BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK...
Transcript of BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK...
![Page 1: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/1.jpg)
1 | P a g e
BANK OF INDIA
STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G-BLOCK, BANDRA KURLA COMPLEX, BANDRA (E), MUMBAI-
400051
Event No. BOI/BKC/ 8 / 19-20 / ET/ 10
TENDER DOCUMENT FOR
Interior and Allied Services work of 3rd Corporate Office Building at C-29, G-Block, Bandra-Kurla Complex,
Mumbai.
VOLUME-I CONTRACT CONDITIONS
CLIENT GENERAL MANAGER,
PREMISES DEPARTMENT 3rd FLOOR, STAR HOUSE 2, BKC
BANK OF INDIA Ph: 022-61317528
ARCHITECT & PROJECT MANAGEMENT CONSULTANTS
M/S ARK DESIGNS PVT LIMITED. ARCHITECTS, DESIGNERS AND PROJECT MANAGEMENT CONSULTANTS
101, Anish Tower CHS LTD., Senapati Bapat Marg, Matunga West, Mumbai
![Page 2: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/2.jpg)
2 | P a g e
BANK OF INDIA
STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT C-4, G-BLOCK, BANDRA KURLA COMPLEX BANDRA (E), MUMBAI-400051
TENDER DOCUMENT FOR
Interior Furnishing and allied services work of 3rd Corporate Office Building at C-29, G-Block, Bandra Kurla Complex, Mumbai.
Event No. BOI/BKC/ 8 / 19-20 / ET/ 10
LAST DATE OF SUBMISSION OF APPLICATION / BID: UPTO 3.00 PM. ON 10.02.2020
Name ofthefirm ………………………………………………….. Address ...………………………………………………..
..………………………………………………… PhoneNumbers– …………………………………………………… MobileNo. ……………………………………………………
FaxNo. …………………………………………………… E-mail: …………………………………………………….
PRICE OF THIS TENDER FORM: Rs 10,000/- (Nonrefundable) payable on line as per direction given in the NIT
Contact Persons: Bank Of India: P.K. SHARMA (Ph – 022-61317524); AMIT DWIVEDI (Ph – 022-61317528, +91-7715837903)
ARCHITECTS & PMC: ARK DESIGNS PVT LIMITED Asmita Sawant (Ph. - 022-24303535/ 022-24321484)
![Page 3: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/3.jpg)
3 | P a g e
Interior and Allied Services work of 3rd Corporate Office Building at C-29, G-Block, Bandra-Kurla Complex,
Mumbai. -----------------------------------------------------------------------------------
Key Information on the Tender Response Submission
Particulars Timeline
Event no. BOI/ BKC /8 / 19-20/ ET/ 10
RFP Issuance Date 17-01-2020
RFP Coordinator Name: Shri Amit Dwivedi
Chief Manager
Address: Premises Department, 3rd Floor, Bank of India Head Office, Star House 2 C-4, G-block, Bandra-Kurla Complex, Mumbai, 400 051 Tel No: 022- 61317528
Telephone +91 022- 61317528
E mail id [email protected]
Pre–bid Meeting (online) 10 am to 5:00 pm on January 27, 2020 Address: Premises Department, 3rd Floor, Bank of India Head Office, Star House 2 C-4, G-block, Bandra-Kurla Complex, Mumbai, 400 051 Tel No: 022- 61317528
Opening Date and Time for RFP submission Last date and time for receipt of RFP response
10.00 AM on 28.01.2020 03:00 PM on 10.02.2020
Time and Date of Opening of Technical Bids 3:30 PM on 10.02.2020
Time and Date for Technical Presentations Will be communicated subsequently by the Bank
Time and Date for Opening of Commercial Bids Will be communicated subsequently by the Bank
Address for Response Submission Premises Department, 3rd Floor, Bank of India Head Office, Star House 2 C-4, G-block, Bandra-Kurla Complex, Mumbai, 400 051 Tel No: 022- 61317528
Application Money INR 10,000/- (Rupees Ten Thousand Only)
Transaction fee of MSTC 0.05% of Rs.40Crores (Estimated value of the tender) subjected to maximum of Rs. 15,000/- Important instruction to the bidder: Bidders have to pay transaction fee using link “transaction fee payment” available in your login using NEFT/RTGS, through challan or using credit card/debit card/net banking etc.
CONFIDENTIALITY
This document is meant for the specific use by Organizations interested to participate in the current Tender process. This document in its entirety, is subject to Copyright Laws. Bank of India expects the Bidder or any person acting on behalf of the Bidder to strictly adhere to the instructions given in the document and maintain confidentiality of information. The Recipient
will be held responsible for any misuse of information contained in the document, and will be liable to be prosecuted by the Bank in the event that such a circumstance is brought to the notice of the Bank. By virtue of issuance of this RFP document, the Recipient is subject to the confidentiality clauses.
![Page 4: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/4.jpg)
4 | P a g e
INDEX
1. Notice inviting E-Tender
2. Annexure 1 – Important instructions for E-Tender
3. Annexure 2 – Covering letter format
4. Criteria for Pre-Qualification
5. Instructions to Applicants
6. Annexure 3 – Information of the company
7. Annexure 4 – Details of Litigation History
8. Annexure 5 – List of references
9. Annexure 6 – List of important Projects
10. Annexure 7 – Important works in Hand
11. Annexure 8 – Technical personal Data
12. Annexure 9 – Details of Machinery
13. Annexure 10 – Performance Certificate
14. Annexure 11 – Pre-Contract Integrity Pact
15. Clarifications
16. 1.0 Part I – Instruction to tender
17. 1.0 Part II – Commencement, Completion & Delays
18. 1.0 Part III – Payments & Certificate
19. 1.0 Part IV – Remedies & Powers
20. 1.0 Part V – General Obligation
21. 1.0 Part VI – Site Supervision
22. 1.0 Part VII– Labour & Insurance
23. 1.0 Part VIII – Safety Code
24. 1.0 Part IX – Special Conditions
25. 1.0 Part X – Maintenance of Records
26. Schedule A
27. Form of Agreement
28. List of Drawings 29. Safety Manual 30. IGBC guidelines, rules & regulations
![Page 5: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/5.jpg)
5 | P a g e
NOTICE INVITING E-TENDERS
Interior Furnishing and allied services work of 3rd Corporate
Office Building at C-29, G-Block, Bandra Kurla Complex, Mumbai
Bank of India invites e-tender offer from reputed Civil - Interior Contractors/ Companies/ Firms for the Interior Furnishing and allied Services work of 3rd Corporate Office Building at C-29, G-Block, Bandra Kurla Complex, Mumbai for Bank of India. The reputed contractors / companies/ firms registered in unlimited class with PWD, CPWD, CIDCO, State Government, Central Government departments, Public Sector Bank, Railways, etc. & who have successfully executed similar types of works and meeting all qualification criteria need only apply. Sr. No.
Project Description EMD Time Period
1. Interior Furnishing and allied services work of 3rd Corporate Office Building at C-29, G-Block, Bandra Kurla Complex, Mumbai
Rs.40,00,000.00 (Rs. Forty Lakh only)
8 Months
1) E-Tenders (Two Cover System) on item rate basis, are to be submitted online at www.mstcecommerce.com/eprochome/boi.To facilitate the prospective bidders, detailed process and instructions to participate in MSTC e-Tender portal are provided in Annexure 1 below. 2) The bid documents consist of two parts. I)- Part A i.e. Technical Bid consists of plans, Technical specifications, Terms & Conditions to be complied with, Forms of application, Prequalification Criteria etc. II)- Part B i.e. Price bid consists of Bill of Quantities. Detailed tender documents consisting of Technical Bid and Price Bid can be available on line at www.mstcecommerce.com/eprochome/boi and www.bankofindia.co.in 3) However, the bids can be submitted only after deposition of the following amounts by NEFT in favor of MSTC and Bank of India as under within the period of bid submission:
a) Rs. 40,00,000/- (Forty Lacs only) towards Earnest Money Deposit (EMD) and Rs. 10000/- (Ten Thousand only) towards cost of Tender in the name of Bank of India in the following account Account No.: 01220SUNCR822 Name of the Bank: Bank of India Branch: Bandra Kurla Complex Branch, Mumbai IFSC Code: BKID0000122, Title of the account: ESTATE DEPTT. COLLECTION ACCOUNT
b) Payment of MSTC Transaction Fee has to be paid through “Transaction Fee Payment” link only.
![Page 6: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/6.jpg)
6 | P a g e
4) The last date of submission of tenders is up to 3.00 P.M. on 10.02.2020. Technical Bid, if possible, will be opened at 3.30 P.M.on the same day i.e.on 10.02.2020.
5) All the applications will be scrutinized as per the prequalification criteria given in this document and terms and conditions of technical bid. Price Bid of only those applicants/contractors who fulfill the Prequalification criteria and the technical bid criteria, whose works are found satisfactory on inspection and against whom there is no adverse comments/reports from previous clients, will be opened. The time and date of opening of the price bid will be intimated subsequently. Our endeavors will be to open the Price Bids of valid tenders at the earliest. 6) A Pre-bid meeting of the above-mentioned work will be conducted on-line mode only. The bidders are requested to upload their queries on MSTC portal only which will be replied on the portals of MSTC & Bank of India subsequently. Accordingly, the MSTC Portals will be available for Pre-bid Meeting from till 5.00 PM 27.01.2020.
7) Bank of India reserves the right to accept or reject any or all the tenders, without assigning any reasons for doing so.
Yours faithfully, General Manager
![Page 7: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/7.jpg)
7 | P a g e
ANNEXURE-1
Important instructions for E-Tender
This is an E- Tender event of Bank of India. The E-Tender service provider is MSTC Ltd., 225C, A.J.C. Bose Road, Kolkata-700 020.
Bidders are requested to read the process of E-Tender (A to E), terms & conditions of this tender before submitting their online tenders. Bidders who do not comply with the conditions with documentary proof (wherever required) will not qualify in the Tender process for opening of Pricebid.
Process of E-Tender: A) Registration: The process involves Bidder’s registration with MSTC E-Procurement portal which is free of cost. Only after registration, the Bidder(s) can submit his/their bids electronically. Electronic Bidding for submission of Technical Bid as well as Price Bid will be done over the internet. The Bidder should possess Class III signing type digital certificate. Bidders have to make their own arrangement for bidding from a P.C. connected with Internet. MSTC is not responsible formakingsucharrangement. (Bids will not be recorded without Digital Signature). SPECIAL NOTE: THE TECHNICAL BID AND PRICE BID HAVE TO BE SUBMITTED ON-LINE ATwww.mstcecommerce.com/eprochome/boi
Bidders are required to register themselves online with
www.mstcecommerce.com→E - Procurement →PSU/Govt depts→Register as Bidder under BANK OF INDIA -- Filling up details and creating own user id and password→Submit. Bidders will receive a system generated mail confirming their registration in their email which has been provided during filling the registration form. In case of any clarification, please contact BANK OF INDIA /MSTC, (before the scheduled time of the e- tender).
Contact person (BANK OF INDIA)
Name: AMIT DWIVEDI, Chief Manager- Premises Department M-+91-7715837903, Tel. No.- 022-61317528
Email: [email protected]
![Page 8: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/8.jpg)
8 | P a g e
Contact person (MSTC Ltd):
Centralized Helpdesk No – 033-22901004
1. Ms. Archana Juneja 2. Ms. Rupali Pandey
Designation: Assistant Manager Designation:Assistant Manager
Tel. No.: 022 22872011/022 22870471 Tel No: 022 22883501/22886266
Mob: 9990673698 Mob: 9458704037
E-mail: [email protected] E-mail: [email protected]
Mr.AbhishekKanaujia
Designation: Executive
Mobile No.: 9930119718
E-mail: [email protected]
B) SystemRequirement:
I. Windows 98 /XP-SP3 & above/Windows 7 OperatingSystem II. IE-7 and above Internet browser. III. Signing type digital signature IV. JRE7 update79 software to be downloaded and installed in the system. V. Security level should be medium
To enable ALL active X controls and disable ‘use pop up blocker’ under Tools→Internet Options→ custom level (Please run IE settings from the page www.mstcecommerce.comonce). Prospective vendors are suggested to refer to “Vendor Guide” at www.mstcecommerce.com/eprochome.
• Part I Technical bid will be opened electronically on specified date and time as
given in the NIT. Bidder(s) can witness electronic opening of bid.
• Part II Price bid will be opened electronically of only those bidder(s) whose
Part-I Technical Bid is found to be acceptable by BANK OF INDIA. Such bidder(s)
will be intimated date of opening of Part-II Price bid, through valid email confirmed
by them.
• All entries in the tender should be entered in online Technical & Price Formats
without any ambiguity.
C) Special Note towards deposition of EMD, Cost of Tender and Transaction fee:
a) Rs.40, 00,000/- (Forty Lakh only) towards Earnest Money Deposit (EMD).
b) 10,000/- (Ten Thousand only) towards cost of Tender in the name of Bank of India in the following account
Account No. : 01220SUNCR822
Name of the Bank : Bank of India
Branch : Bandra Kurla Complex Branch, Mumbai
IFSC Code : BKID0000122
Title of the Account : ESTATE DEPT COLLECTION ACCOUNT
![Page 9: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/9.jpg)
9 | P a g e
NOTE: The bidders should submit the EMD. Cost of Tender and transaction fee
ON OR BEFORE THE PRESCRIBED DATE as they will be authorized for bid
submission only after receipt of the same by Bank of India and MSTC.
After depositing the amounts mentioned above, prospective vendors are
required to send an email in this regard to below email ids stating the transaction
details viz Amount, Date of Transfer, UTR No., Bank etc. Only upon receipt of
intimation email, Vendor’s login will be activated for bidding in this event.
For Bank of India:
E-mail: 1. [email protected]
For MSTC:
Email : 1. [email protected],
Bidders may please note that the Cost of Tender, EMD and transaction fee
should be deposited by debiting the A/C of the bidder only. These amounts
deposited from or by debiting any other party’s a/c will not be accepted. Cost of
Tender and Transaction fee is non-refundable. The EMD of the successful
bidder will be adjusted towards Initial Security Deposit. The EMD of the
unsuccessful bidders will be returned as soon as possible but without any
interest.
In case of failure to submit the payment towards EMD, Cost of Tender and
Transaction fee for any reason, the Bidder, will not have the access to onlineE-
Tender.
D) All notices /corrigendum /addendum etc. will be published in Bank’s/ MSTC website only. Any correspondence to the bidder(s) shall be sent by email only during the process till finalization of tender by BANK OF INDIA. Hence the bidders are required to ensure that their corporate email id provided is valid and updated at the stage of registration of Bidder with MSTC (i.e. Service Provider). Bidders are also requested to ensure validity of their DSC (Digital Signature Certificate).
