FIDIC PRELIMINARIES GENERALS PRASA In-Cab · PDF fileFIDIC PRELIMINARIES GENERALS PRASA In-Cab...
Transcript of FIDIC PRELIMINARIES GENERALS PRASA In-Cab · PDF fileFIDIC PRELIMINARIES GENERALS PRASA In-Cab...
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
No
BILL NO. 1
PRELIMINARIES
NOTES:
i) The Special Conditions of Contract for Plant Design and
Build for Electrical and Mechanical Plant, And for Building and
Engineering Works, Designed by the Contractor as issued by the
Federation Internationale des Ingenieurs-Conseils (FIDIC), First
Edition 1999, shall be the applicable contract for the execution of
the Works.
ii) Tenderers are referred to the abovementioned
documents for the full intent and meaning of each clause thereof
(hereinafter referred to by heading and clause number only) for
which such allowance must be made as may be considered
necessary.
All references in the above mentioned documents and this
Preliminaries Sheet to "Architect"/"Principal Agent" are deemed to
be references to "The Engineer"
iii) Where standard clauses or alternatives are not applicable
to this contract such modifications, corrections or supplements as
will apply are given under each relevant clause heading.
iv) Where N/A appears opposite any clause, such clause as
detailed in the standard documents referred to is NOT
APPLICABLE to this contract.
SECTION A : CONDITIONS OF CONTRACT
A.1 - GENERAL PROVISIONS
1 Clause 1.1: Definitions Item
2 Clause 1.2: Interpretation Item
3 Clause 1.3: Communications Item
4 Clause 1.4: Law and Language Item
5 Clause 1.5: Priority of Documents Item
6 Clause 1.6: Contract Agreement Item
7 Clause 1.7: Assignment Item
8 Clause 1.8: Care and Supply of Documents Item
9 Clause 1.9: Errors in the Employer's Requirements Item
10 Clause 1.10: Employer's Use of Contractor's Documents Item
11 Clause 1.11: Contractor's Use of Employer's Documents Item
12 Clause 1.12: Confidential Details Item
13 Clause 1.13: Compliance with Laws Item
Clause 1.14: Joint and Several Liability Item
A.2 - THE EMPLOYER
14 Clause 2.1: Right of Access to the Site Item
15 Clause 2.2: Permits, Licenses of Approvals Item
16 Clause 2.3: Employer's Personnel Item
1
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
17 Clause 2.4: Employer's Financial Arrangement Item
18 Clause 2.5: Employer's Claims Item
A.3 - THE ENGINEER
The Engineer shall be deemed for the purposes of this contract, to be
the Principal Agent, Architect or any other person appointed by the
Employer to fulfill such duties.
19 Clause 3.1: Engineer's Duties and Authority Item
20 Clause 3.2: Delegation by the Engineer Item
21 Clause 3.3: Instructions of the Engineer Item
22 Clause 3.4: Replacement of the Engineer Item
23 Clause 3.5: Determinations Item
A.4 - THE CONTRACTOR
24 Clause 4.1 - Contractor's General Obligations Item
25 Clause 4.2 - Performance Security Item
26 Clause 4.3 - Contractor's Representative Item
27 Clause 4.4 - Sub-Contractors Item
28 Clause 4.5 - Nominated Subcontractors Item
29 Clause 4.6 - Co-operation Item
30 Clause 4.7 - Setting out Item
31 Clause 4.8 - Safety Procedures Item
32 Clause 4.9 - Quality Assurance Item
33 Clause 4.10 - Site Data Item
34 Clause 4.11 - Sufficiency of accepted Contract Amount Item
35 Clause 4.12 - Unforeseeable Physical Conditions Item
36 Clause 4.13 - Right of Way and Facilities Item
37 Clause 4.14 - Avoidance of Interference Item
38 Clause 4.15 - Access Route Item
39 Clause 4.16 - Transport of Goods Item
40 Clause 4.17 - Contractor's Equipment Item
41 Clause 4.18 - Protection of the Environment Item
42 Clause 4.19 - Electricity, Water and Gas Item
