Construction Administration

Construction Administration

5/10/2011 11:39:14 PMhttp://www.fmozeleski.com/news.htm

The Comprehensive Guide to Construction Contract AdministrationKeyword Search: Simply select the topic you wish to review and "click"

Application for Payment Notice of Commencement Proposal RequestArchitect Supplemental

Instruction Notice to Proceed Schedules forConstruction

Change Order Payment and PerformanceBond Substantial Completion

Construction Administration PreConstruction Meeting TestingConstruction Change Directive Project Close-out Time ExtensionFinal Application for Payment Project Site Observation Warranty Inspection

INTRODUCTION

ROLE OF THE CONSTRUCTION ADMINISTRATOR

This material has been prepared as a guide for the office standards and procedures for the construction administration services offered by The MozeleskiGroup, Inc. The services described in the following pages shall be performed by the Construction Administration Consultant, while representing the ProjectArchitects and/or Owner. For clarity, the manual is written specifically for the Construction Administration Consultant and hence limits project authority on theconstruction site to that enumerated in the Owner/Contractor and Owner/Consultant Agreements. Project Architects and Project Managers who have a largerrange of responsibility and authority, are encouraged to consider the ramifications involved with on-the- spot decisions, made at the Contractor's insistence.

Although the following standards represent general office policy, they are, in fact, subservient to the Owner / Architect Agreement, Owner/Contractor Agreementand General, Supplementary, and Special Conditions of each individual project. The Project Administrator should attempt to include the standards andprocedures established in this manual in the Contract Documents for each project. The Administrator shall thoroughly review the complete set of documents,collectively referred to as the Contract Documents, and modify the construction administration procedures for each project accordingly.

The Administrator is responsible for the comprehensive and timely administration of all project related documentation and information. The primary role of theAdministrator is to represent the Owner and/or Architect in all project meetings and other field matters relating to the construction of the project. TheAdministrator will make periodic site visits to the project, record observations and report to the Project Administrator all observations related to status ofcompletion, quality of workmanship and compliance with the Contract Documents.

The authority and responsibility of the Administrator shall be as described in AIA Document B352. In addition to AIA B352 (Figure 1-1) the Administrator willadhere to the following company policies for Construction Administration:

1. The Administrator does not have the authority to authorize any deviations from the Contract Documents.

2. The Administrator does not have the authority to stop any on the work on the project.

3. The Administrator does not conduct any tests.

4. The Administrator is not obligated to solve construction problems on the spot. Despite the Contractor's alleged urgency, the Administrator will deferany decisions until he may return to the office for consultation and review with the Owner and/or Architect or appropriate engineer.

5. The basic role of the Administrator is to observe the work and advise the Owner and/or Architect and the Owner of the progress and quality of thework and conformance with the Contract Documents.

6. The Administrator shall wear a hard hat at the job site at all times. Hard hats are often provided by the Contractor but will be furnished by TheMozeleski Group, Inc. if not available.

7. Neither the Administrator nor the Owner and/or Architect are responsible for construction means and/or methods.

8. Neither the Administrator nor the Owner and/or Architect are responsible for construction safety.

9. The Owner and/or Architect will be invited to make a monthly review of the project, preferably at the time the Application for Payment is reviewed.

10. Neither the Administrator nor the Owner and/or Architect will "supervise" any portion of the construction.

The role of the Administrator is to periodically visit the job to observe the work. The person responsible for supervising the construction is, in fact, theConstruction Manager or General Contractor. That entity has contracted to complete the work and legally assumes primary responsibility for the work. The



The role of the Administrator is to periodically visit the job to observe the work. The person responsible for supervising the construction is, in fact, theConstruction Manager or General Contractor. That entity has contracted to complete the work and legally assumes primary responsibility for the work. TheAdministrator is not an "inspector". His duties do not encompass the time nor the effort required to provide a comprehensive or exhaustive "inspection" of thework.

The Administrator's responsibilities include the transmission of large quantities of paper work and project documentation, particularly AIA standardizeddocuments. The Administrator is encouraged to take advantage of the time savings involved in producing computerized Master Forms for each individual AIAdocument for the project. Proposal Requests, Change Orders, Transmittal Letters and A.S.I.s should be prepared in advance with all consistent projectinformation ( i.e. project name, project address, project number etc.) included and ready for specific information to be inserted.

The traditional construction triangle often places the Owner, the Architect and the Contractor in adversarial relationships. The Administrator must defend therights of the Contractor as well as those of the Owner. The Administrator is charged with the impartial administration of the Contract Documents. Since a gooddeal of the Administrator's time is spent reviewing, and then evaluating the Contractor's work, it is wise to remember to complement the Contractor on work welldone as quickly as you point out his errors.

The Administrator should take every opportunity to cultivate a "partnering" style relationship between the Architect and the Contractor. The Contractor, Ownerand Architect must remember that they share a common goal which is the successful completion of the project.

PHASE1 - SCOPE OF PRE-CONSTRUCTION SERVICES

In the Bidding or Negotiations Phase the Owner and the Architect, respectively, following the Owner's approval of the Construction Documents and of the mostrecent Statement of Probable Construction Cost, shall provide those services designated in the Schedule of Designated Services necessary for the Architect toassist the Owner in obtaining bids or negotiated proposals and in awarding and preparing contracts for construction.

In the case of phased construction, the Owner may authorize bidding and/or negotiation of portions of the Work prior to completion of the ConstructionDocuments Phase. The following descriptions shall apply to those services assigned in the Schedule of Designated Services as the responsibility of the partyindicated therein.

1.01 Project Administration services consist of the following bidding or negotiation administrative functions:

ConstructionResearchConferencesCommunicationsTravel timeProgress reportsDirection of the work of in-house architectural personnel

1.02 Disciplines Coordination / Document Checking services consist of bidding or negotiation activities for:

Coordination between the architectural work and work of engineering and other involved disciplines for the Project.Review and checking of documents prepared for the Project.

1.03 Agency Consulting/Review/Approval services during the Bidding or Negotiations Phase relating to applicable laws, statutes, regulations and codes ofregulating entities relating to the Owner's interests before construction begins.

1.04 Owner-supplied Data Coordination services consisting of activities relating to bidding or negotiation including:

Review and coordination of data furnished for the Project as a responsibility of the OwnerAssistance in establishing criteriaAssistance in obtaining data

1.05 Bidding Materials services consisting of organizing and handling Bidding Documents for:

CoordinationReproductionCompleteness reviewDistributionDistribution recordsRetrievalReceipt and return of document depositsReview, repair and reassembling of returned materials.

1.06 Addenda services consisting of preparation and distribution of Addenda as may be required during bidding or negotiation and including supplementaryDrawings, Specifications, instructions and notices(s) of changes in the bidding schedule and procedure.

1.07 Bidding/Negotiations services consisting of:

Assistance to Owner in establishing list of Bidders or proposersPrequalification of Bidders or proposersParticipation in pre-bid conferences



Responses to questions from Bidders or proposers and clarifications or interpretations of Bidding DocumentsAttendance at bid opening(s)Documentation and distribution of bidding results

1.08 Analysis of Alternates/Substitutions services consisting of consideration, analyses, comparisons, and recommendations relative to alternates orsubstitutions proposed by Bidders or proposers either prior or subsequent to receipt of Bids or proposals.

1.09 Special Bidding Services consisting of:

Attendance at bid openings, participation in negotiations, and documentation of decisions for multiple contracts or phased constructionTechnical evaluation of proposals for building systemsParticipation in detailed evaluation procedures for building systems proposals.1.39 Bid Evaluation services consisting of:Validation of Bids or proposalsParticipating in reviews of Bids or proposalsEvaluation of Bids or proposalsRecommendation on award of Contract(s)Participating in negotiations prior to or following decisions on award of the Contract(s) for Construction.

1.10 Construction Contract Agreements services consisting of:

Notification of Contract award(s)Assistance in preparation of construction contract Agreement forms for approval by OwnerPreparation and distribution of sets of Contract Documents for execution by parties to the Contract(s)Receipt, distribution and processing, for Owner's approval, of required certificates of insurance, bonds and similar documentsPreparation and distribution to Contract(s), on behalf of the Owner, of notice(s) to proceed with the work.

PHASE2 - SCOPE OF CONSTRUCTION CONTRACTADMINISTRATION SERVICES

In the Construction Contract Administration Phase the Owner and the Architect, respectively, shall provide those services designated in the Schedule ofDesignated Services necessary for the administration of the construction contract as set forth in the General Conditions of the Contract for Construction. Unlessotherwise provided in the Schedule of Designated Services, the Administrator's duties and responsibilities during construction shall be as set forth in theAgreement between Owner and Administrator for Designated Services. The following descriptions shall apply to those services assigned in the Schedule ofDesignated Services as the responsibility of the party indicated therein.

2.01 Project Administration services consisting of construction contract administrative functions including:

ConsultationResearchConferencesCommunicationsTravel timeProgress reportsCoordination of out-of-normal-sequence construction operationsCoordination of multiple-prime construction contractsCoordination of work by the Owner's forcesDirection of the work of in-house personnel.

2.02 Disciplines Coordination/Document Checking services consisting of construction contract administration activities for:

Coordination between the architectural work and the work of engineering and other involved disciplines for the ProjectReview and checking of documents prepared for the Project.

2.03 Agency Consulting/Review/Approval services

During the Construction Contract Administration Phase relating to applicable laws, statutes, regulations and codes of regulating entities relating to theOwner's interests during construction of the Project.

2.04 Owner-supplied Data Coordination services consisting of activities relating to construction contract administration including:

Review and coordination of data furnished for the Project as a responsibility of the OwnerAssistance in establishing criteriaAssistance in obtaining dataCoordination of delivery and installation for Owner-supplied equipmentCoordination of delivery and installation of Owner-supplied furniture and furnishings.

