1

County of El Paso Purchasing Department 800 E. Overland Room 300

El Paso, Texas 79901 (915) 546-2048 / Fax: (915) 546-8180

www.epcounty.com

ADDENDA 1

To:

From:

Date:

Subject:

All Interested Vendors

Oscar Avila, Procurement Data Analyst

May 29, 2019

Bid 19-020, Construction of Employee Fitness and Wellness Center for the County of El Paso (Re-Bid)

This addenda has been issued to notify vendors of the following:

In accordance with Chapter 2270 of the Texas Government Code, a company, other than a sole proprietorship, with ten or more full time employees is required to certify in writing that it does not boycott Israel and will not boycott Israel during the term of the contract, if the contract has a value of $100,000 or more.

The following is a recap of the pre-bid conference held on Thursday, May 16, 2019:

1. What does the ‘(8 hours) per diem wage rate’ consist of, what does it mean? Is it perday or per hour?

RESPONSE: Wages listed on the ‘per diem’ column of the Prevailing WageRates are per day.

2. What is the distance for the prevailing wage rate? For example does Las Cruces fallunder this?

RESPONSE: Section 2258.021 of the Texas Local Government Code assignsworkers on public work contracts for the County the right to be paid theprevailing wage in the “Locality in which the work is performed.” Section2258.001(1)(B) states that “Locality in which the work is performed” meansthe geographical limits of the political subdivision awarding the contract for apublic work. This definition means that the workers on this contract must be

http://www.epcounty.com/

2

paid the prevailing wage of El Paso County regardless of where they physically report each day.

3. Will certified payroll be required?

RESPONSE: Yes, certified payroll will be required.

4. What are the security measures for entering the building?

RESPONSE: There will need to be coordination with Sheriff Security and Facilities to maintain secure access to the building. Front entrance to building must always remain accessible to the public.

5. Do building entrances have to be ADA compliant?

RESPONSE: Yes, all building entrances must remain ADA compliant.

6. Will workers be required to check in with security every time they are enter the building

from any entry point?

RESPONSE: Yes, proper procedures must be followed whenever entering the building. Further coordination can be undertaken if the need arises.

7. How strictly will tools be monitored?

RESPONSE: Strict tool inventory is not a foreseeable procedure. However, varying threat levels may affect security conditions and procedures.

8. What is the approximate time to enter the building and start work, from check-in to

work site?

RESPONSE: It will not take long, normal screening time will take a few minutes. Using an on-site drop box and other approved accommodations can be implemented to reduce the time needed to check in.

9. How long will it take to bring in material?

RESPONSE: Further planning and coordination can be undertaken for best time-saving solution.

10. Will the awarded vendor need to work after-hours or overtime?

RESPONSE: It will fall upon the awarded vendor to decide whether overtime work will be required. Minimum of one week notice must be given to the County before any afterhours work can be conducted.

11. Will parking be provided?

RESPONSE: There is no available parking. Parking will need to be coordinated through the vendor’s own efforts.

3

12. Will vendor be responsible for permits for parking?

RESPONSE: Yes, vendor will be responsible for obtaining parking and other necessary permits.

13. Is there a staging area available?

RESPONSE: There is no staging area available. Staging area will need to be coordinated through the vendor’s own efforts.

14. Will areas need to be fenced off?

RESPONSE: There will need to be coordination between vendor and City.

15. Do employees need to carry an ID/Badge?

RESPONSE: Yes, vendor employees need to be badged while on County premises.

16. Would a vest with the name company be sufficient?

RESPONSE: Yes, a noticeable logo on a vest is acceptable.

17. Will the awarded vendor need to bring in their own porta-potty?

RESPONSE: Yes, for a large project vendor will need to bring in their own porta-potty for on-site use. Due to security reasons it would be best to reduce the number of building entries/exits.

18. Will there be a sheriff posted on the entrance to the job site?

RESPONSE: Depending on vendor activity an individual from Sheriff’s Office or Facilities Department will be stationed to monitor the entrance.

19. Can afterhours work be conducted?

RESPONSE: Work to be done before or after building working hours will need to be coordinated. Minimum of one week notice must be given to the County before any afterhours work can be conducted.