E) E-Tender cannot be accessed after the due date and time mentioned in NIT. Bidding in E-Tender*
The process involves Electronic Bidding for submission of Technical and Price Bid.
The bidder(s) who have submitted the above amounts / fees can only
submit their Technical Bid and Price Bid through internet in MSTC websitewww.mstcecommerce.com→ e- Procurement→PSU /Govt depts→ Login under MSTC→ My menu→ Auction Floor Manager→ live event→Selection of the live event
The bidder should allow to run an application namely “enApple” by
![Page 10: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/10.jpg)
10 | P a g e
accepting the risk and clicking on run. This exercise has to be done twice immediately after opening of Bid floor. Then they have to fill up Common terms / Price specification and save the same. After clicking on the Technical bid, if this application does not run then the bidder will not be able to save/submit his Technical bid.
After filling the Technical Bid, bidder should click ‘save’ for recording
their Technical bid. Once the same is done, the Price Bid link becomes active and the same has to filled up and then bidder should click on “save” to record their Price bid. Then once both the Technical bid & Price bid have been saved, the bidder can click on the “Final submission” button to register their bid
Bidders are instructed to use Upload Documents link in My Menu to
upload documents in document library. Multiple documents can be uploaded. Maximum size of single document for upload is 5MB.
Once documents are uploaded in the library, Bidders can attach
documents through Attach Document link against the particular tender. For further assistance please follow instructions of Bidder guide.
In all cases, bidder should use their own ID and Password along with
Digital Signature at the time of submission of their bid. During the entire E-Tender process, the bidders will remain completely
anonymous to one another and also to everybody else.
The E-Tender floor shall remain open from the pre-announced date & time and for as much duration as mentioned above.
All electronic bids submitted during the E-Tender process shall be
legally binding on the bidder. Any bid will be considered as the valid bid offered by that bidder and acceptance of the same by the Buyer will form a binding contract between Buyer and the Bidder for executionof supply.
It is mandatory that all the bids are submitted with digital signature
certificate otherwise the same will not be accepted by thesystem. Employer reserves the right to cancel or reject or accept or withdraw or
extend the tender in full or part as the case may be without assigning any reasonthereof.
No deviation of the terms and conditions of the tender document is
acceptable i.e. No deviation to the Prequalifying as well as Price & General terms & conditions are allowed. Any order resulting from this open E-Tender shall be governed by the terms and conditions mentioned therein.
Submission of bid in the E-Tender floor by any bidder confirms his
![Page 11: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/11.jpg)
11 | P a g e
acceptance of terms & conditions for the tender. Unit of Measure (UOM) is indicated in the E-Tender Floor. Rate to be
quoted should be in Indian Rupee as per UOM indicated in the E-Tender floor.
The Employer has the right to cancel this E-Tender or extend the due
date of receipt of bid(s) without assigning any reason thereof. The online tender should be submitted strictly as per the terms and
conditions and procedures laid down in the website www.mstcecommerce.com/eprochome/boi of MSTC Ltd.
The bidders must upload all the documents required as per terms of
NIT. Any other document uploaded which is not required as per the terms of the NIT shall not be considered. The bid will be evaluated based on the filled-in technical & Price formats.
The documents uploaded by bidder(s) will be scrutinized. In case any of the information furnished by the bidder is found to be false during scrutiny, punitive action including blacklisting of the firm can also be taken against defaulting bidders.
Bidders are requested to read the Bidder guide and see the video in the
page www.mstcecommerce.com/eprochometo familiarize them with the system before bidding.
![Page 12: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/12.jpg)
12 | P a g e
ANNEXURE- 2
COVERING LETTER FORMAT
To The General Manager, Bank of India, Premises Department Head Office.
Dear Sir,
I / We have read and understood the press notice and the notification in Bank’s web-site for Pre-qualification and instructions to the Applicants. I/We do hereby declare that the information furnished by me / us are correct to the best of my/our knowledge and belief.
Yours faithfully,
Authorized Signatory:
Name:
Designation:
Address:
Seal:
![Page 13: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/13.jpg)
13 | P a g e
SCOPE OF WORK
Interior and Allied Services work of 3rd Corporate Office Building at C-29, G-Block, Bandra-Kurla Complex, Mumbai
The Scope of work includes the following:
1. Civil works as required
2. Interior Furnishing Works
3. Landscaping Work
4. Electrical Works i.e.
• Panels and distribution boards
• LT cables, cable trays, floor trunking
• Earthing
• Point wiring
• Lighting fixtures
• Facade & landscape lighting
• UPS system
• ELV system
• Data networking
• Public addressal system
• Access control system
• CCTV surveillance system
• Perimeter security system
• BMS system
• AV system
• Board room AV system
• Conference room AV system (9 nos. conference room)
A very high standard of workmanship and speed of construction is expected for this project.
![Page 14: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/14.jpg)
14 | P a g e
ELIGIBILITY CRITERIA FOR PRE-QULAIFICATION
The Companies / Firms that fulfill the criteria as given below shall be eligible:
1. a. The Company should be either a Partnership or a Public Limited
Company or a Private Limited Company registered under the Indian
Companies Act 1956 or a reputed Proprietor firm having rich experience.
b. The Company / Firm should have registration with PWD / CPWD /
CIDCO / State Government/ Central Government department/ Public
Sectors/ Banks and Railways.
2. The Company / Firm should have average financial turnover of Rs.40 Crore
on similar works during the last three years ending 31st March 2019. The
Balance sheet certified by CA to be produced.
3. Reports on financial standing of the Company / Firm, annual turnover of the
Company/ Firm, profit and loss statement and auditors report for last three
years. (Audited Balance sheets and copy of IT returns to be acknowledged)
4. The company / firm should have proper office structure in Mumbai / Navi Mumbai /Thane.
5. The Contracting Company/ Firm should have satisfactorily completed during
last 7 years ending 31st March 2019 the following:
I. Atleast 3 similar type of works of individual contract value not less than
Rs.16 crore each out of which at least one similar work should have
been in Mumbai/ Navi Mumbai/ Thane.
OR
II. Atleast 2 similar type of works of individual contract value not less than
Rs.20 crore each out of which at least one similar work should have
been in Mumbai/ Navi Mumbai/ Thane.
OR
III. Atleast 1 similar type of works of individual contract value not less than
Rs.32 crore. If this single work is carried out outside Mumbai /Navi
Mumbai / Thane then at least one similar work costing 16 Crores should
have been in Mumbai/ Navi Mumbai/ Thane.
The definition of similar work shall mean the works of Civil works, Interior
Furnishing (i.e. Partitions, Flooring, False Celling etc.), Landscaping, Electrical
works etc. in a Corporate Office Building or Institutional Building of any PSU/
Bank/ Government/ Private Sector.
6. The Firm should also have completed at least one project of similar work of Govt. /Public Sector Undertaking/ Nationalized Banks costing minimum Rs. 16 Crore anywhere in India.
Note: The contractors should provide proper documentary proof in support of
satisfactory completion of similar works in terms of Letter of award, photographic
![Page 15: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/15.jpg)
15 | P a g e
evidence, Completion certificate from the clients indicating the date of
commencement, date of completion & estimated & actual cost of execution of
the work failing which it may be treated that they have not completed such
works. The experience certificate should be issued by the employer and should
be supported by TDS certificate by the employer. Certificate and testimonials of
the project should clearly identify completion of the above activities satisfactorily
for the projects referred to meet pre-qualification criteria.
7. Bank Solvency Certificate of Rs.10 crore and authority to seek references from Company’s / Firm’s bankers and evidence of adequacy of working capital for this contract.
8. Should possess major construction equipment like H-frame, scaffolding and exterior cradles and detailed list of machinery and equipments to be submitted.
9. Should possess and furnish details of technical personnel with sufficient skill set in all the above work types and details of personnel with qualification and experience to be submitted.
10. Should possess in name of company or nominated sub-contractor valid license for executing water supply, sanitary, drainage works, Firefighting, fire detection and electrification, HVAC, IBMS works and AV systems.
11. Joint Venture is not allowed.
12. Confidential reports from previous employers will be sought by Client.
13. A committee comprising Bank’s representatives, ARCHITECT & PMC representatives would inspect the work executed by the firms. The visit is to ascertain quality, workmanship & ability of the contracting firm.
14. The firm / company should have registration with GST, PF, ESIC and Prof. Tax and submit the proof of the same.
15. The firm should produce acknowledged copies of IT returns for the last three years.
![Page 16: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/16.jpg)
16 | P a g e
INSTRUCTIONS TO APPLICANTS:
1. While deciding upon the pre-qualification of contractor emphasis will be given on the ability and competence of applicants to do good quality work within the specified time schedule.
2. Applications containing false and /or inadequate information will be summarily rejected.
3. Clarifications if any required, may be obtained from Bank of India, Head Office, Premises Department, C 4, G Block, Bandra Kurla Complex, Bandra (East), Mumbai. Name: AMIT DWIVEDI Chief Manager- Premises Department M:+91-7715837903, Tel. No.- 022-61317528 E-mail:[email protected] 4. Mere fulfillment of minimum eligibility criteria will not entitle Pre-qualification as pre- qualification will be done after taking into account various parameters including receipt of satisfactory reports from Clients.
5. Decision of the Bank in regards to pre-qualification of Contractor shall be final. The Bank reserves the right to reject any or all applications without assigning any reason there to.
6. Independent External Monitors (IEM) Bank of India has empanelled Independent External Monitors (IEMs) for implementation of Integrity Pact (IP) in respect of procurements as per directives received from the Central Vigilance Commission (CVC).
The details are as under: -
1 2
Dr. Joginder Paul Sharma, IAS (Retd)Ex- Principal Secretary. Govt. of UPD-266,
Sector- 47, Noida,UPMobile:9650999444
E-mail: [email protected]
Shri Ashwani Kumar
(Ex-CMD,Dena Bank )
Ruby CHSL, Flat No. 101, 1st
floor, Plot No.
81, 29thRoad, Near Duruoella Convent High
School, Bandra West. Mobile:9920262626
Email- [email protected]
Integrity Pact
Only those Vendors/ bidders/Sellers who commit themselves to Integrity Pact (IP) with the Bank, would be considered competent to participate in the bidding process. In other words, entering into this pact would be the preliminary qualification. In case of bids not accompanied with signed IP by the bidders along with the technical bid, the offers shall be summarily rejected. Performa of Integrity pact is attached in Annexure 11.
![Page 17: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/17.jpg)
17 | P a g e
BASIC INFORMATION
NOTES:
a) Information has to be filled up specifically in this form only. Do not write remark
“As indicated in Brochure or “As enclosed” unless asked for by Bank of India.
b) Information shall be limited to the Applicant. If any relevant data concerning the Group of Companies to which the Applicant belongs is desired to be given, the same shall be given separately in a supplementary sheet.
c) Documentary evidence etc. have to be enclosed.
![Page 18: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/18.jpg)
18 | P a g e
ANNEXURE- 3 INFORMATION OF THE COMPANY
1. Name of the Applicant and address of the Registered
office.
Phone No. :
E-mail address : Name of Authorized representative: Mobile No. : Website, if any :
2.
(a)
Year of establishment
(Enclose documentary evidence)
(b)
No. of years of experience in the relevant field (Minimum experience required is 7 years as on 31.03.2019 in relevant field)
3 Type of the organization (Whether sole proprietorship, Partnership, Private Ltd. or Co-operative body etc.)
4. Name of the Proprietor/Partners/Directors of Applicant with address and phone Numbers.
(a)
(b)
(c)
5 Details of registration – Whether Partnership firm, Company, etc. Name of Registering Authority, Date and Registration number.
6. Whether the firm has worked for the PWD/ CPWD / CIDCO / State Government/ Central Government department/ Public Sectors/ Banks and Railways.
7. No. of years of experience in the relevant field. (Enclose CA’s certificate)
8. Address of office through which the proposed work of the Bank will be handled and the name & designation of
the officer in charge.
9. Adequate and satisfactory evidence to indicate financial capacity of the Applicant to undertake the said works with names of Bankers and their full addresses. (Solvency certificate from a bank & Income tax
clearance certificate has to be attached).
10. Yearly turnover of the Organization during last Three
years. (year wise) – As certified by the Chartered
Accountant (C.A’s certificate has to be enclosed).
Rs …………For April2018 -2019 Rs …………For April2017 -2018 Rs …………For April2016 -2017
11. Number of supplementary sheets attached.
12. Ability to provide Bank Guarantee or other equivalent
form of security from a Nationalized Bank / scheduled
Price Bank (Specify the amount maximum).
Rs.
13. Enclose Performance Certificates from previous clients
during last 7 years for the work carried out and
matching each of the similar work criteria indicated.
![Page 19: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/19.jpg)
19 | P a g e
14. Whether any Civil Suit/litigation /Arbitration arisen with Govt./Semi Govt./PSU/Banks etc. during the last 7 years/ being executed now. If yes, please furnish the details in the Performa given below.
![Page 20: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/20.jpg)
20 | P a g e
ANNEXURE- 4-
Details of Litigation History
Sr.
No. Name of the project and employer
Nature of work
Work Order No. & date
Present stage of work
Value of contract (Rs.)
Brief details of the Dispute
![Page 21: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/21.jpg)
21 | P a g e
ANNEXURE- 5 LIST OF REFERENCES
Give reference of two Respectable Consulting Engineers,
PMC/ARCHITECTS, Officers with Designations from Govt., /Semi Govt.,
/Public Sector Corporation Office with address and phone numbers, who
may be directly contacted by the Bank, so as to enquire about your ability,
competence, capability of your organization in confidence.
i)
ii)
Signature of Applicant
![Page 22: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/22.jpg)
22 | P a g e
ANNEXURE- 6 – LIST OF IMPORTANT PROJECTS EXCECUTED
Work capability and previous experience.
a) List of important Projects executed by the organization as per the criteria of
similar works specified previously, during last 7 years costing Rs.16.0 Crore and
above.
(Supporting documentary proofs such as copies of work order, satisfactory
completion certificate of the work from clients etc. with proper indexing to be
enclosed failing which the application will be liable for rejection)
Sr. No
Name of the Project mentioning all features, scope of services and location
Name & full postal address of the owner & Consultant. Also indicate whether Govt. or Private body with full postal address & phone no.
Total final value of work (Rs.)
Completion period with dates
Whether work was left incomplete or contract was terminated from either side. Give full details.
Any other relevant information
Stipulated Actual
1. 2. 3. 4. 5. 6. 7. 8.
Signature of Applicant
NOTES:
1. Information has to be filled up specifically in this format. Please do not write remark “As indicated in Brochure / as enclosed” unless unavoidable.