43 Clause 4.20 - Employer's Equipment and Free-issue Material Item
44 Clause 4.21 - Progress Reports Item
45 Clause 4.22 - Security of the Site Item
46 Clause 4.23 - Contractor's Operations on Site Item
47 Clause 4.24 - Fossils Item
A.5 - DESIGN
48 Clause 5.1 - General Design Obligations Item
49 Clause 5.2 - Contractor's Documents Item
50 Clause 5.3 - Contractor's Undertaking Item
51 Clause 5.4 - Technical Standards and Regulations Item
52 Clause 5.5 - Training Item
53 Clause 5.6 - As-Built Documents Item
54 Clause 5.7 - Operation and Maintenance Manuals Item
55 Clause 5.8 - Design Error Item
A.6 - STAFF AND LABOUR
56 Clause 6.1 - Engagement of Staff and Labour Item
57 Clause 6.2 - Rates of Wages and Conditions of Labour Item
58 Clause 6.3 - Persons in the Service of the Employer Item
59 Clause 6.4 - Labour Laws Item
2
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
60 Clause 6.5 - Working Hours Item
61 Clause 6.6 - Facilities for Staff and Labour Item
62 Clause 6.7 - Health and Safety Item
63 Clause 6.8 - Contractor's Superintendence Item
64 Clause 6.9 - Contractor's Personnel Item
65 Clause 6.10 - Records of Contractor's Personnel and Equipment Item
66 Clause 6.11 - Disorderly Conduct Item
A.7 - PLANT, MATERIALS AND WORKMANSHIP
67 Clause 7.1 - Manner of Execution Item
68 Clause 7.2 - Samples Item
69 Clause 7.3 - Inspection Item
70 Clause 7.4 - Testing Item
71 Clause 7.5 - Rejection Item
72 Clause 7.6 - Remedial work Item
73 Clause 7.7 - Ownership of Plant and Material Item
74 Clause 7.8 - Royalties Item
A.8 - COMMENCEMENT, DELAYS AND SUSPENSION
75 Clause 8.1 - Commencement of Works Item
76 Clause 8.2 - Time for Completion Item
77 Clause 8.3 - Programme Item
78 Clause 8.4 - Extension of Time for Completion Item
79 Clause 8.5 - Delays caused by Authorities Item
80 Clause 8.6 - Rate of Progress Item
81 Clause 8.7 - Delay Damages Item
82 Clause 8.8 - Suspension of Work Item
83 Clause 8.9 - Consequences of Suspension Item
84 Clause 8.10 - Payment for Plant and Materials in Event of
Suspension
Item
85 Clause 8.11 - Prolonged Suspension Item
86 Clause 8.12 - Resumption of Work Item
A.9 - TESTS ON COMPLETION
87 Clause 9.1 - Contractor's Obligation Item
88 Clause 9.2 - Delayed Tests Item
89 Clause 9.3 - Retesting Item
90 Clause 9.4 - Failure to pass Tests on Completion Item
A.10 - EMPLOYER'S TAKING OVER
91 Clause 10.1 - Taking over of the Works and Sections Item
92 Clause 10.2 - Taking over of parts of the works Item
93 Clause 10.3 - Interference with Tests on Completion Item
94 Clause 10.4 - Surfaces requiring Reinstatement Item
A.11 - DEFECTS LIABILITY
95 Clause 11.1 - Completion of Outstanding work and Remedying
Defects
Item
96 Clause 11.2 - Cost of Remedying Defects Item
97 Clause 11.3 - Extension of Defects Notification Period Item
98 Clause 11.4 - Failure to Remedy Defects Item
99 Clause 11.5 - Removal of Defective Work Item
100 Clause 11.6 - Further Tests Item
101 Clause 11.7 - Right of Access Item
3
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
102 Clause 11.8 - Contractor to Search Item
103 Clause 11.9 - Performance Certificate Item
104 Clause 11.10 - Unfulfilled Obligations Item
105 Clause 11.11 - Clearance of Site Item
A.12 - TESTS AFTER COMPLETION
106 Clause 12.1 - Procedure for Tests after Completion Item
107 Clause 12.2 - Delayed Tests Item
108 Clause 12.3 - Retesting Item
109 Clause 12.4 - Failure to Pass Tests after Completion Item
A.13 - VARIATIONS AND ADJUSTMENTS
110 Clause 13.1 - Right to vary Item
111 Clause 13.2 - Value Engineering Item
112 Clause 13.3 - Variation Procedure Item
113 Clause 13.4 - Payment in Applicable Currencies Item
114 Clause 13.5 - Provisional Sums Item
