
the costliest Unit is dispatched the last.
2.4 PROJECT MANAGEMENT
2.4.1 During Public Hearing, Shri. Sridhar stated that the project administration and
implementation of MSPGCL should be in an efficient manner to safeguard the
interest of the consumers.
MSPGCL’s reply
2.4.2 In response to the comments received, MSPGCL in its reply stated that the
project was efficiently monitored and managed by the Project Department and
review of same is taken at Head Office periodically.
Commission’s view
2.4.3 The Commission is of the view that the project management technique of
MSPGCL needs to be improved further and proper co-ordination with major
contractors should be done for a focused approach to ensure timely completion
of all stages of the project.
MERC, Order in Case No 44 of 2013 Page 25
3 APPROACH OF THIS ORDER
3.1.1 MSPGCL filed the present Petition for determination of Capital Cost and
Tariff of Khaperkheda Unit # 5 for FY 2012-13 under Sections 61, 62 and
86(1)(a)(b) of the Electricity Act, 2003 and Part E of MERC (Terms and
Conditions of Tariff) Regulations, 2005.
3.1.2 It is to be noted that MERC (Terms and Conditions of Tariff) Regulations,
2005 were applicable till the end of FY 2010-11. The Commission notified the
MERC (Multi Year Tariff) Regulations, 2011 to be applicable from FY 2011-
12 to FY 2015-16. However, the Commission exempted MSPGCL from
applicability of MERC MYT Regulations, 2011 for a period of 2 years
through its Order dated 23 August, 2011 in Case No. 44 of 2011. The said
dispensation reads as follows:
“There is no choice but to enable the Petitioner to file its ARR and Tariff
filings under the “Maharashtra Electricity Regulatory Commission (Terms
and Conditions of Tariff) Regulations, 2005”.
“In light of the above, the Commission is of the view that it has become
necessary to invoke the proviso to Regulation 4.1 of MYT Regulations, 2011 in
order to exempt the determination of tariff of the Petitioner under the Multi-
Year Tariff framework till March 31, 2013 (i.e., for a period of 2 years). The
said exemption is hereby granted. The Commission is also empowered under
Regulation 100 of MYT Regulations, 2011 to remove any difficulty arising in
giving effect to the provisions of MYT Regulations, 2011.”
3.1.3 Hence, the Commission in this Order has approved the Capital Cost and Tariff
of Khaperkheda Unit # 5 for FY 2012-13 in accordance with MERC (Terms
and Conditions of Tariff) Regulations, 2005.
MERC, Order in Case No 44 of 2013 Page 26
4 CAPITAL COST OF KHAPERKHEDA UNIT # 5
4.1 Capital Cost of Khaperkheda Unit # 5
4.1.1 As regards Capital Cost, Regulation 30.1 of MERC Tariff Regulations, 2005
specifies as under:
“Subject to prudence check by the Commission, the actual expenditure incurred
on completion of the project shall form the basis for determination of the
original cost of project. The original cost of project shall be determined based
on the approved capital expenditure actually incurred up to the date of
commissioning of the generating station and shall include capitalised initial
spares subject to following ceiling norms as a percentage of the original cost as
on cut-off date:
(i) Coal-based/lignite-fired generating stations - 2.5%
(ii) Gas Turbine/Combined Cycle generating Stations – 4.0%
(iii) Hydro power generating stations – 1.5%
Provided that where the power purchase agreement entered into between the
Generating Company and the Distribution Licensee provides a ceiling of actual
expenditure, the original cost of project shall not exceed such ceiling for the
purpose of these Regulations:
Provided further that in case of the existing generating stations, the actual
original cost of project recorded in the books of account of the Generating
Company, subject to prudence check by the Commission, shall be considered as
the original cost of project for the purpose of these Regulations.”
4.1.2 MSPGCL submitted that the proposal for developing 500 MW Khaperkheda
Unit # 5 was approved by the Board of MSPGCL vide the Board Resolution
MSPGCL/BM-9/Item-5 dated 28 March, 2006. MSPGCL submitted that as per
the said Resolution, the approved cost estimates were for Rs. 2170 Crore and it
included hard cost of Rs. 2022 Crore and IDC of Rs. 148 Crore. MSPGCL
submitted that IDC was calculated at a notional rate of 7.5%. MSPGCL
submitted that it had placed the BTG contract with M/s BHEL on 23 January,
2007 and M/s BGR was appointed for undertaking the BoP works on 3 July,
2007.
MERC, Order in Case No 44 of 2013 Page 27
4.1.3 MSPGCL submitted that the capital cost approved by its Board was indicative
in nature and should not be considered as base cost. MSPGCL submitted that
the project cost capitalised on the Date of Commercial Operation of the Unit is
Rs. 3376.90 Crore and it includes hard cost of Rs. 2709.55 Crore and IDC of
Rs. 667.35 Crore. The comparison of various components of Capital Cost as per
Orders placed for various packages of the Project (i.e., Ordering Cost) and
actual cost incurred (i.e., Cost as on COD) as submitted by MSPGCL is given in
Table below:
Table 4.1: Comparison of Ordering Cost and Cost as on COD submitted by MSPGCL
(Rs. Crore)
Particulars Ordering Cost Cost as on COD
Land & Site Development 35.00 29.00
BTG 1352.62 1427.14
BoP 666.59 641.80
Civil Works 563.87 483.96
Construction & Pre-
Commissioning activities 1.00 40.11
Overheads 89.85 87.53
IDC *658.15 667.35
Total 3367.08 3376.90
*Calculated
4.1.4 MSPGCL submitted that the key reasons for deviation in Ordering Cost vis-a-
vis the cost as on COD are as below:
a. Certain works in BTG, BoP Electrical and Mechanical and BoP Civil
which were supposed to be completed within COD are now in progress
beyond COD. MSPGCL submitted that these balance works are now
proposed to be completed within the cut-off date and capitalized under
additional capitalization.
b. The BTG contract has a price variation clause subject to a ceiling of
20% on the overall increase on account of indexed prices.
c. The difference in ordering cost and cost as on COD of Construction and
Pre-Commissioning activities is mainly due to the cost of fuel (Rs. 28.05
Crore) used for startup power generation.
MERC, Order in Case No 44 of 2013 Page 28
d. The project was scheduled to complete trial operations within 42 months
but was commissioned in a time period of around 63 months leading to
increase in IDC.
4.1.5 The analysis of submissions of MSPGCL and the Commission’s ruling on
various components of Capital Cost are detailed in the subsequent sections of
the Order.
4.2 Background to Project Commissioning
4.2.1 The Commission in its Order dated 10 January, 2006 in Case No. 35 of 2005
directed MSPGCL to explain through an affidavit its efforts to ensure the
implementation of its capacity addition programme as planned. Subsequently,
MSPGCL filed an affidavit before the Commission vide letter dated 29 April,
2006 enclosing the DPR of Khaperkheda Unit # 5 along with other Units under
its Capacity Addition Programme. The Commission on assessing the capacity
addition programme submitted by MSPGCL with reference to the provisions of
the Electricity Act, 2003, Tariff Policy and Tariff Regulations accorded the in-
principle clearance of the proposed capacity addition programme vide its letter
dated 14 July, 2006. In the said DPR of Khaperkheda Unit # 5, MSPGCL has
estimated a cost of Rs. 2170 Crore including IDC.
4.2.2 MSPGCL submitted that the proposal for developing 500 MW Khaperkheda
Unit # 5 was approved by its Board vide the Board Resolution MSPGCL/BM-
9/Item-5/ dated 28 March, 2006. As per the said resolution, the approved cost
estimate was for Rs. 2170 Crore. In the said Board Resolution, the Board
concluded to invite International Competitive Bidding (ICB) tenders for Main
Plant Package and separate tenders through Domestic Competitive Bidding
(DCB) for BoP Package including the civil works for Main Plant Package.
4.2.3 MSPGCL submitted that it had initiated ICB process for award of BTG and M/s
Ansaldo Caldie SpA (local associate in India: M/s Monnet Projects India Ltd.),
M/s BHEL and M/s Doosan Heavy Industries & Construction Co. Ltd.
purchased the bid documents. MSPGCL submitted that pursuant to ICB process,
M/s BHEL emerged as the sole participant and was found to qualify the
requirements of the RFP and the order was placed on M/s BHEL on 23 January,
2007.
MERC, Order in Case No 44 of 2013 Page 29
4.2.4 MSPGCL submitted that pursuant to Domestic Competitive Bidding, the
contract for BoP and other works was placed on M/s BGR Energy Systems on 3
July, 2007. MSPGCL submitted that out of 10 bidders who purchased the tender
document, only four bidders submitted their bid and the lowest bidder M/s BGR
was awarded the Contract for BoP and the civil and structural works of Main
Plant. The details of Award of BoP package as submitted by MSPGCL is given
in the Table below:
Table 4.2: Award of BoP Package submitted by MSPGCL
Package Agencies participated Qualified Agencies Final Order
placed on
BoP (Electrical,
Mechanical and
Civil)
1) Tata Projects Ltd. 1) Tata Projects Ltd. GEA Energy
Systems (I) Ltd.
(Later named as
BGR Energy
Systems Ltd.)
2) L&T Ltd. 2) Reliance Energy Ltd.
3) Reliance Energy Ltd. 3) GEA Energy Systems (I)
Ltd. (Later named as BGR
Energy Systems Ltd.)
4) GEA Energy Systems (I)
Ltd. (Later named as BGR
Energy Systems Ltd.)
4.2.5 MSPGCL submitted that in order to ensure least cost principle, it had adopted
the conventional route of inviting tenders through Competitive Bidding process
for placement of associated auxiliaries and sub-systems for Khaperkheda Unit #
5. MSPGCL submitted that the following agencies were awarded the other
works of Khaperkheda Unit # 5 through DCB as per details given in Table
below:
Table 4.3: Award of other Packages submitted by MSPGCL
S.
No. Package Agencies participated Qualified Agencies
Final Order
Placed on
Date of
Award
1 C.W. & R.W.
Ozonisation
1) M/s.SMS Infrastructure
Ltd., Nagpur
1) M/s.Ozone Research &
Applications Pvt. Ltd., Nagpur
M/s.Ozone
Research &
Applications Pvt.
Ltd., Nagpur
7
February,
2011 2) M/s.Ozone Research &
Applications Pvt. Ltd., Nagpur
2) M/s. Fluid Technologies,
Raipur
3) M/s. Fluid Technologies,
Raipur
2 Civil Works
(Staff
Quarters)
1) M/s.Shah Construction 1) M/s.Shah Construction M/s.Shah
Construction
13 June,
2007 2) M/s Nagarjun Construction 2) M/s Nagarjun Construction
3) M/s Laxmi Engineering 3) M/s Laxmi Engineering
4) M/s Metcon India 4) M/s Metcon India
MERC, Order in Case No 44 of 2013 Page 30
S.
No. Package Agencies participated Qualified Agencies
Final Order
Placed on
Date of
Award
3 Civil Works
(Railway
Sliding)
1) M/s.ARSS Infrastructure 1) M/s.ARSS Infrastructure M/s SMS
Infrastructure
22
October,
2008
2) M/s Indrajit Singh Chhabra 2) M/s Indrajit Singh Chhabra
3) M/s Suresh Chand Gupta 3) M/s Suresh Chand Gupta
4) M/s SMS Infrastructure 4) M/s SMS Infrastructure
5) M/s NMC Industries
4 Civil Works
(Railway
Sliding)
1) M/s.ISC Project 1) M/s.ISC Project M/s.ISC Project 21
October,
2008
2) M/s Suresh Chanda Gupta 2) M/s Suresh Chanda Gupta
5 Civil Works
(Ash Bund)
1) M/s. Ketan Construction 1) M/s MG Bhangdiya M/s Sunil Hitech
Engineer Ltd
-
2) M/s MG Bhangdiya 2) M/s Anoj Kumar Agarwal
3) M/s Anoj Kumar Agarwal 3) M/s R.N.Nayak & Sons
4) M/s R.N.Nayak & Sons 4) M/s SMS Infrastructure
Limited
5) M/s SMS Infrastructure
Limited
5) M/s Sharda Construction &
Corporation
6) M/s Sharda Construction &
Corporation
6) M/s Sunil Hitech Engineer
Ltd
7) M/s Sunil Hitech Engineer
Ltd
7) M/s Srihari Associates Pvt.
Ltd.
8) M/s Srihari Associates Pvt.
Ltd.
6 Civil Works
(Ash Bund)
1) M/s. Abhi Engineering
Corporation
1) M/s SMS Infrastructure M/s B.C Biyani
Projects Pvt. Ltd.
-
2) M/s SMS Infrastructure 2) M/s B.C Biyani Projects
Pvt. Ltd. 3) M/s Bhavana Energy
Infrastructure Pvt. Ltd.
4) M/s B.C Biyani Projects
Pvt. Ltd.
4.2.6 MSPGCL submitted that it is empowered to utilise the services of Government
Institute and Government undertaking on single quotation basis and in exercise
of such powers, the order for consultancy of Project Management for Railway
Siding was placed on M/s RITES on single quotation basis after assessing the
reasonability of the offer, specialised nature of work and expertise of M/s
RITES in executing similar type of work.
4.2.7 MSPGCL submitted that its Board has approved the revised cost estimates of
Khaperkheda Unit # 5 vide the Board Resolution MSPGCL/BM-69/Item-69.17/
dated 24 May, 2010. MSPGCL submitted that Power Finance Corporation
MERC, Order in Case No 44 of 2013 Page 31
(PFC) had sanctioned additional loan to the tune of 80% of revised cost estimate
vide its Loan Sanction letter dated 4 August, 2010.
4.2.8 MSPGCL submitted that due to the delays in execution of the Project, the
scheduled COD has been extended from 22 July, 2010 to actual COD 16 April,
2012. MSPGCL submitted that the Project was under constant supervision of
Ministry of Power, Government of India and Central Electricity Authority.
4.2.9 MSPGCL submitted that the following reasons contributed to the delay in
commissioning of the Unit:
Non-sequential material receipt such as LDO pump skid and related piping,
LDO trip valve, LDO pressure controller, igniters, scanner system, valve for
Boiler Light up, etc.
Award of contracts to BHEL in excess of their production capacities.
Shifting of some critical material such as Boiler Circulating pump, Ring
header of boiler, etc., to Dadri TPS as per the guidelines of Govt. of India as
same was to be commissioned within scheduled period for supply of power
to Commonwealth games.
Inadequate erection group/ manpower provided by the contractors.
Pre-project activities such as infrastructural development, roads, and
drainage compound wall work started after Zero date as per earlier policy
that led to delay in project.
Local issues like contractor strike, shortage of professional and technical
manpower of contractors led to delay.
Stator lifting activity delayed by 3 months.
Delay of 63 days occurred during shifting of ash slurry line to Waregoan due
to demand/agitation on 2 May, 2011 by local people to lay the line on ground
level instead of high level (on pedestals).
Problems faced in material storage, material handling and fabrication works
of BTG as well as BoP activities during construction due to space constraint.
Dismantling of old civil structure, in the vicinity of plant area took more time
than envisaged and was completed in December, 2010.
Non-readiness of FD and PA Fan A, ESP Pass B, TDBFP, CHP and AHP by
BHEL and BGR led to delay in start of trial operations.
Damages in equipments/ materials supplied and erected by BHEL.
MERC, Order in Case No 44 of 2013 Page 32
Supply of inadequate quantity of coal by MCL. MSPGCL submitted that the
delay in commissioning of the project due to non availability of coal was
communicated to the Commission vide the letter dated 19 May, 2012.
4.2.10 Further, MSPGCL submitted that the following reasons contributed to the delay
between Synchronisation and COD.
i) MSPGCL submitted that the following activities were pending in BHEL’s
scope:
FD & PA Fan A were not ready
ESP pass B was not ready
TDBFP was not ready
Standby station transformer was not ready
Unit Auxiliary Transformer was not ready
ii) MSPGCL submitted that the following activities were pending in BGR’s
scope:
Coal Handling Plant (Wagon tippler, CHP control room and CHP
second stream) was not ready
Ash Handling Plant (Pumps, Ash slurry disposal line and Transfer Air
Compressor) was not ready
iii) MSPGCL submitted that the following equipments/ materials supplied and
erected by BHEL were found damaged:
Control & Power cable of water wall soot blowers, coal mill dampers,
flames scanners, secondary air damper control actuators, positioners,
limit switches, igniters, burner tilt cylinders, Drum level transmitters,
thermocouples & RTDs laid between corner 3 & 4 of the boiler
Igniter hoses, Igniter transformers and oil gun hoses
Secondary air damper actuators, positioners, burner tilt cylinders
Drum level transmitters
Insulation at various locations at Corner no. 4 such as oil station at
firing floor, secondary air wind-box
iv) MSPGCL submitted that the Unit was synchronized on 22 November, 2011
and withdrawn on 24 November, 2011 due to water wall tube leakage in 9 mtr
S-panel.
MERC, Order in Case No 44 of 2013 Page 33
v) MSPGCL submitted that the Unit was synchronized on 28 November, 2011
and withdrawn on 20 December, 2011 due to Boiler tube leakage in 2nd
pass in
between Lower and Middle Economizer coils.
vi) MSPGCL submitted that the Unit was synchronized on 28 December, 2011,
and tripped on Drum level high, fire protection, MDBFP R/c valve failed to
close.
vii) MSPGCL submitted that M/s BHEL could not locate the material at any
sourcing point pertaining to Trichy.
viii) MSPGCL submitted that the Unit was synchronised on 10 February, 2012 and
tripped due to condenser vacuum and fire incident @ 22.15 hrs on 13
February, 2012 at corner no. 4 of the Boiler.
4.2.11 MSPGCL submitted that the Project Management Group was very vigilant on
the performance of the contractors in terms of quality, quantity and supply of
materials. MSPGCL submitted that it was very proactive in terms of pursuing
the contractors through letters and communication at the highest level for
supply of equipments at the right time and of the best quality. The summary of
letters written by MSPGCL to M/s BHEL and M/s BGR is given in Table
below:
Table 4.4: Letters written to M/s BHEL and M/s BGR submitted by MSPGCL
Date of Letter Agency Issue highlighted
16 June, 2008 M/s BHEL Slow erection rate
18 October, 2008 M/s BHEL Boiler Ceiling Girder ‘D’ Welding Joint failure and
erection of ‘D’ Girder regarding
10 November, 2008 M/s BHEL Slow progress of Boiler erection and pending works
2 March, 2009 M/s BHEL Critical issues with BHEL Haridwar
5 March, 2009 M/s BHEL Non-availability of civil inputs
15 April, 2009 M/s BHEL Slow progress in Boiler erection
11 September, 2009 M/s BHEL Hydraulic Test (Drainable) regarding
3 November, 2009 M/s BGR CS Tank filling for hydraulic test of boiler
4 February, 2010 M/s BHEL Delay in boiler light up schedule
26 February, 2010 M/s BHEL Casual approach towards date committed in site
movement meetings
5 March, 2010 M/s BHEL Boiler Light up
MERC, Order in Case No 44 of 2013 Page 34
Date of Letter Agency Issue highlighted
18 March, 2010 M/s BHEL Commissioning and charging of Station
Transformer 5B
26 March, 2010 M/s BHEL Casual approach towards date committed in site
movement meetings
6 April, 2010 M/s BHEL Non-Sequential supply of material
18 May, 2010 M/s BHEL Delay in erection of auxiliaries for want of material
26 May, 2010 M/s BGR Slow Progress of BoP works
31 May, 2010 M/s BHEL No progress in ESP work due to labour unrest
17 July, 2010 M/s BHEL Issues in charging of Station Transformer 5-A
3 August, 2010 M/s BHEL Defects in Station transformer and Bus ducts
29 October, 2010 M/s BHEL Erection and Commissioning defect of Boiler
27 December, 2010 M/s BHEL Slow progress of Steam Blowing activities
6 June, 2011 M/s BGR Slow work progress of Coal handling Plant
4.2.12 MSPGCL submitted the delay in milestone activities as shown below:
Table 4.5: Delay in milestone activities submitted by MSPGCL
S.
No. Milestone Activity
Scheduled
Date
Actual
Date
Activity
Delay
(Days)
Period Required
for Completion
from Previous
Activity as per
Schedule
(Days)
Period Required
for Completion
from Previous
Activity as per
Actual
(Days)
Contribution
of Delay in the
Activity
(Days)
1 2 3 4 5=4-3 6 7 8=7-6
Boiler Activities
1 Project Start 23.01.2007 23.01.2007 0
2 Boiler Erection Start 22.12.2007 22.02.2008 62 333 395 62
3 Drum lifting 22.06.2008 28.11.2008 159 183 280 97
4 Hydraulic Test (D) 22.05.2009 05.11.2009 167 334 342 8
5 Boiler Light Up 22.12.2009 27.10.2010 309 214 356 142
Turbine Activities
6 Condenser Erection Start 22.09.2008 28.03.2009 187 608 795 187
7 Turbine Erection Start 22.11.2008 05.06.2009 195 61 69 8
8 Oil Flushing Completion 22.01.2010 07.02.2011 381 426 612 186
Commissioning Activities
9 Steam Blowing 22.02.2010 08.02.2011 351 31 1 *-30
10 Synchronization 22.03.2010 31.03.2011 374 28 51 23
11 Coal Firing 22.04.2010 31.03.2011 343 31 0 *-31
12 Trial Operation 22.06.2010 04.04.2012 652 61 370 309
MERC, Order in Case No 44 of 2013 Page 35
*As per schedule, steam blowing and coal firing activities were supposed to be taken
up in series. However, the same were taken up in parallel and have thus led to a
saving of 30 and 31 days, respectively.