2. Information shall be limited to the Applicant. If any relevant data concerning the
Group of Companies to which the Applicant belongs is desired to be given, the
same shall be given separately in a supplementary sheet.
![Page 23: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/23.jpg)
23 | P a g e
ANNEXURE 7: Important works in hand
a) A)- List of important works IN HAND costing (Rs. 16.0 Crore and above)
Sr. No.
Name of the Project and location
Name & full postal address of the owner & Consultant. Also indicate whether Govt. or Private body with full postal address.
Contract Amount (Rs.) & date of award of work
Progress of work along with Completion Period inmonths
Any other relevant information
Stipulated Expected date of completion
1. 2. 3. 4. 5. 6. 8.
Signature of Applicant
NOTES:
1. Information has to be filled up specifically in this format. Please do not write
remark “As indicated in Brochure / as enclosed’ unless unavoidable
2. Information shall be limited to the Applicant. If any relevant data concerning the Group of Companies to which the Applicant belongs is desired to be given, the same shall be given separately in a supplementary sheet.
![Page 24: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/24.jpg)
24 | P a g e
ANNEXURE 8:
Technical personnel data
A)- List of your technical personnel, giving details about their technical qualifications & experience including that in your establishment.
Signature of Applicant
NOTES:
1 Information has to be filled up specifically in this format. Please do not write
remark “As indicated in Brochure / as enclosed’ unless unavoidable
2 Information shall be limited to the Applicant. If any relevant data concerning the Group of Companies to which the Applicant belongs is desired to be given, the
same shall be given separately in a supplementary sheet.
Sr. No.
Name Age Qualifications Experience Nature
of Works
handled
Name of
the projects
Handled
costing Rs 16.0
Date from
which employed in
your
organization
Indicate
special experience
such as
Advance
Management
Techniques, ISO Certificate
etc.
Crore & above
1. 2. 3. 4. 5. 6. 7. 8. 9.
![Page 25: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/25.jpg)
25 | P a g e
ANNEXURE 9
DETAILS OF MACHINERY
Sr.
No.
Description of Machinery
/ Equipment
Nos Age in Years
![Page 26: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/26.jpg)
26 | P a g e
ANNEXURE 10
PERFORMANCE CERTIFICATE
FORMAT OF PERFORMANCE CERTIFICATE TO BE GIVEN BY THE
PREVIOUS CLIENTS OF THE APPLICANT CONTRACTOR
i. Name ofwork executed: with scope of work in brief
ii. Client’s name and address:
iii. ARCHITECTs for the project:
iv. PMC of the Project, if any:
v. a) Tendered cost;
b) Value of work executed:
c) Time allowed for completion
d) Actual time taken forcompletion
e) If delayed, reasons for the sameand whether extension granted.
f) Whether liquidated damages levied on thecontractor
vi General attitude and approach of the contractor inthework
vii. Assessment of work:
Excellent Good Satisfactory Poor
Workmanship
Competence
Integrity and
reliability
Attitude and
approach
Quality of work
Viii Any Litigation involving Arbitration/ Court of Law with details:
ix. Any other information about the overall performance of the contractor the authority would like to mention.
Signature: Place: Name and Designation: Date: Address:
![Page 27: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/27.jpg)
27 | P a g e
ANNEXURE 11
PRE-CONTRACT INTEGRITY PACT
PRE-CONTRACT INTEGRITY PACT BETWEEN BANK OF INDIA
AND
--------------------------------------------
General
This pre-bid pre-contract Agreement (hereinafter called the Integrity Pact) is made on_____ day
of the month of 2019, between, on one hand, the Bank of India acting through Shri ___,
Designation of the Officer (here in after called the “BUYER”, which expression shall mean and
include, unless the context otherwise requires, his successors in officer and assigns) of the First
Part and M/s.________ represented by Shri __________Chief Executive Officer
(hereinafter called the “BIDDER/Seller” which expression shall mean and include, unless the
context otherwise requires, his successors and permitted assigns) of the Second Part.
WHEREAS the BUYER proposes to procure (Name of the Stores/Equipment/Item) award the contract and the BIDDER/Seller is willing to offer/has offered the stores and
WHEREAS the BIDDER is a private company / public company / Government undertaking /
partnership / registered export agency, constituted in accordance with the relevant law in the
matter and the BUYER is a Public Sector Undertaking Bank of India.
NOW, THEREFORE, To avoid all forms of corruption by following a system that is fair, transparent and free from any influence/prejudice dealings prior to during the subsequent to the currency of the contract to be entered into with a view to: -
Enabling the BUYER to obtain the desired said stores / equipment / work at a competitive price in conformity with the defined specifications by avoiding the high cost and the distortionary impact of corruption on public procurement, and Enabling BIDDERs to abstain from bribing or indulging in any corrupt practice in order to secure the contract by providing assurance to them that their competitors will also abstain from bribing and other corrupt practices and the BUYER will commit to prevent corruption, in any form, by its officials by following transparent procedures.
The parties hereby agree to enter into this Integrity Pact and agree as follows.
Commitments of the BUYER
The BUYER undertakes that no official of the BUYER, connected directly or indirectly with the contract, will demand, take a promise for or accept, directly or through intermediaries, any bribe, consideration, gift, reward, favour or any material or immaterial benefit or any other advantage from the BIDDER, either for themselves or for any person, organization or third party related to the contract in exchange for an advantage in the bidding process, bid evaluation, contracting or implementation process related to the contract.
1. The BUYER will, during the pre-contract stage, treat all BIDDERS alike, and will
![Page 28: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/28.jpg)
28 | P a g e
provide to all BIDDERS the same information and will not provide any such information to any
particular BIDDER which could afford an advantage to that particular BIDDER in comparison to
other BIDDERS. All the officials of the BUYER will report to the appropriate Government office any
attempted or completed breaches of the above commitments as well as any substantial suspicion
of such a breach.
2 In case any such preceding misconduct on the part of such officials(s) is reported
by the BIDDER to the BUYER with full and verifiable facts and the same is prima facie found to be
correct by the BUYER, necessary disciplinary proceedings, or any other action as deemed fit,
including criminal proceedings may be initiated by the BUYER and such a person shall be
debarred from further dealings related to the contract process. In such a case while an enquiry is
being conducted by the BUYER the proceedings under the contract would not be stalled.
Commitments of BIDDERS
2. The BIDDER commits itself to take all measures necessary to prevent corrupt practices, unfair
means and illegal activities during any stage of its bid or during any pre-contract or post- contract
stage in order to secure the contract or in furtherance to secure it and in particular commit itself to
the following: -
The BIDDER will not offer, directly or through intermediaries, any bribe, gift, consideration, reward,
favour, any material or immaterial benefit or other advantage, commission, fees, brokerage or
inducement to any official of the BUYER, connected directly or indirectly with the bidding process,
or to any person, organisation or third party related to the contract in exchange for any advantage
in the bidding, evaluation, contracting and implementation of the contract.
The BIDDER further undertakes that it has not given, offered or promised to give, directly or
indirectly any bribe, gift, consideration, reward favour, any material or immaterial benefit or other
advantage, commission, fees, brokerage or inducement to any official of the BUYER or otherwise
in procuring the Contract or forbearing to do or having done any act in relation to the obtaining or
execution of the contract or any other contract with the Government for showing or forbearing to
show favour or disfavor to any person in relation to the contract or any other contract with the
Government.
BIDDERS shall disclose the name and address of agents and representatives and Indian
BIDDERS shall disclose their foreign principals or associates.
BIDDERS shall disclose the payments to be made by them to agents/brokers or any other
intermediary, in connection with this bid/contract.
The BIDDER further confirms and declares to the BUYER that the BIDDER is the original
manufactures / integrator / authorized government sponsored export entity of the stores /
supplier and has not engaged any individual or firm or company whether Indian or foreign to
intercede, facilitate or in any way to recommend to the BUYER or any of its functionaries,
whether officially or unofficially to the award of the contract to the BIDDER nor has any
amount been paid promised or intended to be paid to any such individual, firm or company in
respect of any such intercession, facilitation or recommendation.
The BIDDER, either while presenting the bid or during pre-contract negotiations or before
signingthecontract, shall disclose any payments he has made, is committed to or intends to
make to officials of the BUYER or their family members agents, brokers or any other
intermediaries in connection with the contract and the details of services agreed upon for such
payments.
The BIDDER will not collude with other parties interested in the contract to impair the
transparency, fairness and progress of the bidding process, bid evaluation, contracting and
implementation of the contract.
The BIDDER will not accept any advantage in exchange for any corrupt practice, unfair means
and illegal activities.
The BIDDER shall not use improperly, for purposes of competition or personal gain, or pass
![Page 29: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/29.jpg)
29 | P a g e
on to others, any information provided by the BUYER as part of the business relationship,
regarding plans, technical proposals and business details including information contained in
any electronic data carrier. The BIDDER also undertakes to exercise due and adequate care
lest any such information is divulged.
The BIDDER commits to retrain from giving any complaint directly or through any other
manner without supporting it with full and verifiable facts.
The BIDDER shall not instigate or cause to instigate any third person to commit any of the
actions mentioned above.
If the BIDDER or any employee of the BIDDER or any person acting on behalf of the BIDDER,
either directly or indirectly, is a relative of any of the officers of the BUYER or alternatively, if
any relative of an officer of the BUYER has financial interest / stake in the BIDDERs firm, the
same shall be disclosed by the BIDDER at the time offilling of tender.
The term relative for this purpose would be as defined in Section 6 of the Companies Act 1956. The BIDDER shall not lend to or borrow any money from or enter into any monetary dealings or transactions, directly or indirectly, with any employee of the BUYER.
Previous Transgression
The BIDDER declares that no previous transgression occurred in the last three years immediately
before signing of this Integrity Pact, with any other company in any country in respect of any
corrupt practices envisaged hereunder or with any Public Sector Enterprise in India or any
Government Department in India that could justify BIDDER’s exclusion from the tenderprocess.
The BIDDER agrees that if it makes incorrect statement on this subject, BIDDER can be
disqualified from the tender process or the contract, if already awarded can be terminated for such
reason.
5. Earnest Money (Security Deposit)
While submitting commercial bid, the BIDDER shall deposit an amount Rs. 40 lakh as specified in
the Tender as Earnest Money/Security Deposit, with the BUYER as advised earlier.
The Earnest Money / Security Deposit shall be valid upto the complete conclusion of the
contractual obligations to the complete satisfaction of both the BIDDER and the BUYER, including
warranty period / Defect liability period.
In case of the successful BIDDER a clause would also be incorporated in the Article pertaining to
Performance Bond in the Purchase Contract that the provisions of Sanctions for Violation shall be
applicable for forfeiture of Performance Bond in case of a decision by the BUYER to forfeit the
same without assigning any reason for imposing sanction for violation of this Pact.
No Interest shall be payable by the BUYER to the BIDDER on Earnest Money / Security Deposit
for the period of its currency.
6. Sanctions forViolations
Any breach of the aforesaid provisions by the BIDDER or any one employed by it or acting on its
behalf (Whether with or without the knowledge of the BIDDER) shall entitle the BUYER to take all
or any one of the following actions, whenever required:-
(i) To immediately call off the pre-contract negotiations without assigning any reason or giving
any compensation to the BIDDER. However, the proceedings with the other BIDDER(s) would
continue.
(ii) The Earnest Money Deposit (in pre-contract stage) and / or Security Deposit / Performance
![Page 30: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/30.jpg)
30 | P a g e
Bond (after the contract is signed) shall stand forfeited either fully or partially as decided by the
BUYER and the BUYER shall not be required to assign any reasontherefore.
(iii) To immediately cancel the contract if already signed, without giving any compensation to
the BIDDER.
(iv) To recover all sums already paid by the BUYER and in case of an Indian BIDDER with
interest thereon at 2% higher than the prevailing Prime Lending Rate of State Bank of India, while
in case of a BIDDER from a country other than India with interest thereon at 2% higher than the
LIBOR. If any outstanding payment is due to the BIDDER from the BUYER in connection with any
other contract for any other stores, such outstanding payment could also be utilized to recover the
aforesaid sum andinterest.
(v) To encash the advance bank guarantee and performance bond / warranty bond, if furnished
by the BIDDER, in order to recover the payments already made by the BUYER, along withinterest.
(vi) To cancel all or any other Contracts with the BIDDER. The BIDDER shall be liable to pay
compensation for any loss or damage to the BUYER resulting from such cancellation / rescission
and the BUYER shall be entitled to deduct the amount so payable from the money(s) due to the
BIDDER.
(vii) To debar the BIDDER from participating in future bidding processes of the Government of
India for a minimum period of five years, which may be further extended at the discretion of the
BUYER.
(viii) To recover all sums paid in violation of this Pact by BIDDER(s) to any middlemen or agent
or broker with a view to securing thecontract.
(ix) In cases where irrevocable Letters of Credit have been received in respect of any contract
signed by the BUYER with the BIDDER, the same shall not beopened.
(x) Forfeiture of Performance Bond in case of a decision by the BUYER to forfeit the same
without assigning any reason for imposing sanction for violation of thisPact.
The BUYER will be entitled to take all or any of the actions mentioned at para 6.1(i) to (x) of this
Pact also on the commission by the BIDDER or any one employed by it or acting on its behalf
(Whether with or without the knowledge of the BIDDER), of an offence as defined in Chapter IX of
the Indian Penal code, 1860 or Prevention of Corruption Act, 1988 or any other statute enacted for
prevention of corruption.
The decision of the BUYER to the effect that a breach of the provisions of this Pact has been
committed by the BIDDER shall be final and conclusive on the BIDDER. However, the BIDDER
can approach the Independent Monitor(s) appointed for the purposes of this Pact.
7. Fail Clause
The BIDDER undertakes that it has not supplied / is not supplying similar product / systems or
subsystems at a price lower than that offered in the present bid in respect of any other Ministry /
Department of the Government of India or PSU and if it is found at any stage that similar product /
systems or sub systems was supplied by the BIDDER to any other Ministry / Department of the
Government of India or a PSU at a lower price, then that very price, with due allowance for elapsed
time, will be applicable to the present case and the difference in the cost would be refunded by the
BIDDER to the BUYER, if the contract has already been concluded.
8. IndependentMonitors
There shall be Independent Monitors (hereinafter referred to as Monitors) appointed by the BUYER
for this Pact in consultation and with approval of the Central Vigilance Commission.
The task of the Monitors shall be to review independently and objectively whether and to what
![Page 31: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/31.jpg)
31 | P a g e
extent the parties comply with the obligations under this Pact.
The Monitors shall not be subject to instructions by the representatives of the parties and perform
their functions neutrally and independently.