115 Clause 13.6 - Daywork Item
116 Clause 13.7 - Adjustments for Changes in Legislation Item
117 Clause 13.8 - Adjustments for Changes in Cost Item
A.14 - CONTRACT PRICE AND PAYMENTS
118 Clause 14.1 - The Contract Price Item
119 Clause 14.2 - Advance Payment Item
120 Clause 14.3 - Application for interim Payment Certificates Item
121 Clause 14.4 - Schedule of Payments Item
122 Clause 14.5 - Plant and materials intended for the works Item
123 Clause 14.6 - Issue of interim Payment Certificates Item
124 Clause 14.7 - Payment Item
125 Clause 14.8 - Delayed Payment Item
126 Clause 14.9 - Payment of Retention Money Item
127 Clause 14.10 - Statement at Completion Item
128 Clause 14.11 - Application for Final Payment Certificate Item
129 Clause 14.12 - Discharge Item
130 Clause 14.13 - Issue of Final Payment Certificate Item
131 Clause 14.14 - Cessation of Employer's liability Item
132 Clause 14.15 - Currencies of Payment Item
A.15 - TERMINATION BY EMPLOYER
133 Clause 15.1 - Notice to Correct Item
134 Clause 15.2 - Termination by Employer Item
135 Clause 15.3 - Valuation at Date of Termination Item
136 Clause 15.4 - Payment after Termination Item
137 Clause 15.5 - Employer's Entitlement to Termination Item
A.16 - SUSPENSION AND TERMINATION BY CONTRACTOR
138 Clause 16.1 - Contractor's Entitlement to suspend Work Item
139 Clause 16.2 - Termination by Contractor Item
140 Clause 16.3 - Cessation of Work and removal of Contractor's
Equipment
Item
141 Clause 16.4 - Payment on Termination Item
A.17 - RISK AND RESPONSIBILITY
4
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
142 Clause 17.1 - Indemnities Item
143 Clause 17.2 - Contractor's Care of the Works Item
144 Clause 17.3 - Employer's Risks Item
145 Clause 17.4 - Consequences of Employer's risks Item
146 Clause 17.5 - Intellectual and Industrial Property Rights Item
147 Clause 17.6 - Limitation of Liability Item
A.18 - INSURANCE
148 Clause 18.1 - General Requirements for Insurance Item
149 Clause 18.2 - Insurance for Works and Contractor's Equipment Item
150 Clause 18.3 - Insurance against Injury to Persons and Damage to
Property
Item
151 Clause 18.4 - Insurance for Contractor's Personnel Item
A.19 - FORCE MAJEURE
152 Clause 19.1 - Definition of Force Majeure Item
153 Clause 19.2 - Notice of Force Majeure Item
154 Clause 19.3 - Duty to Minimise Delay Item
155 Clause 19.4 - Consequences of Force Majeure Item
156 Clause 19.5 - Force Majeure affecting Sub-Contractor Item
157 Clause 19.6 - Optimal Termination, Payment and Release Item
158 Clause 19.7 - Release from performance under the law Item
A.20 - CLAIMS, DISPUTES AND ARBITRATION
159 Clause 20.1 - Contractor's Claim Item
160 Clause 20.2 - Appointment of the Dispute Adjudication Board Item
161 Clause 20.3 - Failure to agree to Dispute Adjudication Board Item
162 Clause 20.4 - Obtaining Dispute Adjudication Board's decision Item
163 Clause 20.5 - Amicable settlement Item
164 Clause 20.6 - Arbitration Item
165 Clause 20.7 - Failure to comply to Dispute Adjudication Board's
decision
Item
166 Clause 20.8 - Expiry of Dispute Adjudication Board's appointment Item
SECTION B : MODEL PRELIMINARIES
B1: Supplementary documentation
167 B1.1: Consultants
ENGINEER
Telephone No. : +27 (0)
Facsimile No. : +27 (0)
CONSULTANT 1
5
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
Telephone No. : +27 (0)
Facsimile No. : +27 (0)
CONSULTANT 2
Telephone No. : +27 (0)
Facsimile No. : +27 (0)
CONSULTANT 3
Telephone No. : +27 (0)
Facsimile No. : +27 (0)
CONSULTANT 4
Telephone No. : +27 (0)
Facsimile No. : +27 (0)
168 B1.2: Performance guarantee by the Contractor Item