4.2.13 MSPGCL submitted that delay in execution of the project is an industry-wide
phenomenon. MSPGCL submitted the comparison of project timelines as shown
in the figures below:
Figure 1: Timeline for development of 500 MW Units by Central Utilities submitted by
MSPGCL
Figure 2: Timeline for development of 500 MW Units by State Sector Utilities submitted
by MSPGCL
4.2.14 As regards the delay in commissioning of the Unit, the Commission directed
MSPGCL to submit the details of Revenue Loss due to the delay.
MERC, Order in Case No 44 of 2013 Page 36
4.2.15 In reply, MSPGCL submitted that on a time scale, the expenses incurred by
MSPGCL can be broadly classified into pre-COD and post-COD expenses.
MSPGCL submitted that the expenses incurred by it are Interest on Loans,
Operations and Maintenance Expenses and Fuel Expenses. MSPGCL submitted
that apart from the above, depreciation which is a non-cash expense is allowed
under the Tariff Regulations. MSPGCL submitted that there is also a return on
the equity invested in to the project. MSPGCL submitted that after the COD of
the project, the sum of the aforesaid expenses as approved after prudence check
by the Commission for each of the financial years is allowed to be recovered
from the consumers at least till the 25 year normative life of the project.
4.2.16 MSPGCL submitted that before COD of the project, O&M expenses (expenses
towards salaries, administration and general expenses), and interest on loans
gets capitalised and becomes part of the GFA. MSPGCL submitted that the fuel
cost incurred by MSPGCL for generating the infirm power (power generated
before COD) is also charged to the Discom as per prevailing practices and the
net amount (cost of fuel – revenue from sale of such inform power) is
capitalised in the project cost subject to prudence check by the Commission.
MSPGCL submitted that in case of delay in the project commissioning, such
expenses which otherwise would have been allowed as a revenue expense
upfront in the form of ARR gets capitalised and their recovery gets spread over
the life of the project. MSPGCL submitted that the RoE in this case will be
allowed on the approved equity investment from the actual date of COD of the
project at least till 25 years of normative life. MSPGCL submitted that even in
this case, if time value of money is not considered, then there is only an
apparent deferment in the start of the RoE amount.
4.2.17 MSPGCL submitted that if the project had been commissioned as per schedule,
it would have started getting the returns from such earlier envisaged COD date.
MSPGCL submitted that in the current circumstances, there is a deferment in
start of such recovery to the extent of delay in the project.
4.2.18 MSPGCL submitted that it had elaborated the reasons for the delay in the
Petition and had requested the Commission to approve the project cost.
MSPGCL submitted that any disallowance in actual project cost would
essentially lead to a loss of revenue to MSPGCL as the approved expenses
would not be sufficient to recover the actual cost incurred by it.
MERC, Order in Case No 44 of 2013 Page 37
4.2.19 The key milestones in the commissioning of the Unit as submitted by MSPGCL
are as follows:
Table 4.6: Key milestones
S. No. Particulars Date
1 Approval of Board for implementation of
Khaperkheda Unit # 5 28 March, 2006
2 Placement of Order for Main Plant
equipment/Project start 23 January, 2007
3 Approval of Board based on revised cost estimates 24 May, 2010
4 Synchronization date 31 March, 2011
5 COD of the Unit 16 April, 2012
4.2.20 MSPGCL submitted the Audited Accounts as on 15 April, 2012, pertaining to
Khaperkheda Unit # 5.
4.3 COMPARISON OF CAPITAL COST
4.3.1 The Commission in the first TVS directed MSPGCL to submit the comparison
of Capital Cost of Khaperkheda Unit # 5 with other Units of 500 MW capacity.
The Commission also directed MSPGCL to submit item wise comparison of
Capital Cost with other Units of 500 MW capacity.
4.3.2 MSPGCL submitted that CERC vide its Order dated 4 June, 2012 had suggested
the benchmark hard cost for thermal power plants with coal as primary fuel.
MSPGCL submitted that as per CERC, the benchmark prices for Greenfield
1x500 MW project is Rs. 5.08 Crore/MW and that of 2x500 MW is Rs. 4.71
Crore/MW. MSPGCL submitted that the above cost excludes taxes and duties,
IDC, FC, MGR, Railway siding, unloading equipment at jetty, rolling stock,
locomotive, transmission line till tie point, right of way charges, cost of R & R.
MSPGCL submitted that Capital Cost of Khaperkheda Unit # 5 falls in the
range of industry benchmark as shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 38
Table 4.7: Comparison of Capital Cost submitted by MSPGCL (Rs. Crore/MW)
Parameter CERC CERC
NTPC
Mauda
NTPC
Rihand
Khaperkheda
Unit # 5
1x500 MW 2x500 MW 2x500 MW 2x500 MW 1x500 MW
Base Capital Cost (BTG, BoP,
Civil Works, Overheads) 5.08 4.71 4.79 4.79 4.91
Add Items not included in above
Taxes and Duties 0.61 0.57 0.27*
MGR and Railway Siding 0.24 0.24 0.26 0.23 0.24
Sub Total 5.93 5.52 5.05 5.02 5.42
Less: Benefit in Tax due to Mega
Status 0.00 0.41 0.00
Total Hard Cost 5.93 5.11 5.05 5.02 5.42
IDC 1.14** 0.99** 0.53 0.50 1.33
Total Project Cost 7.07 6.51 5.58 5.53 6.75
*Part of Taxes and Duties merged with the main package cost in BoP
components
**IDC in CERC cost is added by assuming uniform drawl of individual hard
cost over 42 month period @ 11% rate of interest for State Utility
4.3.3 MSPGCL submitted that cost of Khaperkheda Unit # 5 appears reasonable as
compared to the benchmark norm of 1x500 MW Units. MSPGCL submitted
that the Hard Cost is also within the range when compared to a cost of Rs. 5.86
Crore/MW worked out on based on NTPC project cost. MSPGCL submitted
that variation in IDC is observed in comparison to NTPC, which can arise on
account of the following:
a. Rate of borrowing depending upon the rating of the utility
b. Debt Equity Ratio of the project
c. Hard cost of the project
4.3.4 MSPGCL submitted that the packages vary from Unit to Unit. MSPGCL
submitted the item wise comparison of cost of Khaperkheda Unit # 5 with other
Units of 500 MW capacity as shown in the Table below:
Table 4.8: Item wise comparison of Capital Cost submitted by MSPGCL (Rs. Crore)
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
Capacity 1500 1000 1500 500 1000 500 1000 500
Developer
NTPC Tamil
Nadu Energy
Company Limited
(NTECL)
NTPC
Aravali Power
Company Limited
(APCL)
MSPGCL NTPC NTPC NTPC CSPGCL
Date of award of EPC 13-Aug-07 28-Nov-08 7-Jun-07 23-Jan-07 26-Mar-07 30-Oct-06 28-Feb-09 11-Apr-08
Actual/Estimated COD of 1
st
Unit 31-Aug-12 1-Oct-12 31-Oct-10 16-Apr-12 16-Sep-11 1-Nov-11 19-May-12 22-Mar-13
Actual/Estimated COD of last
Unit 30-Sep-13 1-Apr-13 1-Nov-12 16-Apr-12 31-Jul-12 1-Nov-11 Dec-13 22-Mar-13
1 Cost of Land & Site
Development
1.1 Land
204.50
279.57
545.00
-
22.00
24.00
1.2 Rehabilitation & Resettlement
(R&R)
- - -
-
2.36
4.90
1.3 Preliminary Investigation & Site
development
73.03
1.15
139.80
29.00
5.24
3.67
0.50
1.4 Other Development Works -
MERC, Order in Case No 44 of 2013 Page 40
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
27.00 -
Total Land & Site
Development
304.53
280.72
684.80
29.00
7.60
3.67
27.40
24.00
2 BTG
2.1 Steam Generator Island
2,175.03
1,384.24
2,059.39
834.27
1,301.20
1,153.67
1,805.04
1,656.00 2.2 Turbine Generator Island
1,271.86
735.94
1,134.72
498.85
923.58
1,006.61
2.3 BOP Mechanical
2.3.1 External water supply system
- -
2.30
14.99
21.60
2.3.2 CW system
215.00
79.14
66.93
16.09
21.12
8.67
2.3.3 DM water Plant
113.77
16.16
29.18
48.73
10.23
13.80
2.3.4 Clarification plant
- -
31.73
9.25
30.21
2.3.5 Chlorination Plant(Ozonization)
9.91
28.11
27.13
2.3.6 Fuel Handling & Storage
system
87.72 - -
3.69
7.87
MERC, Order in Case No 44 of 2013 Page 41
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
2.3.7 Ash Handling System
207.98
170.99
175.06
153.15
114.98
85.13
142.76
2.3.8 Coal Handling Plant
365.21
285.76
284.00
170.49
126.00
9.03
407.50
2.3.9 Rolling Stock and Locomotives
-
29.24
28.01
2.3.10 MGR
235.40
110.14
2.3.10 External CHP
89.52
2.3.11 Air Compressor System
- - -
6.19
2.3.12 Air Condition & Ventilation
System
18.91
16.36
20.58
17.39
12.67
7.85
25.09
2.3.13 Fire fighting System
25.72
17.78
21.13
22.66
16.89
8.00
22.98
2.3.14 HP/LP Piping
-
26.69
41.02
33.60
94.74
23.44
2.3.17 Work shop equipments
1.88
4.06
7.32
0.50
1.52
2.3.18 Other items not covered above - -
MERC, Order in Case No 44 of 2013 Page 42
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
- 7.83 21.66
Total BOP Mechanical
1,135.60
909.68
842.21
474.29
406.38
163.17
696.76
2.4 BOP Electrical
2.4.1 Switch Yard Package
126.99
69.85
71.05
42.00
28.10
126.39
2.4.2 Transformers Package
236.55
107.82
150.09
19.07
88.20
45.00
13.67
2.4.3 Switch gear Package
-
24.26
35.79
21.86
34.11
19.12
41.34
2.4.4 Cables, Cable facilities &
grounding
-
16.45
68.08
69.58
42.44
25.91
49.48
2.4.5 Lighting Spacage
-
38.48 -
4.07
2.4.6 Emergency D.G. set
0.36 - -
8.46
2.4.10 communication system
-
7.59 -
0.83
2.4.13 Other items not covered above
-
8.23 -
8.25
Total BOP Electrical
MERC, Order in Case No 44 of 2013 Page 43
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
363.90 272.67 325.01 118.97 206.75 123.03 239.13 993.00
2.5 Control & Instrumentation (C
& I) Package
52.77
36.34
47.01
2.32
38.66
22.40
32.32
Total Plant & Equipment
excluding taxes & Duties
5,303.69
3,619.59
5,093.15
1,957.70
2,884.17
1,465.94
3,807.26
2,673.00
2.6 Taxes and Duties
2.6.1 Custom Duty
- - -
2.6.2 Other Taxes & Duties
- - -
133.50
Total Taxes & Duties
- - -
133.50
-
-
Total Plant & Equipment
5,303.69
3,619.59
5,093.15
2,091.20
2,884.17
1,465.94
3,807.26
2,673.00
3 Initial spares
15.15
4 Civil Works
4.1 Main plant/Adm. Building
719.32
523.66
598.71
186.50
359.53
188.71
619.14
4.2 CW system
104.11
63.55
164.53
19.19
92.87
30.54
MERC, Order in Case No 44 of 2013 Page 44
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
4.3 Cooling Towers
-
81.09
200.28
52.68
167.04
43.36
106.88
4.4 DM water Plant WTP
- - -
35.07
2.25
4.7 Minor bridge
56.15 - -
4.19 Fuel Handling & Storage
system
- - -
1.47
4.20 Coal Handling Plant
- - -
21.66
92.52
4.21 MGR & Marshalling Yard
- - -
120.63
72.26
232.10
4.22 Ash Handling System
177.45 - -
8.54
20.08
4.23 Ash disposal area development
- -
27.13
-
23.99
4.24 Fire fighting System
165.37 - -
0.36
4.25 Township & Colony
40.00
137.57
84.70
17.88
6.04
4.26 Temp. construction & enabling
MERC, Order in Case No 44 of 2013 Page 45
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
works - 2.16 16.60 0.56 4.06 0.53
4.27 Road & Drainage
- -
18.00
4.86
28.36
4.28 Chimney
71.29
54.25
64.18
46.89
23.39
4.32 Misc. works not covered above
- - -
19.42
48.72
Total Civil works
1,333.69
862.27
1,174.14
483.96
893.34
309.00
1,035.20
86.00
5 Construction & Pre-
Commissioning Expenses
5.1 Erection Testing and
commissioning
-
24.38
31.94
24.63
5.2 Site supervision
- - -
5.3 Operator's Training
- -
2.00
12.06
2.00
5.4 Construction Insurance
- - -
6.74
5.5 Tools & Plant
11.81
11.81
30.82
7.00
0.18
MERC, Order in Case No 44 of 2013 Page 46
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
5.6 Start up fuel less generation
215.00 - -
28.05
29.83
21.59
Total Construction & Pre-
Commissioning Expenses
226.81
36.19
64.76
46.86
36.83
21.77
26.63
6 Overheads
6.1 Establishment
271.63
258.53
188.33
76.30
152.83
6.2 Design & Engineering
- -
85.50
4.30
6.3 Audit & Accounts
- - -
6.4 Contingency unknown
- -
186.05
4.00
6.7 Vehicles for project and O&M
staff
- - -
0.06
6.9 Cost toward hospital
upgradation/ extension -
6.10 Others (T&P and Special T&P)
2.87
139.07
86.36
Total Overheads
271.63
258.53
459.88
87.53
139.07
86.36
152.83
MERC, Order in Case No 44 of 2013 Page 47
S.
No. Particulars
Capital Cost as on COD (Rs. Crore)
Vallur TPP
(3x500 MW)
Mauda TPP
(2x500 MW)
Indira Gandhi
STPP (3x500
MW)
Khaperkheda
TPS Unit-5
(1x500 MW)
Simhadri
STPS
Stage-II
(2x500
MW)
Farakka
STPS
Stage-III
(1x500
MW)
Rihand
TPP
Stage-III
Korba
West Ext.
7 Capital cost excluding IDC &
FC
7,135.82
4,776.58
6,791.92
2,709.55
3,968.56
1,883.07
5,021.92
2,759.00
7.1 Interest During Construction
(IDC)
1,182.90
526.34
910.52
667.35
418.75
318.08
347.56
397.31
7.2 Financing Charges (FC)
3.30 -
26.93
0.52
25.00
7.5 Notional IDC
14.30 - -
Total IDC, FC, FERV &
Hedging Cost
1,200.50
526.34
937.45
667.35
418.85
318.60
504.41
397.31
8 Capital cost including IDC &
FC
8,336.32
5,302.92
7,729.37
3,376.90
4,387.41
2,201.67
5,526.33
3,156.31
9 Capital cost (Rs. Crore/MW)
5.56
5.30
5.15
6.75
4.39
4.40
5.53
6.31
4.4 HARD COST
Land & Site Development
4.4.1 MSPGCL submitted that Khaperkheda Unit # 5 was set up in the space lying
vacant after dismantling 3 Units of 10 MW and 3 Units of 30 MW in the vicinity
of Khaperkheda TPS.
4.4.2 MSPGCL submitted that the estimated cost for Land and Site Development was
Rs. 35.00 Crore and actual cost incurred as on COD is Rs. 29.00 Crore.
Commission’s Analysis
4.4.3 The Commission asked MSPGCL to submit the justification for Land and Site
Development cost of Rs. 29.00 Crore in addition to Site Development work
awarded to M/s BGR.
4.4.4 MSPGCL submitted that the Site Development work awarded to M/s BGR under
the BoP Civil Package does not include the removal of 132 kV substation and
associated GCR building and transmission lines of MSEDCL located in the
premises of Khaperkheda unit # 5. MSPGCL further submitted that Scope of work
involved in the Site Development is as follows:
Removal of 66 kV Saoner Transmission Line with associated works.
Removal of 66 kV Koradi Transmission Line with associated works.
Removal of 66 kV Khanane Transmission Line with associated works.
Removal of 33 kV Gundyagao Transmission Line.
Removal of 33 kV Mhadula Transmission Line.
Any other associated work.
4.4.5 The Commission has gone through the submissions of MSPGCL and
observed that the actual cost under land and site development as claimed by
MSPGCL is the cost incurred by MSPGCL in addition to the site
development work awarded to M/s BGR under the BoP Civil package order.
Hence, the Commission has approved the cost of Rs. 29.00 Crore for Land
and Site Development as on COD as submitted by MSPGCL.
MERC, Order in Case No 44 of 2013 Page 49
Table 4.9: Land & Site Development Cost as on COD approved by the Commission (Rs.
Crore)
Particulars MSPGCL Approved Cost as
on COD Ordering Cost Cost as on COD
Land & Site
Development 35.00 29.00 29.00
BTG Package
4.4.6 MSPGCL submitted the copy of note put up to its Board for approval of
placement of Order for Main Plant Package for Khaperkheda Unit # 5 on M/s
BHEL. MSPGCL submitted that in order to assess the reasonability of the price
offered by M/s BHEL, it had compared the Ex-works supply price offered by M/s
BHEL for Khaperkheda Unit # 5 with the accepted Ex-works supply price of Parli
Unit # 7 and Paras Unit # 4 on cost per MW basis. MSPGCL submitted that the
Ex-Works supply price offered by M/s BHEL for Khaperkheda Unit # 5 was also
compared with that of Korba Stage III, 500 MW Unit of NTPC ordered on M/s
BHEL on 24 March, 2006. MSPGCL submitted the copy of Letter of Intent dated
24 March, 2006 issued by NTPC on M/s BHEL for supply of Main Plant Package
for Korba Super Thermal Power Project Stage III (1x500 MW). The comparison
of ex-works supply price of BTG submitted by BHEL is given in Table below:
Table 4.10: Comparison of Ex-works supply price of BTG submitted by MSPGCL
Particulars Khaperkheda
Unit 5
Parli Unit 7/
Paras Unit 4
Korba
Stage III
Capacity offered (MW) 500 250 500
Ex Works Supply Price (Rs. Crore) 956.24 498 961.95
Ex Works Supply Price (Rs. Crore per
MW) 1.913 1.992 1.9239
4.4.7 MSPGCL submitted that the price for erection, testing and commissioning was
also compared with the accepted price for Parli Unit # 7 and Paras Unit # 4
Main Plant Equipment on percentage basis as shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 50
Table 4.11: Comparison of price for Erection, Testing and Commissioning submitted by
MSPGCL
Particulars Khaperkheda
Unit 5
Parli Unit 7/
Paras Unit 4
Ex Works Supply Price (Rs. Crore) 956.24 498
Price for Erection, testing and
commissioning (Rs. Crore) 93.69 65.88
Price for Erection, testing and
commissioning as percentage of Ex
Works Supply Price
9.80% 13.23%
4.4.8 MSPGCL submitted that considering the reasonability of the BHEL offer, it had
placed the Order with M/s BHEL for supply, erection and commissioning of
BTG.
4.4.9 MSPGCL submitted that the placement of order on M/s BHEL for BTG was
approved by its Board vide the Board Resolution MSPGCL/BM-14/Item-4/
dated 6 October, 2006. MSPGCL submitted that the approval of Government of
Maharashtra for placement of order on M/s BHEL was accorded vide the letter
dated 25 January, 2007.
4.4.10 MSPGCL submitted that against the Ordering Cost of Rs. 1352.62 Crore, the
actual cost as on COD is Rs. 1427.14 Crore.
Commission’s Analysis
4.4.11 The Commission asked MSPGCL to submit the Contract Agreements executed
with M/s BHEL. The Commission also asked MSPGCL to submit the statement
of bills received in respect of BTG and the justification for variation in cost as
on COD from Ordering cost.
4.4.12 MSPGCL submitted the Contract Agreements executed with M/s BHEL for
Supply and Erection & Commissioning of Main Plant Package along with
statement of bills received. MSPGCL also submitted that the increase in cost as
on COD from Ordering cost is due to Price Variation and Taxes & Duties.