Both the parties accept that the Monitors have the right to access all the documents relating to the
project / procurement, including minutes of meetings.
As soon as the Monitor notices, or has reason to believe, a violation of this Pact, he will so inform
the Authority designated by the BUYER.
The BIDDER(s) accepts that the Monitor has the right to access without restriction to all Project
documentation of the BUYER including that provided by the BIDDER. The BIDDER will also grant
the Monitor, upon his request and demonstration of a valid interest, unrestricted and unconditional
access to his project documentation. The same is applicable to Subcontractors. The Monitor shall
be under contractual obligation to treat the information and documents of the BIDDER /
Subcontractor(s) with confidentiality.
The BUYER will provide to the Monitor sufficient information about all meetings among the parties
related to the Project provided such meetings could have an impact on the contractual relations
between the parties. The parties will offer to the Monitor the option to participate in such meetings.
The Monitor will submit a written report to the designated Authority of BUYER/Secretary in the
Department/ within 8 to 10 weeks from the date of reference or intimation to him by the BUYER
/ BIDDER and, should the occasion arise, submit proposals for correcting problematic situations. 9. Facilitation of Investigation
In case of any allegation of violation of any provisions of this Pact or payment of commission, the
BUYER or its agencies shall be entitled to examine all the documents including the Books of
Accounts of the BIDDER and the BIDDER shall provide necessary information and documents in
English and shall extend all possible help for the purpose of such examination.
10. Law and Place ofJurisdiction
This Pact is subject to Indian Law. The place of performance and jurisdiction is the seat of the BUYER.
11. Other LegalActions
The actions stipulated in this Integrity Pact are without prejudice to any other legal action that may
follow in accordance with the provisions of the extant law in force relating to any civil or criminal
proceedings.
12. Validity
The validity of this Integrity Pact shall be from date of its signing and extend upto 5 years or the
complete execution of the contract to the satisfaction of both the BUYER and the BIDDER / Seller,
including warranty period, whichever is later. In case BIDDER is unsuccessful, this Integrity Pact
shall expire after six months from the date of the signing of the contract.
Should one or several provisions of this Pact turn out to be invalid, the remainder of this Pact shall
remain valid. In this case, the parties will strive to come to an agreement to their original intentions.
13. The parties hereby sign this IntegrityPactat on
![Page 32: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/32.jpg)
32 | P a g e
BUYER BIDDER
Name of the Officer Name of the Officer
Designation Designation
Bank of India
Witness Witness
1. 1.
2. 2.
CLARIFICATIONS
QUANTITIES
The quantities set out in the Schedule of Quantities are the estimated quantities of the work and they are not to be taken as the actual and correct quantities of the Work to be executed by the Vendor in fulfillment of his obligations under the Contract. The quantities in Schedule of Quantities can vary up to any extend of the contract provision and in event of any excess or shortfall therefore the rates are same for such excess or shortfall.
INDEMNIFICATION AND INSURANCE: - The owner at all times stands indemnified by the contractor for any loss whatsoever to the Bank ( The Employer ) / to its property by accident theft, fire and / or earthquake, injury / death of the workers, Bank’s Employees and third party and the contractor shall obtain C.A.R. policy in joint name first being that of the owner. Unless otherwise instructed the Contractor shall insure the works and keep them insured until the virtual completion of the contract against loss or damage by accident theft, fire and / or earthquake, flood etc. The insurance must be taken from a company approved by the Owner, in the joint names of the Owner and the Contractor for contract value and for any further sum if called to do so by the Owner. WRITTEN GUARANTEE FOR THE SPECIALISED WORKS: - Wherever provision for submission of a written guarantee has been advised, the same shall be submitted from the specialized agency along with a counter guarantee by the main Contractor engaged for the work before receiving any payment from the employer, against such items of work and be furnished on a non-judicial stamp paper of appropriate value. The guarantee shall however come to the force from the date of the completion of the entire contracted work.
TECHNICAL EXAMINATIONS: -
The proposed work covered under this tender during its progress or after completion is subject to inspection/examination by the Chief Technical Examiner / Technical Examiner, Central Vigilance Commission, Govt. of India or by an Auditor, Officer of the vigilance Cell of the Authority, on behalf of the Engineer-in-charge. The Contractor will be required to extend all co-operation, assistance and facilities for such inspection and thereafter complying their observation. All the observation of such authorities will be final and binding on the Contractor. If as a result of this examination or otherwise any sum is found to have been overpaid or over certified it
![Page 33: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/33.jpg)
33 | P a g e
shall be lawful for the owner to recover the same. The owner shall have also right to cause a technical scrutiny of the works and the bills of the contractor including all supporting vouchers, challans, abstracts etc. If as a result of this scrutiny any sum is found to have been overpaid or over certified it shall be lawful for the owner to recover the same.
GOVERNMENT AND LOCAL RULES: -
The Contractor shall confirm to the provisions of all local Bye-laws and Acts relating to the work and to the Regulations etc. of the Government and Local Authorities and of any company UNDER WHOSE JURISDICTION the work is to be carried out. The Contractor shall give all notices required by said Act, Rules, Regulations and Bye-laws etc. and pay all fees payable to such Authority/authorities for execution of the work involved. The cost, if any, shall deemed to have been included in his quoted rates, taking into account all liabilities for licenses, fees for footpath encroachment and restoration etc. and shall indemnify the owner against such liabilities and shall defend all actions arising from such claims or liabilities.
THE RIGHT TO SITE OF CLIENT
The Client reserves the right to use the premises and any portion of site for execution of any work not included in this contract which the Client may desire to get executed by other agencies. The Contractor shall allow all reasonable facilities for the execution of such work but shall not be required to provide any plant or materials for which work except by special arrangement with the Client in such a manner as not to impede the progress of the works included in this contract and the Contractor shall not be responsible for any damage or delay which may happen or be occasioned by suchwork. The Contractor shall not be permitted to enter on (other than for inspection purpose) or take possession of site until instructed to do so by PMC/Client in writing. The portions of the site to be occupied by the Contractor shall be defined and / or marked on the site plan failing which these shall be indicated by the PMC/ARCHITECT/Client at site and the operations beyond the areas, in respect of any land permitted by the Client for the use of the Contractor for the purpose of or in connection with the contract, the same shall be subject to the following and such other terms and condition as may be imposed by Client. The use or occupations of such shall not confer any right of tenancy of the land to the Contractor.
The Contractor shall have no right to put up any construction of his own of any nature or type on Client’s land except temporary constructions for storage of equipment for the work under the contract or as a resting place for the laborers employed by him for the work provided that he obtain the requisite previous permission they would be entitled to refuse in their absolute discretion. Such construction will be erected at the contractor’s own cost. If any electricity is used in any such construction the Contractor shall pay for the same. The Contractor shall at his own cost demolish all such constructions and remove the debris thereof. As also all his materials and equipment and clean and level the site thereof before handing over the completed work to the PMC/ARCHITECT/Client. The Client shall be entitled to and will be at liberty to occupy even the partially completed portion of the work by themselves or through their agents and servants if they so desire. Necessary extension of time for completing the work shall, however, be granted to the Contractor but he shall have no claim for any compensation whatsoever due to the delay, if any involved in completing the work on account of partial occupation.
MOCK – UP
![Page 34: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/34.jpg)
34 | P a g e
The Contractor shall prepare a mock – up of each item, if required, strictly in accordance with the specifications free of cost, for approval and fulfillment of Client/ PMC/ARCHITECT. The work on these items shall proceed further only after the approval of the mock – up. LIASIONING WITH STATUTORY AUTHORITIES The Contractor shall be responsible for taking all the approvals / NOC’s from the statutory bodies like BMC, Fire Departments, MSEDCL, PWD for lifts, Ward Offices or any other Statutory approval authority and the official charges of these departments shall be reimbursed by the Bank on production of necessary documentary evidence in the form of challans & receipts. The successful contractor will indemnify the Bank/Architect for any problems arising out of such approvals. Also, the out-of-pocket expenditure for getting such Approvals/ NOC’s shall be managed and paid by the contractor and no extra claim whatsoever shall be entertained. The PMC/ARCHITECT shall assist the contractor in making available the necessary drawings proposed by him for submission to these departments if required and the Bank shall make the contractors available the necessary documents / papers required for submission. However, the necessary follow/up/ Liasioning shall be the responsibility of the contractor. Any damage arising out of strict action of any of these departments shall be the sole liability of the contractor.
a) Contractor to liaison and obtain required permissions such royalties debris disposal from local statutory authorities for carrying out the entire work. All required documentation that will be necessary for obtaining the requisite permissions from the concerned office shall be prepared and submitted by the Contractor. Any statutory fees that may arise in lieu of obtaining permission from BMC will be paid by Client against demand notice issued.
b) The work shall be considered “Virtually Complete” only after the Contractor submits to Client the following documents obtained by him:
• Drainage Completion Certificate by the Local Municipal Corporation. • Approval for obtaining dry fittings & wet fitting permission and permanent watersupply connection. • Necessary Certificate under prevailing section of Municipal Act from the concerned Municipal Authority for adequate water supply to the building. • NOC from concerned Fire Authority (Under chief fire Officer or as applicable) towards compliance of the conditions of the firefighting system specified by the authority for the building. • To assist Client and provide necessary Liasioning with the Municipal Authority for obtaining building completion and Occupation Certificate & / or building Completion Certificate as applicable as per the bye-laws.
DECLARATION: -
![Page 35: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/35.jpg)
35 | P a g e
I / We have inspected the site of works and have made me/us fully acquainted with the local conditions in and around the sites works. I / We hereby declare that I/We have gone through the conditions laid down in the Notice Inviting Tender, General Conditions of Contract, Special conditions of contract, Technical Specifications and understood the same on the basis of the same. I / We quoted our rates in the schedule of quantities with the tender document.
Date Witness:
Name of Authorized representative
Signature of Tenderer Address
List of Annexure required for Technical bid
![Page 36: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/36.jpg)
36 | P a g e
I. Annexure 1 – Important instructions for E-tender
II. Annexure 2 – Covering letter format
III. Annexure 3 – Information of the company
IV. Annexure 4 – Details of Litigation History
V. Annexure 5 – List of References
VI. Annexure 6 - List of Important Projects Executed
VII. Annexure 7 – Important works in hand
VIII. Annexure 8 – Technical personal data
IX. Annexure 9 – Details of Machinery
X. Annexure 10 – Performance Certificate XI. Annexure 11 – Pre-Contract Integrity Pact
ADDITIONAL DOCUMENTS TO BE SUBMITTED BY CONTRACTOR
1. Annexure 12 – Work Program 2. Annexure 13 – Mythology of Work 3. Annexure 14 – List of Approved Sub vendors proposed
![Page 37: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/37.jpg)
37 | P a g e
VOLUME – I (CONTRACT CONDITIONS)
![Page 38: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/38.jpg)
38 | P a g e
CONTRACT CONDITIONS VOLUME
– I
C O N T E N T S
SR. NO. PARTICULARS
1. INSTRUCTIONS TO TENDERER
2. TENDER FORM
3. GENERAL CONDITIONS OF CONTRACT
4. SPECIAL CONDITIONS OF CONTRACT
![Page 39: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/39.jpg)
39 | P a g e
VOLUME – I INSTRUCTIONS TO TENDERER
![Page 40: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/40.jpg)
40 | P a g e
INSTRUCTIONS TO TENDER VOLUME –
I CONTENTS
IT.1.0 GENERAL
IT.2.0 TENDERER TO STUDY DOCUMENTS AND VISIT SITE
IT.3.0 SUFFICIENCY OF TENDER
IT.4.0 EARNEST MONEY DEPOSIT (EMD)
IT.5.0 METHOD OF TENDERING
IT.6.0 TENDER TO BE VALID FOR
IT.7.0 OPENING OF TENDER
IT.8.0 AGREEMENT
IT.9.0 PROCEDURE FOR REJECTION
![Page 41: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/41.jpg)
41 | P a g e
VOLUME – I INSTRUCTIONS TO TENDERER
IT.1.0 GENERAL
IT.1.1 Tender shall be available on line at www.mstcecommerce.com/eprochome/boi and www.bankofindia.co.in
IT.1.2 The documents consist of the following and which are uploaded in parts or alltogether:
1. Volume – I
Contract Conditions
Instructions to Tenderer, Eligibility Criteria, Pre-qualification form,
Integrity pact
Tender form with Appendix TF
General Conditions of Contract Special Conditions of Contract
Maintenance of records Schedule A Form of agreement - Performa of material advance (indemnity bond)
Annexure A- list of NOCs Safety Manual
2. Volume –II
Technical Specification & Approved Make List
3. Volume –III
Bills of Quantities
4. Volume – IV
Drawings& List of Drawing
5. Addenda / Corrigenda / Clarifications as and when if issued
Modifications/ correlations / addictions in any of the above documents will be made by addenda/corrigenda, copies of which will be available online at www.mstcecommerce.com/eprochome/boi. and www.bankofindia.co.in
![Page 42: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/42.jpg)
42 | P a g e
IT.1.4 The tender documents shall be available on line in English. All accompanying literature
and correspondence shall be inEnglish.
IT.1.5 No claim for costs, charges, expenses incurred by the tenderer in connection with online
tender submission and for subsequent clarifications of their tender shall be accepted.
IT.2.0 TENDERER TO STUDY DOCUMENTS AND VISIT SITE IT.2.1 Submission of the tender by the tenderer implies that he has read tender documents
listed in clause IT 1.2 and has made himself aware of the scope, specifications of the
work, conditions of contract, drawings and other reports if any and also the site
environment.
IT.2.2 Tenderers are requested to inspect and examine the site and its surroundings before
submitting tender so as to satisfy themselves about -
a) Nature of ground and soil conditions (so far as practicable). b) Means of access to the site. c) Accommodation they may require for staff / labour at and around site. d) Water and Electricity requirements for construction and for staff/labour etc. e) Risk, contingencies, safety regulations to be followed and any other circumstances. f) Local conditions and other factors affecting the works. g) Acquaint himself with local hydrological and climatic conditions. h) Acquaint himself with Rules and Regulations of Local authorities including traffic,
airport authorities or any other if any.
I) Fencing/Barricading around existing/Proposed building G+4 structure. J) Space for material under construction, workmen, and for excavated soil. k) Investigate the built structure for getting conversant with the extent of balance work
to be executed.
IT.2.3 The Tenderer shall be deemed to have full knowledge of documents and site and no
extra charges consequent on any misunderstanding or otherwise shall be allowed.
IT.2.4 Questions regarding the meaning of any of the tender documents and discrepancies shall
be directed to the Employer in writing or by e-mail. All clarifications, interpretations,
meanings and specific directions if any shall be uploaded in the above portal in the form
of Addenda /Corrigenda.