20. What are the County Courthouse working hours?

RESPONSE: Normal operating hours for the Courthouse are 7 a.m.-5 p.m. Monday-Friday.

21. Would there be any issues closing off parts of the sidewalk?

RESPONSE: Closing off the sidewalk would need to be coordinated. There must still be proper routing and accessibility to the Courthouse.

22. Will the vendor be permitted to work in hallways during normal working hours?

4

RESPONSE: Hallway work will be coordinated on a case-by-case basis. Loud work may disrupt some offices.

23. Are there liquidated damages?

RESPONSE: Liquidated damages are in the sum of $750.00 for each consecutive calendar day thereafter the agreed upon date of project completion.

24. If work needs to be stopped, will there be prorated days of completion?

RESPONSE: Prorated days will be mitigated on a case-by-case basis.

The Purchasing Department has received the following questions:

1. The solicitation states that there is Telecom/IT work involved but there was no mention of it in the bid. Will there be telecom/IT work on this project?

RESPONSE: Yes, I.T. is required in this project. I.T. requirements are included in the electrical drawings.

2. The plans call for electrical work but the drawings seem to be missing. Will the plans be made available?

RESPONSE: Yes, electrical drawings E.0 Electrical Legend, E1.1 Overall Electrical Plan, E2.1 Enlarged Floor Plan, E2.2 Electrical Plans, and E3.1 Overall HVAC Equipment Plan attached.

- EXIT LIGHT W/ DIR. AND INTEGRAL BATTERY

- DISCONNECT SWITCH

- J-BOX

- 20 AMP, 120 VOLT DUPLEX RECEPTACLE

- GROUND

J

US - UN-SWITCHED

-EMPTY CONDUIT WITH PULL WIREE.C.

BACK-UP, AND "LIGHT BAR"

- FIXTURE IS A SELF-CONTAINED EMERGENCYEMFIXTURE WITH BATTERY

ELECTRICAL LEGEND ELECTRICAL NOTES

- CONDUIT ABOVE SLAB

- LAY-IN FIXTURE WITH SELF-CONTAINED EMERGENCYBATTERY BACK-UP.

- WALL MOUNTED VACANCY/ OCCUPANCY SENSORMANUAL-ON AND AUTOMATIC/MANUAL - OFF, TIMEADJUSTABLE, DUAL TECHNOLOGY, TO BE INACCORDANCE WITH 2015 IECC.

- VOICE/DATA OUTLET WITH COVER PLATE. RUNRACEWAY AND CABLING TO EXISTING IDF ROOM

- LAY-IN FIXTURE

1. ALL ELECTRICAL WORK UNDER THIS CONTRACT SHALL BEDONE IN ACCORDANCE WITH THE NATIONAL ELECTRICALCODE, LOCAL AUTHORITY POWER COMPANY ANDREQUIREMENTS AS APPLICABLE.

2. THIS CONTRACT IS TO INCLUDE ALL CONTINGENCIESWHICH MAY ARISE AND WHICH MAY BE REQUIRED BYALTERATION AND DEMOLITION WORK.

3. ALL MATERIALS SHALL BE NEW U.L. LABELED UNLESSOTHERWISE INDICATED.

4. ELECTRICAL CONTRACTOR SHALL VERIFY ANDCOORDINATE THE FOLLOWING WITH THE MECHANICALCONTRACTOR AND COMPLY AS REQUIRED.

4.1. LOCATION OF EQUIPMENT (I.E. MOTORS, T-STATS,ETC.)

4.2. ELECTRICAL CHARACTERISTIC (I.E. VOLTAGE, H.P.,AMPS, CONTROL WIRING)

5. ALL CONDUIT SHALL BE EMT ABOVE GRADE & PVC BELOWGRADE.

6. GROUNDING OF ELECTRICAL EQUIPMENT SHALL BE ASPER APPLICABLE CODES AND AS INDICATED ONDRAWINGS.

7. ALL CONDUCTORS SHALL BE TYPE THHN COPPER UNLESSNOTED OTHERWISE. BRANCH CIRCUIT WIRING TO BEMINIMUM #12 AWG. OTHER SIZES SHALL BE AS INDICATEDOR AS REQUIRED BY CODE. ALUMINUM CONDUCTORS ARENOT ALLOWED.