4.4.13 The Price Variation clause as per the Contract Agreements is as shown below:
MERC, Order in Case No 44 of 2013 Page 51
“4.0 CONTRACT PRICE ADJUSTMENT / VARIATION
4.1 The Ex-works supply price shall be subjected to the price variation and
shall be paid as per the formulae given in clause No.11.0 of Section-3 of
Volume-I of the Bid Specification under ref.1, if any, for the
corresponding period, with base indices as on June’06. The Price
Variation shall be subjected to a ceiling of (+/-) 20% of the Ex-works
supply price
4.2 In case the contract period is required to be extended beyond the cut off
dates for reasons attributable to the Contractor, for making payments
towards price variation, the Owner shall select the indices in the P.V.
formula either by restricting their value to contractual cut off date or the
actual indices prevailing at that time, whichever is lower. In case the
contractual period is extended for the reasons attributable to the Owner,
in such event the price variation shall be payable on the extended period
of contractual cut off dates, based on prevailing market indices.”
4.4.14 MSPGCL submitted that the Price Variation has been computed in accordance
with relevant provisions of Contract Agreements.
4.4.15 The Commission, in view of delay on part of M/s BHEL in execution of the
Project and quality issues submitted by MSPGCL, asked MSPGCL to submit
the action taken against M/s BHEL in terms of payments made to them.
MSPGCL submitted that as per the Contractual Agreements, it is only entitled
to levy the Liquidated Damages on the supplier and it was religiously
undertaken by it. The Commission has detailed its approach on Liquidated
Damages in subsequent sections of this Order.
4.4.16 The Commission has gone through the submissions of MSPGCL. As discussed
earlier, MSPGCL initiated ICB process for award of BTG and pursuant to ICB
process, only M/s BHEL emerged as the sole participant, which was found to
qualify the requirements of the RFP and hence, the order was placed by M/s
MGPCL on M/s BHEL on 23 January, 2007.
4.4.17 As regards the contract price variation, the Commission observed that the
same is within the 20% price variation cap as stipulated in the contract and
further, the Contract stipulates that in case of delay for reasons
attributable to the Contractor, price variation shall be restricted till
MERC, Order in Case No 44 of 2013 Page 52
contractual cut off date. As MSPGCL has awarded the BTG Contract after
following the competitive bidding process and cost increase is on account of
the price variation for various components as per the formulae prescribed
in the contract, the Commission approves the actual cost of BTG package
as on COD.
Table 4.12: Cost of BTG as on COD approved by the Commission (Rs. Crore)
Particulars MSPGCL Approved cost
as on COD Ordering Cost Cost as on COD
BTG Supply
Supply of BTG Package 954.77 954.69 954.69
Taxes 192.70 128.16 128.16
PV - 168.59 168.59
Total Supply 1147.47 1251.43 1251.43
BTG Erection & Commissioning
Erection of BTG Package 87.69 86.66 86.66
Insurance 6.00 14.55 14.55
Taxes 11.47
PV - 17.61 17.61
Total Erection 105.15 118.83 118.83
BoP Electrical and Mechanical Package
4.4.18 MSPGCL submitted that pursuant to Domestic Competitive Bidding, the
contract for BoP and other works was placed on M/s BGR Energy Systems on 3
July,2007. MSPGCL also submitted that it had sought feedback on performance
of M/s BGR in execution of BoP works at Vijayawada and Kakatiya 500 MW
Projects of APGENCO from Director (Projects), APGENCO and in reply to the
same it was confirmed that the performance of the agency in execution of
Balance of Plant works is found to be generally satisfactory. MSPGCL
submitted that the comparison of the scope of M/s BGR for BoP package of
Kakatiya project with that of Khaperkheda Unit # 5 was also made to assess the
reasonability of price quoted by M/s BGR for Khaperkheda Unit # 5.
4.4.19 MSPGCL submitted that against the Ordering Cost of Rs. 666.59 Crore of BoP
Electrical and Mechanical, the actual cost as on COD is Rs. 641.80 Crore.
MSPGCL submitted that Ozonisation Plant was beyond the scope of work of
M/s BGR and was awarded to M/s Ozone Research & Application Pvt. Ltd.
MERC, Order in Case No 44 of 2013 Page 53
MSPGCL submitted that the Ozonisation Plant is included in Additional
Capitalisation of FY 2012-13. MSPGCL submitted the Contracts executed for
Supply and Erection of BoP Electrical and Mechanical with M/s BGR are firm
price contracts.
Commission’s Analysis
4.4.20 The Commission asked MSPGCL to submit the Bid evaluation report for the
Competitive Bidding Process conducted for award of BoP Package, Contract
Agreements executed with M/s BGR and the statement of bills received in
respect of BoP Package.
4.4.21 MSPGCL submitted the Note put up to its Board evaluating the bids submitted
for BoP Package and Contract Agreements executed with M/s BGR for Supply
and Erection, Testing and Commissioning of BoP Package. MSPGCL also
submitted the statement of bills received.
4.4.22 The Commission has gone through the submissions of MSPGCL and is of
the view that it has followed prudent utility practices in the award of BoP
Package as the same was awarded after the competitive bidding process.
Further, the actual cost of BoP Electrical & Mechanical as on COD is lower
than the Ordering Cost. The Commission has hence, approved the cost of
BoP Electrical and Mechanical as on COD as submitted by MSPGCL.
Table 4.13: Cost of BoP Electrical and Mechanical as on COD approved by the
Commission
Particulars MSPGCL Approved cost as
on COD Ordering Cost Cost as on COD
BoP Supply 617.23 614.25 614.25
BoP Erection 30.80 25.12 25.12
Mandatory Spares 12.48 2.43 2.43
Ozonisation Plant 6.08 - 0.00
Grand Total 666.59 641.80 641.80
Civil Works
4.4.23 MSPGCL submitted that the Civil Works includes BoP Civil, Railway Siding,
Ash Disposal area, Township and other miscellaneous works.
MERC, Order in Case No 44 of 2013 Page 54
4.4.24 MSPGCL submitted that Civil Works have been awarded through Domestic
Competitive Bidding.
Commission’s Analysis
4.4.25 The Commission asked MSPGCL to submit the Contract Agreements for major
contracts executed for Civil Works. The Commission also asked MSPGCL to
submit the statement of actual bills received against the contracts for Civil
Works.
4.4.26 MSPGCL submitted the Board Resolutions on award of Civil Works and the
Contract Agreements executed for Civil Works along with the statement of
actual bills received against such contracts.
4.4.27 Further, MSPGCL submitted Miscellaneous works of Rs. 19.42 Crore as on
COD. The Commission asked MSPGCL to submit the breakup of such
miscellaneous works. MSPGCL submitted the breakup of miscellaneous works
as shown in the Table below:
Table 4.14: Details of Miscellaneous Civil Works submitted by MSPGCL
Scope of Work Contractor Ordering Cost
(Rs. Crore)
Cost as on COD
(Rs. Crore)
Soil investigation work Soham Engg. 0.12 0.08
Soil investigation work Kulkarni & Asso 0.15 0.15
Soil investigation work Kulkarni & Asso 0.05 0.06
Soil investigation work Kulkarni & Asso 0.02 0.03
Soil investigation sample for
Nandgaon Ash Bund
Shrirang Pande 0.05 0.04
Dismantling of existing
Power House structure
(RCC)
M/s W. D. Kumbhare 0.03 0.03
Chainlink fencing M/s Surkan company 0.62 0.19
WBM approach road to
Power House
M/s Deepak Const. 0.23 0.23
11 KV sub-station M/s W. D. Kumbhare 0.14 0.11
MERC, Order in Case No 44 of 2013 Page 55
Scope of Work Contractor Ordering Cost
(Rs. Crore)
Cost as on COD
(Rs. Crore)
Additional work carried out
for WBM Road
M/s Deepak Const. 0.29 0.29
WBM road to BHEL yard M/s Abhi Engr 0.15 0.04
WBM road to BHEL yard M/s M.F.Jain 0.15 0.13
Chainlink fencing M/s Shah Constn. 0.49 0.36
Diversion of pipe line fuiling
in ID fan area
M/s Abhi Engr 0.20 0.19
Diversion of pipe line foiling
in NDCT
M/s Sudhir Constn. 0.31 0.30
Conts. Of Store shed MF Jain 0.54 0.41
Const of store shed in Major
Store
M/s. S.R. Enterprises 0.17 0.17
Const of store shed in CHP
Area for 4x210 MW
M/s. Sunil Hi-Tech 0.08 0.08
Diversion of Nalla K.J.Jadhav 4.20 2.72
Providing drinking water
supply pipe line
Prime Constn 0.34 0.34
Providing and laying 800
mm dia pipeline
Abhi Engr. Corpn. 3.72 3.81
sanitary line to new staff
quarters
Shah Const 0.09 0.09
water supply to new staff
quarters
Shah Const 0.29 0.30
a) Work of providing and
fixing Tree Guards to
plantation site at Chicholi
and TPS colony K'kheda.
M/s. Subhash Construction ,
Khaperkheda.
0.01 0.01
b) Work of providing and
fixing Tree Guards to
plantation site at Chicholi
and TPS colony K'kheda.
M/s. Mohini Constn. K'kheda. 0.01 0.01
c) Work of providing and
fixing Tree Guards to
plantation site at Chicholi
and TPS colony K'kheda.
M/s R.N. Kukde, K'kheda. 0.01 0.01
MERC, Order in Case No 44 of 2013 Page 56
Scope of Work Contractor Ordering Cost
(Rs. Crore)
Cost as on COD
(Rs. Crore)
d) Work of providing and
fixing Tree Guards to
plantation site at Chicholi
and TPS colony K'kheda.
M/s. Sanjay V. Waghmare ,
Khaperkheda
0.01 0.01
e) Work of providing and
fixing Tree Guards to
plantation site at Chicholi
and TPS colony K'kheda.
M/s. Anjali Constn. K'kheda 0.005 0.005
f) Work of providing and
fixing Tree Guards to
plantation site at Chicholi
and TPS colony K'kheda.
M/s. D.H. Bhagat, K'kheda. 0.005 0.005
Diverting 300 mm dia MS
pipe and 200 mm dia D.I.
pipe line, 100 mm dia G.I.
pipe line and strengthening
of over head bridge for
carrying diverted pipe lines.
M/s W. D. Kumbhare, K'kheda and
Various other agencies
0.49 0.35
Land cost (Forest land ,
Govt. land and
Afforestation)
Amount deposited to Forest Dept. 4.79 4.79
Land cost for pump house at
Pench RBC
0.00 0.00
various small order 0.00 1.48 1.32
Development of land and
landscaping in power house
area
Various agencies 0.03 0.01
Compound wall near
Bhanegaon
Various agencies 0.17 0.15
Construction of road in plant
area outside battery limit of
BOP package
Various agencies 0.25 0.00
Water supply line for ‘A’
type quarters
Various agencies 0.04 0.04
Construction of ‘B’ type
building 3 nos. including
Various agencies 0.04 0.04
MERC, Order in Case No 44 of 2013 Page 57
Scope of Work Contractor Ordering Cost
(Rs. Crore)
Cost as on COD
(Rs. Crore)
road, water supply, sanitary
etc. (Soil Investigation
work)
Miscellaneous work (out
sourcing of typist, day to day
assistance, vehicle drivers,
hiring of vehicle,
departmental vehicles,
maint. Contract for Xerox
machine, computer repairs
on office establishment
(Period of one and half year
( 2.25 x 18 = 41)
Various agencies 0.41 0.37
For Unseen works Various agencies 0.25 0.23
consultancy for design of
pile
IIT, Chennai 0.01 0.00
consultancy & Engg services
for Project implementation
DCPL 0.00
consultancy for Project
management(B.G. Railways)
Rites 5.20
consultancy for Project
management(Exchange
yard)
Rites 1.37
consultancy for Project
management(Renovation)
Kalumna to Khaperkheda
Rites 2.53
Consultancy for ROB on
Dahegaon - Kamptee road
PWD 0.48 0.35
Consultancy for Nandgaon
Ash Bund
CDO, Nashik (MERI) 0.46 0.40
Construction of WBM along
re-routed ash pipe line.
M/s. M.F. Jain, K'kheda 0.15 0.10
Walkway for maintenance of
re-routed pipe line
M/s. David Industrial Works,
K'kheda
0.05 0.05
a) Work of providing and M/s. A. R. Toshniwal, 0.03 0.02
MERC, Order in Case No 44 of 2013 Page 58
Scope of Work Contractor Ordering Cost
(Rs. Crore)
Cost as on COD
(Rs. Crore)
construction of fabricated
supports out of 300/350 mm
dia. M.S. scrap pipes for
rerouting of 1 No. -200 mm
dia.HCSD pipe lines from
Ch. 2884.00 M to 4524.00
M leading to Waragaon Ash
Bund. (Line 1).
Laxmi Nagar,
Nagpur
b) Construction of supports
and thrust block for 350mm
dia ash disposal pipe line of
1X500 MW Unit from Ch.
2884.00 M to 4524.00 M
leading to Waragaon Ash
Bund.
M/s. P.R. Chandekar
Main Road,
Ward No. 2
Khaperkheda
0.14 0.14
Constn. of operator's cabin
at various floors in main
plant building, boiler & mill
area. - 9.99% above.
(Estimated cost. Rs.
14,27,551.00)
M/s David Industrial Work.,
Khaperkheda
0.16 0.13
Providing & fixing single
concertina coil fencing over
UCR boundary wall around
the periphery of 1x500MW
TPS Expansion. Proj.
K'kheda
M/s. S. Lahoti
Enterprises
Akola
0.08 _
Construction of WBM road
from OHP to Wagon Tippler
passing through railway
track for new expansion
project 1x500MW TPS
Khaperkheda
M/s. M. F. Jain,
Engineers & Contractors,
Main Road, Khaperkheda,
0.23 _
Pipeline Various agencies 0.35
Other Works Various agencies 0.39 0.38
Total 31.72 19.42
MERC, Order in Case No 44 of 2013 Page 59
4.4.28 The Commission has gone through the submissions of MSPGCL and found
the same to be in order. The Commission observed that the Contracts
executed for Staff Quarters and Railway Siding through Domestic
Competitive Bidding includes Price Variation clause. As the increase in
price is mainly due to Price Variation, the Commission approves the cost of
Civil Works as on COD as submitted by MSPGCL.
Table 4.15: Cost of Civil Works as on COD approved by the Commission (Rs. Crore)
Particulars MSPGCL Approved cost as
on COD Ordering Cost Cost as on COD
Civil Works
BOP-Civil
package 337.51 326.03 326.03
MGR &
Marshalling Yard 135.73 120.63 120.63
Ash disposal area
development 42.03 0.00 0.00
Township &
Colony 16.89 17.88 17.88
Miscellaneous 31.71 19.42 19.42
Total 563.87 483.96 483.96
Construction and Pre-Commissioning activities
4.4.29 MSPGCL submitted that the cost of construction and pre-commissioning
activities as on COD is Rs. 40.11 Crore as against the Ordering cost of Rs. 1.00
Crore. MSPGCL submitted that the difference in ordering cost and cost as on
COD is mainly due to the cost of fuel of Rs. 28.05 Crore used for startup power
generation. MSPGCL also submitted that the cost of operators’ training as on
COD is Rs. 12.06 Crore as against the estimated cost of Rs. 1.00 Crore.
Commission’s Analysis
4.4.30 The Commission in the data gaps asked MSPGCL to submit the justification for
increase in cost of construction and pre commissioning activities.
4.4.31 MSPGCL submitted that the estimate of Rs. 1.00 Crore for Operators Training
was based on the initial estimates for the training of Project staff. MSPGCL
MERC, Order in Case No 44 of 2013 Page 60
submitted that it had deputed its O&M staff in addition to Project staff for
rigorous training and this has led to increase in cost of Operators Training from
Rs. 1.00 Crore to Rs. 12.06 Crore.
4.4.32 MSPGCL further submitted that it had incurred fuel expenses of Rs. 171.78
Crore for 454.86 MU infirm power supplied to MSEDCL. MSPGCL submitted
that it had received payment of Rs. 143.73 Crore from MSEDCL against the
same and MSEDCL asked MSPGCL to include the balance expenses of Rs.
28.05 Crore in the Capital Cost.
4.4.33 The Commission, in this regard, asked MSPGCL to submit the supporting
documents for the bills raised for supply of infirm power to MSEDCL and
payments received from MSEDCL. MSPGCL submitted the copies of bills
raised and the copies of payments received for the supply of infirm power to
MSEDCL.
4.4.34 The Commission observes that MSPGCL has capitalised the amount of fuel
costs less revenue, on account of infirm generation of power. However, as
fuel cost is a revenue expense, whether incurred during infirm generation
or firm generation, the Commission is of the view that the same needs to be
recovered directly for the power supplied during the period instead of
capitalising it as a part of Capital Cost. As these expenses have been
incurred prior to the COD, the Commission has considered the same as a
part of capital cost for the purpose of computation of IDC. However, the
Commission has not considered fuel expenses as part of Capital Cost for
computing the tariff and the Commission hereby allows MSPGCL to
recover the under-recovered fuel cost, i.e., Rs. 28.05 Crore for infirm
power supplied to MSEDCL in three monthly instalments after the issue of
this Order and MSEDCL can recover this amount through Fuel
Adjustment Cost (FAC) mechanism.
4.4.35 Hence, the Commission has allowed cost of construction and pre
commissioning activities as on COD as Rs. 40.11 Crore including net fuel
costs for start-up power generation .
MERC, Order in Case No 44 of 2013 Page 61
Table 4.16: Cost of Construction and pre commissioning activities as on COD approved
by the Commission (Rs. Crore)
Construction and pre
commissioning activities
MSPGCL Approved Cost
as on COD Estimated Cost Cost as on COD
Operators Training 1.00 12.06 12.06
Net Fuel Cost for Start-up
Generation 0.00 28.05 28.05
Total 1.00 40.11 40.11
Overheads
4.4.36 MSPGCL submitted that the capitalisation of Overheads is based on the
accounting principles adopted to reduce the revenue expenses. MSPGCL
submitted that the actual overheads as on COD is Rs. 87.53 Crore as against
estimated cost of Rs. 89.85 Crore.
Commission’s Analysis
4.4.37 The Commission in the data gaps asked MSPGCL to submit the justification for
variation in various heads of overheads as on COD from estimated cost.
4.4.38 MSPGCL submitted that the establishment expenses in the base cost were mere
estimates to the extent of the hard cost of the project and did not factor in the
actual prevailing cost. MSPGCL submitted that these charges pertain to
expenses incurred by it towards employees working in the project site, A&G
and other miscellaneous expenses of similar nature, which have been capitalised
on actual basis. MSPGCL submitted that the capitalisation against Contingency
unknown is actually towards miscellaneous expenses incurred on very small
contracts under contingency provision awarded for the Project. MSPGCL has
also submitted the list of such contracts along with brief description of scope of
work of each contract.
4.4.39 The Commission has gone through the submissions of MSPGCL. The
Commission observes that the overheads as on COD are approximately 3%
of hard cost, which seems reasonable as per the industry practices. Hence,
the Commission has approved the overheads as on COD as submitted by
MSPGCL.
MERC, Order in Case No 44 of 2013 Page 62
Table 4.17: Overheads as on COD approved by the Commission (Rs. Crore)
Overheads MSPGCL Approved cost as
on COD Estimated Cost Cost as on COD
Establishment 56.32 76.30 76.30
Design &
Engineering 16.44 4.30 4.30
Contingency
Unknown 5.71 4.00 4.00
Vehicles for Project
and O&M staff 1.00 0.06 0.06
Others (T&P and
Special T&P) 10.39 2.87 2.87
Total 89.85 87.53 87.53
Initial Spares
4.4.40 As regards the cost of spares, Regulation 30.1 of the MERC Tariff Regulations,
2005 stipulates as under:
“Subject to prudence check by the Commission, the actual expenditure
incurred on completion of the project shall form the basis for determination of
the original cost of project. The original cost of project shall be determined
based on the approved capital expenditure actually incurred up to the date of
commissioning of the generating station and shall include capitalised initial
spares subject to following ceiling norms as a percentage of the original cost
as on the cut-off date:
(i) Coal-based/lignite-fired generating stations - 2.5%
...”
4.4.41 The Commission observed that the cost of spares procured till COD is
1.79% of Capital Cost as on COD, which is within 2.5% of project cost as
stipulated in Regulation 30.1 of MERC (Terms and Conditions of Tariff),
Regulations, 2011. Hence, the Commission has approved the cost of spares
as on COD as submitted by MSPGCL.
MERC, Order in Case No 44 of 2013 Page 63
Table 4.18: Initial Spares as on COD approved by the Commission
Particulars MSPGCL Approved cost
as on COD Ordering Cost Cost as on COD
BTG - Mandatory Spares (included in cost of BTG)
Supply of Mandatory Spares 81.42 49.57 49.57
Taxes 18.58
PV - 7.31 7.31
Total 100.00 56.88 56.88
BoP - Mandatory Spares (included in cost of BoP)
Mandatory Spares 12.48 2.43 2.43
Total Spares 112.48 59.31 59.31
Based on the above, the total Hard Cost approved by the Commission is Rs.