IT.3.0 SUFFICENCY OF TENDER
IT.3.1 TheTenderer shall be deemed to have satisfied himself before tendering as to the
correctness and sufficiency of his tender for the works and about the rates and prices
quoted by him, and except in so far as it is otherwise provided in the contract, cover all
his obligations under the contract and all matters and things proper execution and
maintenance of the works.
![Page 43: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/43.jpg)
43 | P a g e
IT.4.0 EARNEST MONEY DEPOSIT (EMD)
IT.4.1 Tender must be accompanied by earnest money deposit (on line through NEFT as per
annexure-1 hereinbefore) and shall be interest free. Amount of EMD and its validity
period shall be as given in Annexure 1, from the date of submission of tender or as
extended by mutual agreement.
IT.4.2 The EMD deposited by the successful tenderer shall be held back towards the security
deposit till as per provision of contract conditions.
IT.4.3 Tenders without Earnest Money Deposit shall be rejected.
IT.5.0 METHOD OF E-TENDERING
As mentioned in Annexure above.
IT.5.1.0 Authority of Signing
IT.5.1.1 If the tender is submitted by an individual, it shall be signed by him.
IT.5.1.2 If the tender is submitted by a proprietary firm, it shall be signed by the Proprietor.
IT.5.1.3 If the tender is submitted by a partnership firm, it shall be signed by all the partners of
the firm or by a partner holding the power of attorney for the firm for signing the tender,
in which case, a certified copy of power of attorney shall accompany the tender.
IT.5.1.4 If the tender is submitted by a limited company or a corporation, it shall be signed by a
duly authorized person or the person holding the power of attorney for signing the
tender, in which case a certified copy of the power of attorney shall accompany the
tender.
IT.5.2. Witnesses and Sureties
All witnesses and sureties shall be persons of respectable status and probity and their full
name, occupations and addresses shall be stated below their signatures.
IT.5.3.0 Unbalanced Unit Rates
IT.5.3.1 In the case of a tender where the unit prices of any item appears unrealistic, such a
tender will be considered as unbalanced. The Employer reserves the right to call for the
rate analysis in all items which are in his opinion, unbalanced and the tenderer is required
to give them in a specified format. In case the tenderer is unable to provide satisfactory
explanations, the Employer reserves the right to disqualify such a tender and forfeiting
EMD without prejudice to any other right for failure on part of the tenderer.
![Page 44: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/44.jpg)
44 | P a g e
IT.5.4.0 Packing and Submission
IT.5.4.1 The Tenderer shall be submitted online as per Annexure 1. Any tender received after
the date and time specified in the tender shall not be accepted. Tenders shall be
submitted in two covers;
a) Cover‘A’
b) Cover‘B’
With documents listed below.
IT.5.4.2 Cover A shall contain
a) Earnest Money Deposit – EMD
b) Tender cost
c) Transaction fees.
d) The Covering letter giving undertaking that Tender Form is duly completed with
terms and conditions for this contract.
e) Volume I – Contract Conditions,
Volume II – Technical Specifications,
Volume IV- tender drawings
Volume V- Agenda / corrigenda / clarification / amendments / corrections issued
before due date of tender.
f) Further the Tenderer shall be required to submit
Annexure 3- Details of Organization
Annexure 4- Details of litigation Annexure 5 – References Annexure 6- work capability and previous experience Annexure 7- Important works in hand Annexure 8- Technical personnel data Annexure 9- Details of Machinery Annexure 10- Clients performance certificate Annexure 11- Integrity pact Annexure 12- Work completion Programme Annexure 13- Methodology of executing work Annexure 14- Name of specialist subcontractor proposed to be used with their CV’s.
IT.5.4.3 Cover B shall contain
a) Volume–III Bills of Quantities ,duly completed with item quantities, rates and
amount, grand total and duly signed as detailed in clause IT.5.1.0
![Page 45: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/45.jpg)
45 | P a g e
IT6.0 TENDER TO BE VALID FOR
Rates quoted by the tenderer and the earnest money deposit submitted shall be valid for
a period as given in Annexure TF from the date of submission or till an extended date
mutually as agreed on expiry of the said period.
The Tenderer shall not withdraw or revise or alter any conditions, rate(s) quoted within a
stated period, unless he is called upon to do so in mutual agreement / negotiations. The
Employer reserves the right to forfeit the earnest money deposit if the tenderer revokes
or withdraws the tender within a stated period.
IT.7.0 OPENING OF TENDER
IT.7.1 To be opened in confidence.
IT.8.0 AGREEMENT
IT.8.1 The successful tenderer shall be bound to implement the contract on receipt of intimation
of acceptance from the Employer and he shall sign an agreement in accordance with as
per enclosed draft agreement within 45 days. However till formal agreement is not
signed, acceptance by the Employer together with tender form by the tenderer shall
constitute a binding contract between them. Upon the finalization of rates & Conditions
of contract, Letter Of Intent, Work Order and agreements of Contract will be made
between Finalized Tenderer and BANK OFINDIA.
IT.8.2 The successful tenderer shall bear stamp duty and other expenses pertaining to
preparation and execution of contract document/agreement.
IT.9.0 PROCEDURE FORREJECTION
IT.9.1 The Employer reserves the right to accept or reject any tender or reject all tenders
without giving any reasons for their decision.
IT.9.2 Tenders are liable to be rejected in which any of the particulars/ prescribed information is
either missing or incomplete in any respect and or if the prescribed conditions are not
fulfilled.
IT.9.3 Canvassing in connection with tender is strictly prohibited and tender submitted by
tenderers who resort to canvassing will be liable to rejection.
IT.9.4 Tenders containing uncalled for remarks or any additional conditions are liable to be
rejected. Tenderer shall not revise, add, omit or assume anything other than detailed in
tender.
* * * * *
![Page 46: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/46.jpg)
46 | P a g e
VOLUME – I TENDER FORM
![Page 47: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/47.jpg)
47 | P a g e
TENDER FORM
To,
Bank of India, H.O.,
Premises Department,
Star House 2, 3rd floor, C -4, G Block,
Bandra Kurla Complex, Bandra East,
Mumbai – 400051.
SUB: Interior And Allied Services work of 3rd Corporate Office Building at C-29, G-Block, Bandra-Kurla Complex, Mumbai.
Dear Sir,
(a) Having examined the Instructions to Tenderers, Conditions of Contract, Specifications, Bills of
Quantities, and Drawings; familiarized ourselves with land surface, sub surface, metrological,
climatological, environmental condition, we, the undersigned offer to execute completely
and maintain the whole of the works in conformity with the documents listed in IT1.2 and
IT2.0. In complying execution, we, do hereby confirm to carryout surveys, procurement,
construction, installation, testing, pre-commissioning, startup and commissioning as per the
contract document. The work covered under the contract documents shall be completed to
the entire satisfaction of yourself or your representatives at the prices and schedule of rates
accompanying thistender.
(b) Earnest Money Deposit (EMD) as given in(Annexure-TF)
(c) We agree to abide by this tender for the period given in ANNEXURE TF from the opening date
fixed for receiving the same and it shall remain binding upon us for a mutually extended
period agreed in writing by us.
(d) If our tender is accepted, we undertake to commence, complete and deliver the whole of the
Works, comprised in contract within specified periods in ANNEXURE TF from receipt of the
work order in writing from the Employer.
(e) If our tender is accepted we will, obtain and arrange;
1. Security Deposit and Performance Security as defined.
2. Insurances.
3. LabourLicenses.
4. All statutory obligation, if any, as a contractor prior to commencement of work as stated in above.
![Page 48: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/48.jpg)
48 | P a g e
(f) We acknowledge to your right to forfeit our EMD without prejudice to your any other
right or remedy for the following failures on our part.
1. EMD is less than as specified in Annexure TF.
2. Withdraw all or Changes to tender are made within Validity Period as specified in
Annexure TF.
3. Work is not commenced within specified period as given in Annexure TF
4. Obligations under (e) above are not fulfilled.
5. Failure to sign the prescribed agreement within time specified.
6. Seeking modification to agreed terms and conditions after issue of Work Order / Letter of Intent.
(g) Unless and until a formal Agreement is prepared and executed, this tender together with
our written acceptance thereof, shall constitute abinding contract between us.
(h) We understand that you are not bound to accept the lowest or any tender you may receive.
(i) We represent that we have physically visited the site and fully satisfied ourselves as to the
nature and location of the Works having in mind the general and local conditions and other
factors incidental to the performance of the works and the costs thereof.
(j) We further represent that from our own investigation of the site of the works we have fully
satisfied ourselves with respect to scope of work and other conditions to be encountered in
the performance of the works and we understand and represent that any failure to acquaint
ourselves in respect of these matters and the other factors and conditions as set forth shall
not relieve us from any responsibility for estimating properly the difficulty and cost of
successfully performing theworks.
(k) We also acknowledge and accept that you shall not pay for any discontinuance or low works
performance rate resulting from malfunction of / or inadequacy of our equipment,
instruments or personnel.
(l) We agree to return you all reports and technical data provided for our use in preparing this
tender and in the subsequent conduct of the works. We undertake that we will not use the
same for any other work /purpose.
(m) We further represent that we have familiarized ourselves with all the terms and provisions
of the various parts of the bidding documents and that in making our tender, we do not rely
upon any representation made by any agent or employee of yourselves in respect of the
terms of the bidding documents or the nature of the performance of the works.
![Page 49: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/49.jpg)
49 | P a g e
(n) We submit this bid with the full understanding that our offer fully complies with the
bidding documents requirement and that no deviation / exception to the bidding
documents have been taken by us. We also agree that in case we have taken any
exceptions / deviations to the bidding documents, the Employer will be free to reject our
offer on account of such exceptions /deviations.
Authorized signatory to tender Signature dated
Designation and Authorization
Name
ADDRESS
WITNESS 1
SIGNATURE ADDRESS
NAME
DATE
WITNESS 2
SIGNATURE ADDRESS
NAME
DATE
* * * *
![Page 50: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/50.jpg)
50 | P a g e
ANNEXURE – TF
SR.NO. PARTICULARS REMARKS
1. Validity of Tender 6 months from date of Tender
Opening (Technical Bid) or 3 months from date of tender opening (Financial bid) whichever is later
2. Tender Issuing Authority General Manager Bank of India,Head Office, Premises Dept, Star House 2, 3rd Floor, C-4, G- Block, Bandra Kurla Complex, Bandra (E), Mumbai- 400 051.
3. Address for Submission of Tender ONLINE
4. Opening of Tender CONFIDENTIAL
5. Period of Commencement of
worksfrom Employer's workorder
Within 15 days of issue of work order
including Mobilization period
6. Time / Periodof Completion 08 (Eight) months
7. Liquidated Damages (L.D.) i) 0.5% of Contract value per week of
delay.
ii)
8. E M D 40.00 Lacs (on line as per Annexure1hereinbefore)
9A. Amount of Security
Deposit/ RetentionMoney
i) Initial Security Deposit
2% of Contract Price within 7
days from the date of award of
works including EMD.
ii) RetentionMoney
5 % of Contract Price shall be
deducted at prorata percentage
starting from RA Bill till final bill
and on PVA
10. Material Advance No
Limited to maximum
5% of Contract Value.
![Page 51: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/51.jpg)
51 | P a g e
SRNO. PARTICULARS. REMARKS
11. Mobilization Period Not Applicable.
12. Submission of Interim Bill /RA Bills Once per month. Minimum
Value of Interim Bill shall be Rs.
3 Crores.
13. Time within which payment to be
made after submission of correct
bill
Ad-hoc amount i.e. 75% of the
running bill amount as certified
by the PMC will be released in
7 (Seven) working days from
the date of receipt of the
PMC’s certificate with all the
supporting documents. The
final payment of the running
bill amount will be released in
21 (Twenty-one) working days
from the date of receipt of the
PMC/Architect’s certificate
with all the supporting
documents. No interest shall
be payable for any delay
whatsoever in releasing the
interim payment.
14. Submission of Final Bill within 45 days of
receipt of taking over certificate from the PMC/ Architect.
15. Time for Certification of Final Bill within 60 days of Submission.
16. Time for payment of Final Bill Admissible payments within 90 days
aftercertification.
17. Programme Submission/
Work Methodology
Within 7 days of issue of
work order
18. Insurances Following minimum cost
of insurance shall be obtained.
CAR Policy Project cost. All insurance policies to remain in force till completion of contract period for full amount.
Workmen’scompensation Insurance as per Workmen’s of India
![Page 52: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/52.jpg)
52 | P a g e
As per statutory guidelines or as
decided by Bank.
![Page 53: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/53.jpg)
53 | P a g e
SRNO. PARTICULARS REMARKS
19. Type of Contract
Item rate contract
20. Price Escalation As per PVA clauses
21. Basic Rates As specified in Bill of Quantities
22. Watersupply Contractor to make his
Own arrangement at his own cost 23. Electricity supply Contractor to make his Own
Arrangement at his own cost.
24. Use of water / electricity by
other contractors
As per direction of Client/Architect .
25 Fencing Barricading and safety measures to be carried out as required by PMC/ Architect
26. Space for Accommodation
for Labour and Staff of
Contractor
To be as per direction of Client.
No space available at site for
labour and staff of contractor
accomodation.
![Page 54: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/54.jpg)
54 | P a g e
27. Space for site office and yard To be as per
direction of PMC/Architect
28 Architect / PMC/Client office To be provided by the contractor as directed.
29. Defect Liability Period / 12 months
Maintenance Period
30. Jurisdiction MUMBAI
SEAL AND SIGNATURE OF TENDERER
* * * * *
![Page 55: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/55.jpg)
55 | P a g e
VOLUME – I GENERAL CONDITIONS OF CONTRACT
![Page 56: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/56.jpg)
56 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I
I N D E X
1. DEFINITIONS AND INTERPRETATIONS
2. COMMENCEMENT, COMPLETIONANDDELAYS
3. PAYMENTS, CERTIFICATE
4. REMEDIES AND POWERS
5. GENERAL OBLIGATIONS OFTHECONTRACTOR
6. SITESUPERVISION
7. LABOUR AND INSURANCE
8. SAFETYCODE
9. SPECIAL CONDITIONS
![Page 57: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/57.jpg)
57 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I PART – I
DEFINITIONS AND INTERPRETATIONS
![Page 58: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/58.jpg)
58 | P a g e
GENERAL CONDITIONS OF CONTRACT
VOLUME – I
PART – I 1.0.0 DEFINITIONS In the Contract, as hereinafter defined, the following words and expressions shall have the
meaning hereby assigned to them, except where the context otherwise requires.