2.05 Office Construction Administration services consisting of:

Processing of submittals, including receipt, review of, and appropriate action on Shop Drawings, Product Data, Samples and other submittals requiredby the Contract Documents



Distribution of submittals to Owner, Contractor and/or Architect's field representative as requiredMaintenance of master file of submittalsRelated communications.

2.06 Construction Field Observations services consisting of visits to the site at intervals appropriate to the stage of construction or as otherwise agreed inwriting to become generally familiar with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with theContract Documents, and preparing related reports and communications.

2.07 Project Representation services consisting of selection, employment and direction of:

Full-time Project Representative(s)Part-time Project Representative(s).

2.44 Inspection Coordination services relating to independent inspection and test agencies, consisting of:

Administration and coordination of field testing required by the Contract DocumentsRecommending scope, standards, procedures and frequency of testing and inspectionsArranging for testing and inspection on Owner's behalfNotifying inspection and testing agencies of status Work requiring testing and inspectionEvaluating compliance by testing and inspection agencies with required scope, standards, procedures, and frequencyReview of reports on inspections and tests and notifications to Owner and Contractor(s) of observed deficiencies in the Work.

2.45 Supplemental Documents services consisting of:

Preparation, reproduction and distribution of supplemental Drawings, Specifications and interpretations in response to requests for clarification byContractor(s) or the Owner and as required by construction exigenciesForwarding Owner's instructions and providing guidance to the Contractor(s) on the Owner's behalf relative to changed requirements and schedulerevisions.

2.46 Quotation Requests/Change Orders services consisting of:

Preparation, reproduction and distribution of Drawings and Specifications to describe Work to be added, deleted, or modifiedReview of proposals from Contractor(s) for reasonableness of quantities and costs of labor and materialsReview and recommendations relative to changes in time for Substantial CompletionNegotiations with Contractor(s) on Owner's behalf relative to costs of Work proposed to be added, deleted, or modifiedAssisting in the preparation of appropriate modifications of the Contract(s) for ConstructionCoordination of communications, approvals, notifications, and record- keeping relative to changes in t he Work.

2.47 Project Schedule Monitoring services consisting of monitoring the progress of the Contractor(s) relative to established schedules and making statusreports to Owner.

2.48 Construction Cost Accounting services consisting of:

Maintenance of records of payments on account of the Contract Sum and all changes theretoEvaluation of Applications for Payment and certification thereofReview and evaluation of expense data submitted by the Contractor(s) for Work performed under cost-plus-fee arrangements.

2.49 Project Closeout services initiated upon notice from the Contractor(s) that the Work or a designated portion thereof which is acceptable to the Owner, issufficiently complete, in accordance with Contractor Documents, to permit occupancy or utilization for the use for which it is intended, and consisting of:

A detailed inspection with the Owner's representative for conformity of the Work to the Contract Documents to verify the list submitted by the Contractor(s) of items to be completed or correctedDetermination of the amounts to be withheld until final completionSecuring and receipt of consent of surety or sureties, if any, to reduction in or partial release of retainage or the making of final payment(s)Issuance of Certificate(s) of Substantial CompletionInspection(s) upon notice by the Contractor(s) that the Work is ready for final inspection and acceptanceNotification to Owner and Contractor(s) of deficiencies found in follow-up inspection(s), if anyFinal inspection with the Owner's representative to verify final completion of the WorkReceipt and transmittal of warranties, affidavits, receipts, releases and waivers of lien or bonds indemnifying the Owner against liensSecuring and receipt of consent of surety or sureties, if any, to the making of final payment(s)Issuance of final Certificate(s) for Payment.

PHASE3 -SCOPE OF POST CONSTRUCTION SERVICES

In the Post construction Phase the Owner and the Architect, respectively, shall provide those services designated in the Schedule of Designated Servicesnecessary to assist the Owner in the use and occupancy of the facility. The following descriptions shall apply to those services assigned in the Schedule ofDesignated Services as the responsibility of the party indicated therein.

3.01 Project Administration services consisting of post construction administrative functions including:



ConsultationResearchConferencesCommunicationsTravel timeProgress reportsDirection of the work of in-house personnel.

3.02 Disciplines Coordination/Document Checking services consisting of postconstruction activities for:

Coordination between the architectural work and the work of engineering and other involved disciplines for the ProjectReview and checking of documents prepared for use or occupancy of the Project.

3.03 Agency Consulting/Review/Approval services relating to applicable laws, statutes, regulations and codes of regulating entities that require complianceduring postconstruction use, occupancy and operation.

3.04 Owner-supplied Data Coordination services consisting of postconstruction activities during occupancy and operation relative to Owner-supplied furniture,furnishings and equipment.

3.05 Maintenance and Operational Programming services consisting of:

Assistance in the establishment by the Owner of in-house or contract program(s) of operation and maintenance of the physical plant and equipmentArranging for and coordinating instructions on operations and maintenance on equipment in conjunction with manufacturers' representativesAssistance in the preparation of operations and maintenance manual(s) for the Owner's use.

3.06 Start-up Assistance services consisting of:

On-site observation, troubleshooting and assistance in the operation of building systems during initial occupancyAssistance in the training of the Owner's operation and maintenance personnel in proper operations, schedules, and proceduresAdministration and coordination of remedial work by the Contractor(s) after final completion.

3.07 Record Drawings services consisting of:

Making arrangements for obtaining from Contractor(s) and other parties information certified by them on all changes made during construction from theinitial Contract Documents and on the location of concealed systems as installed during constructionReview of general accuracy of information submitted and certified to by the Contractor(s)Preparation of record drawings, based on information furnished by the Contractor(s), including significant changes in the Work made during constructionTransmittal of record drawings and general data, appropriately identified, to the Owner and others as directed.

3.08 Warranty Review services consisting of:

Consultation and recommendation to the Owner during the duration of warranties in connection with inadequate performance of materials, systems, andequipment under warrantyInspection(s) prior to expiration of the warranty period(s) to ascertain adequacy of performance of materials, systems, and equipmentDocumenting defects or deficiencies and assisting the Owner in preparing instruction to the Contractor(s) for correction of noted defects.

PRECONSTRUCTION

PRE-CONSTRUCTION MEETING AGENDA

Following the acceptance of the successful bid and subsequent award of the contract for construction, the Owner, Contractor and Administrator shall scheduleand attend the Pre- Construction Meeting. The purpose of the Pre- Construction Meeting is to discuss the specific requirements of the Contract Documents andhow they relate to the daily operation of the construction project.

The following is a sample agenda for the Pre-Construction Meeting and should be edited to conform to the specific requirements of each project. Items listed inthe sample agenda are more comprehensively discussed later in this manual.

AGENDA FOR PRE-CONSTRUCTION MEETING

1. INTRODUCTIONS

a. Owner, Architect, Engineers, Contractor, Contract Administrator.

2. COMMUNICATIONS

a. All communications between the Owner and the Contractor shall be in writing to the Owner and/or Architect, routed through theAdministrator.

b. All "Requests for Information" (RFI's) shall be in written form to the Owner and/or Architect routed through the Administrator. All responsesfrom the Owner and/or Architect will be in writing addressed to the Contractor's Project Manager.



c. All RFI's shall be consecutively numbered and include specification reference number.

3. BOND, INSURANCE & NOTICE TO PROCEED

a. Submit for review, Performance and Payment Bonds.

b. Submit required insurance certificates.

c. Notice of Commencement filed by Owner

d. Approval of Contractor pre-construction documentation is required prior to Owner's issuance of Notice to Proceed.

4. PLANS AND SPECIFICATIONS

a. Number of sets provided shall be as per the Contract Documents.

b. Contractor is responsible for all subcontractors having all addenda, ASI, Change Orders, and using correctly updated Contract Documentsin the field.

c. Any discrepancies in the plans, specifications, or details must be brought to the Architects attention and clarified prior to installation of thework. Assumptions will not justify improper work.

d. All field sets of drawings shall be made available for review by the Administrator at all times.

5. SCHEDULE OF VALUES

a. Submit to Architect within eight (8) business days of Award of Contract. (Form AIA G703).

b. Schedule of Values shall be broken down into each division of the work and will become the basis for Change Order pricing and paymentrequest review. Multiple buildings shall be broken down individually.

6. PROGRESS SCHEDULE

a. Submit in approved form (CPM, PERT, BAR).

b. Submit revised, updated schedule with each payment requisition. No schedule = No payment.

c. Submit Submittal Schedule for ease of tracking critical path or long lead items.

7. MONTHLY JOB MEETING

a. Set time, date, and location (on site).

b. Includes Owner, General Contractor and Administrator.

8. SHOP DRAWINGS

a. Contractor will review, sign and stamp all submittals to the Architect. Failure to do so will result in a "Submittal Return Notification" with noaction taken on that particular item.

b. ONLY two sizes will be accepted (8 1/2" x 11" and 24" x 36").

c. Shop drawings: Submit four bluelines (4) and one (1) reproducible transparency. Contractor will print all required bluelines.

d. Product Data and Catalogs: Submit eight (8) copies of each specified item, hi- lited or clouded in red.

e. Contractor is responsible for coordination and interface of materials when shop drawings differ from information on plans. Deviations fromplans or specs shall be brought to the approver's attention in writing.

f. NOTICE: Mechanical, Electrical, and Plumbing submittals MUST BE COMPLETE. They shall be in ring type binders with Index I.D. tabs andhi-lighted cut sheets. Anything less than a complete submittal will be returned stamped "INCOMPLETE".

g. ALL SUBMITTALS SHALL INCLUDE THE SPECIFICATION REFERENCE NUMBER.