2709.55 Crore.
Table 4.19: Hard Cost as on COD approved by the Commission (Rs. Crore)
Particulars
MSPGCL Approved
Cost as on
COD
Ordering
Cost
Cost as on
COD
Land & site development 35.00 29.00 29.00
BTG (including spares) 1352.62 1427.14 1427.14
BOP (including spares) 666.59 641.80 641.80
Civil Works 563.87 483.96 483.96
Construction & Pre-Commissioning activities 1.00 40.11 40.11
Overheads 89.85 87.53 87.53
Total Hard Cost 2708.93 2709.55 2709.55
4.5 INTEREST DURING CONSTRUCTION
4.5.1 MSPGCL submitted that the initial estimate of IDC in the Capital Cost of
Khaperkheda Unit 5 approved by its Board vide the Board Resolution dated 28
March, 2006 was worked out in a notional manner considering a notional
interest rate of 7.5%. MSPGCL submitted that in accordance with the Judgment
of Hon’ble ATE in Appeal No. 34 of 2012, it had calculated the base IDC
considering the actual interest rates. MSPGCL submitted that it had considered
the base case IDC as the IDC that would have been incurred if the base project
MERC, Order in Case No 44 of 2013 Page 64
cost was to be taken into consideration for a scheduled construction period of 42
months.
4.5.2 MSPGCL submitted that as per Clause 2.3 of the Loan Sanction letter, PFC had
an option to reset the interest rate immediately following the 3rd
period from the
date of first disbursement and accordingly the interest rate on individual tranche
of loan was constant for a 3 year period beginning with the date of first
disbursement. MSPGCL submitted that it had considered the loan drawal
schedules as shown in the Table below:
Table 4.20: Loan Drawdown Schedule submitted by MSPGCL (Rs. Crore)
Year Quarter Scheduled Loan
Drawal
Cumulative
Scheduled Loan
Drawal
Actual Loan
Drawal
Cumulative
Actual Loan
Drawal
FY
2006-07
Q3 180.31 180.31
Q4 31.72 212.03
FY
2007-08
Q1 88.49 300.52
Q2 195.34 495.86 98.00 98.00
Q3 202.02 697.88 7.11 105.11
Q4 278.81 976.69 152.53 257.64
FY
2008-09
Q1 283.82 1260.51 83.38 341.02
Q2 283.82 1544.33 150.28 491.30
Q3 298.85 1843.18 113.05 604.35
Q4 318.88 2162.06 338.06 942.41
FY
2009-10
Q1 198.68 2360.74 203.37 1145.79
Q2 215.37 2576.11 237.73 1383.52
Q3 161.95 2738.06 213.44 1596.96
Q4 188.66 2926.72 113.50 1710.45
FY
2010-11
Q1 42.19 1752.65
Q2 115.76 1868.41
Q3 23.64 1892.05
Q4 31.89 1923.93
FY
2011-12
Q1 28.22 1952.15
Q2 86.09 2038.23
Q3 104.38 2142.62
MERC, Order in Case No 44 of 2013 Page 65
Year Quarter Scheduled Loan
Drawal
Cumulative
Scheduled Loan
Drawal
Actual Loan
Drawal
Cumulative
Actual Loan
Drawal
Q4 140.68 2283.30
FY
2012-13
Q1 0.00 2283.30
Total 2926.72 2283.30
4.5.3 MSPGCL submitted that the envisaged loan drawal was supposed to start from
October 2006 while the actual loan drawal started from 2nd
quarter of FY 2007-
08. MSPGCL submitted that the envisaged loan drawal was spread over a
period of 42 months as compared to the actual loan drawal spread over a period
of 63 months. MSPGCL submitted that due to the deferred loan drawal, there
has been an overall increase in IDC. MSPGCL submitted that the IDC has been
computed considering the following parameters shown in the Table below:
Table 4.21: Assumptions for IDC Computation submitted by MSPGCL
Particulars Base Case Cost as on COD
Project Cost (Rs. Crore) 3658.39 3376.90
Debt Equity ratio 80:20 77:23 (excluding
Undischarged Liabilities)
Loan component (Rs.
Crore) 2926.72 2283.30
Draw down schedule
Original draw down
schedule envisaged in
Loan Agreement with PFC
Actual draw down
Interest Rate Actual Actual
Construction Period 42 months 63 months
COD 22 July, 2010 16 April, 2012
IDC (Rs. Crore) 658.15 667.35
4.5.4 MSPGCL submitted that in comparison to base case IDC of Rs. 658.15 Crore
the actual IDC is Rs. 667.35 Crore and the increase in IDC due to time overrun
is Rs. 9.20 Crore.
MERC, Order in Case No 44 of 2013 Page 66
Commission’s Analysis
4.5.5 The Commission asked MSPGCL to submit the actual phasing of capital
expenditure.
4.5.6 The Commission has recomputed actual IDC considering the approved Hard
Cost, actual phasing of capital expenditure and actual interest rates submitted by
MSPGCL.
4.5.7 The Commission observed the variation in Project Cost and Loan amount
submitted by MSPGCL in the Petition as considered for computation of Base
Case IDC and the same in the Excel computation sheet of Base Case IDC
submitted by MSPGCL. MSPGCL submitted the Loan amount considered for
computation of Base case IDC as Rs. 2926.72 Crore in the Petition and as Rs.
2925.50 Crore in the Excel computation sheet. The Commission asked
MSPGCL to reconcile the data and MSPGCL has submitted the revised
computations of Base Case IDC. The Commission observed that the Hard Cost
approved by MSPGCL’s Board vide the Board Resolution MSPGCL/BM-
69/Item-69.17/ dated 24 May, 2010 is Rs. 3000.24 Crore and the same has been
considered by MSPGCL in the Excel computation sheet of Base Case IDC. The
Commission observed that MSPGCL, in its computation of Base Case IDC, has
considered the Hard Cost approved by its Board vide the Board Resolution
dated 24 May, 2010 and has computed the IDC based on actual interest rates
and proportion of loan drawal as envisaged in the original drawal schedule.
Further, MSPGCL has considered the Debt Equity ratio of 80:20 approved by
its Board.
4.5.8 Based on the Base Case IDC computations submitted by MSPGCL, the
Commission observed that the Hard Cost as well as Loan amount considered by
MSPGCL for computation of Base Case IDC is substantially higher than the
actual Hard Cost and actual Loan amount as on COD respectively. MSPGCL in
its submissions also submitted that the capital cost approved by its Board was
indicative in nature and should not be considered as base cost.
4.5.9 The Commission observes that the purpose of Base Case IDC is to determine
the impact of time overrun on IDC, i.e., to determine the difference in IDC if
the Project had been completed in the stipulated time duration and the actual
IDC incurred for the actual time duration of completion. While doing so, it
would be prudent to consider the Hard Cost as on COD for the computations of
Base Case IDC. Regarding the same, Hon’ble ATE in its Judgment in Appeal
No. 72 of 2010 ruled as under:
MERC, Order in Case No 44 of 2013 Page 67
“7.4. The delay in execution of a generating project could occur due to
following reasons:
i) due to factors entirely attributable to the generating
company, e.g., imprudence in selecting the
contractors/suppliers and in executing contractual
agreements including terms and conditions of the
contracts, delay in award of contracts, delay in
providing inputs like making land available to the
contractors, delay in payments to contractors/suppliers
as per the terms of contract, mismanagement of
finances, slackness in project management like
improper co-ordination between the various
contractors, etc.
ii) due to factors beyond the control of the generating
company e.g. delay caused due to force majeure like
natural calamity or any other reasons which clearly
establish, beyond any doubt, that there has been no
imprudence on the part of the generating company in
executing the project.
iii) situation not covered by (i) & (ii) above.
In our opinion in the first case the entire cost due to time over
run has to be borne by the generating company. However, the
Liquidated Damages (LDs) and insurance proceeds on account of
delay, if any, received by the generating company could be retained by
the generating company. In the second case the generating company
could be given benefit of the additional cost incurred due to time over-
run. However, the consumers should get full benefit of the LDs
recovered from the contractors/suppliers of the generating company
and the insurance proceeds, if any, to reduce the capital cost. In the
third case the additional cost due to time overrun including the LDs
and insurance proceeds could be shared between the generating
company and the consumer. It would also be prudent to consider the
delay with respect to some benchmarks rather than depending on the
provisions of the contract between the generating company and its
contractors/suppliers. If the time schedule is taken as per the terms of
the contract, this may result in imprudent time schedule not in
accordance with good industry practices.”
MERC, Order in Case No 44 of 2013 Page 68
“8.6 ....
We agree with the State Commission that the infusion of debt & equity has to be
more or less on pari passu basis as per normative debt equity ratio. However,
the increase in IDC due to time over run has to be allowed only according to
the principles laid down in para 7.4 above. Accordingly, the State Commission
is directed to re-determine the IDC for the actual period of commissioning of
the project and then work out the excess IDC for the period of time over run
on a prorata basis and limit the disallowance to 50% of the same on account
of excess IDC. This question is answered accordingly.”
4.5.10 As may be observed, the Hon’ble ATE in its Judgment has clearly stipulated
that extra IDC on account of the delay has to be shared between the generating
company and the consumers. In such a case, the extra IDC needs to be
computed considering the impact of the delay in the commissioning of the
project only (i.e., period of construction under base case and under the actual
case).
The Commission has thus recomputed the Base Case IDC considering the
approved Hard Costas on COD. As regards the Debt Equity ratio for
computation of Base Case IDC, the Commission has considered 80:20 as the
same has been approved by GoM while according approval to Khaperkheda
Unit # 5 and initially the Project was envisaged to be funded through
Debt:Equity of 80:20. The Commission has considered the actual interest rates
and proportion of loan amount drawn as submitted by MSPGCL.
4.5.11 As regards the delay in project, due to which the actual IDC has increased,
MSPGCL has elaborated the reasons for delay in execution. MSPGCL also
submitted that the main reasons that contributed to the delay were beyond its
control. MSPGCL submitted that BHEL being the only major supplier of the
equipment in the country at that time could not cope up with the targeted
schedules due to heavy orders. MSPGCL submitted that delays were
experienced at other projects also.
4.5.12 The Commission has gone through MSPGCL’s submission of reasons for
delay. The Commission is of the view that the present case appears to be of
sudden spurt in execution of Power Projects in the country and
consequential increase in demand of equipments and the gestation period
required by the industry in enhancing the manufacturing capacity.
MERC, Order in Case No 44 of 2013 Page 69
Considering all the facts and documents submitted by MSPGCL, though it
is evident that there was delay on the part of BHEL in supply and
commissioning of the main plant, it is not established beyond doubt that the
entire delay was due to the reasons beyond the control of MSPGCL. In
light of the above, the Commission is of the view that the present case falls
under the category (iii) described in the ruling of Hon’ble ATE stated
above. Accordingly, the Commission allows the cost of time overrun to be
shared equally between MSPGCL and the consumers. Admittedly, there is
no enhancement in cost of the contract price of the equipment as no price
variation escalation was permissible to BHEL beyond the schedule date of
completion of the Project according to terms of the agreement. The impact
of time overrun beyond the contractual schedule is only on IDC.
4.5.13 The Project cost including IDC approved by the Commission is shown in the
Table below:
Table 4.22: Project Cost including IDC approved by the Commission (Rs. Crore)
Particulars MSPGCL Approved
Hard Cost 2709.55 2709.55
Actual IDC 667.35 667.35
Base Case IDC 658.15 594.39
IDC allowable 667.35 630.87
Project cost including
IDC 3376.90 3340.41
4.6 LIQUIDATED DAMAGES
4.6.1 MSPGCL submitted that even after making all diligent efforts within its
purview, towards pursuing the contractor for expeditious commissioning of the
Unit, the Unit could not be commissioned in the envisaged time frame.
MSPGCL submitted that as a last resort, it had withheld some payments against
damages caused on account of delay in supplies and impact of time overruns.
Commission’s Analysis
4.6.2 The Commission asked MSPGCL to submit the details of Liquidated Damages
levied and recovered in accordance with the provisions of contracts.
MERC, Order in Case No 44 of 2013 Page 70
4.6.3 MSPGCL submitted that as per the Contract, in case the Contractor fails to
achieve the trial operation of the Unit within the stipulated time period due to
reasons attributable to him, it shall levy Liquidated Damages on the Contractor
at 1/2% of the Contract Price with applicable price variation per week of delay
or part thereof subject to maximum 10% of the Contract Price with applicable
price variation. MSPGCL submitted that the Liquidated Damages amount shall
be finalised and recovered upon closing of the Contract. MSPGCL submitted
that it had not levied any Liquidated Damages against the Contractors and had
only withheld some payments.
4.6.4 The Commission also asked MSPGCL if Contract Performance Guarantee was
furnished by M/s BHEL and it was encashed due to any reasons. The
Commission also asked MSPGCL to submit if the cost of damages caused by
fire or cost of rectification/delays due to any other equipment as submitted by
MSPGCL has been reimbursed from errant agencies.
4.6.5 MSPGCL submitted that Contract Performance Guarantee has been furnished
by M/s BHEL and it shall be kept valid till 90 days beyond the Guarantee
Period (Defect Liability Period). MSPGCL submitted that the issues related to
project implementation including delay/unsatisfactory progress of the contract
was discussed in Site Movement meetings and Project Review Meetings at
regular intervals with senior officials of the contracting agencies. MSPGCL
submitted that no legal notices were served and performance guarantee was not
encashed against unsatisfactory performance of the contractors.
4.6.6 MSPGCL further submitted that entire cost of damage caused by fire or cost of
rectification is borne by the respective BTG and BoP contractors and delays due
to damages to equipment shall be covered in the Liquidated Damages applicable
to the respective contractor.
4.6.7 In reply to Commission’s query regarding defect liability period, MSPGCL
submitted that the Performance & Guarantee Test in respect of BTG and BoP
has been recently concluded and the reports of the same are being prepared by
the Contractors. MSPGCL submitted that the defect liability period of 12
months of BTG package commenced from 1 April, 2013. MSPGCL submitted
that the defect liability period of BoP package commenced from 17 June, 2012
and no Latent defects have been noticed so far. MSPGCL submitted that Latent
defects could only be identified during the operating life of the Unit as the same
could not get identified during the normal quality checks. MSPGCL submitted
MERC, Order in Case No 44 of 2013 Page 71
that the deficiencies, if any, regarding poor performance shall be known only
after scrutiny of P&G Test report.
4.6.8 MSPGCL further submitted that the Commission might consider the retention
amount against LD.
The Commission observes that MSPGCL has not yet levied Liquidated
Damages on the contracts as the contracts have not yet been closed. The
Commission therefore at this stage has considered the 50% of retention amount
against the Liquidated Damages and deducted the same from the Capital Cost,
in accordance with the Hon’ble ATE’s Judgment as discussed in Para 4.5.9.
The Commission directs the Petitioner to submit a separate report
regarding the actual amount of the LD recovered from the Contractors
upon finalisation of the Contracts so that the same can be considered while
approving the final Capital Cost after finalisation of Contracts.
4.6.9 Thus, the Capital Cost of Khaperkheda Unit # 5 approved by the Commission as
on COD after deducting the fuel expenses allowed to be recovered separately
and LD amount is shown in the Table below:
Table 4.23: Capital Cost as on COD approved by the Commission (Rs. Crore)
Particulars Approved
Capital Cost including IDC 3340.41
Less Fuel Expenses allowed
to be recovered separately 28.05
Capital Cost as on COD after
deducting fuel expenses 3312.36
LD deducted 115.38
Capital Cost after
deducting LD amount 3196.99
4.7.1 The Commission in this Order has approved the capital cost for Khaperkheda
Unit # 5 on COD as Rs. 3312.36 Crore. The Capital Cost as on COD after
deducting the 50% of LD amount works out to Rs. 3196.99 Crore. Further, the
final Capital Cost as on COD will get revised once MSPGCL submits the final
LD amount recovered from the Contractors upon finalisation of Contracts.
MERC, Order in Case No 44 of 2013 Page 72
4.7 MEANS OF FINANCE
4.8.1 MSPGCL submitted that the total capital expenditure as on COD is Rs. 3376.90
Crore. MSPGCL submitted that it had tied up long term debt of Rs. 2576 Crore
from Power Finance Corporation (PFC). MSPGCL submitted that out of the
total sanctioned loan of Rs. 2576 Crore, loan amount of Rs. 2283.30 Crore was
drawn till COD. MSPGCL submitted that there was an unfunded liability of Rs.
415.63 Crore (including the retention amount) as on COD in the books of
Accounts. MSPGCL submitted that Government of Maharashtra (GoM)
provided an equity contribution of Rs. 599.37 Crore and the balance funding of
Rs. 78.60 Crore had been met through internal accruals.
Commission’s Analysis
4.8.2 The Commission asked MSPGCL to submit the supporting documents
regarding the project financing for Khaperkheda Unit # 5.
4.8.3 MSPGCL has submitted the Loan Agreement executed with PFC, Resolutions
passed by Government of Maharashtra regarding Equity infusion for
Khaperkheda Unit # 5 and details of Internal Accruals.
4.8.4 As regards the Equity infusion by GoM, the Commission observed some
discrepancies in amounts of Equity submitted by MSPGCL in excel formats and
equity granted in the Government Resolutions. In this regard, the Commission
asked MSPGCL to reconcile the data. In reply, MSPGCL submitted that the
amounts of Equity submitted in the excel formats is the actual utilisation for the
project while the Government Resolutions depict the sanctioned amounts.
MSPGCL submitted that there had been a time lag of 2-3 days between the date
of sanction by GoM and receipt of funds by MSPGCL. MSPGCL submitted that
in the period from FY 2010-11 to FY 2012-13, the sanctions took place on the
last 2-3 days of financial year and the actual amount was received by MSPGCL
in the next financial year.
4.8.5 As regards the Internal Accruals, MSPGCL submitted that the internal accruals
used for funding the project were from internal profits of the company.
MSPGCL submitted the details of internal accruals as shown in the Table
below:
MERC, Order in Case No 44 of 2013 Page 73
Table 4.24: Details of Internal Accruals submitted by MSPGCL (Rs. Crore)
Particulars FY
2005-06
FY
2006-07
FY
2007-08
FY
2008-09
FY
2009-10
FY
2010-11
FY
2011-12
FY
2012-13
Profit After Tax 113.00 234.00 300.00 84.00 203.00 309.00 200.00
Cumulative Profit After Tax 113.00 347.00 647.00 731.00 934.00 1,243.00 1,443.00 1,443.00
Fu
nd
ing
of
New
Pro
ject
s th
rou
gh
Inte
rnal
Acc
rual
s
Paras-3 38.35 75.91 191.18
Parli-6 47.36 148.27 110.86
Paras-4 - 3.57 18.46 35.14 23.07
Parli-7 1.73 11.42 45.93 86.82 48.77
Total Funding of New
Projects through Internal
Accruals
85.71 225.91 317.03 64.38 121.96 71.84 -
Cumulative Funding of New
Projects through Internal
Accruals
85.71 311.62 628.65 693.04 815.00 886.84 886.84 886.84
Cumulative Balance of
Internal Accruals 27.29 35.38 18.35 37.96 119.00 356.16 556.16 556.16
Funding of Khaperkheda
Unit-5 through Internal
Accruals
0.40 5.12 16.27 23.81 26.08 6.92
Cumulative Funding of
Khaperkheda Unit-5
through Internal Accruals
0.40 5.53 21.79 45.60 71.68 78.60
4.8.6 As regards Undischarged Liabilities as on COD, MSPGCL submitted that it had
an Undischarged Liability of Rs. 415.63 Crore (including retention amount) as
on COD in its books of accounts. MSPGCL submitted that out of Rs. 415.63
Crore, Rs. 401.21 Crore is towards retention money from suppliers, which also
includes the retention amount towards Liquidated Damages. MSPGCL
submitted that assets have been considered against this amount in the ARR
computation but no funding had been shown against this amount as on COD.
MSPGCL submitted that post COD, Rs. 117.34 Crore has been replaced by part
of loan drawal in FY 2012-13. MSPGCL submitted that the funding against the
Undischarged Liabilities would be submitted as and when payments would be
paid against the same in future.
4.8.7 The Commission observed that the Undischarged Liabilities of Rs. 415.63 Crore
is inclusive of retention amount against LD of Rs. 230.75 Crore. The
Commission observed that out of the balance Undischarged Liabilities of Rs.
MERC, Order in Case No 44 of 2013 Page 74
184.88 Crore, MSPGCL has proposed to replace Rs. 117.34 Crore of this
amount with portion of Loan drawal during FY 2012-13.