8. UPON COMPLETION OF THE WORK, THE VARIOUSSYSTEMS SHALL BE TESTED FOR SHORT CIRCUITS ANDGROUNDS IN ACCORDANCE WITH THE METHOD ANDRESISTANCE VALUES OUTLINED IN THE NATIONALELECTRICAL CODE AND FOR LOAD BALANCE ON FEEDERSAND BRANCH CIRCUITS. THE COMPLETED SYSTEM SHALLOPERATE SATISFACTORILY IN EVERY RESPECT. MAKEANY REPAIRS OR ADJUSTMENTS NECESSARY TO THIS ENDTO THE SATISFACTION OF THE OWNER.

9. AT THE COMPLETION OF THIS PROJECT, THECONTRACTOR SHALL PROVIDE THE OWNER WITH ONE (1)COMPLETE AND FINAL CORRECTED SER OF WORKINGDRAWINGS. THIS SET OF WORKING DRAWINGS SHALL BENEW, UNUSED AND IN GOOD CONDITION ACTUAL CIRCUITNUMBERS SHALL BE RECORDED ON THE AS-BUILTDRAWINGS.

10. THE WORK PERFORMED SHALL BE GUARANTEED, FOR APERIOD OF ONE YEAR AFTER FINAL ACCEPTANCEAGAINST FAULTY WORKMANSHIP AND/OR MATERIALS. ANYFAILURE OR TROUBLE DUE TO SUCH CAUSES WITHIN THEPERIOD OF THE GUARANTEE SHALL BE MADE GOOD UPONDEMAND OF THE OWNER AND WITHOUT COST TO THEOWNER.

11. SITE OBSERVATION BY THE ENGINEER IS FOR THEEXPRESS PURPOSE OF VERIFYING COMPLIANCE BY THECONTRACTOR WITH THE CONTRACT DOCUMENTS, ANDSHALL NOT BE CONSTRUED AS CONSTRUCTION SUPERVISION OR INDICATION OF APPROVAL OF THE MANNER ORLOCATION IN WHICH THE WORK IS BEING PERFORMED ASBEING A SAGE PRACTICE OR PLACE.

12. THE CONTRACTOR SHALL THOROUGHLY EXAMINE THESITE AND SATISFY HIMSELF AS TO THE CONDITIONSUNDER WHICH THE WORK IS TO BE PERFORMED. THECONTRACTOR SHALL VERIFY AT THE SITE ALLMEASUREMENTS AFFECTING HIS WORK AND SHALL BERESPONSIBLE FOR THE CORRECTNESS OF THE SAME. NOEXTRA COMPENSATION WILL BE ALLOWED TO THECONTRACTOR FOR THE EXPENSES DUE TO HIS NEGLECTTO EXAMINE OR FAILURE TO DISCOVER CONDITIONSWHICH AFFECT THIS WORK. NO EXTRA COMPENSATIONWILL BE ALLOWED ON ACCOUNT OF DIFFERENCEBETWEEN ACTUAL DIMENSIONS AND THOSE INDICATEDON THE DRAWINGS.

13. PROVIDE TYPE-WRITTEN CIRCUIT DIRECTORIES FOR ALLNEW ELECTRICAL PANELS AND AND FOR ALL EXISTINGELECTRICAL PANELS THAT HAVE BEEN UPDATED WITHTHE NEW CIRCUITS.

14. GENERAL CONTRACTOR IS RESPONSIBLE FOR LOCATINGALL UTILITIES, PIPING, CONDUITS, ETC., PRIOR TO STARTOF CONSTRUCTION WITH THE EXECUTION OF THECONTRACTOR AGREES TO INDEMNIFY THE ARCHITECT,ENGINEER, AND OWNER FROM ANY ACTION ARISING AS ARESULT OF DAMAGE TO ANY EXISTING UTILITIES.

15. EVERY BRANCH CIRCUIT SHALL BE PROVIDED WITH ASEPARATE, DEDICATED NEUTRAL IN ACCORDANCE WITHNEC, WETHER SHOWN ON DRAWINGS OR NOT.