9. SUBSTITUTIONS OF MATERIALS

a. Proposed substitutions of materials must be submitted to the Architect for approval prior to bid opening. **(This requirement may vary, checkGeneral and supplementary Conditions of Contract to verify)

b. Substitutions will not be accepted without credit to Owner in time or money. **(This requirement may vary, check General andSupplementary Conditions of contract to verify)

10. COORDINATION OF THE WORK

a. The Contractor is responsible for coordination of all elements of the work and every aspect of the coordination of the subcontractors work.



b. Each subcontractor is required to have a competent supervisor in charge of the work at all times.

c. Subcontractors shall verify their work to the Contractor for compliance with the contract documents, workmanship and completeness.

d. Any minor changes in the work shall be promptly transferred to the record drawings.

11. GENERAL SUPERINTENDENT

a. Contractor shall submit resume and historical data for Project Manager, Superintendent and Assistant Superintendent.

b. Superintendent shall be on site at all times when work is in progress.

12. FIELD OFFICE

a. Furnish per Contract Documents.

13. SIGNS

a. Furnish per Contract Documents.

14. TEMPORARY UTILITIES

a. Construction water furnished per contract.

b. Temporary toilets furnished per contract.

c. Temporary electricity furnished per contract.

d. Temporary telephone furnished per contract.

15. RECORD DRAWINGS - AS BUILTS

a. Must be updated weekly and will be reviewed at each progress payment meeting.

b. Record drawings will be supplied to Owner upon completion as per contract.

16. OBSERVATIONS - SCHEDULE ON SITE

a. The Administrator shall be on site at regularly scheduled intervals, for additional observation, one day (24 hrs.) notice shall be required.

17. SURVEY

a. Contractor shall engage a professional surveyor or engineer of verify property survey and building lay-out information shown on drawingsand advise Owner and/or Architect of any deviations.

b. Provide a survey of the building foundation locations immediately upon completion of that phase of construction to verify actual buildinglocation.

c. Prior to Substantial Completion provide final property survey showing all significant improvements on the property which have resulted fromthe construction contract. Verify finish floor elevations to Architect in writing per Contract Documents.

18. SOIL, CONCRETE AND OTHER TESTING

a. Testing as required by Contract Documents.

b. Testing lab to provide services at General Contractors request.

c. Additional testing may be requested by

the Owner and/or Architect, failed tests paid for by General Contractor.

d. Testing lab to provide copies of all test reports to Architect and Owner per Contract Documents.

19. REQUISITION FOR PAYMENT

a. Architect will review percentages of work complete, in place and/or properly stored prior to General Contractor preparing form G702 in finalform at monthly job meeting.

b. Review as-built drawings.

c. Submit updated progress schedule and schedule of values with each requisition per contract.

d. Submit Lien Releases as required by the contract.

e. Correct all non-conforming work prior to next payment requisition, including submittal requirements.



f. Invoices required for all stored

materials shall be included in payment requisition.

20. CERTIFICATE FOR PAYMENT

a. Architect shall forward to the Owner Application for Payment within three (3) days of receipt.

b. Four (4) copies:Owner (2), Architect (1) Contractor (1)

c. All supporting documents must accompany payment requisitions.

d. Notarized documents as required, and Contractor's signed statement verifying payment of previous request items.

21. PROPOSAL REQUESTS (PR), CHANGE ORDERS (CO), ARCHITECTS SUPPLEMENTAL INSTRUCTIONS (ASI), AND CONSTRUCTIONCHANGE DIRECTIVES (CCD)

a. Owner must authorize all Change Orders prior to commencement of work.

b. Architect to submit Proposal Requests responses to Owner for review and directions.

c. Proposal Requests will not be accepted without proper backup information as per GC Article 1.2.1.

d. Change Orders shall be prepared from and upon Owners approval of Proposal Request.

e. Architects Supplemental Instructions (ASI's) shall be used to document minor, no cost changes in the work.

f. Construction Change Directive shall be utilized (with Owner approval) when changes in the contract are required and the costs for theadditional work cannot be agreed upon by the Owner, Contractor and Architects. This action is usually taken to prevent delays in constructionwhile costs are reviewed and negotiated.

22. STORED MATERIAL POLICY

a. The Owner will pay for stored materials only under the following condition and terms:

1. Materials requiring long lead time for ordering.

2. Payment for materials stored and protected at site will take place only upon receipt of complete backup documentation attached to each payrequest.

3. The following Pay Request will include proof of payment to suppliers and subcontractors.

4. Materials stored off-site shall be in an independent bonded warehouse at no cost to the Owner, with prior approval of Owner.

23. DAILY LOG (CONTRACTOR)

a. The following shall be included in Daily Log:

1. Daily activities

2. Problems or potential delays

3. Temperatures, general weather

4. Accidents

5. Meetings and significant decisions

6. Unusual events (stoppages, emergency actions)

7. Change Orders received, implemented

8. Partial completion

9. Orders/Requests by governing agencies

10. Submit Daily Log weekly to Administrator.

24. ACCESS TO SITE

a. The Contractor has the responsibility to provide and maintain per Contract Documents.

25. AGENCIES HAVING JURISDICTION

a. City, County, State, Health Department, FDOE, School Board, Utilities, DER, SWFWMD (as required).



26. NON-COMPLIANCE NOTICES

a. The Contractor is responsible for verifying that all work complies with the Contract Documents.

b. Any work observed as defective or non-complying shall be recorded by the Administrator on a non-compliance notice.

c. All Non-Compliance work not corrected and approved by the next pay request shall be deleted (line item) from that and subsequent payrequests until corrected.

28. FINAL COMPLETION AND PROJECT CLOSE-OUT

a. Final acceptance and project close-out will not take place until all contract requirements, warranty and close-out documents along with allpunch list items have been resolved.

PRE-CONSTRUCTION DOCUMENTS

Following the Pre-Construction Meeting and prior to beginning construction the Administrator or Owner and/or Architect, will verify that the following documentshave been properly executed between the Owner and the Contractor:

1. "Notice of Commencement" from Owner

2. "Notice to Proceed" from the Owner.

3. Property survey from the Owner.

4. Permits, Licenses and Governmental Approval as required. (i.e. SWFWMD, County, State and DER)

5. Insurance coverage and Bonds as required by the Contract Documents.

NOTICE OF COMMENCEMENT

The Notice of Commencement is a legal document which is prepared by the Owner's attorney or financial lending institution and recorded with the Clerk of theCounty Court. A recorded copy must be posted by the Owner at the project site. Financing institutions will require the filing of a Notice of Commencement as aprovision of the loan agreement. The Owner and/or Architect should obtain a photocopy of the Notice of Commencement for his project files.

The purpose of the Notice of Commencement is to provide at the project site and on public record the name of the Owner, Contractor and Surety, so that thosewishing to file Notice to Owner may do so to the appropriate parties. Work performed at the project site prior to the Notice of Commencement is not covered bythe lien laws.

Although the Notice of Commencement is the Owner's responsibility, the Owner and/or Architect should so advise the Owner of both the need and benefits ofsuch a document. The Owner/Contractor Agreement should stipulate that the work shall not commence until the Notice of Commencement has been filed.

NOTICE TO PROCEED

Work to be performed under the Owner/Contractor Agreement generally commences on the date specified in a Notice to Proceed, as established in the GeneralConditions of the Contract for Construction. The Notice to Proceed should not be issued until the following documents (or copies thereof) have been receivedand reviewed by the Owner and/or Architect:

1. Evidence to the Contractor of satisfactory financing for the project, or sufficient funds available, by the Owner.

2. Recording of the Notice of Commencement.

3. Issuance of a building permit(s) by the applicable governing authorities.

4. Certificate of Insurance from the Contractor as specified in the Owner/Contractor Agreement.

5. Performance and Payment Bonds.

The Owner and/or Architect shall recognize that the "Date of Commencement" is the official date for the start of the construction project and is specificallyidentified in the Notice to Proceed. The Contractor should not necessarily be expected to commence work on the very date the Notice to Proceed is issuedunless the Contractor has had adequate time to mobilize his resources and equipment to the site.

SCHEDULES FOR CONSTRUCTION

The Administrator will receive and review the following schedules from the Contractor prior to processing the first Application for Payment:

1. Schedule of Values (Figure 1-2)

The Schedule of Values shall be prepared as required by the Contract Documents and equal the total cost of the project. Line items for theSchedule of Values shall be divided into the appropriate specification divisions and broken down to reflect material and labor costs for eachitem.



Unit measurement for the materials described in the Schedule of Values shall be included. The Schedule of Values for the project willultimately become the source for verifying costs for additional work (Proposal Requests) and establishing prices for changes to the ContractDocuments (Change Orders).

2. Project Construction Schedule (Figure 1-3)

The Project Construction Schedule shall be prepared as required by the Contract Documents in either PERT, BAR, GANTT, or C.P.M. format.The Project Construction Schedule shall be updated each period by the Contractor and verified by the Administrator to ensure that the currentschedule is accurate. The updated Project Construction Schedule shall be a part of each monthly Application for Payment.

3. Cash Flow Schedule (Figure 1-4)

The Contractor will prepare and transmit to the Administrator a Cash Flow Schedule for the Owner's use.

The Cash Flow Schedule will be used by the Owner to facilitate funding for the project by projecting the estimated Application for Paymentamounts and allowing for the appropriation of the necessary funds. The Cash Flow Schedule shall be updated as required to maintain it'seffectiveness.

4. Shop Drawing Review Schedule (Figure 1-5)

The Contractor will prepare and forward to the Administrator a Shop Drawing Review Schedule prior to the first Application for Payment. The ShopDrawing Review Schedule will list all items to be submitted to Administrator for approval and an estimated date for receipt. This schedule will allow theAdministrator to ensure that the shop drawings are properly and expeditiously processed by allocating additional time or personnel for shop drawingreview at such times as they may be required.

SHOP DRAWING REVIEW PROCEDURE

The following procedure shall be used by the Administrator for the processing of all shop drawings and related product data for the project:

1. Shop drawing shall be submitted in the format required by the Contract Documents. Shop drawing received in any other format shall be returned tothe Contractor with a "Not Reviewed" note attached to the submittal.