4.8.8 The proportion of Debt and Equity as on COD submitted by MSPGCL is shown
in the Table below:
Table 4.25: Debt and Equity as on COD submitted by MSPGCL
Particulars MSPGCL
Rs. Crore %
Debt 2283.30 77.11%
GoM Equity 599.37 22.89%
Internal Accruals 78.60
Sub-Total 2961.27 100.00%
Add: Undischarged Liabilities 415.63
Total 3376.90
Less: Retention Amount 0.00
Capital Cost as on COD 3376.90
4.8.9 The Commission has considered the Means of Finance for total Capital Cost as
approved by the Commission on COD of the project before deduction of
Liquidated Damages on proportionate basis based on the Means of Finance and
Undischarged Liabilities as on COD as submitted by MSPGCL. As the retention
amount towards Liquidated Damages is part of Undischarged Liabilities, the
Commission has reduced the Liquidated Damages from the Undischarged
Liabilities. The Means of Finance as on COD approved by the Commission is
given in Table below
Table 4.26: Means of Finance as on COD (Rs. Crore)
Particulars Approved
Debt 2239.66
GoM Equity 587.92
Internal Accruals 77.10
Undischarged Liabilities 292.31
Total 3196.99
MERC, Order in Case No 44 of 2013 Page 75
4.8.10 The Commission has considered the funding of Undischarged Liabilities of Rs.
117.34 Crore with Loan availed by MSPGCL in FY 2012-13. Further, the
Commission on provisional basis has considered the funding of balance
Undischarged Liabilities excluding retention amount towards LD in the same
proportion of Debt, Equity and Internal Accruals as submitted by MSPGCL as
on COD of the Project. The Commission will approve the revised Project Cost
and carry out the truing up including funding of Undischarged Liabilities based
on actual LD amounts and actual funding of Undischarged Liabilities.
5 Tariff of Khaperkheda Unit # 5 for FY 2012-13
5.1 ENERGY CHARGES
Fuel Supply Agreement
5.1.1 MSPGCL submitted that domestic coal is the primary fuel for Khaperkheda
Unit # 5. MSPGCL submitted that it had signed MoU with MCL for supply of
2.312 MMT of coal to Khaperkheda Unit # 5, which was valid up to 31 March,
2013. MSPGCL submitted that as per the communication received from CEA
vide letter dated 24 May, 2012, MCL is directed to supply 70% of LoA to
MSPGCL. MSPGCL submitted that FSA had been executed with MCL for
supply of 2.312 MMT of coal to Khaperkheda Unit # 5 on 31 January, 2013.
MSPGCL submitted that as per the Presidential directives to Coal companies,
MCL has to adhere to at least 80% of FSA quantity.
5.1.2 MSPGCL submitted that as the quantum of domestic coal available is
insufficient to run the unit at normative level, it procured imported coal.
MSPGCL submitted that it had entered into agreements with MMTC and
Knowledge Infrastructure for supply of 0.150 MMT and 0.486 MMT of
imported coal for the period April, 2012 to June, 2012 and November, 2012 to
March, 2013 respectively. MSPGCL submitted the delivery schedule of
imported coal by MMTC and Knowledge Infrastructure as shown in the Table
below:
Table 5.1: Imported Coal supply schedule submitted by MSPGCL
S.
No. Month
Quantity
(MMT)
MMTC Delivery Schedule
MERC, Order in Case No 44 of 2013 Page 76
S.
No. Month
Quantity
(MMT)
1 April, 2012 0.030
2 May, 2012 0.061
3 June, 2012 0.059
Sub-Total (MMTC) 0.150
Knowledge Infrastructure Delivery Schedule
1 18 to 30, November, 2012 0.045
2 December, 2012 0.111
3 January, 2013 0.110
4 February, 2013 0.110
5 March, 2013 0.110
Sub-Total
(Knowledge Infrastructure) 0.486
Total 0.636
Commission’s Analysis
5.1.3 The Commission asked MSPGCL to submit a copy of MoU executed with
MCL, FSA executed with MCL and other coal supply agreements for imported
coal.
5.1.4 MSPGCL submitted that it procures imported coal through International
Competitive bidding on yearly basis to meet the shortfall in supply of domestic
coal. MSPGCL submitted the FSA executed with MCL. MSPGCL also
submitted the Coal Supply Agreements executed with MMTC and Knowledge
Infrastructure.
5.1.5 Further, the Commission asked MSPGCL to submit the domestic coal
requirement to be able to run the Unit at normative performance parameters and
procurement methodology intended to be followed to fulfil the shortfall in
supply of domestic coal.
5.1.6 MSPGCL submitted that considering the normative PLF of 85%, SHR of 2425
kcal/kWh and domestic coal CV of 3400 kcal/kg, the coal quantity required
would be 2.655 MMT per annum. MSPGCL submitted that it had signed FSA
with MCL for 2.312 MMT of coal with a CV of 3400 kcal/kg. MSPGCL
submitted that the 2.312 MMT per annum would ensure a PLF of around 59%.
MERC, Order in Case No 44 of 2013 Page 77
MSPGCL submitted that considering the actual realisation of coal, the shortfall
in coal can be met through 0.806 MMT of domestic coal of CV 3400 kcal/kg or
0.589 MMT of imported coal of CV 4650 MMT.
5.1.7 MSPGCL further submitted that it is analysing the possibility of shifting
domestic coal to the new Unit and maximising the usage of imported coal in the
older Units, which have higher design GCV subject to the technical constraints.
MSPGCL submitted that the optimal usage of domestic and imported coal will
be used for the overall Station by meeting the requirement with imported coal to
the extent feasible in both the Units. MSPGCL submitted that any balance
requirement would be met through e-auction coal. MSPGCL submitted that the
possibility of loss in generation due to non-realisation of such options or
prolonged shortages by domestic coal companies could not be fully ruled out
even after making all sincere efforts to maximise the availability of coal.
5.1.8 MSPGCL submitted that as per the presidential directives, MCL had agreed to
supply 80% of FSA quantity. MSPGCL submitted that as per FSA,
compensation for shortfall in delivery of domestic coal is applicable below 80%
of FSA quantity (1.850 MMTPA). MSPGCL submitted that this includes 65%
of domestic coal by quantity (1.503 MMTPA) and 15% of imported coal on
GCV basis for FY 2012-13, FY 2013-14 and FY 2014-15, 70% of domestic
coal by quantity (1.618 MMTPA) and 10% of imported coal on GCV basis for
FY 2015-16 and 75% of domestic coal by quantity (1.734 MMTPA) and 5% of
imported coal on GCV basis from FY 2016-17 onwards. MSPGCL submitted
that the quantity of imported coal will be on GCV parity basis. MSPGCL
submitted that as per this option, the possible PLF during FY 2013-14 to FY
2016-17 would be around 59%.
5.1.9 In view of repetitive concern raised by MSPGCL regarding the poor quality and
inadequate quantity of coal received from Coal India Limited, the Commission
in the second TVS directed MSPGCL to submit the summary of proceedings in
the Case filed in Competition Commission of India against Coal India Limited.
The Commission also directed MSPGCL to submit the study conducted by its
Fuel Management Cell regarding the usage of different types of coal in
Khaperkheda Unit # 5. The Commission also directed MSPGCL to submit a
note on the current status of coal washery proposed to be set up at Chandrapur,
Maharashtra.
MERC, Order in Case No 44 of 2013 Page 78
5.1.10 MSPGCL submitted the summary of proceedings in the Case filed with
Competition Commission of India. MSPGCL also submitted the study done by
its Fuel Management Cell regarding the usage of various types of coal at
Khaperkheda Unit # 5 as shown in the Table below:
Table 5.2: Study on usage of coal submitted by MSPGCL
S.
No. Particulars Formula Scenario-1 Scenario-2 Scenario-3 Scenario-4
Scenario-
5
Scenario-
6
1 Gen. Capacity (MW) 500 500 500 500 500 500
2 Design CV (kcal/kg) 3400 3400 3400 3400 3400 3400
3 Coal Heat Rate
(kcal/kWh) 2,415 2,415 2,415 2,415 2,415 2,415
4 Target Availability
(%) 85 85 85 85 85 85
5 Target Generation
(MU) 3,723 3,723 3,723 3,723 3,723 3,723
6 Target heat input
(Mkcal) 3x5 89,91,045 89,91,045 89,91,045 89,91,045 89,91,045 89,91,045
7 Received CV of raw
coal (kcal/kg) 2,800 2,800 2,800 2,800 2,800 2,800
8 Raw coal quantity
(Th.MT) 3,212 2,725 2,292 1,902 1,550 1,232
9 Raw coal quantity % 100% -
13 100 90 80 70 60 50
10 Raw coal Heat input
(Mkcal) 7 x 8 89,93,600 76,30,000 64,17,600 53,25,600 43,40,000 34,49,600
11 GCV of Imported
coal (kcal/kg) 4,500 4,500 4,500 4,500 4,500 4,500
12 Qty. of import coal
(Th.MT) 13 x(8/9) 0 303 573 815 1,033 1,232
13 Import coal blending
qty (%) 0 10 20 30 40 50
14 Import coal Heat
input (Mkcal) 11 x 12 0 13,62,500 25,78,500 36,68,143 46,50,000 55,44,000
15
Total Heat input
(raw+import)
(Mkcal)
10 + 14 89,93,600 89,92,500 89,96,100 89,93,743 89,90,000 89,93,600
16
Total Qty
(Raw+Import)
(Th.MT)
8 + 12 3,212 3,028 2,865 2,717 2,583 2,464
17 Avg.Price of Raw 2053.31 2053.31 2053.31 2053.31 2053.31 2053.31
MERC, Order in Case No 44 of 2013 Page 79
S.
No. Particulars Formula Scenario-1 Scenario-2 Scenario-3 Scenario-4
Scenario-
5
Scenario-
6
coal (Rs./MT)
18 Cost of Raw coal
(Rs. Lakhs) 8 x 17 65,952 55,953
47,062 39,054 31,826 25,297
19 Price of Import coal
(Rs./MT) 5552.56 5552.56 5552.56 5552.56 5552.56 5552.56
20 Cost of Import coal
(Rs. Lakhs) 12 x 19 0 16,812 31,816 45,261 57,376 68,408
21
Total cost of
received coal
(Rs.Lakhs)
18 + 20 65,952 72,765 78,878 84,315 89,203 93,704
22
GCV of blended coal
at bunker
(kcal/kg)
15/16 2800 2970 3140 3310 3480 3650
23
Specific Coal
Consumption
(kg/kWh)
16/5 0.863 0.813 0.770 0.730 0.694 0.662
24 Energy Charge
(Rs./kWh) 21/5 1.77 1.95 2.12 2.26 2.40 2.52
5.1.11 MSPGCL submitted that the approval for installation of 12 MTPA coal washery
at Chandrapur was accorded by its Board vide Board Resolution MSPGCL/BR-
111/Item 111.18 dated 19 December, 2011. MSPGCL further submitted that the
DPR of coal Washery was submitted by M/s Desein Pvt. Ltd., Delhi on 21 May,
2013 and is under review.
5.1.12 The Commission has taken note of MSPGCL’s submissions. While the
Commission acknowledges the efforts of MSPGCL to operate the Unit at target
performance parameters, the Commission also advises MSPGCL to optimise the
usage of coal of varying calorific value so as to avoid adverse long term effect
on the performance of the Unit.
Calorific Value and Price of Fuel
5.1.13 MSPGCL submitted that the CV and landed price of coal and secondary oil for
FY 2012-13 as shown in the Table below:
Table 5.3: Calorific Value and Price of Fuel submitted by MSPGCL
Fuel
Stabilisation Period
( 16/04/2012 to 12/10/2012)
(Actuals)
Post-Stabilisation Period
( 13/10/2012 to 31/03/2013)
MERC, Order in Case No 44 of 2013 Page 80
Calorific Value
(kcal/kg)
Landed Price
(Rs./MT)
Calorific Value
(kcal/kg)
Landed Price
(Rs./MT)
Domestic Coal 2941.00*
1895.60 3033.63*
1935.03
Imported Coal 7317.25 5554.56
FO 10196.41 43511.33 10100.82 43623.20
LDO 10603.00 48548.97 10596.29 58430.15
*Bunkered CV
Commission’s Analysis
5.1.14 The Commission asked MSPGCL to submit the actual calorific value and
landed fuel cost for FY 2012-13. The Commission also asked MSPGCL to
submit calorific value of Domestic Coal and Imported Coal separately.
5.1.15 MSPGCL submitted the actual calorific value and landed fuel cost for FY 2012-
13. MSPGCL has also submitted the calorific value of Domestic Coal and
Individual Coal separately.
5.1.16 The Commission, for the purpose of computation of Energy Charge for FY
2012-13, has considered the landed price of all fuels as submitted by MSPGCL.
The landed price and calorific value considered by the Commission is shown in
the Table below:
Table 5.4: Landed Price and Calorific Value of Fuel considered by the Commission
Fuel
Stabilisation Period
( 16/04/2012 to 12/10/2012)
Post-Stabilisation Period
( 13/10/2012 to 31/03/2013)
Calorific Value
(kcal/kg)
Landed Price
(Rs./MT)
Calorific Value
(kcal/kg)
Landed Price
(Rs./MT)
Bunkered Coal 2941.00 - 3033.63 -
Domestic Coal 2991.42 1895.60 2744.27 1935.03
Imported Coal 5452.00 7317.25 4500.00 5554.56
FO 10196.41 43511.33 10100.82 43623.20
LDO 10603.00 48548.97 10596.29 58430.15
5.1.17 Further, the Commission observed that there are significant variations between
the bunkered Calorific Value of blended coal and weighted average Calorific
Value of blended coal as submitted by MSPGCL. The variations in the two
Calorific Values is shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 81
Table 5.5: Comparison of Bunkered Calorific Value and Weighted Average Calorific
Value
S. No. Particulars
FY 2012-13
Stabilisation
Period
Post Stabilisation
Period
1 Bunkered Calorific Value 2941.00 3033.63
2 Weighted average Calorific
Value 3157.37 3274.79
3=2-1 Difference 216.37 241.16
4 % Difference 7.36% 7.95%
5.1.18 In this regard, the Hon’ble ATE in its Judgement dated 14 December, 2012 in
Appeal No. 47 of 2012 observed as under:
“13. Before we consider the next issue we would like to express our concern
over loss of CV and vast difference between calorific value of fuel ‘as received’
and ‘as fired’. The coal looses calorific value when stored for very long time in
the open due to presence of oxygen in atmosphere. It is understood that
presently, due to country wide shortage of coal; power stations have fuel stock
for few days only. Any loss of CV in such a short duration needs proper
explanation.”
5.1.19 Further, the Commission would like to highlight the observation made by CPRI
in its study conducted during FY 2008-09 on stacking loss:
“…there is no methodology for computing stacking loss and the best available
as on date is the CERC/MoP norm of reducing receipt coal GCV by 150kcal/kg
(100kcal/kg+1% moisture)”. Hence it is recommended to use this method for
computing the stacking loss.”
5.1.20 As evident from the above Table, the variation in Calorific Value of coal is
higher than 150 kcal/kg and the Commission directs MSPGCL to take suitable
measures to restrict such losses within 150 kcal/kg.
Operational Parameters
5.1.21 MSPGCL submitted that as per Regulation 33.1.5 of MERC Tariff Regulations,
2005, the stabilization period for new Units shall be reckoned from the date of
MERC, Order in Case No 44 of 2013 Page 82
commissioning and shall be 180 days for coal based stations. MSPGCL
submitted that the Tariff Regulations stipulates relaxed norms for operations
during such stabilization period as compared to the norms applicable after the
stabilization of the Unit. MSPGCL submitted that Khaperkheda Unit # 5 was
commissioned on 16 April, 2012 and achieved stabilization on 12th October
2012 within 180 days as per the Regulations.
5.1.22 MSPGCL submitted that it was not able to achieve normative parameters during
the stabilization period due to:
i) Consistent low load unstable operation mainly due to Poor Coal
receipt, Poor Coal Quality, Wet coal problems and CHP problems.
Total coal received during the period was only 42 % of required
coal quantity.
ii) Consistent low load unstable operation resulted in increased Fuel
Oil Consumption. Average load during stabilization period was
only 248 MW. To avoid unit tripping on flame failure oil support is
necessary for such low load operation.
iii) Consistent low load unstable operation resulted in increased
auxiliary consumption.
5.1.23 MSPGCL submitted that as per Regulation 33.1.1 of MERC Tariff Regulations,
target availability for full recovery of Annual Fixed Charges shall be 80 percent.
MSPGCL submitted that the Unit has achieved actual availability of 32.85%
during the stabilization period and 73.67% availability post stabilization period.
MSPGCL submitted that the availability achieved during stabilization period
was lower than the target availability due to poor coal receipt and CHP
Problems. MSPGCL submitted that a major part of stabilization period is
coming in rainy season and hence, the performance in the stabilization period is
below norms.
5.1.24 MSPGCL submitted that it had signed a MoU with MCL for supply of 2.312
MMT of coal to Khaperkheda Unit # 5, which was valid up to 31 March, 2013.
MSPGCL submitted that as per the communications received from CEA (letter
dated 24 May, 2012), MCL was directed to supply 70% of LOA quantity, i.e.,
1.618 MMT of coal. MSPGCL submitted that monsoon had a significant impact
on the performance of the Unit. MSPGCL submitted that the actual availability
of the Unit had been low during the months of June, July and August due to the
MERC, Order in Case No 44 of 2013 Page 83
impact of monsoon. MSPGCL submitted that with the usage of imported coal,
the availability of the Unit is likely to improve.
5.1.25 MSPGCL submitted a PLF of 32.85% during the stabilization period and
73.64% thereafter. MSPGCL submitted that loss in PLF during stabilization
period was mainly due to coal quantity and quality related issues.
5.1.26 MSPGCL submitted that as per Regulation 33.1.2, auxiliary consumption for
coal based generating stations with cooling tower is 8.0% during stabilization
period and 7.5% post stabilization period. MSPGCL submitted that during the
stabilization period, the auxiliary consumption has been reckoned at 3.45%
more than the norm of 8.0%. MSPGCL submitted auxiliary energy consumption
of 11.45% during the stabilization period and 6.58% post stabilization period
for FY 2012-13.
5.1.27 MSPGCL submitted that as per Regulation 33.1.3, gross station heat rate for
coal based generating stations with 500 MW sets during stabilization period is
2550 kcal/kWh and for the subsequent period it is 2450 kcal/kWh. MSPGCL
submitted that it had considered station heat rate in its tariff calculations as per
actuals (2814 kcal/kWh) which is more than the normative value due to low
load operation, coal shortages and CHP issues in the stabilization period.
MSPGCL submitted that for the period beyond stabilization period it had
considered the station heat rate of 2450 kcal/kWh in its tariff calculations.
5.1.28 MSPGCL submitted that as per Regulation 33.1.6, allowable Transit Loss for
coal based generating stations, as a percentage of quantity of coal dispatched by
the coal supply company during FY 2012-13, shall be 0.8% for non-pit head
generating stations. MSPGCL submitted transit losses of 0.8% during the
stabilization period and post stabilization period for FY 2012-13.
5.1.29 MSPGCL submitted that as per Regulation 33.1.4, allowable secondary oil
consumption for coal based generating stations during stabilization period is 4.5
ml/kWh and for subsequent period it is 2.0 ml/kWh. MSPGCL submitted that
the secondary fuel oil consumption during the stabilization period is higher than
the normative due to low load operation, coal shortages, CHP issues, unstable
operation and more forced outages during rainy season in the stabilization
period. MSPGCL submitted that it had considered the actual specific oil
consumption for the stabilization period in FY 2012-13 in its tariff calculations.
MERC, Order in Case No 44 of 2013 Page 84
5.1.30 MSPGCL submitted that it had considered the charges for water, chemicals and
lubricants, which is Rs. 8.76 crore during stabilization period and Rs. 7.39 crore
for the period beyond stabilization period in a similar manner as considered by
the Commission for the existing stations in its past Orders.
Commission’s Analysis
5.1.31 The Commission has scrutinised the submissions of MSPGCL. The
Commission has observed that the main reasons stated by MSPGCL are coal
related problems.
5.1.32 The Commission has observed that MSPGCL stated the poor quality of coal as
the reason for lower generation of Khaperkheda Unit # 5 in FY 2012-13. The
Commission has also observed that the operational parameters of the Unit have
improved post stabilisation period.
5.1.33 As regard the poor quality of coal received, Hon’ble ATE in its judgement dated
19 April, 2012 in Review Petition No. 9 of 2011 in Appeal No. 199 of 2011 has
opined as under:
“We do not accept that the quality of coal is totally beyond the control of the
appellant. If the quality of raw coal supplied by the coal companies is poor, the
appellant has to make arrangements for washing of coal and blending with
superior quality of coal”
5.1.34 As per Hon’ble ATE’s Judgment, quality of coal is not totally beyond the
control of MSPGCL and MSPGCL can take other steps such as utilisation of
washed coal, imported coal, etc., to improve the performance and MSPGCL has
already taken some of these steps to a certain extent.
5.1.35 The Commission further asked MSPGCL to substantiate its claims for not
achieving the normative operational parameters as per MERC Tariff
Regulations, 2005. MSPGCL replied that it had entered into an MoU with M/s
MCL for supply of 2.312 MMT of domestic coal with GCV of around 3400 to
3700 kcal/kg to Khaperkheda Unit # 5, which was valid up to 31 March, 2013.