(a) "Employer" means the Bank of India Premises Dept., Star House 2, C-4, G- Block,
Bandra Kurla complex, Mumbai-400 051, who will employ the Contractor and the legal
successors in title to theEmployer or its assigner.
(b) "Contractor"/ “Contracting agency” means the person(s), firm or company whose
tender has been accepted by the Employer. Further it shall also mean as follows,
i) In case of Partnership firm, "Contractor"/“Contracting agency” shall mean and
trading as partners in the name and style oand having a place of business at and shall
include the partners for the time being of the said firm and the heirs, legal successors
and legal representatives of eachpartner.
ii) In case of Individual, "Contractor"/“Contracting agency” shall mean Shri ____trading in the name and style of______and shall include his heirs, successors and legal representatives.
iii) In case of Company, "Contractor"/“Contracting agency” shall means a company legally incorporated under and having its registered office at _______________and shall include its successors and assigns.
(c) "Architect" means Architect(s)/ Architect firm(s) designated, or other Architect(s)
appointed from time to time by the Employer and notified in writing to the Contractor to
act as Architect for the purpose of the contract, in place of the Architect(s)/
Architect’sfirm(s)so designated.His duties shall be as detailed inspecial conditions.
(d) "Project Management consultant" or "PMC" means the Engineer(s)/ Engineering firm or
designated other Engineer(s) /Engineering firm appointed from time to time by the
Employer and notified in writing to the Contractor to act as Project Management
consultant for the purpose of the contract. His duties shall be as detailed in Special
Conditions of Contract.
(e) "Resident Engineer" or "RE" means any resident engineer or assistant of the PMC, or any
clerk of works appointed from time to time by the PMC to perform the duties set forth in
special conditions ofcontract.
(f) "Engineer" means authorized assistant or deputy or subordinates appointed by the PMC
from time to time to RE. His duties shall be as given in writing by RE.
(g) "Contract" means the Conditions of Contract, Specifications aswell as such other documents
![Page 59: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/59.jpg)
59 | P a g e
as are specified in the document attached hereto as forming part hereof including
the Conditions, Drawings, Priced Bills of Quantities, Tender, work order and such
further documents as may be expressly incorporated in the work order or the
Contract Agreement.
(h) "Subcontractor" means any person / company / agency (other than the Contractor)
named in the Contract for any part of the Works, or any person / company / agency
to whom any part of the Contract has been sub contracted with the consent of the
Client/Contractor/PMC, and the Subcontractor's legal successors in title but not any
assignee of the Subcontractor.
(i) "Section" means a part of the Works specifically identified as such in the Contract.
(j) "Drawings" means all drawings, calculations and technical information of a like
nature provided and / or approved by the Architect/PMC or his representative and
the drawings referred to in the specification and any modifications of such drawings
approved in writing by the Architect/ PMC and such other drawings as may, from
time to time, be furnished or approved in writing by the PMC to the Contractor
under the Contract from time to time.
i. "Employer's Drawings" means all the drawings and information provided by the
Architect/PMC to the Contractor under the Contract.
ii. "Contractor's Drawings" means all drawings, samples, patterns, models and
operation and maintenance manuals to be submitted by the Contractor in
accordance with clause6.2.2.
(k) "Contract Agreement" means the document recording the terms of the Contract
between the Employer and the Contractor.
(l) "Plant"means machinery, apparatus, materials and all things to be provided under
the Contract for incorporation in the Works.
(m) "Contractor's Equipment"means all appliances or things of whatsoever nature required
for the purposes of the Work but does not include Plant. Contractor's Equipment
covers all items that the Contractor requires for the purposes of the Works or about
the execution or maintenance of the works but are not intended to form a permanent
part of the Works whencompleted.
(n) "Gross Misconduct" means any act or omission of the Contractor in violation of the
most elementary rules of diligence which a conscientious contractor in the same
position and under the same circumstances would havefollowed.
![Page 60: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/60.jpg)
60 | P a g e
(o) "Force Majeure" has the meaning assigned to it under special conditions Sub- Clause 4.3.0
(p) "Work" shall include both Permanent Works and Temporary Works or either of them
as appropriate to be executed in accordance with contract and includes materials,
apparatus, equipment, fittings, temporary supports and things of all kinds to be
provided under the obligations of the contractor hereunder and works to be done by
the contractor under the contract.
(q) "Temporary Works" means all temporary works of every kind required in or about the
execution or maintenance of the Works.
(r) "Permanent Works" means the Permanent Works to be executed and maintained in
accordance with the Contract.
(s) "Specification" means the specification referred to in the Tender including relevant
specification where so required and where such specification is not available, the
specification approved by the PMC/ Architect and any modification thereof, or
addition, thereto, as may from time to time be furnished or approved in writing by the
PMC/ Architect.
(t) "Site" means C-29, G Block, Bandra Kurla Complex, Mumbai, the land and other
places, on, under, in or through which the Permanent Work designed by the Architect
are to be executed and any other lands and places, provided by the Employer for
working spaces or any other purpose which may be specifically designated in the
contract as forming part of the Site.
(u) "Approved" means approved in writing, including subsequent written confirmation of
previous verbal written approval and "approval” means approval in writing including
as aforesaid.
(v) "I.S.S. or I.S.” means Indian Standard Specification.
(w) "Notice in writing" or written notice shall mean a notice in written, typed, or printed
characters sent (unless delivered personally) or otherwise proved to have been
received by registered post to the last known private or business address and shall be
deemed to have been received when in the ordinary course of post, it would have
been delivered. Email forwarded to the company email id shall also be considered as a
written notice or notice in writing.
(x) "Act of Insolvency" shall mean any Act of Insolvency as defined by the Presidency Towns
Insolvency Act or the Provincial Insolvency Act or any Act amending such original.
(y) “Commencement Date” means the date upon which the Contractor commences the
work as per the clause no. 2.1 of General Condition’s of Contract.
(aa) “Time for Completion” means the time for completing the execution of and passing the
Test on completion of the works or any section or part there of as stated in the Contract
![Page 61: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/61.jpg)
61 | P a g e
(or as extended under the clause no. 2.3 of General Conditions of Contract) calculated
from the commencement date.
(bb) “Mobilisation of the contractor” means performance by the contractor of all those things
necessary to be fully ready to execute work at site satisfying all work pre-requisites
stipulated in the contract. Mobilisation of the contractor shall include but shall not be
limited to providing of all transport from points of origin to site, all equipment and
materials ofconstruction,all personnel,satisfaction of government requirements,all
logistical support to the construction operations and setting up at site in a condition of
full readiness to executework.
Tender /Contract
(a) "Tender" means the documents listed in clauses of Instructions to Tenderer and
completed with price, sealed and signed by the contractor and submitted to authority
as defined in the contract.
(b) "Contract" means agreement between the Employer and the contractor for the
execution of the works incorporating Conditions of Contract, Specifications as well as
such other documents as are specified in the document attached hereto as forming part
hereof including the Conditions, Drawings, Bills of Quantities and Prices if any, Tender,
Work Order and such further documents as may be expressly incorporated in the Work
Order or the Contract Agreement. (Ref.1.3.1)
(c) "Conditions" means the Tender Form / Appendix TF to and these Conditions of
Contract, Parts 1 to 9 along with Programmes.
(d) "Work Order" means the formal acceptance by the Employer of the Tender
incorporating any adjustments or variations to the Tender agreed between the
Employer and the Contractor.
(e) "Performance Security" means the security to be provided by the Contractor in
accordance with Sub-Clause 3.1.2 for the due performance of the Contract
(f) "Provisional Sum" means a sum, included in the contract and so designated in the Bills of
Quantities for the execution of work or for the supply of goods, materials or services or
for contingencies, which may be used, in whole or in part, or not at all, at the direction
and discretion of the ARCHITECT/PMC/Client.
(g) Words importing persons or parties shall include firms and corporations and any
organization having legal capacity.
(h) Wherever in the Contract provision is made for a communication to be "written" or "in
writing" this means any hand-written, type-written or printed communication, including
telex, cable, e-mail and facsimile transmission.
![Page 62: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/62.jpg)
62 | P a g e
Cost / Rates
(a) The word "Cost" shall be deemed to include material cost inclusive of income tax, taxes
etc. or duties of appropriate authority or royalties insurances, licenses if any and
expense towards transportation, loading, unloading, storing at site, safely handling at
site, wastages expected, labor (skilled / unskilled), tools, plants and equipments, all
overhead costs, miscellaneous expenditure properly incurred or to be incurred whether
on or off the Site including overhead and profit on production of actual payment
vouchers and other charges properly allocable thereto. GST must be indicated
separately as per the BOQ formats.
(b) "Contract Price" means the sum named in the Work Order as payable to the contractor
for the execution, maintenance and completion of the Works and the remedying of any
defects therein, subject to such additions thereto or deductions there from, as may be,
under the provisions hereinafter contained.
(c) “Bills of Quantities” means the rates agreed between the Employer and the Contractor
as entered in Bills of Quantities and Rates and such further rates as may be agreed to
between the Employer and the Contractor from time to time as the works proceed.
(d) (d) “Market Rate” means the rate as required by the PMC/ARCHITECT on the basis of
cost of materials at Site inclusive of all taxes, duty, transport, loading, unloading.
(e) "Variation Order" means any written order, identified as such, issued to the Contractor
by the PMC under Sub-Clause3.8.2
Commencement / Completion
(a) "Commencement Date" means whichever is the latest of:
i) The date specified in the Appendix TF to Tender Form as the date for commencement of
Works.
(b) "Programme" means the Programme to be submitted by the Contractor in accordance
with Sub-Clause 5.4.1 and any approved revisions thereto.
(c) "Time for Completion" means the time stated in the Appendix TF for completing the
Works or any Section thereof and passing the Tests on Completion calculated from the
Commencement Date unless extended in accordance with Clause2.3.1
(d) "Defects Liability Period" means the period stated in Appendix TF to Tender Form and
Special Conditions following taking over, during which the Contractor is responsible for
making good defects and damage in accordance with Clause2.8.1.
(e) In these Conditions"day"means calendar day and"year"means 365 days.
![Page 63: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/63.jpg)
63 | P a g e
Certificates, Test
(a) "Defects Liability Certificate" means the certificate to be issued by the PMC/Architect
to the Contractor in accordance with Sub-Clause2.8.6
(b) "Tests on Completion" means the tests specified in the Contract or otherwise agreed
by the PMC/ARCHITECT and the Contractor to be performed before the Works are
taken over by thePMC/ARCHITECT.
(c) "Taking-Over Certificate" means the certificate to be given by the PMC/ ARCHITECT to
the Contractor in accordance with Clause2.7.3.
(d) "Final Certificate of Payment", means the certificate to be issued by the PMC/ARCHITECT
to the Employer in accordance with Sub-Clause 3.4.3b).
Singular and Plural
Words importing the singular only also include the plural and vice-versa where the
context requires.
Gender
Unless otherwise specifically stated, the masculine gender shall include the feminine and
neutral gender and vice versa.
Headings
The headings in these Conditions of Contract shall not be deemed to be part thereof or
be taken into consideration in the interpretation or construction thereof or of the
Contract.
Wherever in the Contract provision is made for the giving of notice, consent or
approval by any person, such consent or approval shall not be unreasonably withheld.
Unless otherwise specified, such notice, consent or approval shall be in writing and the
word "notify" shall be construed accordingly.
1.2.0 LANGUAGES AND LAW The language for this contract shall be English and the law which this contract is to subject
is Indian Law.
CONTRACT DOCUMENTS The following documents shall constitute the Contract Document:
a) Volume 1 - General conditions of contract with tender form. Appendix- TF and special
conditions.
b) Volume 2- Technical specifications c) Volume 3- Bill of quantities
![Page 64: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/64.jpg)
64 | P a g e
d) Volume 4- Tender drawings e) Volume 5- Agenda/ Corrigenda/ / clarification / amendments / corrections issued before
due date oftender.
f) Letter of Intent and/or workorder
Order of Precedence In case of any conflict in interpretation, the following order of precedence shall prevail: (a) For Contract Conditions, Special Conditions shall prevail over General Conditions.
Addenda/Corrigenda/Clarifications issued shall prevail over SpecialConditions.
(b) For Technical clarifications, Bills of Quantities will prevail over Drawings and Contract
Conditions will prevail over Technical Specification.
(c) Bills of Quantities shall prevail over all, for items, units and scope in brief read in
conjunction with Technical Specifications, Drawings for unit rate quoted. Changes to
BOQ during and till award of tender other than asked by Employer stands invalid.
(d) For legal matters, contract conditions read along with addenda/corrigenda/clarifications issued prevail over specification and BOQ.
(e) For drawings, written dimensions shall prevail over scaled dimensions.
Documents Mutually Explanatory
The several documents forming the contract are to be taken as mutually explanatory of
one another, but in case of ambiguities or discrepancies the same shall be explained and
adjusted by the PMC/ARCHITECT who shall have authority thereupon to issue to the
Contractor instructions thereon. Provided always that if, in the opinion of the
PMC/ARCHITECT, compliance with any such instruction shall involve the contractor in
any cost, which by reason of any such ambiguity or discrepancy could not reasonably
have been foreseen by the contractor, the PMC/ARCHITECT shall certify and the
Employer shall pay such additional sum as may be reasonable to cover such costs. This
shall be done only with prior written approval of employer.
Bills of Quantities
The bills of quantities given are the estimated quantities for the Works and are mean to
indicate the intent and extent of the Works and to provide a uniform basis for tendering
and they are not to be taken as the actual and correct quantities of the works to be
executed by the Contractor in fulfillment of his obligations under the contract. The
PMC/Architect with prior written approval of Employer reserves the right to increase or
decrease any of the quantities or to totally omit any item of the Work and the Contractor
shall not claim any extras or damages for increase / decrease in profit on these grounds.
Any discrepancies/error in description or in quantity or omission of items from the bills of
![Page 65: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/65.jpg)
65 | P a g e
quantities shall not vitiate this contract. Payment shall be made on actual quantities
executed and measured at site.
Drawings / Documents etc.
(a) In general, the Drawings shall indicate dimensions, position and type of construction; the
Specifications shall indicate the quantities of materials and the method of execution; and
the Bill of Quantities shall indicate the brief quantum, scope of work, unit of measurement
and the rate for each item of Work. Any Work not specifically detailed, called for, marked
or specified but required to be carried out prior, along with or afterward as customary or
prerequisite or post requisite for technical or practical requirement shall be deemed to be
part of respective items of relevant Document.
(b) The Contractor's work shall not deviate from the Drawings, Item Description (BOQ) and
the Specifications. The PMC/ARCHITECT’s/Owner interpretations of these Documents shall
be final and without appeal.