16. CONTRACTOR SHALL INSTALL EQUIPMENT AS PERMANUFACTURER REQUIREMENTS.

17. ALL LIGHTS FIXTURES SHALL BE HUNG FROM AND/ORFASTENED TO THE BUILDING STRUCTURAL NOT FROMCEILING.

18. PROVIDE ARC-FLASH LABELING ON ALL NEW ELECTRICALPANELS. ALL LABELING SHALL BE DONE USING ANNEX HOF NFPA 70E, 130.5(D); OR BY CALCULATIONS.

19. PROVIDE UN-SWITCHED HOT CONDUCTOR TO ALLEMERGENCY BATTERIES OF FIXTURES. THIS HOTCONDUCTOR SHALL BYPASS ANY SWITCHES, OCCUPANCYSENSORS, AND LIGHTING CONTROL RELAYS. TYPICAL

20. REFER TO MECHANICAL AND PLUMBING DRAWINGS FOREXACT LOCATIONS OF HVAC AND PLUMBING EQUIPMENT.

21. MC CABLE WILL NOT BE ALLOWED.

22. LABEL THE COVERS OF ALL NEW ELECTRICAL PANELSWITH PHENOLIC NAMEPLATES. LABEL SHALL SAY THEPANEL NAME, VOLTAGE, AND AMP RATING (I.E. PANEL L3,120/208 /3PH, 200AMP).

23. ALL LIGHTING AND LIGHTING CONTROLS SHALL BE INACCORDANCE WITH THE IECC 2015 ENERGY CODE.

24. THE MOUNTING HEIGHTS OF ALL RECEPTACLES,SWITCHES, AND ALL OTHER PERTINENT ELECTRICALDEVICES AND EQUIPMENT, SHALL BE IN ACCORDANCEWITH THE ARCHITECTURAL DRAWINGS, ADA, AND TAS.PRIOR TO ROUGH-IN, THE CONTRACTOR SHALL REFER TOTHE ARCHITECTURAL DRAWINGS FOR MOUNTINGHEIGHTS. IF THERE ARE NO MOUNTING HEIGHTSSPECIFIED ON THE ARCHITECTURAL DRAWINGS THEN THECONTRACTOR SHALL USE THE MOUNTING HEIGHTS ASSPECIFIED BY ADA AND/OR TAS.

25. THE CONTRACTOR SHALL NOTIFY THE OWNER 7 DAYS INADVANCE OF ALL NECESSARY POWER OUTAGES. THEPOWER OUTAGES SHALL OCCUR ON NIGHTS AND/ORWEEKENDS. PREPARE ALL WORK IN ADVANCE SO THATTHE DURATION OF THE POWER OUTAGES IS KEPT TO AMINIMUM.

26. COLOR OF DEVICES & COVER PLATES SHALL BESTAINLESS STEEL TO MATCH EXISTING, VERIFY WITHARCHITECT PRIOR TO ORDERING.

27. ALL TRANSFORMERS SHALL HAVE COPPER WINDINGS.MOUNT TRANSFORMER ON SPRING-TYPE VIBRATIONISOLATORS AND 4" CONCRETE SLAB. SLAB SHALL EXTEND4" PAST THE EDGE OF THE TRANSFORMER AROUND THEENTIRE PERIMETER.

28. THE ELECTRICAL PANELS SHALL HAVE COPPER BUSSINGAND DOOR-IN-DOOR CONSTRUCTION.

29. WHERE MORE THAN ONE SWITCH OCCURS IN THE SAMELOCATION, THEY SHALL BE INSTALLED IN GANG TYPECONTROLS UNDER ONE COVER PLATE. DIMMERSWITCHES, THERMOSTATS, FAN CONTROLS OR OTHERDEVICES WHICH CAN NOT BE INSTALLED UNDER THESAME GANG-TYPE COVER PLATE SHALL BE CLOSELY

SPACED AND ALIGNED HORIZONTALLY WITH THE LIGHTSWITCHES.

30. 5-YEAR MANUFACTURER WARRANTY IS REQUIRED FORALL LED DRIVERS.