2. Shop drawing shall be reviewed by the Contractor and stamped accordingly. Shop drawings which do not bear the contractors approval stamp shallbe returned to the Contractor with a "Not Reviewed" note attached to the submittal. Regardless of the Contractors stamp, do not process shopdrawings which contain numerous errors and/or indicate that the Contractors review was not sufficient. The Contractor shall perform the original reviewof the materials which are supplied by his subcontractors.

3. All submittals are to be date stamped upon receipt.

4. All submittals are to be stamped with the standard office review stamp directly below the date stamp.

5. All submittals are to be recorded using the Standard AIA Shop Drawing Review form. (Figure 1-6) A separate sheet shall be used for eachspecification division. Log submittals by CSI number and number chronologically. (Example: 03000-1(1), 03000-2(1), 03000-3(1) etc.) The number inparenthesis indicates 1st submission for that particular shop drawing. In the event that the 1st submission be rejected, the suffix number in parenthesiswould become (2) upon second submission. (Example: 03000-1(2), 03000-2(2), etc.)

6. Shop drawings shall be submitted as required by the Contract Documents. Transmit (1) sepia and (2) blueline drawings to consultants. Theconsultant shall review, mark-up and stamp (1) one sepia and return to the Administrator. The Administrator will produce (2) bluelines of the stampedsepia for his files and distribution to the Owner, the Administrator will then transmit the corrected and stamped sepia to the Contractor.

In the event that the sepia requires major corrections, the Administrator will note on the return transmittal that the Contractor is to return (2) twocorrected bluelines for his files and distribution to Owner. All transmittals to consultants shall be recorded in the Shop Drawing Log in the same manneras those submittals reviewed by the Owner and/or Architect. The shop drawing number should be written in the upper corner of the transmittal for easein tracking.

7. The Architect's shop drawing review shall be conducted on the blueline copy of the submittal. Mark through all items, dimensions, etc., which arecorrect with yellow marker. Mark deficiencies which require correction in red marker. Note any questions during review process with green marker.Red/green notes shall be corrected before reviewed is completed.

8. Upon completion of the shop drawing review, transfer review comments to the (1) one sepia with black marker. The Administrator will run (2) twoblueline copies of the corrected sepia for his files and distribution to the Owner.

9. The (1) one corrected sepias shall be transmitted back to the Contractor. The sepia will have all review comments, date stamp and approval stampwith required action indicated.

The return submittal shall be recorded in the Shop Drawing Log with submittal number, date and status of transmitted item recorded. If the submittal isrejected, note the rejection with a high-liter for ease in confirming re-submittal.

10. Retain the engineer's marked-up copy of the submittal for reference. It is suggested that the copies be marked accordingly. (i.e. "mark-up" "Final"."Rejected", etc.)

11. When the shop drawing has been approved, distribute as follows:

General ContractorArchitect Files



Owner

The following steps should be taken in the shop drawing review process to avoid any unnecessary work or assumption of responsibility by the Administrator:

1. Do not perform the work of the Contractor. Do not accept the responsibility for verifying field dimensions, confirming compatibility with othersubmitted items etc., this work is clearly described in the Contract Documents as the work of the General Contractor.

2. Do not use or sign the Contractor's approval stamp.

3. Shop drawings and project samples should be kept in a file cabinet at the Administrator's desk; not in the Central File System.

4. Shop drawings should be processed within (10) ten working days. The Contractor should be advised in writing if the review for a particular item isanticipated to take longer than (10) ten days.

5. When the shop drawings for specialized equipment are furnished by the fabricator, the following precautions will be taken:

A. Carefully review the Administrator's responsibilities related to the shop drawing.

B. Do not rely solely on statements in the Owner/Architect agreement that may relieve the Architect of responsibility of design and constructionwork by others.

C. Determine if enough is known about the specialized equipment to judge the risk involved.

D. Consider having design and construction details checked by a qualified specialist even when our responsibilities extend only to generaldesign concept.

E. Consider having a specialist (engineer) design and approve the equipment if it presents unusual risks, not a fabricator. Request thespecialist review and approve the equipment.

CONSTRUCTION

OWNER/CONTRACTORMEETING

The Administrator will represent the Owner and/or Architect at the Owner/Contractor meetings held on the site as provided in the Contract Documents. Theproject meeting should be held once per week and attended by the General Contractor, Owner and the Administrator.

The Administrator will establish who will take minutes of the meeting and verify that all persons are copied with the minutes. The project meeting is a usefulforum for discussions involving Owner requested changes, problems with construction and/or field observations which the Administrator feels require correction.All items which may directly impact the completion of the project should be addressed at this meeting.

PROJECT SITE OBSERVATION

The Administrator will schedule field observation visits to the project as required to properly monitor the progress and quality of the work. The project scope andbudget shall determine the frequency of the field observations. One beneficial arrangement for the site observation is directly prior to the project meeting. Thisschedule allows for the Administrator to verify that directions from the previous meeting have been followed and also to update himself with the current status ofthe project before the present meeting takes place.

Regardless of the schedule for project observation and project meeting, the Administrator should set a regular time and date for the site observation, this willallow the Contractor to prepare questions and receive directives crucial to maintain construction progress.

At each site visit the Administrator will tour the entire project and note activities in each building or area of the project. The Administrator will photograph theproject at regular intervals, not to exceed one month, and also keep photographic records of all construction deficiencies from discovery through the finalcorrection.

The Administrator should not allow himself to be summoned to the project site more frequently than once per week. The Contractor will come to rely on theconstant presence of the Administrator if he is allowed to do so, and will attempt to have the Administrator resolve all of the project problems for him no matterhow large or small.

The Administrator will prepare an Administrator's Field Report each time he completes a site visit. The Field Report will include current status of the project,work in progress, weather, time, special instructions given the Contractor and questions from the Contractor. The Field Report will be consecutively numberedand a copy will be entered into the Project Log Book and the Central File System. (See Figure 1-7 Administrator's Field Report)

The Administrator will establish a schedule for site observations by the consultants, based upon the consultant's opinion regarding when they should revieweach stage of the construction. The consultants shall prepare a written field report each time they visit the project, the field reports will be filed in the Project LogBook and a copy sent to the Contractor and Owner.

Following site visits the Administrator will return to the office and prepare Architect's Supplemental Instructions for any verbal directions given the Contractor.The Administrator will maintain a list of all construction deficiencies observed on the project in numerical order. When a defect is observed, verbally notify theContractor and record on the list of construction defects. Unless urgent action is required do not make a formal record of the deficiencies until the second weekthe defect remains uncorrected. Record the date that the defect was corrected and what action was taken.

PROJECT PHOTOGRAPHY



The Administrator shall take photographs of the project at regular intervals, not to exceed (1) one month. The purpose for project photography is to record thequality of the work for items which are to be covered, provide documentation regarding the proper sequence of the work and to record the progress of the work.

Project photography has proven to be extremely beneficial in dealing with latent defects which were not discovered prior to covering and also in improvingoriginal design concepts when re- issue of project drawings is required for another project. The project photography shall be included into the Project Log Bookand displayed in chronological order. Major items which should be photographed include:

1. Slab on grade areas prior to concrete placement

2. Above ceiling areas prior to ceiling installation

3. Fire wall penetration prior to ceiling installation

PROJECT SAFETY

The Administrator, Owner and/or Architect nor any field representative are responsible for safety on the construction project. This does not mean that any majorsafety or life- threatening conditions are to be ignored. An unsafe condition is one that would be recognized as unsafe by the average architect or constructionpersonnel.

Situations which may be considered life-threatening, are any one in which there is immediate danger of physical harm present. In the event that an unsafe orlife-threatening condition is observed by the Administrator, he shall take the following action, with ABSOLUTELY NO EXCEPTION:

Unsafe Project Condition - The Administrator shall notify the Project Superintendent verbally of the unsafe conditions and leave the project immediately. TheAdministrator shall confirm his observation of the unsafe conditions, in writing to the Contractor's Project Manager with a copy of the notification to the Owner.

Life Threatening Conditions - The Administrator shall notify the Project Superintendent verbally of the condition and leave the project immediately. TheAdministrator shall confirm his observation of a Life Threatening safety condition, by telegram to the Contractor's Project Manager with a copy of the notificationto the Owner. The Administrator shall follow the telegram with written confirmation of the observation.

In the event of a construction accident, the Administrator shall verify that the Owner and/or Architect has been notified and recommend that he notify both hisliability carrier and the Owner. The Administrator shall immediately take extensive photographs of the area and shall make extensive written notes of hisobservations. Under no circumstances shall the Construction administrator make any statement regarding the accident to any media, or construction personnel.

PROJECT LOG BOOK

The Administrator will prepare and maintain a Project Log Book for the project while under construction. The Project Log Book will contain the followingdocumentation:

Shop Drawing Review Log

A. S. I. Log

Proposal Request Log

Constructions Change Directive Log

Change Order Log

Field Report Log

The Administrator will maintain (1) one copy of all documents related to the project in the Project Log Book for his reference, a second copy of all importantdocumentation such as A.S.I.s, Proposal Requests, Field Reports, Change Orders etc., will be filed in the Central Filing System.

The Project Log Book will be divided into the required divisions and separated by indexed tabs. Each section will begin with a summary sheet as required forreference. (See Figures 1-8 thru 1-11 Change Order Log, Proposal Request Log, A.S.I. Log etc.) It is imperative that the preparation of all Proposal Requests,Change Orders, A.S.I.s and Field Reports begin at the Project Log Book so that the proper consecutive numbering may be assigned by the Administrator.

The Administrator will list each new document on the appropriate summary sheet to avoid any duplication of the consecutive numbering system. Projectphotography may be included into the Project Log Book if this additional service has been retained.

APPLICATION FOR PAYMENT

At lest (10) ten days prior to the date for each payment established in the Owner- Contractor Agreement, the Contractor shall submit to the Administrator anitemized Application for Payment draft for review. This "pencil copy" review will take place prior to the preparation of the actual Application for Payment by theContractor.