The full security for the due fulfilment of all obligations under
this contract is to remain in force after the 90 (ninety) days after
the issue of the Practical Completion certificate.
No guarantee containing any clause which allows the financial
institution providing such guarantee to withdraw from their
undertaking before 90 (ninety) calendar days after the date of
issue of the Practical Completion Certificate by the Engineer nor
any guarantee stipulating an expiry date, will be acceptable by the
Employer.
Notwithstanding the above, the guarantee will only be
returned to the contractor after receipt of satisfactory proof that
the contractor has met all his obligations under any and all
selected and nominated sub-contract agreements applicable to
this contract.
169 B1.3: Payment guarantee by Employer N/a
170 B1.4: Waiver of contractor's lien Item
171 B1.5: Signing powers Item
172 B1.6: Tenders Item
Notwithstanding anything contained in this clause tenders
shall be valid for a period of ninety days (180) from the closing
date of tenders.
6
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
The Employer reserves the right to correct any arithmetical or
other errors in the extension of the rates and totals in the tender and
/ or to adjust any rates that are considered by him to be imbalanced
and unacceptable.
Tenders shall complete all the information requested on the Form
of Tender and provide copies of all supporting documentation
requested on the Form of Tender
Tenders shall be submitted on all official forms and shall NOT be
qualified by the Tenderer's own conditions of tender.
Tenderers are referred to the Form of Tender for the closing
date of the Tender.
Failure to comply with these requirements may disqualify the
Tender.
173 B1.7: Inspection of documents Item
B2 THE SITE
174 B2.1: Site and site boundaries Item
175 B2.2: Area of the works Item
The area of the works to be occupied by the contractor, any
restriction to the area and the limit of access or exit will be pointed
out to the contractor by the Engineer on handing over of the site.
Storage space for materials and site management offices shall be
located by the Engineer.
176 B2.3: Boundary beacons, setting out pegs and master datum Item
The Contractor shall notify the Engineer if any encroachments of
adjoining foundations, buildings, structures, pavements, etc. exist
so that the necessary arrangements can be made for the
rectification of such encroachments.
177 B2.4: Site soil investigation Item
No site soil investigation report is available and the Tenderer is
advised, before the submission of his tender, to inspect the site to
ascertain the exact nature of the ground as no extra will be granted
due to the Tenderer having failed to comply with the above
instruction.
178 B2.5: Viewing of the site Item
7
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
The Tenderer is strongly advised to inspect the site and make
himself thoroughly acquainted with the nature and extent of the
works, the site conditions pertaining to power and water supply,
transport facilities, condition of adjacent existing buildings and
also access to the site, limitations and availability of working
space, etc. before submitting his tender as no extras arising out of
his failure to do so will be entertained.
179 B2.6: Existing premises occupied Item
180 B2.7: Dimensional accuracy of work executed under the
previous contract
Item
181 B2.8: Patent defects of work executed under the previous
contract
Item
182 B2.9: Existing known services Item
Existing services and points of connection are shown on the site
plans or will be pointed out on the site by the Engineer.