MSPGCL submitted that as per the said MoU, MCL had agreed to supply at
least 70% of the MoU quantity. MSPGCL submitted that it had subsequently
signed an FSA with MCL for supply of 2.312 MMT of coal to Khaperkheda
Unit # 5 on 31 January, 2013. MSPGCL submitted that as per the Presidential
MERC, Order in Case No 44 of 2013 Page 85
directives to Coal Companies, MCL has to adhere to at least 80% of FSA
Quantity.
5.1.36 MSPGCL submitted the achievable PLF under different coal scenarios
assuming normative performance parameters including the usage of oil as
follows:
i) MSPGCL submitted that if the entire MoU/ FSA quantity (2.312 MMT)
of coal was realized during the year, the PLF could have been around
76% in FY 2012-13.
ii) MSPGCL submitted that if the agreed quantity of 70% of MoU quantity
(from 16 April, 2012 to 31 January, 2013) and subsequently 80% of
FSA quantity (from 1 February, 2013 to 31 March, 2013) of coal was
realized during the year, the PLF could have been around 55%.
iii) MSPGCL submitted that considering the actual realization of domestic
coal of 1.447 MMT, the PLF could have been only around 41% in FY
2012-13.
iv) MSPGCL submitted that it had used 0.402 MMT of imported coal.
MSPGCL submitted that considering the aforesaid imported coal
quantity and realized domestic coal of 1.447 MMT, the overall
achievable PLF could have been around 59% in FY 2012-13.
5.1.37 MSPGCL submitted that it was able to achieve a PLF of 52% in FY 2012-13.
MSPGCL submitted that the PLF of 59% is based on normative performance
parameters considering no seasonal variations (monsoon related issues)
throughout the period of operation. MSPGCL submitted that under real time
operations shortage of coal leads to partial load operations, higher usage of oil
for flame stabilization and issues of wet coal during monsoon season ultimately
leading to higher station heat rate (higher coal utilization).
5.1.38 MSPGCL submitted that during the stabilization period, the performance of the
Unit was significantly influenced by the poor realization of coal from CIL.
MSPGCL submitted that the effective realization of coal was insufficient to
operate the Unit at normative PLF. MSPGCL submitted the details of the actual
receipt of coal in FY 2012-13 as shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 86
Table 5.6: Actual Realisation of coal during FY 2012-13 submitted by MSPGCL
Month
Linkage (MT) Realisation (MT) Possible
PLF at
normative
parameters
Domestic
coal
Imported
coal
Domestic
coal
Imported
coal
April,
2012 66509.59 30000 44,300 578 28.17%
May, 2012 137453.15 61000 1,14,616 9,838 42.94%
June, 2012 133019.18 59000 61,554 29,617 32.68%
July, 2012 137453.15 0 1,01,497 5,083 35.30%
August,
2012 137453.15 0 1,13,638
- 36.43%
September,
2012 133019.18 0 1,16,136
- 33.81%
October,
2012 137453.15 0 1,63,563
- 49.13%
November,
2012 133019.2 45000 1,87,888 16,727 65.82%
December,
2012 137453.2 111000 1,41,571 95,727 82.68%
January,
2013 137453.2 110000 1,53,558 70,425 79.52%
February,
2013 141887.1 110000 1,17,405 56,601 63.45%
March,
2013 157089.3 110000 1,31,442 1,17,032 84.94%
Total 1589262.50 636000 14,47,167 4,01,629 54.79%
5.1.39 MSPGCL submitted that the realization of coal during the stabilization period
was roughly around 35%. MSPGCL submitted that on an annual basis, the
realized quantum of coal from various sources demonstrates that the overall
PLF that could have been achieved at normative performance could have been
around 54% (considering bunkered CV). MSPGCL submitted that accordingly
the average load during stabilization period was only 248 MW and the overall
PLF that could be achieved by the Unit on an annual basis was around 51%.
5.1.40 MSPGCL submitted that significant shortages in coal especially during the
stabilization period impacted the stable operations of the Unit resulting in
partial load operations, higher outages, increase in secondary oil consumption,
lower generation and higher auxiliary consumption. MSPGCL submitted that
MERC, Order in Case No 44 of 2013 Page 87
another important consideration during the stabilization period was that the said
period had fallen under the monsoon season, which aggravated the coal quality
related issues leading to issues associated in Coal Handling Plant and hence, a
higher usage of secondary oil.
5.1.41 MSPGCL submitted that the performance of Khaperkheda Unit # 5 was in close
convergence to the normative performance during the post stabilization period.
MSPGCL submitted that the PLF of the Unit during the months of December,
2012, January, 2013 and March, 2013 had been around 81.60%, 87.16% and
87.96%, respectively, which had exceeded the normative PLF of 80%.
MSPGCL submitted that the overall average auxiliary consumption during the
post stabilization period was at around 6.58%, which is significantly lower than
the normative auxiliary consumption of 8.5%. MSPGCL submitted that the key
elements that supported the performance of the Unit during the aforesaid period
were relatively better realization of domestic coal supported by the availability
of imported coal during these months. MSPGCL submitted that improvement in
coal quality lead to stable operations of the Unit lowering the outages and also
reducing the consumption of secondary oil. MSPGCL submitted that the
consumption of oil also got lowered significantly to less than the normative
value of 2 ml/kWh in certain months.
5.1.42 MSPGCL submitted the impact on performance parameters during stabilisation
period and post stabilisation period, as shown in the Table below:
Table 5.7: Impact on performance parameters submitted by MSPGCL
Parameters
16
April,
2012 to
30
April,
2012
May-
12 Jun-12 Jul-12 Aug-12 Sep-12 Oct-12 Nov-12 Dec-12 Jan-13 Feb-13 Mar-13
No of Outages 3 7 6 6 3 4 2 1 3 2 2 1
Generation Loss (MU) due to
Poor coal quality and poor coal
receipt
129.82 230.2 251.23 258.38 247.67 241.77 196.43 132.26 71.15 74.23 129.55 66.61
SFOC (ml/kWh) 20.61 12.26 15.19 17.01 14.22 19.52 7.23 1.88 2.39 1.99 4.4 1.19
Auxiliary
consumption (%) 13.23% 11.57% 12.06% 11.95% 11.10% 11.14% 9.36% 7.73% 6.07% 6.07% 6.81% 5.73%
SHR (kcal/kWh) 2653.57 2985.32 2793.55 3001.88 2816.8 2713.86 2613.12 2544.48 2509.74 2434.84 2548.08 2528.49
MERC, Order in Case No 44 of 2013 Page 88
5.1.43 MSPGCL submitted that despite the fact that requisite quantum of coal has been
tied up with MCL under a MoU/FSA for supply of coal, significant coal
shortages are the key factors leading to lower generation and deviation from the
normative parameters.
5.1.44 MSPGCL, considering the supply shortages of coal as a national issue,
requested the Commission to consider the performance deviation appropriately,
and approve the actual cost of generation for FY 2012-13.
5.1.45 Further, MSPGCL has submitted that the Performance & Guarantee Test in
respect of BTG and BoP has been concluded and the reports of the same are
being finalised. The Commission directs MSPGCL to submit the
Performance & Guarantee Test Reports after finalisation of the same.
5.1.46 In view of the above, the Commission at this stage has not carried out the
detailed analysis of the reasons of variation in performance parameters with
respect to norm approved in Regulations in FY 2012-13. The Commission is of
the view that it will be more appropriate to analyse the reasons of variation in
performance parameters once the P&G Test reports are available for assessing
the reasons of variation in performance parameters under controllable and
uncontrollable factors. The Commission while carrying out the truing up for FY
2012-13 based on audited accounts will analyse the reasons of variation in
performance parameters and accordingly assess the sharing of gains and losses
on account of controllable and uncontrollable factors as per provisions of
MERC Tariff Regulations, 2005.
5.1.47 Considering the submissions of MSPGCL regarding substantial shortfall in coal
availability and other factors, which affected the performance during
stabilisation period, the Commission on provisional basis has considered the
actual performance parameters during the stabilisation period, which shall be
subject to final truing up. As regards post stabilisation period, the Commission
observed that the variation in performance parameters as compared to norms is
marginal and in some of the months, the actual performance was even better
than the normative parameters. Considering the marginal variation in
performance parameters during post stabilisation period, it is more important to
analyse the P&G Test reports for proper assessment of variation in performance
parameters. The Commission, therefore at this stage has provisionally approved
the performance parameters as per the norms specified in MERC Tariff
MERC, Order in Case No 44 of 2013 Page 89
Regulations, 2005 for post stabilisation period subject to final Truing up for FY
2012-13.
5.1.48 Further, the Commission has considered the Gross Generation as submitted by
MSPGCL during the stabilisation period and post stabilisation period. The
performance parameters approved by the Commission are shown in the Table
below:
Table 5.8: Performance parameters approved by the Commission
Particulars Units
FY 2012-13
Stabilisation period Post stabilisation
period
MSPGCL Approved MSPGCL Approved
No. of days Days 180 180 170 170
Installed Capacity MW 500 500 500 500
Availability % 32.85% 32.85% 73.67% 80.00%
Gross Generation MU 737.08 737.08 1433.62 1433.62
Auxiliary
Consumption
% 11.45% 11.45% 6.58% 7.50%
Net Generation MU 652.71 652.71 1339.22 1326.10
Station Heat Rate kcal/kWh 2814 2814 2519 2450
SFOC ml/kWh 15.32 15.32 2.39 2.00
Transit Loss % 0.80% 0.80% 0.80% 0.80%
5.1.49 The Commission has considered the consumption of FO and LDO in the same
proportion as submitted by MSPGCL. The Commission has also considered the
consumption of domestic coal and imported coal in the same proportion as
submitted by MSPGCL. The Commission has further considered the other
variable charges as submitted by MSPGCL. Based on above, the summary of
energy charges as submitted by MSPGCL and as approved by the Commission
for FY 2012-13 is shown in the Table below:
Table 5.9: Energy Charge approved by the Commission for FY 2012-13
Particulars Units
FY 2012-13
Stabilisation period Post stabilisation period
MSPGCL Approved MSPGCL Approved
MERC, Order in Case No 44 of 2013 Page 90
Particulars Units
FY 2012-13
Stabilisation period Post stabilisation period
MSPGCL Approved MSPGCL Approved
Energy Charge Rs./kWh 3.21 3.21 2.84 2.78
5.2 ADDITIONAL CAPITALISATION
5.2.1 MSPGCL submitted additional capitalization of Rs. 82.07 Crore in FY 2012-13
and Rs. 103.06 Crore in FY 2013-14 for balance works. MSPGCL submitted
that the entire Additional Capitalisation shall be funded by loan from PFC.
Commission’s Analysis
5.2.2 As regards additional capitalisation, Regulation 30.2 of MERC (Terms &
Conditions of Tariff) Regulations, 2005 specifies as follows:
“Additional Capitalisation: The following capital expenditure within the
original scope of work actually incurred after the date of commissioning and up
to the cutoff date may be allowed by the Commission for inclusion in the
original cost of project, subject to prudence check:
(i) Deferred liabilities;
(ii) Works deferred for execution;
(iii) Procurement of initial capital spares in the original scope of work,
subject to ceiling specified in Regulation 30.1;
(iv) Liabilities to meet award of arbitration or for compliance of the order
or decree of a court; and
(v) On account of change in law.
Provided that original scope of work along with estimates of expenditure shall
be submitted along with the application for determination of tariff:
Provided further that a list of the deferred liabilities and works deferred for
execution shall be submitted along with the application for determination of
tariff after the date of commissioning of the generating station.”
5.2.3 The Commission asked MSPGCL to submit the break-up of proposed additional
capitalisation in accordance with MERC Tariff Regulations, 2005.
MERC, Order in Case No 44 of 2013 Page 91
5.2.4 MSPGCL submitted the details of proposed additional capitalisation as shown
in the Table below:
Table 5.10: Details of Additional Capitalisation submitted by MSPGCL
Package
Capitalisation in
FY 2012-13
(Rs. Crore)
Justification
Capitalisation
in FY 2013-14
(Rs. Crore)
Justification
BTG
Steam Generator
Island
3.00 Works Deferred
for execution 1.15
Works Deferred
for execution
20.00 Spares 8.46 Spares
Turbine
Generator Island
6.01 Works Deferred
for execution
23.62 Spares
BOP
Mechanical
External water
supply system
0.02 Works Deferred
for execution
1.00 Spares 0.18 Spares
CW system 0.07
Works Deferred
for execution
0.66 Spares
DM water Plant 1.08
Works Deferred
for execution
0.25 Spares 0.04 Spares
Work shop
equipments 6.08
Works Deferred
for execution
Fuel Handling &
Storage system
0.24 Works Deferred
for execution
0.65 Spares 0.11 Spares
Ash Handling
System
1.01 Works Deferred
for execution 1.40
Works Deferred
for execution
1.20 Spares 0.28 Spares
Coal Handling
Plant
2.13 Works Deferred
for execution
1.96 Spares
Air Compressor
System
0.52 Works Deferred
for execution
0.20 Spares 0.05
Air Condition &
Ventilation
System
0.28 Works Deferred
for execution
0.73 Spares
Fire fighting 0.35 Works Deferred
MERC, Order in Case No 44 of 2013 Page 92
Package
Capitalisation in
FY 2012-13
(Rs. Crore)
Justification
Capitalisation
in FY 2013-14
(Rs. Crore)
Justification
System Fire stop for execution
0.27 Spares
HP/LP Piping 0.55 Works Deferred
for execution
BoP
Electrical
Switch gear
Package 0.07
Works Deferred
for execution
Cables, Cable
facilities &
grounding
0.18 Works Deferred
for execution
0.50 Spares
C&I
Package
Control and
Instrumentation
Package
0.03 Spares
Communication
& Lab
Equipment
0.26
BoP Civil
MGR and
Marshalling Yard 5.52
Works Deferred
for execution 24.37
Works Deferred
for execution
Ash Disposal
Area
Development
9.72 Works Deferred
for execution 31.35
Works Deferred
for execution
BoP 12.16 Works Deferred
for execution
Township &
Colony 0.83
Works Deferred
for execution
Miscellaneous 16.61 Works Deferred
for execution
Total 82.07 103.06
5.2.5 Based on the details submitted by MSPGCL, the Commission observed that the
total initial spares including spares to be capitalised in FY 2012-13 and FY
2013-14 exceeds the ceiling of 2.5% of Capital Cost as on Cut-off date. The
Commission has allowed the actual spares as on COD as the same was within
the ceiling norm as specified in MERC Tariff Regulations, 2005. The
Commission has limited the total quantum of spares to the ceiling limit of 2.5%
of Capital cost as on Cut off date in accordance with MERC Tariff Regulations,
2005. Further, the Commission has considered the entire allowable spares in
MERC, Order in Case No 44 of 2013 Page 93
addition to the spares as on COD, in the additional capitalisation for FY 2012-
13.
5.2.6 As regards the works deferred for execution in Additional Capitalisation,
MSPGCL submitted that certain works in BTG, BoP Electrical and Mechanical
and BoP Civil, which were supposed to be completed within COD are now in
progress beyond COD. MSPGCL submitted that these balance works are now
proposed to be completed within the cutoff date and capitalized under additional
capitalization. The Commission at this stage has considered the additional
capitalisation submitted by MSPGCL for FY 2012-13 and FY 2013-14
(excluding spares) for arriving at Capital Cost as on Cut-off date. The
Commission will carry out the truing up of additional capitalisation for FY
2012-13 and FY 2013-14 once the actual additional capitalisation details are
submitted by MSPGCL. Accordingly, the additional capitalisation approved by
the Commission is shown in the Table below:
Table 5.11: Quantum of Spares after COD and upto cut-off date approved by the
Commission (Rs. Crore)
Particulars MSPGCL Approved
Capital Cost as on COD (before deducting 50% of LD amount) 3376.90 3312.36
Initial Spares as on COD 59.31 59.31
Works Deferred for execution in FY 2012-13 submitted by MSPGCL 31.01 31.01
Works Deferred for execution in FY 2013-14 submitted by MSPGCL 93.94 93.94
Spares after COD and up to Cut-off date 60.19 27.31
Capital cost as on Cut-off date (before deducting 50% of LD
retention amount) 3562.03 3464.62
Total spares upto Cut-off date 119.50 86.62
% of Total spares of Capital Cost as on Cut-off date 3.35% 2.50%
5.2.7 The Commission has also considered the entire Additional Capitalisation to be
funded through loan as submitted by MSPGCL.
Table 5.12: Additional Capitalisation for FY 2012-13 approved by the Commission
Particulars MSPGCL Approved
Additional Capitalisation
Works deferred for execution 31.01 31.01
Spares 51.07 27.31
Total Additional 82.07 58.31
MERC, Order in Case No 44 of 2013 Page 94
Capitalisation for FY 2012-
13 (Rs. Crore)
Debt (Rs. Crore) 82.07 58.31
Debt (%) 100.00% 100.00%
Equity (Rs. Crore) 0.00 0.00
Equity (%) 0.00% 0.00%
5.3 ANNUAL FIXED CHARGES
Operation and Maintenance Expenses
5.3.1 MSPGCL submitted that as per Regulation 34.6.2 of MERC (Terms &
Conditions of Tariff) Regulations 2005, the O&M expenses for the base year
commencing from 1 April, 2005 for a 500 MW new Unit is allowed as Rs 9.73
lakh/MW. MSPGCL submitted that these expenses were to be escalated at the
rate of 4% per annum to arrive at permissible operation and maintenance
expenses for the relevant year of tariff period. MSPGCL submitted that it had
accordingly escalated the same to arrive at the O&M expenses for FY 2006-07.
MSPGCL submitted that to arrive at the normative O&M expenses for FY
2007-08, it had further escalated the expenses in FY 2006-07 at the rate of
5.38%, which was determined by the Commission in the MYT Order dated 25
April, 2007 based on CPI and WPI ratios.
5.3.2 MSPGCL submitted that the Pay revision in FY 2008-09 had an impact of Rs.
95 Crore on the employee expenses. MSPGCL submitted that this impact is
approximately 21% of the actual employee expense for FY 2007-08. MSPGCL
submitted that employee expenses for FY 2007-08 were escalated by 21% to
capture the impact of pay revision and after capturing the impact of pay
revision, normal escalation of 5.29% was applied to work normative expenses
for FY 2008-09. MSPGCL submitted that to arrive at the O&M expenses for FY
2012-13 escalation rates of 5.48%, 7.02%, 8.31% and 8.45% were applied in
FY 2009-10, FY 2010-11, FY 2011-12 and FY 2012-13, respectively, over the
normative expenses for FY 2008-09. MSPGCL submitted that it had considered
the impact of pay revision in the other new Units, i.e., Paras Unit # 4 and Parli
Unit # 7 and the Commission had accepted the approach and allowed the O &M
expenses as projected in the petition. MSPGCL submitted the methodology of
projecting O&M expenses as shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 95
Table 5.13: O&M expenses for FY 2012-13 submitted by MSPGCL
Particulars FY
2005-06
FY
2006-07
FY
2007-08
FY
2008-09
FY
2009-10
FY
2010-11
FY
2011-12
FY
2012-13
Rs Lakh/MW 9.73 10.12 10.66 12.27 12.94 13.85 15.00 16.27
Escalation rate
over previous year
4% 5.38% 15.08%1 5.48% 7.02% 8.31% 8.45%
O&M Expenses
(Rs. Crore)
*78.01
1- Impact of Pay Revision is also considered along with normative O&M expenses
*Calculated only for 11.5 operational months
Commission’s Analysis
5.3.3 The Commission asked MSPGCL to submit the justification for the escalation
rates considered. Further, the Commission asked MSPGCL to submit the
backup calculations for the escalation rate of 15.08% considered for FY 2008-
09.
5.3.4 The computation of escalation rate of 15.08% submitted by MSPGCL is shown
in the Table below:
Table 5.14: Computation of escalation rate for FY 2008-09 submitted by MSPGCL
Particulars
Actuals for
FY 2007-08
(Rs. Crore)
%
Normative for FY
2007-08
(Rs. Lakh/MW)
Escalation due to
impact of Pay
revision
Normative
escalation
Expenses for FY
2008-09
(Rs. Lakh/MW)
O & M expenses 967.66 100.00% 10.66 - - 12.27
Employee expenses 428.24 44.26% 4.72 21% 5.29% 6.01
A&G expenses 57.72 5.96% 0.64 - 5.29% 0.67
R&M expenses 481.70 49.78% 5.31 - 5.29% 5.59
Escalation over FY
2007-08 15.08%
5.3.5 MSPGCL submitted that the escalation rates of 5.48%, 7.02% and 8.31% on
O&M Expenses for FY 2009-10, FY 2010-11 and FY 2011-12, respectively, are
the escalation rates approved by the Commission for the respective years.