At the beginning of the project the Administrator will establish a set time to meet with the Contractor and the Owner to review the Application for Payment. Thismeeting may coincide with the weekly Project Meeting. The Administrator will make a complete site observation prior to the Application for Payment review.

The Contractor shall break down the Schedule of Values into items or quantities of work which can quickly and easily be evaluated by the Administrator whenreviewing the work in place. This breakdown is separate from the Schedule of Values and does not replace it. The sole purpose of the breakdown is to avoiddisagreements between the Contractor and the Administrator as related to quantities of work completed.



The Contractor shall bring to the review meeting all materials required to properly evaluate the Application for Payment, including stored material invoices,Release of Liens, etc. The Administrator, Owner and the Contractor shall review the current project status and the Application for Payment and agree on theproper amounts of compensation due the Contractor as stipulated by the Contract Documents. (See Figure 1-12)

The Contractor will then proceed to prepare the certified copy of the Application for Payment in the format outlined in the Contract Documents. The Administratorshall retain his copy of the "pencil copy" and verify that the certified copy of the Application for Payment is correct as per the review meeting.

If the Administrator and the Contractor cannot agree on the appropriate amount for the Application for Payment, the Contractor has the right to prepare andsubmit an Application for Payment which he considers correct . The Owner and/or Architect will then, following consultation with the Administrator, formallyrecommend to the Owner what amount he feels should be certified for payment.

Following receipt of the formal Application for Payment and all supporting documentation from the Contractor, the Administrator shall:

1. Review the mathematics to verify that the contractors calculations are correct. The Administrator will check each column and each row of theContinuation sheet. The Administrator should remember that the Owner and/or Architect is certifying that the Application for Payment is correct.

2. Prepare a cover letter to the Owner recommending action to be taken by the Owner. The Owner and/or Architect does not authorize payment. TheOwner makes the payment. The Owner and/or Architect only advises the Owner and certifies that the Contractor is due the amount requested. Thecover letter should also include comments regarding the Contractor's adherence to the Project Schedule and the quality of the work in place.

3. The Administrator will process the Application for Payment to the Owner within (3) three working days of receipt.

The Contract Document describe (5) five reasons the Owner and/or Architect may recommend withholding payment from the Contractor. If these conditionsexist, in whole or in part, the Administrator must advise the Owner and/or Architect of the situations and request that he make the recommendation to withholdpayment.

The basic premise to follow in processing the Application for Payment is that enough money remain in the Contract Sum to ensure that the project could becompleted by another Contractor for the remaining funds should the original Contractor default.

In the event that payments are withheld for defective work, the Administrator shall recommend that the Owner and/or Architect withhold (3) three times thevalue of the defective work. The normal 10% retainage is not to be considered as sufficient retainage to cover deficient work. Amounts must be withheld inaddition to the normal retainage should deficient work be discovered. The normal retainage specifically covers defects which are not observed and may bediscovered at a later date. The retainage ensures that adequate funds are available to make corrections to these defects.

If an error is discovered in the formal Application for Payment, the entire Application for Payment must be returned to the Contractor accompanied by a letterfrom the Administrator explaining the reason for rejection and requesting that the Application for Payment be corrected and resubmitted. When the formalApplication for Payment is correct and properly certified by the Owner and/or Architect, the Administrator will ensure that a copy of the Application for Paymentis directed to the Central File System.

CONSTRUCTION CHANGE DIRECTIVE

The Construction Change Directive is not formally accepted by all Owners. Contracts utilizing the 1978 version of the General Conditions do not address theConstruction Change Directive at all, however, since it is a part of the AIA General Conditions of the Contract for Construction (1987 Edition) it has beenincluded in this manual for your informational use. In most cases, changes in the Contract Sum or Contract Time may be handled by the issuance of a ProposalRequest and subsequent preparation of a Change Order.

A Construction Change Directive is a written order prepared by the Architect and signed by the Owner and Architect, directing a change in the work and statinga proposed basis for adjustment, if any, to the Contract Sum or Contract Time, or both (See Figure 1-13). The Owner may, by issuance of the ConstructionChange Directive, without invalidating the Contract, order changes in the work within the general scope of the Contract, consisting of additions, deletions orother revisions, the Contract Sum and Contract Time being adjusted accordingly.

A Construction Change Directive shall be used in the absence of total agreement on terms of a Change Order. If the Construction Change Directive provides foran adjustment to the Contract Sum, the adjustment shall be based on one of the following methods:

1. Mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit proper evaluation.

2. Unit prices stated in the Contract Documents or subsequently agreed upon.

3. Cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee.

If none of the above methods for establishing the proper adjustment to the Contract Sum are acceptable to the Contractor, the method for adjustment of theContract Sum shall be determined by the Owner and/or Architect on the basis of reasonable expenditures and savings of those performing the work attributableto the change, including, in the case of an increase to the Contract Sum, a reasonable allowance for overhead and profit. In such a case, the Contractor shallfurnish to the Owner and/or Architect, an itemized accounting of the additional costs involved in the change, together with all substantiating documentation.

TESTING

Prior to the commencement of construction, a set of Contract Documents should be submitted to the construction testing agency for their review. The testingagency should provide a copy of their current rate schedule for such test work and a budget estimate for the particular project for the Owner's review andinformation.

After the Owner's acceptance and approval, the Owner and/or Architect will authorize the testing agency to proceed, in writing, prior to any testing performed.The Administrator will review the billing with the Owner and/or Architect and transmit the bill to the Owner for payment. It shall be the Contractor's responsibilityto coordinate and schedule all testing activities for the project.



The testing agency shall provide test reports within 48 hours to the Architect, designated engineering consultants, Contractor, and Owner. The Administrator willact immediately, in writing, in response to any test reports which indicate that the work does not conform to the Contract Documents. Since the Contractor isresponsible for the construction means and methods, it is the Contractor's responsibility to propose a method to correct construction deficiencies. It is the Ownerand/or Architect's responsibility to review and act on the Contractor's proposal.

ARCHITECT'S SUPPLEMENTAL INSTRUCTIONS (ASI's)

The Administrator will prepare and issue an Architect's Supplemental Instruction for any additional work which is not included in the Contract Documents and willnot increase the Contract Sum or extend the Contract Time. The Architect's Supplemental Instruction (See Figure 1- 14) will be consecutively numbered andrecorded in the Project Log Book. The Administrator may prepare the Architect's Supplemental Instruction for the Owner and/or Architect's signature.

The Administrator is encouraged to attempt to resolve small incidental items by means of the Architect' s Supplemental Instruction whenever possible. TheArchitect's Supplemental Instruction shall be forwarded to the Contractor for signature as an acknowledgment that the work described will not change theContract Sum or Contract Time.

PROPOSAL REQUESTS

When changes to the Contract Documents are needed or desired, which involve a substantial change to the Contract Sum or Contract Time, the Administratorwill prepare and issue a Proposal Request using AIA Document G709. (See Figure 1- 15) The Proposal Request will be recorded in the Project Log Book andissued a consecutive number. The Proposal Request Summary Sheet will be located at the beginning of the Project Log Book section for Proposal Requests.

The Administrator will issue the Proposal Request using the following procedure:

1. The Administrator will prepare a formal Proposal Request using AIA Document G709, record the Proposal Request in the Project Log and assign it aconsecutive number.

2. The Administrator will transmit the Proposal Request to the Contractor with a copy to the Owner.

3. The Contractor shall analyze the Proposal request and provide written response containing exact cost information including General Contractor'soverhead and profit, and change to the Contract Time.

The Contractor's response should be accompanied by cost breakdown information necessary for the proper evaluation of the proposed cost, (i.e.itemized subcontractor's quotations, labor and material breakdowns, etc.)

4. The Proposal Request and the Contractor's response will be forwarded to the Owner with a letter from the Owner and/or Architect containingrecommendations for action on the part of the Owner. The Owner should be reminded that work is proceeding and that failure to execute the ProposalRequest expeditiously could increase the cost for the proposed work.

CHANGE ORDERS

When the Owner's review of the Proposal Request is complete and approval for the Change Order obtained, the Administrator shall prepare a Change Order,as provided in the Contract Documents, utilizing AIA Document G701. (See Figure 1-17)

The Change Order will be prepared in (3) three copies and forwarded to the Contractor for signature. The Contractor's signature on the Change orderacknowledges that he will complete the work described in the Change Order for the stated amount in the Change Order. Additional time, if any, required for theChange Order work will be included in the Change Order.

Failure by the Contractor to request additional days for the Change Order work will prohibit the Contractor from requesting additional time extensions related tothe Change order work at a later date.

Following the Contractor's signature of the Change Order all (3) three copies will be returned to the Administrator for the Owner and/or Architect's signature andcertification. The Change Order will then be transmitted to the Owner for final signature and distribution. The Owner, Contractor and Owner and/or Architect willreceive (1) one signed and certified copy of the Change Order for their records. The Change Order will then be included in the next monthly Application forPayment. The Change Order will be recorded in the Project Log Book and a copy of the Change Order included in the Log Book. A copy of the Change Orderwill also be directed to the Central File System.

Some owner's prefer to pay for Change Orders separate from the Application for Payment. The Contractor may request assurance that the owner has adequatefunds to pay for the Change Order before executing the work. Financing and lending institutions generally require that all Change Orders be processed throughtheir office before executing the work. Contractor's Performance and Payment Bond, and Builder's Risk Insurance must be adjusted to reflect substantialchanges to the Contract Sum.

The Contractor is obligated to execute any Change Order authorized by the Owner even if there is a dispute regarding the actual cost of the Change Order workor it's impact on the Project Schedule. These matters can be resolved by exercising other provisions included in the Contract Documents.