183 B2.10: Unknown services Item
184 B2.11: Protection of trees, etc. Item
Natural vegetation on the project site is to be preserved as far as
possible and no trees will be removed or branches cut off without
prior written consent of the Engineer
All existing trees that are not to be removed must be clearly
marked with hazard warning tape and adequately protected from
damage. Such protection and tape is to remain in position until the
completion of the contract or any extension thereof.
185 B2.12: Articles of value Item
186 B2.13: Inspection of nearby properties etc. Item
B3 - MANAGEMENT OF CONTRACT
B3.1: Management of works Item
B3.2: Programming of the works Item
The contract shall be programmed by the contractor in
accordance with the special conditions of contract
The programme is to be of a format to the approval of the
Engineer.
187 B3.3: Progress meetings
Progress meetings will be held on the project site once every Item
month and shall be attended by the Contractor, his site
representative, his sub-contractors, Consultants and
Representatives and the Employer.
8
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
Should any of the Consultants and/or representatives of the
Employer have to make separate trips to the project site for any
reason, which is in the opinion of the Engineer due to the fault of
the Contractor, the cost of such trips will be at the Contractor's
expense.
188 B3.4: Technical meetings Item
Technical meetings will be held on the project site once every two
weeks and shall be attended by the Contractor, his site
representative, his sub-contractors, Consultants and
Representatives and the Employer.
Should any of the Consultants and/or representatives of the
Employer have to make separate trips to the project site for any
reason, which is in the opinion of the Engineer due to the fault of
the Contractor, the cost of such trips will be at the Contractor's
expense.
B4 - MATERIALS AND WORKMANSHIP
189 B4.1: Samples of materials Item
190 B4.2: Samples of workmanship and mockups Item
191 B4.3: Ordering of materials Item
The Contractor will be solely responsible for any delay in the
delivery of materials required for the execution and completion of
the Works.
B5 - TEMPORARY WORKS AND PLANT
192 B5.1: Deposits and fees Item
193 B5.2: Enclosure of works Item
194 B5.3: Pavement crossings and parking meters Item
195 B5.4: Advertising Item
196 B5.5: Plant and equipment
197 B5.6: Special scaffolding Item
All scaffolding if and when required for this contract for the use of
the workmen (including all sub-contractors) shall be provided by
the Main Contractor.
198 B5.7: Contractor's offices and sheds Item
Under NO circumstances may any of the buildings at any stage be
used for temporary accommodation for workers, contractor's
offices or the storage of materials.
199 B5.8: Offices Item
200 B5.9: Office of the clerk of works Item
9
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
201 B5.10: Main noticeboard Item
202 B5.11: Sub-contractors' noticeboard Item
B6 - TEMPORARY SERVICES
203 B6.1: Water Item
The contractor shall provide water for the works
Contractors must note that the Employer does not accept any
responsibility for any additional cost that the Contractor may incur
due to failure or inadequacy of any supply already available on the
site.
204 B6.2: Electricity and lighting Item
The contractor shall provide electricity for the works
Contractors must note that the Employer does not accept any
responsibility for any additional cost that the Contractor may incur
due to failure or inadequacy of any supply already available on the
site.
205 B6.3: Telephones Item
Should the Contractor be unable to procure a temporary telephone
line for the site office, he shall, in areas where cellular telephone
coverage exists, ensure the Contractor's Representative has a
cellular telephone in his possession for use on the site.
206 B6.4: Toilets Item
The contractor shall provide toilets
B7 - PROVISIONAL SUMS
207 B7.1: Cash discount
All Budgetary Allowances and Provisional Sums are nett and do
not include a cash discount, nor will the Contractor be allowed or
entitled to a cash discount.
Item
An items for profit for work executed by specialist sub-contractors
is included after each Provisional Sum for percentage mark-up
pricing by the Contractor (if so desired), subcontractors is included
after each Provisional Sum for percentage mark-up pricing by the
Contractor (if so desired).