31. DISABLE PHOTO SENSORS ON ALL OCCUPANCY SENSORSUNLESS NOTED WITH A "PC" AND/OR NOTED ON THEFLOOR PLANS.

32. DISABLE "SELF-ADAPTIVE" MODE ON ALL OCCUPANCYSENSORS.

33. SET "DELAYED OFF" SETTIN TO 20 MINUTES ON ALLOCCUPANCY SENSORS.

34. SET WALL MOUNTED OCCUPANCY SENSORS TO "MANUALON".

35. SET POWER PACKS TO "MANUAL ON".

36. LIGHT SWITCH/DIMMERS ASSOCIATED WITH POWERPACKS SHALL BE CONNECTED TO THE LOAD SIDE OF THEPOWER PACK.

37. WHERE MULTIPLE OCCUPANCY SENSORS ARE INDICATEDWITH "LIKE" SWITCH LEG, CONNECT ALL OCCUPANCYSENSORS IN PARALLEL SO THAT ANY OF THE OCCUPANCYSENSORS WILL ACTIVATE THE "OCCUPIED" MODE FORTHAT AREA.

38. ALL CONDUIT IN COURTYARD AREA SHALL BE RUNEXPOSED, ABOVE SLAB, UNLESS NOTED OTHERWISE. ALLCONDUIT SHALL BE RUN AS LOW AS POSSIBLE.HORIZONTALLY FROM BOX-TO BOX. VERIFY ALL ROUTINGWITH OWNER AND ARCHITECT PRIOR TO INSTALLATION.ALL CONDUIT, BOXES, FITTINGS, ETC., SHALL BE FIELDPAINTED IN A COLOR THAT IS SELECTED BY THEARCHITECT.

39. WEATHER-PROOF RECEPTACLES SHALL HAVE METAL,IN-USE LOCKING COVERS.

40. PROVIDE CUTTING AND TRENCHING AS REQUIRED FORUNDERGROUND CONDUITS. BACKFILL TRENCHES PERARCHITECTURAL SPECIFICATIONS. PATCH AND REPAIRSURFACES AS DIRECTED BY THE ARCHITECT ASREQUIRED.

- MANUAL MOTOR STARTER

T - THERMOSTAT BOX AND 1/2" CONDUIT TO UNIT

- EXHAUST FAN OR MOTOR

- 20 AMP 120 VOLT QUAD. RECEPTACLE

- 120/277 VOLT TOGGLE SWITCH

- DIMMER SWITCH, SLIDE-BAR WITH ON-OFF PRESET, 1500 W

- CEILING MOUNTED OCCUPANCY SENSOR, TIME

- FLEXIBLE METALLIC CONDUIT

TO BE IN ACCORDANDE WITH 2015 IECC.

GFI - GROUND FAULT CIRCUIT INTERRUPTER

NF - NON FUSED

NL

- DUPLEX RECEPTACLE AND VOICE/DATA OUTLET AT+84" FOR TV MONITOR

- A RECTANGULAR FLOOR BOX WITH (1) DUPLEXRECEPTACLE. FLOOR BOXES AND COVER PLATES SHALLBE FULLY FLUSH WITH THE FLOOR COVERING, ANDSHALL BE PARALLEL/PERPENDICULAR TO WALLS.

LEGRAND #880MP WITH FLANGE AND BRASS COVERPLATE.

EXISTING MAIN ELECTRICAL DISTRIBUTIONPANEL ~ 277/480V, 3Ø, 4W; 4,000 AMP. SEEOVERALL ELECTRICAL FLOOR PLAN FOR

APPROXIMATE LOCATION

BASEMENT LEVEL

NEW PANEL "FH"277/480V, 3Ø225 MLO

4#3/01#4 GROUND2"C

#2 CU GND

200/3200 LPS-RK

NEW PANEL "FL"120/208V, 3Ø225 MCB

4" CONCRETEHOUSEKEEPING PAD

NEW TRANSFORMER"FT" 75 KVA

4#4/01#2 GROUND2-1/2"C

ELECTRICALLEGEND

E-0

- NIGHT LIGHT

DR

WAN

BY:

WW

W.B

EEPE

RSP

ECTI

VE.C

OM

2016

-25

CO

UR

T H

OU

SE F

ITN

ESS

CEN

TER

- C

ON

STR

UC

TIO

N D

OC

UM

ENTS

SHEET:

REVISION:DATE:NO.