TIME EXTENSIONS

During the course of the construction process the Contractor may request an extension in the contract time for one of the following reasons:

Changes or additions to the original scope of the work. (ie. Change Order, Construction Change Directive)

Late materials shipments from suppliers.

Excessive bad weather.



The Administrator shall carefully review the contract for the definition of items which constitute a legitimate time extension. For a situation to be considered alegitimate extension in the contract time, it must be absolutely beyond the control the Contractor.

Remember that the Contractor may choose to be the broker of construction services, but he is still responsible for the building schedule. It is not unreasonableto require the Contractor to resolve a scheduling problem with a subcontractor or material supplier by replacing them with another company.

When time extensions are requested because of late material shipments, the contractor should be asked to furnish verification of the original date of which thematerial order was placed. In most cases, the Contractor or the subcontractor, did not place the order in sufficient time to ensure the delivery of the material onschedule.

The most common request for time extensions is for bad weather. The Contractor must make allow for a normal amount of bad weather in his schedule.

Time extensions are granted only for abnormally bad weather, defined as weather which was both detrimental to construction activities and more frequent thanusually experienced during that time of year. On the last day of each month, the local newspaper generally publishes weather statistics which can be used toevaluate the weather conditions experienced during the previous month in comparison with the statistical average. Except in unusual circumstances, it is a goodidea to attempt to retain all time extension requests until the end of the project.

Although the Contractor may have experienced abnormally bad weather during one month, he may have benefited from several months of abnormally goodweather. It is important to remember that bad weather during certain phases of construction can affect the construction schedule more adversely than goodweather can benefit the construction schedule during other phases.

The Contractor is required by the Construction Documents to notify the Owner and/or Architect of any potential claim for additional time, due to delay, withintwenty days of the commencement of the delay. When reviewing claims for time extensions, the Contractors daily log should be reviewed to verify that the badweather occurred and that lost time for that period was actually experience by the Contractor.

MANAGING PROFESSIONAL LIABILITY

We are presently witnessing what some people term a " litigation explosion." In this environment, the private practice of a Administrator can be particularlyvulnerable, because of the damage that even an unfounded lawsuit can do to reputation and financial stability.

What steps can the Administrator take to minimize his risks to litigation? We will begin by looking at the five major areas of the interaction between theAdministrator and the other members of the project team. These are the areas where the Administrator can do the most to protect himself from liability:

PROFESSIONALISMINTERPERSONAL RELATIONSHIPSBUSINESS PROCEDURESTECHNICAL PROCEDURESPROFESSIONAL LIABILITY INSURANCE

The purpose for this discussion is to provide a solid understanding of the basic reasons claims and litigation occur, and the best methods to either prevent ordeal with those claims. The success of any advise depends upon its implementation. Your loss prevention and business management efforts can not onlyreduce damaging claims, but will result in a more profitable operation as well.

I. PROFESSIONALISM

It take more than an education in engineering science or architecture to be a true Administrator. While "design", of course, means work in a conceptually,visually and structurally oriented business, "professional" implies a higher level of performance, commitment and knowledge than most people possess.

Design programs at the University level should be restructured to reflect the current conditions of the design profession and its real opportunities andresponsibilities. Students should develop the ability to analyze, synthesize, evaluate, choose and implement corrections to the problems which arise during theproject.

The first people truly considered professionals were lawyers, physicians, clergymen. Disciplines such as architecture and engineering slowly joined the ranks ofthe professionals through legal statues establishing minimum standards and hard-won public acceptance.

The average person may see his lawyer or doctor many times each year and therefore is reasonably aware of the scope of services provided by each of theseprofessionals. Not so with the architect, the average person may only deal with an architect once or twice in his entire lifetime.

This lack of familiarity between the Administrator and his client could lead to unreasonable expectations on the part of the client. For this reason theAdministrator should be comprehensive when explaining the nature and scope of all services to be provided, with special emphasis on services which are notprovided but could be necessary.

Design professionals are highly vulnerable to claims from clients, owners and users. This vulnerability stems partly from failure by some architects andengineers to understand the demands of professionalism. Design professionals must be above reproach in every aspect of dealings with others and in themanagement of the firm. This will not only prevent claims but also attract clients.

II. WORKING WITH OTHERS

Litigation of any type results from a breakdown in understanding between the parties involved, either in the communication of the professional endeavor itself(the contract documents) or in the practical working communications between the Administrator and others on the construction scene.



Minor disputes are cumulative. They build up to a final breakdown. When the final straw occurs, serious but otherwise forgivable errors can result in litigation.Efforts to maintain an atmosphere of trust and cooperation between the Administrator and the builder are rewarded in this scenario.

Communication failures are often at the center of lawsuits. When this happens, the courts are called upon to decide what was communicated based upon caselaw. The plaintiff's attorney will build their case utilizing the Dictionary of Words and Phrases (West Publishing, 1971, 1987-88 ppt.) This comprehensivedictionary contains 100 volumes each consisting of 700 pages, a total of 70,000 pages of definition. Some words require considerably more definition thanothers, the word "final" for example, accounts for a mere 500 pages. Clearly a word to avoid in your communications.

Dangerous words can be categorized into three basic groups:

1. Extreme words; final, all, any

2. Words of multiple meaning; supervise, inspect, approve

3. Words of promise; guarantee, warrant, certify, ensure

These words should be avoided, and if not possible the content of phrases containing these words should be reviewed very carefully.

Design professionals may need to concentrate more than most professionals on maintaining good relationships with colleagues and co-workers. They oftenwork with highly complicated concepts on very expensive projects. When the stakes are this high, they need the extra advantage that a professional image, alevel head and solid training in crisis management provide. It is these attributes that separate the superior Administrator from the rest.

III. BUSINESS PROCEDURES

It is extremely important to know who your client is, and what kind of business he runs, before agreeing to perform work. Discover the answers to thesequestions:

Does the client have a realistic budget and schedule?Is the client going to be the Owner and user, or is the project being developed for resale. If so, are the end-users requirements understood?Does the client understand what is being purchased in the way of professional services and what to expect from the design firm.Is the client financially capable of carrying out the project?Are all communications clear and direct with the client?

These questions should be thoroughly review and answered, even if the answer indicates that the client should be avoided. Design professionals need tochoose their clients, their projects and their personnel carefully to protect themselves from costly professional liability problems.

In dealing with clients, it is critical that both the Administrator and the client be absolutely clear on the contractual provisions that govern their workingrelationship, and on what their job-related obligations are. Signing a contract without careful analysis can result in serious problems.

Also important to remember, is that your personnel are your most valuable asset. When you select them carefully, set high standards for them, provide cleardirection and treat them fairly, they will reward you by helping your firm grow and prosper.

IV. TECHNICAL PROCEDURES

Obviously, technical mistakes cause embarrassment and cost time and money, more importantly they can cost lives. The true professional regards checkingaids, handbooks and other sources of information enthusiastically - not resentfully -recognizing that anything that produces a better final product has greatvalue.

A design manual should be created and utilized for each project. The manual should contain check lists for each stage of the drawing and specificationdevelopment. The manual should be considered a dynamic documents and should be updated and include notes for improvement for product and/or servicesfor the next project.

Owner's expectations are that the Architect will render a perfect set of design and contract documents. Design professionals know this is a virtual impossibility,but hesitate to discuss the potential of errors and omissions with the client. This discussion must take place, for the design professionals protection.

An acceptable method for dealing with errors and omissions should be worked out between the Owner and the design professional in advance. The clientshould also be advised of the increased potential for errors, omissions, and concealed conditions, which are inherent to certain types of construction, ie.renovation, fast-track.

The potential for errors and omissions is always present in design work. The prudent Administrator, therefore, provides himself with "safety nets" to make suremistakes are corrected before they cause major difficulties. Checklists are very valuable, as is construction review.

However, perhaps the most important thing the Administrator can do to control professional liability in this area is to reach a clear understanding with his clientthat errors will occur, and that you will work together to correct them in a timely manner.

THE PAYMENT AND PERFORMANCE BOND

The most treacherous phase of the delivery of a new project is the actual construction. The construction phase, due to the infinite number of inherent risksassociated the activity, towers over the other phases of the project delivery when it comes to claims, failures, problems and ultimately defaults.

The Administrator must be painfully aware of not only the Owner's rights under the Contract but also the obligations necessary to protect those rights. Shouldthe Administrator, while acting as the Owner's agent in the Administration of the new project, fail to properly ensure the rights of the Owner through negligence



of the requirements, incorrect documentation or the untimely issuance of notice, the Administrator may certainly expect the Owner to hold him responsible for allloses both morally and financially.

No other situation holds more potential for this devastating scenario then the default of the Contractor during the construction of the project. For this reason, thesuccessful Administrator must exercise both caution and diligence while reviewing the types of Payment and Performance Bonds required by the Contract. Theeasiest method of protection is to specify the standard AIA Bond forms A312 (Performance and Performance Bonds), these documents are not only respectedby the Surety industry, but have been thoroughly tested and generally upheld through the judicial process.

While the Payment and Performance Bonds offer the Owner the ultimate in protection against countless scenarios of Contractor default, subcontractor non-payment, material or supplier non-payment and liens, the Administrator must recognize the Surety and its agents for what they are and not what he wishes themto be. By the time the Surety becomes involved in a construction project, the relationships between the Owner, Contractor and Administrator may be verystrained to say the least. The Administrator that believes the Surety to be a deep pocketed, sympathetic benefactor that rolls on to the project doling out moneyto those who deserve it most, just because there is a Payment and Performance Bond, is in for a startling realization the first time he dashes headlong throughthe gauntlet of Contractor default or major claim litigation.

At this time he will come to know the Surety and its agents for what they are, extremely sharp and intelligent businessmen who will live up to all obligations andresponsibilities under the bonds, provided all aspects of the default, are in fact, the Contractor's responsibility. Where the Surety is relieved from theirobligations, in whole or in part, by the erroneous actions of the Administrator or the improper actions of the Owner, the Surety may be expected to mitigate theirlosses to every extent possible under the law. As previously stated, these gentlemen are extremely sharp businessmen, a uniquely hybrid blend of insurancesalesman, accountant and attorney with just a dash of prestidigitator thrown in to help with the strategically placed magic trick.