MSPGCL submitted the details of the Commission’s Orders in which these
escalation rates are approved, as shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 96
Table 5.15: Basis for Escalation rates submitted by MSPGCL
Year Escalation rate
Considered MERC Order
FY 2009-10 5.48% Case 107 of 2011
FY 2010-11 7.02% Case 6 of 2012
FY 2011-12 8.31% Case 6 of 2012
5.3.6 MSPGCL submitted that the escalation rate of 8.45% considered for FY 2012-
13 is based on the CPI-WPI indices for the period April to October 2012 in FY
2012-13. MSPGCL submitted the computation of escalation rate of 8.45% for
FY 2012-13 as shown in the Tables below:
Table 5.16: WPI data submitted by MSPGCL
WPI April May June July Aug Sept Oct Nov Dec Jan Feb March Average
2012-13 163.5 163.9 164.7 165.8 166.6 168.4 165.5
2011-12 152.1 152.4 153.1 154.2 154.9 156.2 157.0 157.4 157.3 158.7 159.3 161.0 156.1
2010-11 138.6 139.1 139.8 141.0 141.1 142.0 142.9 143.8 146.0 148.0 148.1 149.5 143.3
2009-10 125.0 125.9 126.8 128.2 129.6 130.3 131.0 132.9 133.4 135.2 135.2 136.3 130.8
Table 5.17: CPI data submitted by MSPGCL
CPI April May June July Aug Sept Oct Nov Dec Jan Feb March Average
2012-13 205.0 206.0 208.0 212.0 214.0 215.0 210.0
2011-12 186.0 187.0 189.0 193.0 194.0 197.0 198.0 199.0 197.0 198.0 199.0 201.0 194.8
2010-11 170.0 172.0 174.0 178.0 178.0 179.0 181.0 182.0 185.0 188.0 185.0 185.0 179.8
2009-10 150.0 151.0 153.0 160.0 162.0 163.0 165.0 168.0 169.0 172.0 170.0 170.0 162.8
Table 5.18: WPI Inflation submitted by MSPGCL
Upto Date September-13 March-12 March-11 March-10
WPI 165.48 156.13 143.33 130.82
Escalation 5.99% 8.94% 9.56%
Average (March 11-September
13)
8.16%
Table 5.19: CPI Inflation submitted by MSPGCL
Upto Date September-13 March-12 March-11 March-10
CPI 210.00 194.83 179.75 162.75
Escalation 7.78% 8.39% 10.45%
Average (March 11-Sept 13) 8.87%
MERC, Order in Case No 44 of 2013 Page 97
Table 5.20: Computation of escalation rate for FY 2012-13 submitted by MSPGCL
Particulars Percentage
Average WPI 8.16%
Average CPI 8.87%
WPI weightage 60%
CPI Weightage 40%
Average Escalation Rate 8.45%
5.3.7 The Commission has considered the O&M expenses on normative basis for FY
2005-06 as Rs. 9.73 Lakh/MW as specified in Regulation 34.6.2 of MERC
Tariff Regulations, 2005. Further, the Commission has considered an escalation
rate of 4% per annum to arrive at the O&M expenses for FY 2006-07. The
Normative O&M expenses for FY 2007-08, FY 2008-09, FY 2009-10 and FY
2010-11 have been considered based on the escalation rate approved by the
Commission in the respective Orders for those years in accordance with the
increase in WPI and CPI.
5.3.8 The Commission in line with its earlier approach in Case No. 69 of 2011 has
considered the impact of pay revision in FY 2008-09. The Commission has
arrived at the normative O&M expenses of Rs. 10.66 Lakh/MW for
Khaperkheda Unit # 5 for FY 2007-08 after applying the escalation rate of
5.38% on the normative O&M expenses for FY 2006-07. The Commission has
arrived at the normative Employee expenses, A&G expenses and R&M
expenses of Khaperkheda Unit # 5 for FY 2007-08 (in Rs. Lakh/MW)
considering the proportion of the same in the actual O&M expenses of
MSPGCL for FY 2007-08. The Commission has then escalated the normative
Employee expenses by 21% to factor in the impact of pay revision and then
escalated by 5.29%, which is the escalation rate approved by the Commission
for FY 2008-09. The Commission has escalated the normative A&G expenses
and R&M expenses by 5.29%. The Commission thus has arrived at the
normative O&M expenses of Rs. 12.27 Lakh/MW for FY 2008-09.
5.3.9 For FY 2011-12, the Commission has considered the escalation rate of 8.31% as
approved by the Commission in Case No. 6 of 2012. For FY 2012-13, the
Commission has recomputed the escalation rate as 8.35%, on account of
inflation over the approved level of O&M expenses for FY 2011-12, based on
the increase in WPI and CPI. The Commission has considered the point to point
inflation over WPI numbers (as per Office of Economic Advisor of Govt. of
MERC, Order in Case No 44 of 2013 Page 98
India) and CPI numbers for Industrial Workers (as per Labour Bureau,
Government of India) for a period of five years from FY 2008-09 to FY 2012-
13 (upto March, 2013). The Commission has considered a weight of 60% to
WPI and 40% to CPI, based on the expected relationship with the cost drivers.
These escalation rates have been applied over the approved O&M expenses in
FY 2011-12 for projecting the O&M expenses for FY 2012-13. The O & M
expenses approved by the Commission are shown in the Table below:
Table 5.21: O&M expenses approved by the Commission for FY 2012-13 (Rs. Crore)
Particulars MSPGCL Approved
Operation &
Maintenance Expenses
for new
Generating Units of 500
MW sets for FY 2011-12
(Rs. Lakh/MW)
15.00 15.00
Escalation Rate (%) for
FY 2012-13 8.45% 8.35%
O&M expenses for FY
2012-13 (350 days) 78.01 77.94
Depreciation
5.3.10 MSPGCL submitted that for the purpose of depreciation, it had considered the
opening GFA as the original cost of the asset as on COD. MSPGCL submitted
that depreciation has computed annually based on the straight line method at the
rates prescribed in the MERC (Terms & Conditions of Tariff) Regulations,
2005. MSPGCL submitted that it had classified its assets as per the depreciation
schedule in the MERC Regulations and has applied the rates prescribed therein
to work out the depreciation. MSPGCL submitted that depreciation has been
computed on the opening level of GFA (11.5 operational months) and also on
the assets added during the year in line with the approach pursuant to the
Hon’ble ATE’s Judgment in Appeal No. 137 of 2008 dated 15 July, 2009.
Commission’s Analysis
5.3.11 The Commission has prorated the approved opening GFA under various heads
in the same proportion as submitted by MSPGCL. The Commission has
MERC, Order in Case No 44 of 2013 Page 99
considered the disallowance in additional capitalisation submitted by MSPGCL
towards Spares under the head of Plant and Machinery. The Commission has
allowed the additional capitalisation under the other heads as submitted by
MSPGCL. The Commission observed that MSPGCL has claimed depreciation
on opening GFA as well as additional capitalisation during the year for the full
year of operation in FY 2012-13. In this regard, Hon’ble ATE in its Judgement
dated 15 July, 2009 in Appeal No. 137 of 2008, 138 of 2008 and 139 of 2008
has ruled as under:
“In view of the provisions of the Tariff Regulations the Companies Act and the
Accounting Standard-6, we find full justification and rationale in the
contention of the appellant that proportionate depreciation has to be allowed
even for part of the year when the assets have been put to use. The asset once
put to use will be exposed to wear and tear which will not wait to depreciate
till the start of the new financial year. We, therefore, allow the appeal in this
view of the matter also.”
5.3.12 In line with Hon’ble ATE’s Judgment, the Commission has allowed
depreciation on opening GFA for full operational period in FY 2012-13 and on
additional capitalisation for half of operational period in FY 2012-13. Further,
the Commission has considered the rates of depreciation for various classes of
assets as submitted by MSPGCL. The Commission has computed depreciation
for 350 days of operation both on opening GFA and on additional capitalisation
in FY 2012-13.
Table 5.22: Depreciation for FY 2012-13 approved by the Commission
Asset
Classification
Capital Cost as on COD
(Rs. Crore)
Additional Capitalization
(Rs. Crore)
Depreciation
(Rs. Crore)
MSPGCL Approved MSPGCL Approved MSPGCL Approved
Land 0.00 0.00 - - 0.00 0.00
Building 32.45 30.72 - - 1.12 1.06
Cooling Towers
& CWS 277.86 263.06 - - 9.59 9.08
Hydraulic works 3.31 3.13 3.08 3.08 0.16 0.12
Plant &
Machinery 2631.31 2491.12 63.07 39.31 93.01 86.67
Batteries 13.25 12.55 - - 2.29 2.17
Air conditioning 31.51 29.83 - - 1.81 1.72
Overhead Lines,
cables &
networks
81.29 76.96 0.68 0.68 2.83 2.67
Vehicles 0.84 0.80 - - 0.15 0.14
MERC, Order in Case No 44 of 2013 Page 100
Asset
Classification
Capital Cost as on COD
(Rs. Crore)
Additional Capitalization
(Rs. Crore)
Depreciation
(Rs. Crore)
MSPGCL Approved MSPGCL Approved MSPGCL Approved
Furniture &
fixtures 1.10 1.05 - - 0.06 0.06
Office
equipments 0.74 0.70 - - 0.04 0.04
Civil works
(Roads and
Railway sidings)
303.23 287.07 15.24 15.24 5.50 5.09
Total 3376.90 3196.99 82.07 58.31 116.56 108.81
Interest on Long Term Loan
5.3.13 MSPGCL submitted that it had taken long term loan from Power Finance
Corporation (PFC) for funding the capital expenditure for Khaperkheda Unit #
5. MSPGCL submitted that Rs. 2576 Crore of loan from PFC has been
sanctioned for Khaperkheda Unit # 5 and Rs. 2283.30 Crore has been drawn till
CoD. MSPGCL submitted that the loan was drawn with a moratorium period of
4 years 10 months and a repayment period of 15 years. MSPGCL submitted that
the interest rate for the post COD period varied from 11% to 12.50%.
5.3.14 MSPGCL submitted that an additional loan drawl of Rs. 197.39 Crore has been
envisaged in FY 2012-13 post COD for replacing the internal accrual as on
COD with the loan, funding a reduction of Rs. 4.02 Crore in undischarged
liabilities and funding the additional capitalization post COD. MSPGCL
submitted that it is claiming interest on the internal accrual amount getting
replaced by loan post COD. MSPGCL submitted that the total interest expenses
recoverable from the ARR are Rs. 260.64 Crore for FY 2012-13.
Commission’s Analysis
5.3.15 The Commission observed that the sum of Internal Accruals, Additional
Capitalisation in FY 2012-13 and Rs. 4.02 Crore of undischarged liabilities as
submitted by MSPGCL sums up to only Rs. 164.49 Crore while MSPGCL has
submitted a loan drawal of Rs. 197.39 Crore for the same in FY 2012-13. The
Commission also observed that in the excel format F5, MSPGCL has submitted
a loan drawal of Rs. 245.63 Crore in FY 2012-13. Regarding the same, the
Commission in the data gaps asked MSPGCL to reconcile the data.
MERC, Order in Case No 44 of 2013 Page 101
5.3.16 MSPGCL submitted that there had been an inadvertent error in the Petition and
the actual loan drawal in FY 2012-13 is Rs. 245.63 Crore as submitted in the
excel format F5.
5.3.17 Further, the Commission observed that MSPGCL has claimed interest for entire
FY 2012-13 on the amount of internal accruals of Rs. 78.60 Crore while the
same is being proposed to be replaced by loan drawal during FY 2012-13. The
Commission in the data gaps asked MSPGCL to submit the justification for the
same.
5.3.18 MSPGCL submitted that the internal accruals at the time of COD was Rs. 78.60
Crore and was considered as Equity as on COD. MSPGCL submitted that
ideally, RoE should have been claimed on this opening internal accrual at the
time of COD but MSPGCL has not claimed any RoE on this internal accrual as
this amount is envisaged to be replaced by loan post COD. MSPGCL submitted
that it had claimed interest expense on internal accrual in the following manner:
i. MSPGCL submitted that interest on Rs. 78.60 Crore for half period of
the period post COD in FY 2012-13 was being claimed as part of
interest on Rs. 245.63 Crore on average basis.
ii. MSPGCL submitted that interest on Rs. 78.60 Crore for the remaining
period was being claimed as an additional entitlement.
5.3.19 The Commission, on observing that MSPGCL has not explained the difference
between the proposed loan drawal of Rs. 245.63 Crore and Rs. 167.69 Crore,
which is the sum of the amounts under the heads for which the loan drawal is
proposed to be utilised, again asked MSPGCL to reconcile the data. MSPGCL
replied that subsequent to CoD, there was a loan drawal of Rs. 245.63 crore in
FY 2012-13. MSPGCL submitted that the loan drawal in FY 2012-13 has been
utilised for replacing internal accruals of Rs. 46.22 Crore, funding the additional
capitalisation of Rs. 82.07 Crore and towards meeting the Undischarged
Liabilities of Rs. 117.34 Crore.
5.3.20 The Commission has considered the replacement of internal accruals with
portion of loan drawal in FY 2012-13 in the same proportion as submitted by
MSPGCL. The Commission has considered the funding of entire approved
Additional Capitalisation in FY 2012-13 with loan as submitted by MSPGCL.
The Commission has also considered Rs. 163.29 Crore (Rs. 117.34 Crore + Rs.
MERC, Order in Case No 44 of 2013 Page 102
45.95 Crore) as part of loan drawal towards funding of Undischarged Liabilities
during FY 2012-13. The loan drawal considered by the Commission during FY
2012-13 is shown in the Table below:
Table 5.23: Loan Drawal considered by the Commission for FY 2012-13 (Rs. Crore)
Particulars
MSPGCL
Approved Petition
Revised
submission
Internal Accruals
proposed to be replaced
by Loan in FY 2012-13
78.60 46.22 45.34
Additional Capitalisation 82.07 82.07 58.31
Undischarged Liabilities 4.02 117.34 163.29
Total Loan Drawal 164.69 245.63 266.94
5.3.21 MSPGCL submitted a loan repayment of Rs. 120.34 Crore in FY 2012-13. The
Commission in the datagaps asked MSPGCL to submit the computations of
arriving at repayment of Rs. 120.34 Crore considering the opening balance of
Rs. 2283. 30 Crore.
5.3.22 MSPGCL submitted that as per the loan agreement with PFC, the loan is
repayable in sixty (60) quarterly instalments commencing from July, 2012.
MSPGCL submitted that the loan instalments to be repaid have been arrived at
by dividing the outstanding loan as on the due date of repayment with number
of instalments to be paid, as shown in the Table below:
Table 5.24: Loan repayment submitted by MSPGCL
S.
No.
Due date of
payment
Outstanding loan
as on due date
Number of
instalments to be paid
Repayment
instalment
1 16 July, 2012 2285.24 60 38.09
2 15 October, 2012 2420.89 59 41.03
3 15 January, 2013 2401.77 58 41.41
Total 120.53
5.3.23 MSPGCL submitted that repayment amount considered in the Petition was
based on actual loan drawal till 30 November, 2012 and hence, there is a
difference of Rs. 0.19 Crore.
MERC, Order in Case No 44 of 2013 Page 103
5.3.24 The Commission has scrutinised the submissions of MSPGCL. The
Commission computed the loan repayment as per the same methodology as
submitted by MSPGCL. Further, the Commission has considered the interest
rate as submitted by MSPGCL.
5.3.25 The Commission observed that MSPGCL has considered internal accruals as
part of Equity as on COD and accordingly arrived at a Debt:Equity ratio. The
Commission also observed that MSPGCL is proposing to replace some portion
of internal accruals with loan drawn during FY 2012-13. The Commission has
allowed interest for full period for the loan availed to replace internal
accruals post COD in FY 2012-13 as proposed by MSPGCL. The interest
on loan approved by the Commission is shown in the Table below:
Table 5.25: Interest on Loan approved by the Commission (Rs. Crore)
Particulars MSPGCL Approved
Opening Balance 2283.30 2239.66
Addition to Loan including
Undischarged Liabilities 245.63 266.94
Repayment 120.34 121.03
Closing Balance 2408.58 2385.57
Average 2345.94 2312.62
Interest Rate 11.04% 11.04%
Interest 263.31 257.79
Advance Against Depreciation
5.3.26 MSPGCL submitted that Regulation 32.3 of MERC (Terms & Conditions of
Tariff) Regulations, 2005 provides for AAD:
“Where, in respect of a generating station, the actual amount of loan repayment
in any financial year exceeds the amount of depreciation allowable under
Regulation 34.4.1, the Generating Company shall be allowed an advance
against depreciation for the difference between the actual amount of such
repayment and the allowable depreciation in respect of such generating station,
for such financial year:
Provided also that such advance against depreciation shall be restricted to
1/10th of the principal amount of loans minus the amount of depreciation”
MERC, Order in Case No 44 of 2013 Page 104
5.3.27 MSPGCL submitted that it had computed AAD as per MERC Tariff
Regulations, 2005 and the same works out to Rs. 3.78 Crore.
Commission’s Analysis
5.3.28 The Commission has computed AAD in accordance with MERC Tariff
Regulations, 2005 considering the approved loan repayment and depreciation
for FY 2012-13 as shown in the Table below:
Table 5.26: Advance Against Depreciation approved by the Commission (Rs. Crore)
S.
No. Particulars MSPGCL Approved
1 1/10th of the Loan(s) 228.33 223.97
2 Repayment of the Loan(s) as considered for
working out Interest on Loan 120.34 121.03
3 Minimum of the Above 120.34 121.03
4 Less: Depreciation during the year 116.56 108.81
5 (A*) (3-4) 3.78 12.23
6 Cumulative Repayment of the Loan(s) as
considered for working out Interest on Loan 120.34 121.03
7 Less: Cumulative Depreciation 116.56 108.81
8 (B*) (6-7) 3.78 12.23
9 Advance Against Depreciation (Minimum
of A & B) 3.78 12.23
Return on Equity
5.3.29 MSPGCL submitted that as per Regulation 34.1 of MERC Tariff Regulations
2005, RoE has to be computed on the equity capital determined in accordance
with Regulation 31 at the rate of 14 per cent per annum in Indian Rupee terms.
MSPGCL submitted that it had considered a rate of return of 14% on the equity
as on COD pertaining to Government of Maharashtra equity.
Commission’s Analysis
MERC, Order in Case No 44 of 2013 Page 105
5.3.30 The Commission has computed Return on Equity at the rate of 14% as specified
in MERC Tariff Regulations, 2005 on Equity as on COD pertaining to
Government of Maharashtra equity.
5.3.31 Further, MSPGCL submitted that there has been Equity infusion of Rs. 32.38
Crore by Government of Maharashtra in FY 2012-13. MSPGCL submitted that
this equity amount has been utilised to replace internal accruals of Rs. 32.38
Crore.
5.3.32 The Commission has considered the replacement of internal accruals with
equity in the same proportion as submitted by MSPGCL. The Commission has
also allowed Return on Equity on this amount as this amount is a part of Equity.
The Commission has also considered Rs. 11.56 Crore towards funding of
portion of balance Undischarged Liabilities with Equity.
5.3.33 The Return on Equity approved by the Commission for FY 2012-13 is shown in
the Table below:
Table 5.27: Return on Equity for FY 2012-13 approved by the Commission (Rs. Crore)
Particulars
MSPGCL
Approved Petition
Revised
submission
GoM Equity 599.37 599.37 587.92
Equity toward Additional Capitalisation 0.00 0.00 0.00
Internal Accruals replaced by Equity 0.00 32.38 31.66
Equity towards funding of remaining
Undischarged Liabilities excluding LD in
FY 2012-13
0.00 0.00 13.64
Closing Equity 599.37 631.75 633.22
Rate of Return 14% 14% 14%
Return on Equity 80.46* 80.46* 83.18
*Only on Equity of Rs 599.37 Crore
Income Tax
5.3.34 MSPGCL submitted that it had calculated the Income Tax by applying the MAT
rate of 20.01% on RoE for FY 2012-13. MSPGCL submitted that the total
Income Tax payable works out to be Rs. 16.10 Crore for FY 2012-13.
MERC, Order in Case No 44 of 2013 Page 106
Commission’s Analysis
5.3.35 The Commission has computed the Income Tax on RoE at the rate of tax as
submitted by MSPGCL for FY 2012-13.
Table 5.28: Income Tax approved by the Commission for FY 2012-13 (Rs. Crore)
Particulars MSPGCL Approved
RoE 80.46 83.18
MAT Rate 20.01% 20.01%
Income Tax 16.10 16.64
Interest on Working Capital
5.3.36 MSPGCL submitted that the working capital has been calculated in line with
Regulation 34.5 of MERC Tariff Regulations 2005, wherein the following has
been considered:
a. Cost of coal for two months;
b. Cost of oil for two months;
c. Cost of secondary fuel oil for two months;
d. Operation and Maintenance expenses for one month;
e. Maintenance spares @ 1 per cent of the historical cost; and
f. Receivables for sale of electricity equivalent to two months of the sum of
annual fixed charges and energy charges calculated on target availability;
minus
g. Less: Payables for fuel (including oil and secondary fuel oil) to the extent of
one month of the cost of fuel calculated on target availability.