DATE: SEPTEMBER 06 - 2018

500

E SA

N A

NTO

NIO

ST.

EL P

ASO

, TEX

AS

ISSUED FOR CONSTRUCTION

- WALL MOUNTED VACANCY/OCCUPANCY SENSOR IN ACCORDANCE WITH 2015 IECC

- CONDUIT BELOW SLAB

- DUPLEX RECEPTACLE WITH (2) USB PORTS

WP - WEATHER PROOF

CONTRACTOR SHALL VERIFY TYPE ANDMANUFACTURER OF EXISTING MAINELECTRICAL DISTRIBUTION PANEL, ANDVERIFY THAT THERE IS ADEQUATE BUSSEDSPACE, PRIOR TO BIDDING. FURNISH NEWFUSED SWITCH, INCLUDING ALL MOUNTINGHARDWARE, AS REQUIRED.

THE ELECTRICAL CONTRACTOR SHALL MAKE ALLMODIFICATIONS TO THE EXISTING FIRE ALARM SYSTEMAS REQUIRED, INCLUDING ADDING NEW DEVICES ANDWIRING IF NECESSARY. FURNISH ALL PARTS AND LABORAS REQUIRED FOR A COMPLETE TURN-KEY DESIGN-BUILDSYSTEM INCLUDING DRAWINGS AND APPROVALS FROMTHE FIRE MARSHAL'S OFFICE.

FIRE ALARM NOTE

DEMOLITION NOTES:1. CONTRACTOR SHALL REMOVE ALL EXISTING FIXTURES,

RECEPTACLES, CONDUIT, WIRING, ETC. WHERE SHOWN. ANYADDITIONAL ITEMS ENCOUNTERED WITH THE CONSTRUCTIONSHALL BE REMOVED AT NO ADDITIONAL COST.

2. ALL DEMO ITEMS, AND MATERIALS SHALL BE DISPOSED OF BYTHE CONTRACTOR. CONTRACTOR SHALL USE EXTREME CAREAND CAUTION. DURING DEMOLITION AS TO PREVENT ANYEXCESSIVE INTERFERENCE WITH NORMAL BUSINESSACTIVITIES.

3. ALL DEMOLITION WORK SHALL BE EXECUTED WITH THEGREATEST CARE SO AS NOT TO DAMAGE EXISTINGCONSTRUCTION TO REMAIN. ANY DAMAGED TO THE EXISTINGCONSTRUCTION TO REMAIN SHALL BE REPAIRED AT THE COSTOF THE DEMOLITION CONTRACTOR.

4. ALL POWER SHUT-DOWNS & SWITCHOVER SHALL BECOORDINATED WITH OWNER 7 DAYS IN ADVANCE.

5. THERE ARE EXISTING CIRCUITS, RECEPTACLES AND LIGHTFIXTURES BEING REMOVED AND REPLACED. CONTRACTOR TOABANDON CONDUIT AND WIRING IN PLACE WITHOUTCONFLICTS TO NEW CONDUIT AND WIRING.