Any such percentage mark-up priced by the Contractor on
Provisional sums in this contract, will be used as a basis to
determine the final amount for profit to be paid to the Contractor
in direct proportion to the final cost of the relevant sub-contracts.
208 B7.2: Sub-contract documents Item
10
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
Sub-Contracts and shall be executed using the Fidic Sub-
Contract Agreement as issued by the Federation
Internationale des Ingenieurs-Conseils (FIDIC), First Edition
1999
These documents shall be supplied by the Main Contractor at his
own cost. A copy of each signed selected sub-contract document
shall be delivered to the Engineer.
209 B7.3: Attendance sub-contractors Item
Items for special attendance upon sub-contractors have been
measured after each Provisional Sum for pricing by the Contractor
(if desired).
Amounts priced for attendance shall remain fixed unless, in the
opinion of the Engineer, the scope of the sub-contract has been
changed substantially.
210 B7.4: Fuel, power and water for Test, Commissioning of
mechanical and other specialised installations
Item
B8 - FINANCIAL ASPECTS
211 B8.1: Taxes Item
212 B8.2: Contract Price Fluctuation and Escalation Provisions Item
213 B8.3: Payment of preliminaries Item
214 B8.4: Adjustment of preliminaries Item
The adjustment of preliminaries will be on the basis of Fixed price,
value related and time related items
The successful Tenderer, shall submit together with his priced
Pricing Sheets written confirmation of a breakdown of each item
priced in the Preliminaries Sheet in accordance to the following
three categories:
a) Fixed
b) Value Related
c) Time Related
The final adjustment of the Preliminaries, for any reason
whatsoever, shall be done at the end of the contract period.
215 B8.5: Day works Item
Payment of any work on the basis of day works will only be
made, provided that written authorization is obtained from the
Engineer prior commencing with daywork.
11
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
Notwithstanding anything contained in this clause, the signature of
the Engineer shall not indicate acceptance of quantum, value or
method of valuation of the work executed thereunder. The
quantum of these day works and the method of valuation will be
decided by the Financial Expert
216 B8.6: Information supplied by the Contractor Item
Should the Contractor or any of his sub-contractors execute any of
the work which, in his opinion, constitutes a variation to the
contract and is not covered in the Pricing Sheets and hence results
in a loss or expense the Contractor. The onus rests on the
Contractor to inform the Engineer in writing within the period
specified in the Special Conditions of Contract from the date on
which the work was executed, failing which the executed work
shall be deemed to be at the Contractor's own expense.
B9 - GENERAL
217 B9.1: Protection Item
218 B9.2: Protection of existing and/or partially occupied works Item
219 B9.3: Safety Item
220 B9.4: Site security
221 B9.5: Notice before covering work Item
222 B9.6: Disturbance Item
223 B9.7: Clearing and cleaning Item
224 B9.8: Vermin Item
225 B9.9: Overhand work Item
226 B9.10: Jobbing Item
SECTION C : SPECIFIC PRELIMINARIES
227 C1.1: Workmen's Compensation Insurance Item
The Contractor and Selected Sub-Contractors shall insure
workmen in terms of the Workmen's Compensation Act and shall
deposit immediately with the Engineer written confirmation of
evidence of registration under the Workmen's Compensation Act
when signing the Contract.
228 C1.2: Non cession of monies Item
The Contractor shall not cede or assign his rights or claims to any
monies due or to become due under this contract, as no
12
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
cession or assignment will be recognised by the Employer.
229 C1.3: Site instructions
Item
Site instructions issued by any of the Consultants on site are tobe
recorded in triplicate in a site instruction book which is to be
maintained on site by the Contractor.
It shall be the Main Contractor's responsibility to ensure that any
verbal instructions given on the site are recorded in the site
instruction book and signed by the Engineer.
230 C1.4: Employment of Local People
Item
No employee of the Contractor originating from any other country
shall enter South Africa without a work permit and a residence
permit, obtainable from the Ministry of Home Affairs.