The Surety and its agents can be the most formidable of adversaries or the most gracious of financial saviors, depending upon the particular situations involvedand the ultimate causes for their involvement in the project.

The statements and opinions expressed herein reflect the general attitude of the Surety and its posture when confronted with differing construction situations. Beaware, that these opinions are generic and are not legal advise.

The Administrator must read and become familiar with the wording and requirements of each type of Bond, for as every project is unique so is every situationinvolving the Surety. There can be no substitute for studying the requirements of the bond to ensure that each and every action required by the Administrator isnot only completed but completed within the specified time frames outlined in the Bond documents.

FUNCTION OF SURETY

The basic function of the Surety is to pre-qualify the Contractor for each individual project to ensure that there will be as limited an amount of problems aspossible related to lack of experience with a particular type of project, lack of financial ability to complete the project and demands of other current projects onthe Contractor which could detrimentally effect the successful completion of the new project. Based on the Surety's ability to pre-qualify the Contractor they arethen prepared to back their decision with their own money and ultimately pay dearly for any miscalculations in their assumptions.

The standard method of pre-qualification utilized by the Surety consists of the following criteria:

Character - The character of the Contractor indicates his potential for loss and his ability to deals with the problems associated with construction.Capital - How much funding ability does the Contractor have on hand and how much is projected in the immediate future. What is the Contractor's Debtvs. Asset ratio.Capacity - How much construction may the individual Contractor perform at one time, at what point does he become overloaded.

Like any insurance underwriter, the Surety has two major objectives when writing a bond for the Contractor. Since the Surety is a business and depends uponthe bond premiums for income they sincerely want to write as many bonds as possible, however the Surety must carefully consider each project and evaluatethe probability of loss vs. the possibility of loss.

The successful Surety balances the risks of loss equally with the potential for premium income. No Surety could last in the industry if they were forced to paymajor claims on each bond written. The premiums charged for bonding are insignificant compared to the actual dollars paid out in the event of a failure. Whenconstruction failures do occur, neither the Owner, Administrator or Surety come out ahead.

The Surety industry has recovered from a state of elitist fragmentation in the 80's, the older more established companies are slowly moving away from bondingthe smaller more risk prone Contractors. These Contractor are forced to utilize smaller more local companies and only involve the larger Surety when theconstruction value is more than the local carrier can ensure. This process seems to benefit the Contractor in two ways, by making the bond more accessibleand at the same time decreasing the actual premium cost for bonding by increased competition between the local bonding companies.

When a potential failure and claim is identified on the construction project the Surety will not attempt to mediate the dispute. The Surety will be the first to statethat they are not construction experts, the Surety will monitor the progress of the dispute resolution and stand ready to cover all Owner costs, above theestablished Contract Sum, to complete the project and deliver a lien free facility to the Owner. When separate Payment and Performance bonds areestablished, both for the total amount of the Contract Sum, it is hypothetically possible for the Surety to be required to pay on each obligation the full ContractSum. For this reason, the Administrator is advised to always require separate Payment and Performance bonds with separate Power of Attorney letters.

When the Contractor defaults in the middle of the project, the Owner may be required to pay the Surety the remaining Contract Sum while the Surety pays thereplacement Contractor to complete the project. No other scenario demonstrates the importance of the Administrator accurate monthly review of the workcompleted prior to certification of the Contractor's Application for Payment.

If the Contractor default occurs at a point in the project where more money has been paid to the Contractor than the value of the improvements completed, theOwner may be faced with paying additional money to both complete the project and pay all outstanding debts. Again this occurs only when the total of bothPayment and Performance bonds are exceeded.



In summary, the function of the Surety is to pre-qualify the Contractor and make calculated judgments regarding his ability of complete the work in question,basing those judgments upon his financial status, work in progress and expertise in the particular type of construction. If successful in his task the Suretycontrols the growth of the Contractor and in some cases actually forces shrinkage of the Contractor when his plans for growth are unrealistic.

PAYMENT vs. PERFORMANCE BONDS

The Surety offers two standard types of protection for the Owner in the construction process, the Payment and Performance Bonds. Each obligation covers adifferent potential problem which could be encountered during the construction process. The Payment bond assures the Owner that all of the qualified creditors,subcontractors and materialmen for the project will be fully paid upon completion of the work, provided the Contractor is properly paid by the Owner.

To be qualified, the creditors located outside the "sphere of privity", or not in direct contract with the Owner, must file the proper Notice to Owner within the timeframes outlined in the laws of the state where the project is constructed. In Florida this time frame has been established as being within forty-five days of thefirst furnishing of work on the project. Subcontractors, suppliers and materialmen who do not properly file the Notice to Owner will have no recourse in the eventof non-payment other than through the Equity Court system. The Surety will not make payment to even legitimate creditors who has not ensured their lien rightson the project.

The Performance Bond ensures the Owner that the Contractor will complete all obligations of the Contract, again provided that no action by the Owner or hisagents prevents or inhibits the Contractor from the completion of the specific Contract requirements. In the event of Contractor default, the Surety will take oneof the following actions:

1. Finance the Contractor or completion.2. Bring in another Contractor acceptable to the Owner.3. Pay the Owner the face value of the bond or some negotiated settlement based upon any improvement completed prior to the default.

The Surety will generally chose option #2 since the financing of the Contractor to completion may end up costing the Surety more money than simply finishingthe project with another Contractor. The face value payment of the bond is another option that is usually not acceptable to the Owner.

Most bonds written to the Contractor involve some sort of personal indemnity on the part of the Contractor. In the event of default the Surety will attempt torecover any moneys possible through legal action to mitigate their losses. The process of attaching personal assets to offset the losses is referred to assalvage. The Surety will readily admit that they recover little if any money in the salvage process.

Due to the amounts of money at stake when defaults occur, the Surety will generally subjugate the rights of the Contractor during dispute resolution and makeall attempts to either deflect the responsibility for the default or mitigate the expense of the default. The maximum mitigation of default expense is to avoid anyallegations of frivolous settlement of the part of the Surety which may impact their ability to recover funds in the salvage process. The Administrator is mostacutely aware and rightfully afraid of the deflection of responsibility posture.

The initial reaction of the Administrator when confronted by the Surety regarding the design of the project is self-defense, this results from the Surety's ability toassign excellent lawyers and professional witnesses to a case in an attempt to redirect the responsibility for the default. At this point, there is no better defensefor the Administrator then comprehensive and accurate construction documentation.

EVOLUTION OF THE SURETY

The Surety industry may be utilized by the Administrator as a good indicator of the current construction atmosphere. More a thermometer of the industry than abarometer, the Surety is best used to monitor the current effects of the economy on the construction industry. By monitoring the continuous defaults of small,medium and larger subcontractor, the Surety is painfully aware of the ripple effect caused by the default of the smaller subcontractors. The Surety industry hasrecovered fully from a devastating run of defaults which occurred between 1974 and 1980.

In the six year period between 1974 and 1980 the Surety industry took in 1.2 billion dollars in bond premiums while paying out over 1.7 billion dollars inconstruction claims and defaults. The construction industry was severely effected during this period by high interest rates and a depressed economy. Suretycompanies, anticipating the continuation of a strong economy and high interest rates, competed heavily for the business of each Contractor. The lessonslearned by the Surety companies during the late seventies and early eighties account for their rigid criteria for issuance and approval on bonding capacity today.

REQUIREMENTS TO ENSURE BOND PROTECTION

The Administrator should be aware of all requirements which are necessary to ensure the protection of the Payment and Performance bonds. As a constructionexpert, the Administrator's role in the administration of the construction contract requires he verify all notices are made and all prerequisites are followed by boththe Owner and Contractor. This process begins with the selection of the type of bonds required for the project.

The Administrator should specify standard AIA bond forms A312. Separate Payment Bond and Performance Bond with separate bond numbers and Power ofAttorney offer the Owner protection equal to twice the face value of the construction project. The use of combination Payment and Performance Bonds shouldbe avoided due to recent legal precedents which have held that the Surety was obligated to pay only the face value of the construction project through acombination of claim against both sides of the combined bond.

The next precaution, exercised by the Administrator is to ensure that the Owner files the proper Notice of Commencement at the beginning of the work. Thislegal document, files with the Clerk of the Court, informs the subcontractors, materialmen and suppliers who is the Owner, the Surety, the Administrator andgives the legal description of the property. This information is mandatory when the subcontractors and/or materialmen attempt to file their Notice to Owner.Changes in the Florida Lien Law, effective 1/1/92, required that the Notice of Commencement be posted in a conspicuous location, adjacent to the BuildingPermit, prior to the first inspection or signature by the building inspector.

During the course of the project the Administrator should receive copies of all Notice to Owner filed on the project. The Administrator should then require theContractor to provide documentation with each Application for Payment showing that the qualified lienors have been properly paid. The preferred method ofreceiving Lien Releases is to require Full and Final Release of Liens through a particular date. The Contractor may attempt to provide Inducement Release ofLiens, which may also be referred to as Conditional Lien Releases. The operable word here is "conditional", the Administrator should not accept any Release of



Lien which is contingent upon events which he has no control over. Should the Contractor fail to make payment to the lienor who signed the conditional release,the release is voided and subsequently worthless.

The Administrator should insist on Full and Final Releases which release Owner for any work completed through a particular date, even after listening to theContractor's lamentful pleading to avoid being forced to fund the Release of Liens process through his own resources. Contractors who demonstrate theirwillingness to properly and timely make payment to their subcontractors and material suppliers will have little problem securing Full and Final Releases throughthe end of each payment period. The Contractors who protest the most regarding conditional lien releases, may be the ones who are reluctant to pay theirsubcontractor and suppliers until forced to do so.