6. ALL NEW ELECTRICAL COMPONENTS SHALL HAVE NEWCONDUIT AND WIRING.

1. EXISTING PEAK DEMAND PER EPECO = 1,624KW

1,624,000W(480V)(1.73)(0.8pf) X 1.25=

2. NEW PANEL "FH" (HIGH PHASE) = 134.4 AMPS (PHASE A)

TOTAL AMPS HIGH PHASE A =

ELECTRICAL LOAD CALCULATIONS277/480V, 3 PHASE, 4000 AMPS

3,188.0

3,053.6 AMPS/PHASE

ALL DATA/VOICE CABLING AND OUTLETS SHALL BE FURNISHED AND INSTALLED BY THEELECTRICAL CONTRACTOR. ALL I.T. EQUIPMENT SHALL BE FURNISHED AND INSTALLED BY THEELECTRICAL CONTRACTOR. THE ELECTRICAL CONTRACTOR SHALL FURNISH ALL PARTS,LABOR AND MATERIALS FOR A COMPLETE AND FUNCTIONAL TURN-KEY SYSTEM. COMPLYWITH ALL REQUIREMENTS AND SPECIFICATIONS OF EL PASO COUNTY. IT IS THECONTRACTOR'S RESPONSIBILITY TO OBTAIN A COPY OF THESE REQUIREMENTS ANDSPECIFICATIONS PRIOR TO BIDDING. REFER TO THE SPECIFICATION MANUAL FOR MOREDETAIL.

DATA/VOICE CABLING & I.T. EQUIPMENT

OVERALLELECTRICAL PLAN

E1.1

DR

WAN

BY:

WW

W.B

EEPE

RSP

ECTI

VE.C

OM

2016

-25

CO

UR

T H

OU

SE F

ITN

ESS

CEN

TER

- C

ON

STR

UC

TIO

N D

OC

UM

ENTS

SHEET:

REVISION:DATE:NO.

DATE: SEPTEMBER 06 - 2018

500

E SA

N A

NTO

NIO

ST.

EL P

ASO

, TEX

AS

ISSUED FOR CONSTRUCTION

APPROXIMATE LOCATION OF EXISTINGMAIN ELECTRICAL DISTRIBUTIONPANEL. VERIFY EXACT LOCATION INFIELD PRIOR TO BIDDING.

ROUTE NEW CONDUIT/FEEDERS ABOVE EXISTING LAY-INCEILING IN THE CORRIDOR. VERIFY ROUTING WITHOWNER & ARCHITECT PRIOR TO INSTALLATION.CONTRACTOR SHALL REPLACE ALL CEILING TITLES THATBECOME DAMAGED DURING THIS INSTALLATION. NEWCEILING TILES, IF NEEDED, SHALL MATCH EXISTING.

FEEDERS & CONDUIT TO PANEL "FH".SEE ENLARGED POWER FLOOR PLAN

FOR EXACT LOCATION

I.T. CABLING TO VOICE/DATA OUTLETS.SEE ENLARGED POWER FLOOR PLAN.PROVIDE QUANTITIES AS REQUIRED.

PROVIDE PULL BOXES AT EACH 90DEGREE BEND IF NECESSARY, SIZE ASREQUIRED.

PROVIDE PULL BOXES AT EACH 90DEGREE BEND IF NECESSARY, SIZE ASREQUIRED.

APPROXIMATE LOCATION OF EXISTINGIDF ROOM WHERE NEW I.T. EQUIPMENTIS TO BE LOCATED AND THE NEWCABLING IS TO BE TERMINATED.VERIFY IN FIELD PRIOR TO BIDDING.

I.T. CABLING ABOVE CEILING. RUN CABLING IN CONDUIT,CABLE TRAY, AND/OR J-HOOKS AT THE COUNTY'SDIRECTION. VERIFY PRIOR TO BIDDING. VERIFY ROUTINGWITH OWNER & ARCHITECT PRIOR TO INSTALLATION.CONTRACTOR SHALL REPLACE ALL CEILING TITLES THATBECOME DAMAGED DURING THIS INSTALLATION. NEWCEILING TILES, IF NEEDED, SHALL MATCH EXISTING.

TV +84"

FL-4 FL-24

FL-24

TV +84" TV +84"GFI

+44"GFI

+44"GFI

FL-6

GFI

GFI

FL-22

FL-1

FL-3

FL-5

FL-7

FL-9

FL-11

FL-13

FL-17

FL-19

FL-18

T

FL-16

FL-14

PANEL"FH"

PANEL"FL"

TRANSFORMER"FT"

FL-10 +44"

+44"

+44"

FL-12

+44"

+44"

+44"

FL-8

FL-33

FL-31

FL-29

FL-27

FL-25

FL-23

FL-21

FL-19

TV +84"

FL-2

TV +84" TV +84"

GFIGFI

LOCATE UNDERLAVS. FOR

MIXING VALVE.TYP. 2

FOR CIRC.PUMP. VERIFY

LOCATION

30/3NF

FH-14,16,183#12,1#12GND

FL-40

ENLARGEDFLOOR PLAN

E2.1

DR

WAN

BY:

WW

W.B

EEPE

RSP

ECTI

VE.C

OM

2016

-25

CO

UR

T H

OU

SE F

ITN

ESS

CEN

TER

- C

ON

STR

UC

TIO

N D

OC

UM

ENTS

SHEET:

REVISION:DATE:NO.