5.3.37 MSPGCL submitted that the same tariff principle has been adopted in FY 2012-
13 as well. MSPGCL submitted that the short-term Prime Lending Rate of State
Bank of India as on the date of filing this application, i.e., 14.50%, has been
considered for calculation of interest on working capital. MSPGCL submitted
that the total interest on working capital for post COD period works out to be
Rs. 38.95 Cr for FY 2012-13 (11.5 operational months).
Commission’s Analysis
MERC, Order in Case No 44 of 2013 Page 107
5.3.38 The Commission has considered SBI PLR as on date of filing of the Petition (22
March, 2013) for computation of IWC. The Commission has computed the
interest on Working Capital in accordance with MERC Tariff Regulations, 2005
as shown in the Table below:
Table 5.29: Interest on Working Capital approved by the Commission for FY 2012-13
(Rs. Crore)
Particulars Norm MSPGCL Approved
Cost of Coal/Lignite 2 months 47.58 85.61
Cost of Secondary Fuel Oil 2 months 11.17 10.74
O&M expenses one month 6.69 6.68
Maintenance Spares 1% of GFA 33.77 31.97
Receivables 2 months 203.33 198.53
Less Payables for fuel 1 month 29.37 48.17
Total Working Capital
requirement 273.16 285.35
Computation of IWC
Interest Rate (%) SBI PLR 14.50% 14.45%
IWC 37.98 39.54
5.3.39 The significant variation in cost of coal in the Table above is because of the
reason that MSPGCL in its computations has not considering the cost of
imported coal.
Non Tariff Income
5.3.40 MSPGCL has not projected any Non Tariff Income for FY 2012-13. The
Commission directs MSPGCL to submit the details of actual Non Tariff
Income for FY 2012-13 at the time of truing up for FY 2012-13 based on
audited accounts.
Annual Fixed Charges
5.3.41 Based on the above, the Annual Fixed Charges of Khaperkheda Unit # 5
approved by the Commission is shown in the Table below:
MERC, Order in Case No 44 of 2013 Page 108
Table 5.30: AFC approved by the Commission for Khaperkheda Unit # 5 for FY 2012-
13 (Rs. Crore)
Particulars MSPGCL Approved
Depreciation 116.56 108.81
Advance Against Depreciation 3.78 12.23
Operation & Maintenance Expenses 78.01 77.94
Interest on Loan 263.32 257.79
Return on Equity 80.46 83.18
Interest on Working Capital 37.98 39.54
Income Tax 16.10 16.64
AFC 596.21 596.12
5.3.42 Out of the above approved Annual Fixed Charges for FY 2012-13, the AFC
for stabilisation period of 180 days works out to Rs. 306.58 Crore and for
post stabilisation period of 170 days, AFC works out to Rs. 289.55 Crore.
The Commission allows MSPGCL to recover AFC at Availability approved
by the Commission as mentioned in Table 5.8 separately for stabilisation
period and post stabilisation period. As discussed earlier, the Commission
will consider the reasons for variation in actual performance with respect
to norms specified in MERC Tariff Regulations, 2005 while carrying out
the final truing up for FY 2012-13.
5.3.43 The summary of tariff approved by the Commission for FY 2012-13 is shown in
the Table below:
Table 5.31: Tariff approved by the Commission for FY 2012-13
Particulars MSPGCL Approved
Annual Fixed Charges (Rs. Crore) 596.21 596.12
Variable Charge (Rs./kWh)
Stabilisation Period 3.21 3.21
Post Stabilisation Period 2.84 2.78
5.3.44 The Commission has approved the Annual Fixed Charges for FY 2012-13
as Rs 596.12 Crore. The Commission has approved the Energy Charges of
Rs 3.21 kWh for stabilisation period and Rs 2.78/kWh for post stabilisation
period.
MERC, Order in Case No 44 of 2013 Page 109
5.3.45 The Commission has accordingly approved the Capital Cost and Tariff of
Khaperkheda Unit # 5 for FY 2012-13. As FY 2012-13 is already
completed, the Commission allows MSPGCL to recover the difference in
revenue recoverable in accordance with the Tariff approved in this Order
vis-a-vis the Tariff charged by MSPGCL in 6 equal monthly instalments
from October 2013 onwards. The Commission shall carry out the truing up
for FY 2012-13 in accordance with MERC Tariff Regulations, 2005.
5.3.46 The Commission allows MSPGCL to recover fixed cost and energy charges
as per the tariff approved in this Order from MSEDCL till tariff for FY
2013-14 is approved as a part of MSPGCL’s Multi Year Tariff Petition for
the second Control Period for FY 2013-14 to FY 2015-16.
5.3.47 As the variation in cost of generation is ultimately to be passed on to
consumers, the Commission hereby allows the MSEDCL to recover the
variation in energy charge component of the amount billed by MSPGCL to
MSEDCL as approved by the Commission from the consumers through the
FAC mechanism. Similarly, the Commission allows MSEDCL to recover
the variation in fixed charge component of the amount billed by MSPGCL
to MSEDCL as approved by the Commission from the consumers in
proportion to Average Billing Rate of respective consumer categories,
under intimation to the Commission.
Summary of our findings:
i) The Commission has gone through the submissions of MSPGCL and
observed that the actual cost under land and site development as claimed
by MSPGCL is the cost incurred by MSPGCL in addition to the site
development work awarded to M/s BGR under the BoP Civil package
order. Hence, the Commission has approved the cost of Rs. 29.00 Crore
for Land and Site Development as on COD as submitted by MSPGCL.
ii) As MSPGCL has awarded the BTG Contract after following the
competitive bidding process and cost increase is on account of the price
variation for various components as per the formulae prescribed in the
contract, the Commission has allowed the actual cost of BTG package as
on COD.
MERC, Order in Case No 44 of 2013 Page 110
iii) The Commission has gone through the submissions of MSPGCL and is of
the view that it has followed prudent utility practices in the award of BoP
Package as the same was awarded after the competitive bidding process.
Further, the actual cost of BoP Electrical and Mechanical as on COD is
lower than the Ordering Cost. The Commission has hence, approved the
cost of BoP Electrical and Mechanical as on COD as submitted by
MSPGCL.
iv) The Commission observes that MSPGCL has capitalised the amount of
fuel costs less revenue, on account of infirm generation of power.
However, as fuel cost is a revenue expense, whether incurred during
infirm generation or firm generation, the Commission is of the view that
the same needs to be recovered directly for the power supplied during the
period instead of capitalising it as a part of Capital Cost. Accordingly, the
Commission hereby allows MSPGCL to recover the under-recovered fuel
cost, i.e., Rs. 28.05 Crore for infirm power supplied to MSEDCL in three
monthly instalments after the issue of this Order and MSEDCL can
recover this cost through Fuel Adjustment Cost Adjustment (FAC)
mechanism.
v) The Commission observed that the overheads as on COD are
approximately 3% of hard cost, which seems reasonable as per the
industry practices. Hence, the Commission has approved the overheads as
on COD as submitted by MSPGCL.
vi) The Commission observed that the cost of spares procured till COD is
1.80% of Capital Cost as on COD, which is within 2.5% of project cost as
stipulated in Regulation 30.1 of MERC (Terms and Conditions of Tariff),
Regulations, 2005. Hence, the Commission has approved the cost of
spares as on COD as submitted by MSPGCL.
vii) Based on the Base Case IDC computations submitted by MSPGCL, the
Commission observed that the Hard Cost as well as Loan amount
MERC, Order in Case No 44 of 2013 Page 111
considered by MSPGCL for computation of Base Case IDC is higher than
the actual Hard Cost and actual Loan amount as on COD respectively.
MSPGCL in its submissions also submitted that the capital cost approved
by its Board was indicative in nature and should not be considered as
base cost.
viii) The Commission observes that the purpose of Base Case IDC is to
determine the impact of time overrun on IDC, i.e., to determine the
difference in IDC if the Project had been completed in the stipulated time
duration and the actual IDC incurred for the actual time duration of
completion.
ix) The Commission has thus, recomputed the Base Case IDC considering
the approved Hard Cost as on COD. As regards the Debt Equity ratio for
computation of Base Case IDC, the Commission has considered 80:20 as
the same has been approved by GoM while according approval to
Khaperkheda Unit # 5 and initially the Project was envisaged to be
funded through Debt:Equity of 80:20. The Commission has considered
the actual interest rates and proportion of loan amount drawn as
submitted by MSPGCL.
x) The Commission has gone through MSPGCL’s submission of reasons for
delay in execution of the Project. The Commission is of the view that the
present case appears to be of sudden spurt in execution of Power Projects
in the country and consequential increase in demand of equipments and
the gestation period required by the industry in enhancing the
manufacturing capacity. Considering all the facts and documents
submitted by MSPGCL, though it is evident that there was delay on the
part of BHEL in supply and commissioning of the main plant, it is not
established beyond doubt that the entire delay was due to the reasons
beyond the control of MSPGCL. Accordingly, the Commission has
allowed the cost of time overrun to be shared equally between MSPGCL
and the consumers. Admittedly, there is no enhancement in cost of the
contract price of the equipment as no price variation escalation was
permissible to BHEL beyond the schedule date of completion of the
MERC, Order in Case No 44 of 2013 Page 112
Project according to terms of the agreement. The impact of time overrun
beyond the contractual schedule is only on IDC.
xi) As the Commission has allowed only 50% of the incremental IDC
(Difference of Actual IDC and Base Case IDC), the Commission has
deducted 50% of retention amount towards Liquidated Damages from
Capital Cost at this stage. The Commission directs the Petitioner to
submit a separate report regarding the actual amount of the LD
recovered from the Contractors upon finalisation of the Contracts so that
the same can be considered while approving the final Capital Cost after
finalisation of Contracts.
xii) The Commission in this Order has approved the capital cost for
Khaperkheda Unit # 5 as Rs. 3340.41 Crore. The Commission has allowed
MSPGCL to recover the unrecovered fuel expenses of Rs. 28.05 Crore
towards infirm power supply separately and hence, the Capital Cost as on
COD after deducting the fuel expenses and 50% of LD amount works out
to Rs. 3196.99 Crore. Further, the final Capital Cost as on COD will get
revised once MSPGCL submits the final LD amount recovered from the
Contractors upon finalisation of Contracts.
xiii) Considering the submissions of MSPGCL regarding substantial shortfall
in coal availability and other factors, which affected the performance
during stabilisation period, the Commission on provisional basis has
considered the actual performance parameters during the stabilisation
period, which shall be subject to final truing up. As regards post
stabilisation period, the Commission observed that the variation in
performance parameters as compared to norms is marginal and in some
of the months, the actual performance was even better than the normative
parameters. Considering the marginal variation in performance
parameters during post stabilisation period, it is more important to
analyse the P&G Test reports for proper assessment of variation in
performance parameters. The Commission, therefore at this stage has
provisionally approved the performance parameters as per the norms
MERC, Order in Case No 44 of 2013 Page 113
specified in MERC Tariff Regulations, 2005 for post stabilisation period
subject to final Truing up for FY 2012-13.
xiv) The Commission observed that the total initial spares including spares to
be capitalised in FY 2012-13 exceeds the ceiling of 2.5% of Capital Cost as
on Cut-off date. The Commission has allowed the actual spares as on
COD as the same was within the ceiling norm as specified in MERC
Tariff Regulations, 2005. The Commission has limited the total quantum
of spares to the ceiling limit of 2.5% of Capital cost as on Cut off date in
accordance with MERC Tariff Regulations, 2005.
xv) The Commission has allowed depreciation on opening GFA for full
operational period in FY 2012-13 and on additional capitalisation for half
of operational period in FY 2012-13.
xvi) The Commission has approved the Annual Fixed Charges for FY 2012-13
as Rs 596.12 Crore. The Commission has approved the Energy Charges of
Rs 3.21/kWh for stabilisation period and Rs 2.78/kWh for post
stabilisation period.
xvii) As FY 2012-13 is already completed, the Commission allows MSPGCL to
recover the difference in revenue recoverable in accordance with the
Tariff approved in this Order vis-a-vis the Provisional Tariff charged by
MSPGCL in 6 equal monthly instalments from October 2013 onwards.
The Commission shall carry out the truing up for FY 2012-13 in
accordance with MERC Tariff Regulations, 2005.
xviii) The Commission allows MSPGCL to recover fixed cost and energy
charges as per the tariff approved in this Order from MSEDCL till tariff
for FY 2013-14 is approved as a part of MSPGCL’s Multi Year Tariff
Petition for the second Control Period for FY 2013-14 to FY 2015-16.
xix) As the variation in cost of generation is ultimately to be passed on to
consumers, the Commission hereby allows MSEDCL to recover the
MERC, Order in Case No 44 of 2013 Page 114
variation in energy charge component of the amount billed by MSPGCL
to MSEDCL as approved by the Commission from the consumers
through the FAC mechanism. Similarly, the Commission allows
MSEDCL to recover the variation in fixed charge component of the
amount billed by MSPGCL to MSEDCL as approved by the Commission
from the consumers in proportion to Average Billing Rate of respective
consumer categories, under intimation to the Commission.
With this Order, the Commission disposes off MSPGCL’s Petition in Case No. 44 of
2013.
Sd/- Sd/- Sd/-
(Chandra Iyengar) (Vijay L. Sonavane) (V.P. Raja)
Member Member Chairman
MERC, Order in Case No 44 of 2013 Page 115
6 APPENDIX
Appendix-1
List of Persons who attended Technical Validation Session-1 in Case No.44 of
2013 held on 17.4.2013
Sr. No Name of Person Name of Institution
1 Shri. Ashish Sharma, MD MSPGCL
2 Shri J.K Srinivasan MSPGCL
3 Shri. V.P.Singh MSPGCL
4 Shri. C.S Thotawe MSPGCL
5 Shri L N Margade MSPGCL
6 Shri B.K Yadhav MSPGCL
7 Shri. A.A Harne MSPGCL
8 Shri. M.V Deshmukh MSPGCL
9 Shri. V.P Rathode MSPGCL
10 Shri. D.C.Patil MSPGCL
11 Shri .P M Nikhare MSPGCL
12 Shri. S.K. Labde MSPGCL
13 Shri. S.A.Nikalje MSPGCL
14 Shri.R.G Varpe MSPGCL
15 Shri.S.V.Bedekar MSPGCL
16 Shri Rashish Sakharkar MSPGCL
17 Shri Svio Rego MSPGCL
18 Shri.R.T Age MSPGCL
19 Shri. G.S Puranik MSPGCL
20 Ramandeep Singh Deloitte
21 Ms. Swati Kedia Deloitte
MERC, Order in Case No 44 of 2013 Page 116
Appendix-2
List of Person who attended Technical Validation Session-2in Case No.44 of 2013
held on 9.5.2013
Sr. No Name of Person Name of Institution
1 Shri J.K Srinivasan MSPGCL
2 Shri. V.P.Singh MSPGCL
3 Shri. C.S Thotawe MSPGCL
4 Shri Anil Nandanwar MSPGCL
5 Shri L N Margade MSPGCL
6 Shri B.Y Yadhav, MSPGCL
7 Shri. A .A.Harne MSPGCL
8 Shri. M.V Deshmukh MSPGCL
9 Shri. V.P Rathode MSPGCL
10 Shri .P M Nikhare MSPGCL
11 Shri.V.L Sonavane MSPGCL
12 Shri J.M.Pohekar MSPGCL
13 Ms Vaishali Patil MSPGCL
14 Shri R R Kulkarni MSPGCL
15 Shri N N Bishare MSPGCL
16 Shri S A M Naqvi MSPGCL
17 Shri Promad Koparde MSPGCL
18 Shri. S.K. Labde MSPGCL
19 Shri.M.M.Abhyankar MSPGCL
20 Shri Arvind Parate MSPGCL
21 Shri. S.A.Nikalje MSPGCL
22 Shri.R.G Varpe MSPGCL
23 Shri Svio Rego MSPGCL
24 Shri.R.T Age MSPGCL
25 Shri. G.S Puranik MSPGCL
26 Shri. Ramandeep Singh Deloitte
27 Ms. Swati Kedia Deloitte
28 Shri.Sanjay S. Kurhade MSPGCL
29 Shri. Suresh Gehani ABPS
30 Shri Namala K.M Choudhary ABPS
MERC, Order in Case No 44 of 2013 Page 117
Appendix-3
List of Person who attended Technical Validation Session- 3 of Case No.44 of
2013 held on 23.5.2013
Sr. No Name of Person Name of Institution
1 Shri. Ashish Sharma, MD MSPGCL
2 Shri. C.S Thotawe MSPGCL
3 Shri J.K Srinivasan MSPGCL
4 Shri. V.P.Singh MSPGCL
5 Shri Anil Nandanwar MSPGCL
6 Shri L N Margade MSPGCL
7 Shri. A .A.Harne MSPGCL
8 Shri. M.V Deshmukh MSPGCL
9 Shri. V.P Rathode MSPGCL
10 Shri .P M Nikhare MSPGCL
11 Shri J.M.Pohekar MSPGCL
12 Shri R R Kulkarni MSPGCL
13 Shri N N Bighane MSPGCL
14 Shri.S.V.Bedekar MSPGCL
15 Shri S A M Naqvi MSPGCL
16 Shri. S.K. Labde MSPGCL
17 Shri. S.K. Labde MSPGCL
18 Shri. V S Patil MSPGCL
19 Shri K.P.Tujar MSPGCL
20 Shri Arvind Parate MSPGCL
21 Shri.Avinash Tikle MSPGCL
22 Shri. S.A.Nikalje MSPGCL
23 Shri.R.G Varpe MSPGCL
24 Shri. G.S Puranik MSPGCL
25 Shri Sanjay S. Kurhade MSPGCL
26 Shri Ajay Bamne MSPGCL
28 Shri N.M Valvi MSPGCL
29 Shri. S.P.Rekhade MSPGCL
30 Shri Tilok Kumar MSPGCL
31 Ramandeep Singh Deloitte
32 Ms. Swati Kedia Deloitte
MERC, Order in Case No 44 of 2013 Page 118
Sr. No Name of Person Name of Institution
33 Shri. Suresh Gehani ABPS
34 Shri. Raman Gulali ABPS
35 Shri Chirag Gandhi R R Associates
36 Shri Viral Soni R.R. Associates
37 Dr..Ashok Pendse TBI Consumers’ Assn
MERC, Order in Case No 44 of 2013 Page 119
Appendix-4
List of Persons who attended Public Hearing of Case No.44 of 2013 on 16.7.2013
Sr.
No Name of Person Name of Institution
1 Shri. Ashish Sharma, MD MSPGCL
2 Shri Ashok Pendse Thane Belapur Industries Association
3
Shri Baban Chawane Maharashtra Chamber of Commerce
4 Shri Jagdish/Kiran Vishnupant
Paturkar
Consumer Representative
5 Shri Shridhar Vasant
Vyawahare
Consumer Representative
6 Shri Pratap Hogade Maharashtra Veej Grahak Sanghtana
7 Shri Raksh Pal Abrol Bhartiya Udhami Avam Upbhokta Sangh
8 D.M.Kadale Exe Engineer MSPGCL ,Bhusawal TPS
9 V.N Patil, JE MSPGCL, Bhusawal TPS
10 Mahesh Aphale MSPGCL
11 Shri A.D Pimple MSPGCL
12 Shri. A .A.Harne MSPGCL
13 Shri L N Margade MSPGCL
14 Shri S.B.Ghale MSPGCL
15 Shri S A M Naqvi MSPGCL
16 Shri. C.S Thotawe MSPGCL
17 Shri Sanjay S. Kurhade MSPGCL
19 Shri J.K Srinivasan MSPGCL
20 Shri. V.P.Singh MSPGCL
21 Shri Anil Nandanwar MSPGCL
22 Shri A.A.Bapat MSPGCL
23 Shri Vijay Singh MSPGCL
24 Shri M M Abhayankar MSPGCL
25 Shri. V.P Rathode MSPGCL
26 Shri V R Hedaoo MSPGCL
MERC, Order in Case No 44 of 2013 Page 120
Sr.
No Name of Person Name of Institution
27 Shri A.D.Sonkusare MSPGCL
28 Shri S.P Fegade MSPGCL
29 Shri. R.A.Muthane MSPGCL
30 Shri.Y.K.Dhamarkar MSPGCL
31 Shri J.A Khandale MSPGCL
32 Shri. S.K. Labde MSPGCL
33 Shri.R.G Varpe MSPGCL
34 Shri Savio Rego MSPGCL
35 Shri Amar Nimbalkar MSPGCL
36 ShriUmakant Salunkhe MSPGCL
37 Shri Ravi Singh Sayam MSPGCL
38 Shri S.K.Maraskolhe MSPGCL
39 Shri D.R Rane MSPGCL
40 Shri V.L Sonawane MSPGCL
41 Ramandeep Singh Deloitte
42 S.Trilok Kumar Deloitte