It is an explicit condition of this Contract that the labour conditions
of Employment comply with the Localization Documents forming
part of this Contract
231 C1.5: As built drawings, Test Results and Commissioning
Documentation
Item
232 C1.6: Specific Products
The Contactor is advised that his rates must be based on Item
specific products or items as described in these Pricing Sheets He
may only deviate from the designated product or item to another
product or item after written consent has been obtained from
the Engineer, and only after the Contract has been awarded to
the successful Tenderer. Where applicable, the cost of such
substitution with another product or items shall be adjusted by the
Financial Expert in the final account for this project.
The Contractor shall take delivery of, handle, store, use, apply and
/or fix all proprietary branded products or items in strict
accordance with the manufacturer's instructions after the
consultation with the manufacturer's authorised representative.
Where no specific product or item is specified, but a product or
items is referred to as "approved", the Contractor shall obtain
written approval from the Engineer or the product or item, he
intends to use in the Works, prior to ordering such products/item
or using such products/items in the Works.
233 Clause C1.7: Proprietary branded products
Item
The Contractor shall take delivery of, handle, store, use, apply
and/or fix all proprietary branded products in strict accordance
with the manufacturers' instructions after consultation with the
manufacturer's authorised representative.
234 Clause C1.8: Labour record
13
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
Item
At the end of each fortnight the Contractor shall provide the
Engineer with a written record, in schedule form, reflecting the
number, description and citizenship of tradesmen and labourers
employed by him and all Sub-Contractors on the works each day.
235 Clause C1.9: Plant record
Item
At the end of each fortnight the Contractor shall provide the
Engineer with a written record, in schedule form, reflecting the
number, type and capacity of all plant, excluding hand tools,
currently used on the works.
236 Clause C1.10: Guarantees
Item
Where guarantees are called for, the Contractor shall obtain a
written guarantee, addressed to the Employer, from the firm
supplying the materials and /or doing the work and shall deliver
same to the Engineer upon the certified final completion of the
contract.
The guarantee shall state that the materials, workmanship and
installation are guaranteed for a specified period from the date of
certified final completion of the contract and that any defects that
may arise during the specified period shall be made good at the
expense of the firm supplying the materials and doing the work,
upon written notice of the Engineer to do so.
237 Clause C1.11: Registration of Firm as a Company and a South
African Tax Payer
Item
The Tenderer must provide proof that he is registered as a South
African Tax Payer as specified in the Financial Requirements
Document forming part of this contract
238 Clause C1.12: Open Fires
No open fires will be permitted, except in such places as are Item
approved by the Engineer. Any workmen lighting fires in
unauthorised places are to be immediately dismissed.
239 Clause C1.13: Alternative Temporary access, etc. to site where
necessary
Item
The Contractor shall allow here for any alternative temporary
access to the site including taking out and replacing fencing and
gates, boundary walls, etc. if necessary to facilitate access to the
project site including obtaining the necessary permission and/or
permits from the relevant authorities or neighbors as well as the
removal of such access upon the completion and making good all
to match existing and leaving the site clean and in a perfect
condition
14
FIDIC PRELIMINARIES GENERALS PRASA In-Cab Signalling
Item No Quantity Rate Amount
240 Clause C1.14: Testing and Handing over Specialist
Installations
Item
241 Clause C1.15: Drawings and dimensions Item
project site, or to any other person(s) only through the office of the
Engineer, bearing the Engineer's office stamp. All drawings,
wherever their origin, are to be issued to the Contractor shall keep
a date register of all drawings issued at the project site at all times.
242 Clause C1.16: Revenue Stamps Item
The Contractor must allow for any necessary revenue stamps
required in connection with The Conditions of Contract for
Construction as issued by the Federation Internationale des
Ingenieurs-Conseils (FIDIC), First Edition 1999 and Guarantee
in accordance with the Stamp Duty Act or any amendment thereto.
COLLECTION
Total Carried to Form of Tender (FORM C)
15