(c) Inconsistencies or errors discovered in the Drawings, Item Description (BOQ) and Specifications shall be promptly brought to the attention of the PMC/ARCHITECT/Owner for interpretation or correction. Local conditions which may affect the Works shall likewise be brought to the PMC/ARCHITECT’s/Owner attention. If at any time, it is discovered that the Works is being done which is not in accordance with the Contract, Drawings, Item Description (BOQ) and Specifications, the Contractor shall correct the Works immediately. Corrections of defective Works shall not be a basis for any claim for cost and extension of time. The Contractor shall not carry on the Works except with the knowledge of the PMC/ARCHITECT/Owner.
(d) Figured dimensions on the Drawings and large size details shall govern and take precedence over small scale Drawings. Any Work done before receipt of such details, if not in accordance with the same, shall be removed and replaced or adjusted, as directed by the PMC/ARCHITECT to the Contractor without expense to the Employer.The general conditions apply with equal force to all the Works including authorized extra Works.
(e) All Drawings, Bills of Quantities and Specifications and copies thereof furnished by the PMC/ARCHITECT are their property. These shall not be used on any other Work and shall be returned to thePMC/ARCHITECT/Owner on completion or termination of the Contract.
(f) Reinforcing steel bar bending schedules shall be furnished to ARCHITECT /PMC at least fifteen days prior to the fabrication of the reinforcement by the Contractor.
(g) Shop drawings/fabrication drawings for structural steel work shall be submitted by the Contractor to the ARCHITECT / PMC for structural consultant’s approval at least fifteen days prior to start of fabrication works.
(h) Reflected false ceiling, floor and wall tile paneling, etc. drawing coordinated with electrical, plumbing and other services shall be prepared and submitted by the Contractor 15 days in advance for approval of the PMC/ARCHITECT through prior to commencement of Works.
![Page 66: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/66.jpg)
66 | P a g e
(i) The Contractor will prepare and submit 15 days in advance, coordinated services layout drawings for the approval of thePMC/ARCHITECT.
(j) The Contractor shall submit samples as detailed in 9.9.0 and 2 weeks in advance to the PMC/Architect.
Further Drawings and Instructions
The ARCHITECT/PMC shall have full power and authority to supply to the Contractor, from time to time, during the progress of the Works, such further Drawings and instructions as shall be necessary for the purpose of the additional detailing and towards execution and maintenance of the Works. The Contractor shall carry out and be bound by the same.
Assignment
The Contractor shall not assign the Contract or any part of his obligations under the Contract. The whole of the works included in the contract shall be executed by the Contractor and the Contractor shall not directly or indirectly transfer, assign or underlet the contract or any part, share or interest therein nor, shall take a new partner, without written consent of the Owner and no subletting shall relieve the Contractor from the full and entire responsibility of the Contractor or from active superintendence of the work during their progress.
Sub-Letting
The Contractor shall not subcontract the whole of the Works except where otherwise
provided by the Contract, the Contractor shall not subcontract any part of the Works
without the prior consent of the PMC/ ARCHITECT/ Owner. Any such consent shall not
relieve the Contractor from any liability or obligation under the Contract and he shall be
responsible for the acts, defaults, and neglects of any Subcontractor, his agents, servants
or workmen as fully as if they were the acts, defaults or neglects of the Contractor, his
agents, servants or workmen.
Inspection of Site
The Contractor shall be deemed to have inspected and examined the site and its
surroundings and information available in connection therewith and to have satisfied
himself, so far as is practicable, before submitting his tender, as to the form and nature
thereof, including the sub-surface conditions, the hydrological and climatic conditions, the
extent and nature of work and materials necessary for the completion of the Works and
the remedying of any defects therein, the means of access to the site and the
accommodation he may require and, in general, shall be deemed to have obtained all
necessary information, subject as above mentioned, as to risk, contingencies and all other
circumstances which may influence or affect his tender and the Owner shall not in any
event be liable for any damage or loss caused to the contractor in relation to the same. On
![Page 67: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/67.jpg)
67 | P a g e
completion of such inspection the Contractor shall inform the Owner that he has
completed the work and it is ready for inspection. The inspection shall take into account
the existing structure and as is where is basis condition and consider all factors necessary
for further commencement and contractual deliverance of the project keeping in mind the
works already completed by previousagency.
Notices
a) All certificates, notices or instructions to be given to the Contractor by the Owner or the
Architect/PMC under the terms of the Contract shall be sent by post, cable, telex, email or
facsimile transmission or site order book to or left at the Contractor’s principal place of
business or such other address as the Contractor shall nominate for thatpurpose.
b) Either party may change a nominated address in the country where Works are being
executed by prior notice to the other party, which a copy to the Employer, and the
Employer may do so by prior notice.
1.4.0 SUFFICIENCY TENDER
The contractor shall be deemed to have satisfied himself as to the correctness and
sufficiency of the tender, which shall, except insofar as it is otherwise provided in the
contract, cover all his obligations under the contract (including those in respect of the
supply of goods, materials, plant or services or of contingencies for which there is a
provisional sum) and all matters and things necessary for the proper execution and
completion of the works and remedying of any defects therein. The Owner shall not be
responsible for the accuracy of information given in the tender.
1.5.0 SITE DATA
The ARCHITECT/PMC may have made available to the Contractor for his information, prior
to the Base Date, all relevant data in the ARCHITECT’s/PMC possession on subsurface and
hydrological conditions at the site, including environmental aspects. The ARCHITECT/PMC
shall similarly make available to the Contractor all such data which come into the
ARCHITECT’s/PMC possession after the Base Date. However, the contractor shall be
responsible for verifying and interpreting all such data including all details of the existing
structure on as is where is basis.
:
![Page 68: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/68.jpg)
68 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I
PART – II
COMMENCEMENT, COMPLETION & DELAYS
![Page 69: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/69.jpg)
69 | P a g e
GENERAL CONDITIONS OF CONTRACT
VOLUME – I PART – II
COMMENCEMENT, COMPLETION AND DELAYS
COMMENCEMENT OF WORKS
The Contractor shall commence execution of work on Site on the start date or within period
stated in APPENDIX TF and shall carryout the works in accordance with the program submitted
and updated, if any on receipt by him of written order to this effect. He shall diligently peruse
and proceed with the same with due expedition and without delay and shall complete the same
by the intended completion date as specified in the Appendix TF, except as otherwise may be
expresslysanctioned.
Possession of Site.
a) Save in so far as the Contract may prescribe:
i) The extent of portions of the Site of which the Contractor is to be given possession, from
time to time,and
ii) The order in which such portions shall be made available to him and subject to any
requirement in the Contract as to the order in which the Works shall be executed, the
Employer through PMC/ARCHITECT will, with his (Employer's) written order to commence
the Works, give to the Contractor possession of
iii) so much of the Site,and
iv) such access as, in accordance with the contract, is to be provided by the Employer as may
be required to enable the Contractor to commence and proceed with the execution of
the Works in accordance with the programme if any, and otherwise in accordance with
such reasonable proposals as the Contractor shall, by written notice to the PMC/
ARCHITECT, make. The Employer will, from time to time as the Works proceed, will give
to the Contractor possession of such further portions of the Site as may be required to
enable the Contractor to proceed with the execution of the Works with due dispatch in
accordance with such programme or proposals, as the case maybe.
b) Failure to give possession in accordance with the terms of this clause, the owner on
recommendation from the PMC/Architect shall grant an extension of time for the
completion of theWorks.
![Page 70: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/70.jpg)
70 | P a g e
Rights of way and Facilities
The Contractor shall bear all costs and charges for special or temporary way leaves
required by him in connection with access to the Site. The Contractor shall also provide at
his own cost any additional accommodation outside the Site required by him for the
purposes of the Works.
TIME / PERIOD FOR COMPLETION
Subject to any requirement in the Contract as to completion of any section of the Works
before completion of the whole work, the whole of the Works shall be completed, in
accordance with the provision of clause 2.7.0 hereof, within the time stated in the Contract
achieving the passing of the Tests on completion, calculated from the last day of the
mobilization period named in the Appendix TF to the Tender ,as that within which the
Works are to be commenced ,or such extended timeas may be allowed under clause orthe
section (as case may be) for extension of time for completion hereof.
Suspension of work
The ARCHITECT shall have full power to order suspension of the work if
a) In the opinion of the ARCHITECT, the Contractor is neglecting and failing to proceed with
due diligence in performance of his part of the Contract.
b) The Contractor has defaulted to carry out instructions for removal of improper work and
material.
c) The weather or social condition is detrimental to execution of Work.
d) On account of any legal restraint upon the Employer preventing the continuance of the
Work.
e) Due to force majeure.
Order for Suspension
ThePMC/ARCHITECT/Client shall have full power to order suspensions of work (suspend
delivery of Plant or Contractor’s Equipment which is ready for delivery to the site as per
schedule or suspend the erection of plant which has been delivered to the site)
a) In the opinion of thePMC/ARCHITECT/Client, the Contractor is neglecting and failing to
proceed with due diligence in performance of his part of the Contract.
![Page 71: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/71.jpg)
71 | P a g e
b) The Contractor has defaulted more than once /twice to carry out instructions for removal
of improper work and material.
c) The weather or social condition is detrimental to execution of Work.
d) Due to force majeure.
The Contractor shall during suspension protect and secure the works or Plant affected
at the Contractors works or elsewhere or at site, as the case may be against any
deterioration, loss or damage.
Prolonged Suspension
If suspension under Clause 2.2.2 has continued for more than 90 days, and the
suspension is not due to the Contractor's default, the Contractor may by notice to
the ARCHITECT require permission to proceed within 28 days.
If permission is not granted within that time, the Contractor may treat the suspension
as an omission under Clause 3.8.1 of the Section it affects, or if the suspension
affects the whole of the Works, terminate the Contract and the provisions of Clause
4.5.0 and clause 9.47.7 (read harmonious) shall apply
EXTENSION OF TIME FOR COMPLETION
The Contractor may claim an extension of the Time for Completion if he is or will be
delayed in completing the Works by any of the following causes:
a. the failure of the Employer to fulfill any of his obligations under the Contract,
b. any suspension of the Works except when due to the Contractor's default,
c. any industrialdispute,
d. the Employer'sRisks,
e. ForceMajeure.
The Contractor shall give to the PMC/ARCHITECT notice of his intention to make a
claim for an extension of time within 14 days of the circumstances for such a claim
becoming known to the Contractor. The notice shall be followed as soon as possible
by the claim with full supporting details.
The PMC/ARCHITECT shall, after due consultation with the Employer and the
Contractor, grant the Contractor from time to time, either prospectively or
retrospectively, such extension of Time for Completion as may be justified. The
PMC/ARCHITECT shall notify the Employer and the Contractor accordingly.
![Page 72: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/72.jpg)
72 | P a g e
The Contractor shall be entitled to such extension whether the delay occurs before or
after the Time for Completion.
Nevertheless
(i) the Contractor shall constantly use his best endeavors to prevent any delay in the
progress of the works, howsoever caused and to prevent the completion of the
works being delayed or further delayed beyond the time for completion; and
2.4.0 NO NIGHT OR REST DAY WORK
Subject to any provision to the contrary contained in the Contract, none of the Permanent
Works as hereinafter provided, shall be carried out during the night or on Sundays, if locally
recognized as days of rest, or their locally recognized equivalent without written permission of
the PMC/Architect, except when the work is unavoidable or absolutely necessary for the saving
of life or property or for the safety of the Works, in which case the Contractor shall immediately
advise the PMC/ARCHITECT. Provided always that the provisions of this clause shall not be
applicable in the case of any work, which is customary to carry out by rotary or double shifts.
RATE OF PROGRESS
If for any reason, which does not entitle the Contractor to an extension of time, the rate of
progress of the Works or any section is at any time, in the opinion of the PMC/ARCHITECT, too
slow to ensure completion by the prescribed time or extended time for completion, the
PMC/ARCHITECT shall so notify the Contractor in writing and the Contractor shall thereupon
take such steps as are necessary and the PMC/ARCHITECT may approve to expedite progress so
as to complete the Works or such section by the prescribed time or extended time. The
Contractor shall not be entitled to any additional payment for taking such steps. If, as a result of
any notice given by the PMC/ARCHITECT under this clause, the Contractor shall seek the PMC/
ARCHITECT’s permission to do any work at night or on Sundays, or on locally recognized day of
rest, such permission shall not be unreasonably refused. In case if the Contractor fails to take
necessary steps, the PMC/Architect shall be entitled to cause them to be taken and recover cost
thereof from the Contractor. Provided that if any steps, taken by the Contractor in meeting his
obligations under this clause involve the Employer in additional supervision costs, such costs
shall, after due consultation with the Employer and the Contractor, be determined by the PMC/
ARCHITECT and shall be recoverable from the Contractor by the Employer, and shall be
deducted by the PMC/ ARCHITECT from any monies due or to become due to the contractor and
the PMC/ARCHITECT shall notify the Contractor accordingly,with a copy to the Employer.
![Page 73: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/73.jpg)
73 | P a g e
If the works be delayed by any one or more of the followings:
a) Special risk
b) Abnormally bad weather, drought.
c) Serious loss or damage by fire.
d) Civil commotion, local commotion of workmen, strike or lockout, affecting any of the
trades directly employed on the work.
e) Suspension ordered by thePMC/ARCHITECT.
then upon the happening of any such event causing delay, the contractor shall
immediately give notice thereof in writing to the PMC/ARCHITECT but shall nevertheless
use constantly his best endeavours to prevent or make good the delay and shall do all
that may be reasonably required to the satisfaction of the PMC/ARCHITECT to proceed
with the works.
PENALTY FOR DELAYS ON THE PART OF CONTRACTOR / LIQUIDATED DAMAGES
The Contractor is bound to complete work stage wise as per the approved programme.
Stage wise penalties shall be applied in case of delay during the course of work & shall
maintain till next stage is achieved. In case of failure same shall be retained till next stage
of stage wise completion are achieved as per contract programme. Further in the event
of the Contractor failing to comply with (Rate of progress) the contract is liable to be
terminated at any stage and/or the Contractor shall be liable to pay penalty an amount
stated in Appendix TF to Tender Form of contract or such amount of Contract sum as the
PMC/ARCHITECT may decide for the quantity of Work that remains incomplete. The total
penalty shall not exceed maximum amount stated in Appendix TF to Tender Form.
If the Contractor shall fail to achieve completion of the whole of the Works or, if
applicable, any section within the time prescribed hereof relating to time of Completion,
then the Contractor shall pay to the Employer the sum stated in the Appendix TF to
Tender Form an amount as penalty for delays for every day/week/month or part of which
shall elapse between the time prescribed hereof and the date of certified completion of
whole of the Works or any section thereof, if applicable. The PMC/ARCHITECT may,
without prejudice to any other method of recovery, deduct the amount of such damages
from any monies in his hands, due or which may become due to the Contractor as a debt.