DATE: SEPTEMBER 06 - 2018

500

E SA

N A

NTO

NIO

ST.

EL P

ASO

, TEX

AS

ISSUED FOR CONSTRUCTION

RUN I.T. CABLING AND RACEWAYTO EXISTING IDF ROOM. SEE

OVERALL ELECTRICAL FLOORPLAN. TYPICAL

* VIA TIME CLOCK PER 2015 IECC

****

***

THESE HP UNITS REQUIRE (2) SEPARATE ELECTRICAL CONNECTIONS; ONE FOR THE BLOWER & ONE FOR THE HEATSTRIP. PROVIDE SEPARATE BRANCH CIRCUIT HOMERUNS. LOADS SHOWN ARE TOTAL LOAD.

ELECTRICAL

PLANS

E2.2

DR

WA

N B

Y: W

WW

.B

EE

PE

RS

PE

CT

IV

E.C

OM

20

16

-2

5 C

OU

RT

H

OU

SE

F

IT

NE

SS

C

EN

TE

R - C

ON

ST

RU

CT

IO

N D

OC

UM

EN

TS

SHEET:

REVISION:DATE:NO.

DATE: SEPTEMBER 06 - 2018

50

0 E

S

AN

A

NT

ON

IO

S

T.

EL

P

AS

O, T

EX

AS

ISSUED FOR

CONSTRUCTION

30/3 NF.TYP. 3

FH-1,3,53#12, 1#12 GND

FH-13,15,173#12, 1#12 GND

FH-7,9,113#12, 1#12 GND

PANEL "FL"

PANEL "FH"

FL-30

FL-32

30/3 NF.

30/3 NF.

30/2 NF.FL-26,283#10, 1#10 GNDFL-50,52

RECEPTACLE IN CEILING SPACEFOR HEAT PUMP CONDENSATEPUMPS. VERIFY LOCATION. TYP. 3

FL-34

WP/GFI

MOUNT ON SIDE OF COND. UNIT,VERIFY LOCATION ANDCOORDINATE WITH MECH,CONTRACTOR

HP-2

HP-3

FH-26,28,30FH- 2,4,6

FH-32,34,36FH- 8,10,12

NOTE:PROVIDE (2) SEPARATEPOWER CONNECTIONS TO EACHHEAT PUMP; ONE FOR THE BLOWERAND ONE FOR THE HEAT STRIP.VERIFY WITH MECHANICALCONTRACTOR. TYPICAL 3.

OVERALL HVACEQUIPMENT PLAN

E3.1

DR

WAN

BY:

WW

W.B

EEPE

RSP

ECTI

VE.C

OM

2016

-25

CO

UR

T H

OU

SE F

ITN

ESS

CEN

TER

- C

ON

STR

UC

TIO

N D

OC

UM

ENTS

SHEET:

REVISION:DATE:NO.

DATE: SEPTEMBER 06 - 2018

500

E SA

N A

NTO

NIO

ST.

EL P

ASO

, TEX

AS

ISSUED FOR CONSTRUCTION

ROUTE NEW CONDUIT/FEEDERS ABOVE EXISTING LAY-INCEILING IN THE CORRIDOR. VERIFY ROUTING WITHOWNER & ARCHITECT PRIOR TO INSTALLATION.CONTRACTOR SHALL REPLACE ALL CEILING TITLES THATBECOME DAMAGED DURING THIS INSTALLATION. NEWCEILING TILES, IF NEEDED, SHALL MATCH EXISTING.

FEEDERS & CONDUIT TO PANEL "FH".SEE ENLARGED POWER FLOOR PLANFOR EXACT LOCATION

19-020 Addenda 1ELECTRICAL FINAL SET 100%