During the course of the construction project changes in the scope of work may be requested by the Owner and/or Administrator. The changes in the scope ofwork may or may not effect the total Contract Sum or Contract Time, in any event the Surety should be made aware of all changes in the contract which doeffect the Contract Sum or Contract Time.

The Surety will qualify the Contractor for the scope of work described in the bid documents, the Administrator has no way of knowing if the Contractor wasqualified by the Surety as marginally qualified or extremely qualified. The Surety may not wish to extend the coverage for a particular Contractor based on hisability, capacity or other information to which the Administrator is not privileged. As part of the Change Order process, the Administrator should request andreceive verification from the Surety that the Payment and Performance Bond have been increased to include the recent change in the scope of work.

At the first sign of serious trouble on the construction project, the Administrator should be prepared to advise the Surety of a potential situation which may ormay not evolve into a claim. The Surety is not offended by the advisement, rather they appreciate the opportunity to become involved at a time when there maystill be some hope of resolution. The Surety generally believes that the earlier they become involved in a problem the greater their chances are to mitigate theirlosses. The Contractor, however, will not appreciate any letter copied to his Surety agent. Contractors have threatened to sue Design Professionals for merelyadvising the Surety of potential problems with the project.

The Contractor may be at his bonding threshold and desperately requesting additional bonding capacity, an advisement of potential problem at this stage wouldnot enhance his efforts. The Administrator should exercise caution when advising the Surety of a problem yet not be afraid to do so if situations warrant. Onegood way to deal with this situation is to establish a good business like relationship with the Surety agent, remember, he is there to serve not only the Contractorbut the Owner.

At the close of the project, the Administrator will request the single most important documents from the Surety since the bond itself, the Consent of Surety toReduction in Retainage and the Consent of Surety to Final Payment. These documents verify that the Surety has been given adequate opportunity to review theposition of all qualified lienors, suppliers and materialmen and agrees that the Contractor may be paid the remaining moneys due him under the contract. Thereceipt of both documents are an important part of the Administrator's close-out procedure for the project.

Should the Owner reduce retainage or make final payment without the Surety's consent, and the consent is an established obligation in the bond, the Suretycould use this breech of obligation to negate their responsibilities to the Owner, in whole or in part.

The standard AIA bond forms do not require Consent of Surety to Retainage Reduction or Final Payment as part of the standard language, however, if theserequirements are added under the modification section, they will certainly be enforceable.

The final aspect of the relationship with the Surety is the advisement by the Owner or Administrator of a problem following the completion of the project. For thefirst year, minor warranty items are generally handled by the Contractor, but, what happens if a major problem occurs related to the installation work under theContract. The standard bond forms require that notice to the Surety or claims made upon the Surety, must be filed within (2) two years of the completion of theproject. In this case, completion of the project shall be the making of final payment to the Contractor.

In the event the problem involves a latent defect, not readily observable, Florida law allows for the Owner to pursue the Contractor for a period of (5) five years.Needless to say, the Surety and the Contractor should be notified immediately in the event that problems arise with a new project.

POST-CONSTRUCTION

SUBSTANTIAL COMPLETION

The date of Substantial Completion is defined in the Contract Documents (GC 8.1.3) as the date which the Owner and/or Architect will certify that the work, ordesignated portion of the work, may be beneficially occupied or utilized by the Owner for it's intended purpose. The actual date of Substantial Completion will beas noted on the Certificate of Substantial Completion (AIA G704). (See Figure 1-18)

When the Contractor considers that the work, or designated portion of the work as previously agreed to by the Owner, is substantially complete, he will prepareand submit to the Administrator a punch list of items which remain to be completed or corrected. The failure of the Contractor to include any items on the list,will in no way alter his responsibility to complete or correct these items per the Contract Documents.

Upon receipt of the Contractor's punch list the Administrator will review the list and the completed work to determine that the list is both accurate and complete.Items which require correction and/or completion, that are not included in the Contractor's list, shall be added by the Administrator. The Owner should beadvised that the items on the punch list shall be corrected and/or completed within the time limit set forth in the Certificate of Substantial Completion.

The Contractor shall be advised that the correction and/or completion of all punch list items shall be conducted in a manner not to adversely effect the Owner'soccupancy of the facility.



The term "beneficial occupancy" shall be interpreted to mean that the project or portions thereof, are complete in nature to allow the Owner to utilize the projector portions thereof, for their intended usage. The mechanical systems, life safety systems, tele-communications systems and any other systems which arerequired to properly utilize the project or portions thereof, shall be complete and in good working order. The remaining items to be completed shall be such thatthe correction does not cause inconvenience to the Owner or disruption to the Owner's normal operations.

The Owner should be consulted to confirm that there are no other construction deficiencies that he may be aware of which are not on the Contractor's punchlist. It is very important to emphasize that the Contractor is the person who is responsible for preparing the original punch list.

If the Administrator is requested to make a Substantial Completion inspection, and it is obvious that the Contractor's punch list is not comprehensive, theinspection shall be discontinued and the Contractor advised that his list is inadequate.

Prior to issuing a Certificate for Substantial Completion, the Administrator should verify that the following conditions exist:

Written statement from the Contractor that the project, or designated portion thereof, is substantially Complete.Properly executed Consent of Surety for Reduction in Retainage per the Contract Documents.Contractor's "Punch List" with Administrator's supplementary comments added.Certificate of occupancy from appropriate agency.

The Certificate of Substantial Completion shall be prepared by the Administrator and certified by the Owner and/or Architect, prior to being submitted to theOwner and the Contractor for their written acceptance of the responsibilities assigned them in the Certificate. The Certificate of Substantial Completion will alsoestablish the dates and responsibilities of the following transitional arrangements which will be required between the Owner and the Contractor:

The Contractor's time limit for completing the remainder of the work per the Punch List.

Establish the responsibilities of the Owner and Contractor for security, maintenance, utilities, damage to the work and insurance.

Establish date for the commencement of all warranties.

Upon successful execution of the Certificate for Substantial Completion the Owner may make payments which reflect adjustments in the retainage amounts asprovided in the Contract Documents. The reduction in retainage shall be made with the exception of amounts which have been determined to reflect the costsfor remaining work to be completed and/or work requiring correction. In these cases, the Administrator, upon consultation with the Owner and/or Architect, shallestablish the value of the remaining work and suggest that the Owner retain three (3) times the value of that work.

The minimum amount retained for each unacceptable item should be the estimated cost to have another Contractor brought in to complete or correct the item.This includes any costs for mobilization and/or equipment required to correct or complete any outstanding construction deficiencies.

PROJECT CLOSE-OUT

Following Substantial Completion, the Administrator shall receive from the Contractor the following items and materials which shall be collectively referred to asthe Close-Out Documents:

Application for Payment showing all work as completed and requesting retainage.

Punch List showing all items identified by the Contractor and Administrator, certified by Contractor as being completed.

Properly executed Consent of Surety for Final Payment.

Final Release of Liens for the total amount of Contract Sum.

Record Drawings and record specifications as per the Contract Documents.

Warranty and maintenance information as required by the Contract Documents.

Extra stock materials and special tools as provided in the Contract Documents.

Final Accounting of all Change Order for the project.

In addition to the items listed above, the Close-out Documents shall include proof that all equipment and maintenance demonstrations required by the ContractDocuments, have been successfully completed by the Contractor for the Owner's staff.

Equipment demonstrations shall be scheduled by the Contractor, with the Owner given adequate notice to ensure that proper personnel may attend.

The Administrator will review, and transmit to the Owner, the Close-out Documents package. The Administrator will advise the Owner and/or Architect of theClose-Out Documents received by the Contractor and transmitted to the Owner, and any outstanding items which may prevent the Owner and/or Architect fromrecommending that the project be closed out and Final Payment made to the Contractor. Should all prerequisites for project close-out be satisfied, the Ownerand/or Architect will then recommend to the Owner in writing that the Owner make Final Payment to the Contractor.

FINAL APPLICATION FOR PAYMENT

The Administrator will advise the Owner and/or Architect when all Close-Out Documents have been properly transmitted to the Owner, all required punch listwork is completed and all requirements of the contract have been satisfied per the Contract Documents. The Owner and/or Architect will, upon consultation withthe Administrator, recommend that the Owner make Final Payment to the Contractor.

The Final Payment Request from the Contractor will be for the remainder of retainage, should the retainage have been reduced, per the Contract Documents, atSubstantial Completion. The retainage represents a substantial portion of the Contractor's profit for a project, therefore the retainage is excellent insurance that



the Contractor completes the punch list work, properly executes all warranties and Close-Out Documents and assembles all required record drawings andspecifications per the Contract Documents.

Do not reduce the retainage amount, other than any reductions provided for related to the Substantial Completion, the retainage will ultimately become the finalmotivation for completing any outstanding work on the project or documentation.

WARRANTY INSPECTION

The final responsibility of the Administrator is to advise the Owner of the date for the One -year warranty inspection. The Administrator will advise the Owner inwriting of the anniversary date of the warranty and instruct the Owner in how to handle warranty work in the first year of the facilities occupation.

The Owner shall be advised that any warranty work or inspection required will be charged as an additional service on the part of the Administrator. The Ownershould be advised that he may elect to resolve warranty items directly with the Contractor and avoid additional service charges from the Administrator.

The Administrator should also take the opportunity, in the final letter to the Owner, to request a brief evaluation of the services performed for the Owner throughthe construction project. The information received from the Owner regarding the services performed, should be reviewed with the Owner and/or Architect andany improvements in the Administrator's services should be incorporated into the following projects.

EMAILGeneral Information: [email protected]:Customer Support:Webmaster: [email protected]

Send mail to [email protected] with questions or comments about this web site.Copyright © 1997 CompanyLongNameLast modified: May 24, 2006

Construction Administration

Documents

Transcript of Construction Administration