The payment or deduction of such damages shall not relieve the Contractor from his
obligation to complete whole of the Works or any sections, or from any other of his
obligations and liabilities under the Contract.
![Page 74: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/74.jpg)
74 | P a g e
COMPLETION CERTIFICATE
Test on Completion
Testing shall include testing of lifts, air conditioning system, pumps, panels, DG sets,
lighting, Plumbing, water proofing, fire fighting, fire detection, IBMS etc. at site as per the
standard testing procedures.
All expenses related to testing shall be to Contractor’s account. Tests on site of completed
works shall demonstrate the following among others:
That the equipment installed complies with specification in all respects and is of the
correct rating for the duty and site conditions.
That all items operate efficiently and quietly to meet the specified requirements.
That all electrical circuits are correctly protected and that protective devices are properly
co-coordinated.
The contractor shall provide all necessary instruments and labor for testing, shall make
adequate records of test procedures and readings, shall repeat any tests requested by the
PMC/Architect and shall provide test certificate signed by a properly authorized agency
approved by PMC/ARCHITECT. Such test shall be conducted on all materials and
equipments and tests on completed work as called for by the PMC/Architect at
contractor's expense. Without satisfactory completion of all test and submission of all
reports to Architect/PMC the work shall not be deemed complete.
a) Delayed Tests
(i) If the Tests are being unduly delayed by the Contractor the PMC/ARCHITECT may by notice
require the Contractor to make the Tests within 21 days after the receipt of such notice.
The Contractor shall make the Tests on such days within that period as the Contractor may
fix and of which he shall give notice to the PMC/ARCHITECT.
If the Contractor fails to make the Tests within 21 days the PMC/ARCHITECT may himself
proceed with the Tests. All Tests so made by the PMC/ARCHITECT shall be at the risk and
cost of the Contractor and the cost thereof shall be deducted from the Contract Price. The
tests shall then be deemed to have been made in the presence of the Contractor and the
results of the Tests shall be accepted as accurate.
![Page 75: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/75.jpg)
75 | P a g e
b) Facilities for Tests on Completion
Except where otherwise specified, the Contractor shall provide at his cost such labor,
materials, electricity, fuel, water, stores, apparatus and feed stock as may be reasonably
required to carry out the Tests.
c) The results of the tests after completion shall be compiled and evaluated by both the parties
and detailed report will be prepared.
d) Retesting
If the Works or any Section fails to pass the Tests, the PMC/ARCHITECT or the Contractor
may require such Tests to be repeated on the same terms and conditions.
Certification of Completion of Work
When the whole of the Works have been substantially completed and have satisfactorily
passed any final test that may be prescribed by the Contract, the Contractor may give a
notice to that effect to the PMC/ARCHITECT accompanied by an undertaking tocarry out any
rectification work during the Period of Maintenance (Defect Liability Period). Such notice
and undertaking shall be in writing and shall be deemed to be a request by the Contractor
for the Architect to issue a Certificate of Completion in respect of the Works. The
PMC/Architect shall, within twenty one days of the date of delivery of such notice either
issue to the Contractor, with a copy to the Employer, a Certificate of Completion stating the
date on which, in his opinion, the Works were substantially completed in accordance with
the Contract or give instructions in writing to the Contractor specifying all the work which, in
the PMC/Architect’s opinion, requires to be done by the Contractor before the issue of such
Completion Certificate. The Architect shall also notify the Contractor of any defects in the
Works affecting substantial completion that may appear after such instructions and before
completion of the works specified therein. The Contractor shall be entitled to receive such
Certificate of Completion within twenty-one days of completion to the satisfaction of the
PMC/Architect of the works so specified and making good any defects so notified.
Taking Over
The Works shall be taken over by the Employer when they have been completed in
accordance with the Contract, except in minor respects that do not affect the use of the
Works for their intended purpose, have passed the Tests on Completion and a Taking- Over
Certificate has been issued or deemed to have been issued.
![Page 76: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/76.jpg)
76 | P a g e
MAINTENANCE AND DEFECTS
Definition of ‘Defect Liability Period’
In these conditions the expression "Defect Liability Period” shall mean the Defect Liability
Period named in the Appendix TF to the Tender Form, calculated from the date of
completion of the Works, certified by the PMC/ARCHITECT in accordance with clause 2.7.0
Hereof, or, in the event of more than one certificates having been issued by the
PMC/ARCHITECT under the said Clause, from the respective dates so certified and in
relation to the Defect Liability Period the expression "the Works" shall be construed
accordingly.
Execution of Work of Repair:
a) To the intent that the Works shall, at or as soon as practicable after the expiry of the Defect
Liability Period, be delivered to the Employer in the condition required by the Contract, fair
wear and tear excepted, to the satisfaction of the PMC/ARCHITECT, the Contractor shall
execute all such work of repair, amendment, reconstruction, rectification and making good
defects, imperfections, shrinkages or other faults as may be required of the Contractor in
writing by the PMC/ARCHITECT during the Period of Maintenance (Defect Liability Period),
or within fourteen days after its expiry, as a result of an inspection made by the
PMC/ARCHITECT prior to its expiry.
b) Removal of Defective Work
If the defect or damage is such that repairs cannot be expeditiously carried out on the Site,
the Contractor may with the consent of the PMC/ARCHITECT or the Employer remove from
the Site for the purposes of repair any part of the Works which is defective or damaged.
c) Further Tests on Completion
If the replacements or renewals are such that they may affect the performance of the
Works, the Employer may request that Tests on Completion be repeated to the extent
necessary. The request shall be made by notice within 28 days after the replacement or
renewal. The Tests shall be carried out in accordance with Clause 2.7.1.
A replacement or renewal under Clause 2.8.1 may concern important or even vital parts of
the Plant or Works. If they are such that the replacements or renewals "may affect the
performance of the Works", the Employer is entitled to request a repetition of the Tests on
Completion. Any repeated Tests on Completion should be carried out as instructed by
PMC/Architect.
![Page 77: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/77.jpg)
77 | P a g e
d) Right ofAccess
Until the Final Certificate of Payment has been issued, the Contractor shall have the right
of access to all parts of the Works and to records of the working and performance of the
Works.
Such right of access shall be during the Employer's normal working hours at the
Contractor's risk and cost. Access shall also be granted to any duly authorized
representative of the Contractor whose name has been communicated in writing to the
PMC/ARCHITECT. Subject to the PMC/ARCHITECT's approval, the Contractor may also at his
own risk and cost make any tests which he considers desirable.
e) The Contractor has ad uty to notify the Employer or the ARCHITECT/PMC of designs he
considers defective or otherwise inadequate.
Cost of Execution of Works of Repair / Remedying defect
All work referred to in sub clause 2.7.2 shall be executed by the contractor at his own
cost if the necessity thereof is, in the opinion of the PMC/Architect, due to:
a) The use of materials, plant or workmanship not in accordance with the contract,
b) Where the contractor is responsible for the design of part of the permanent works,any
fault in such design,or
c) The neglect or failure on the part of the contractor to comply with any obligation,
expressed or implied, on the contractor’s part under the contract.
Failure to Remedy Defects
If the Contractor fails to remedy a defect or damage within time specified by the ARCHITECT
while notifying defect, the Employer may fix a final time for remedying the defect or damage.
If the Contractor fails to do so, the Employer may:
(a) Carry out the work himself or by others at the Contractor's risk and cost, provided that he
does so in a reasonable manner. The costs properly incurred by the Employer in remedying
the defect or damage shall be deducted from the Contract Price, actual cost+20%
(b) if the defect or damage is such that the Employer has been deprived of substantially the
whole of the benefit of the Works or a part thereof, he may terminate the Contract in
respect of such parts of the Works as cannot be put to the intended use. The Employer shall
to the exclusion of any remedy detailed in Part-IV of this Contract be entitled to recover all
sums paid in respect of such parts of the Works together with the cost of dismantling the
same, clearing the Site and returning Plant to the Contractor or otherwise disposing of it in
accordance with the Contractor'si nstructions.
![Page 78: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/78.jpg)
78 | P a g e
Remedy on Contractor's Failure to carry out Work required :
If the Contractor shall fail to do any such Work as aforesaid required by the PMC/ARCHITECT
within a reasonable time, the Employer shall be entitled to employ and pay other persons to
carry out the same at the risk and cost of the Contractor for which he shall be responsible and
if such Work is that which, in the opinion of the PMC/ARCHITECT, the Contractor was liable to
do at his own expense under the Contract, then all expenses consequent thereon or incidental
thereto shall be recoverable from the Contractor by the Employer, or may be deducted by the
Employer from any monies due or which may become due to the Contractor towards cost of
amending such Works and in the event of the amount retained hereof being insufficient,
recover the balance from the Contractor, together with any expenses the Employer may have
incurred in connection therewith.
The Contractor shall remain liable under the provisions of this clause notwithstanding the
signing of any certificate or the passing of any accounts, by the PMC/ARCHITECT.
Defects Liability Certificate
When the Defects Liability Period for the Works or any part thereof has expired and the
Contractor has fulfilled all his obligations under the Contract for defects in the Works or that
part, the PMC/ARCHITECT shall issue within 28 days to the Employer and the Contractor a
Defects Liability Certificate to that effect.
The contract shall not be considered as completed until a Defect Liability Certificate shall
have been signed by the PMC/ARCHITECT and delivered to the Employer, with a copy to the
contractor, stating the date on which the Contractor shall have completed his obligations to
execute and complete the works and remedy any defects therein to the PMC/ARCHITECT’s
satisfaction. The Defects Liability Certificate shall be given by the PMC/ARCHITECT within 28
days after the expiration of the Defects Liability Period, or, if different defects liability periods
shall become applicable to different sections or parts of the permanent works, the expiration
of the latest such period, or as soon thereafter as any works instructed, pursuant to clause
2.8.0, have been completed to the satisfaction of the PMC/ARCHITECT. The issue of the
Defects Liability Certificate shall be a condition precedent to payment to the contractor of the
second portion of the Retention Money.
* * * * *
![Page 79: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/79.jpg)
79 | P a g e
GENERAL CONDITIONSOFCONTRACT VOLUME –
I PART – III PAYMENTS, CERTIFICATES
![Page 80: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/80.jpg)
80 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I
PART – III PAYMENTS, CERTIFICATES
DEPOSITS
EARNEST MONEY DEPOSIT
The tenderer shall be required to furnish interest free Earnest Money Deposit (EMD) on line
by NEFT as mentioned earlier in this document. As specified in Appendix TF to tender form
and Instructions to Tenderer. Tenders not accompanied by EMD shall be rejected. If during
the period between opening of tender and award of contract, the tenderer withdraws his
tender or make changes not in conformity of tender procedure or as detailed in Tender form,
EMD shall be forfeited.
Tenders with less EMD stand rejected and amount forfeited. EMD of successful tenderers
shall be adjusted towards initial security deposit as specified here under. EMD of unsuccessful
tenderers shall be returned as soon as possible but without any interest.
SECURITY DEPOSIT
Initial Security Deposit: The successful tenderer shall be required to furnish Initial Security
Deposit total 2% of contract value inclusive of EMD deposited by the tenderer along with the
bid document in form of Demand draft or Pay Order of Nationalized Bank / Scheduled
Commercial Bank. This initial security deposit excluding EMD shall be deposited as specified in
special conditions in form of Demand Draft or Pay Order in favor of Bank of India, Mumbai of
Nationalized bank. Thus EMD of successful tenderer shall be adjusted towards initial security
deposit.
Retention Money: Retention money shall be collected from the successful tenderer by
deduction of 5% amount of each running account bill and final bill and PVA Bill 50% of Security
Deposit / Retention money shall be released as under.
a) Issue of virtual completion certificate by thePMC/Architect/Employer.
b) Contractor removes his materials, equipment’s, Labour force, temporary sheds, stores etc.,
from the site after completion of the work (except for small presence required, if any for the
defect liability period and approved by the Bank). 25% of Security Deposit / Retention
money may be refunded 15 days after the end of defect liability period provided that
contractor has carried out all the work.
![Page 81: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/81.jpg)
81 | P a g e
ADVANCES
Material Advance
Material advance shall be 75% of nonperishable material brought at site against
indemnity Bond by the contractor against producing all required necessary original
invoices, challans etc. or any other documents as required by the PMC/
ARCHITECT/Employer to their entire satisfaction.
MEASUREMENTS
Quantities
The quantities set out in the Bills of Quantities are the estimated quantities of the
Works, and they are not to be taken as the actual or correct quantities of the Works
to be executed or material to be ordered by the Contractor in fulfillment of his
obligations under the Contract.
Method of Measurement
The Works shall be measured as per method of measurement detailed in Technical
Specification and preamble to Bills of Quantities of this contract. In absence of these
details relevant SP 27 and IS 1200 shall be followed or shall be measured as per
instructions of the PMC/ARCHITECT.
Quantity Surveying
The Contractor will undertake the quantity surveying and submit running and final bills
along with supported measurement sheets for Work carried out and the required
reconciliation statements for consumption of material and running account bills. The
measurements shall be as per approved construction drawings.
In case if bills submitted by the Contractor show frequent inaccuracies indicating that the
Contractor is incapable of preparing the bills as required, the PMC/ARCHITECT is
empowered to appoint an expert to undertake quantity surveying work on behalf of the
Contractor at his (Contractor's) risk and cost. The remuneration of an expert so appointed
shall be deducted from the Contractor's running account, final bills.
All authorized extra Works, omissions and all variations made without the
PMC/ARCHITECT/Employer’s knowledge, but subsequently sanctioned by him in writing
(with the prior approval in writing of the employer) shall be included in such
measurements. The measurement and valuation in respect of the Contract shall be
![Page 82: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/82.jpg)
82 | P a g e
completed within 30 days of the completion of the Contract.
CERTIFICATES AND PAYMENTS
RUNNING ACCOUNT BILL (R A BILL)
(a) The Contractor shall submit to the PMC/Architect on 5th or any other fixed date of
every month, statements signed by the Contractor showing:
i. Reconciliation statement of material purchased on basic price to be submitted along
with all invoices and approvals
ii. Secured Advance receivable and forming part of bill against materials.
iii. Running account bill based on actual measurements of work done till that date. R A
Bill Certification Ad- hoc amount i.e. 75% of the running bill amount as certified will be
released in 7 (seven) working days from the date of receipt of the PMC’s certificate
with all the supporting the documents. The final payment of the running bill amount
will be released in 21(Twenty-one) working days from the date of receipt of the
PMC/Architect’s certificate with all the supporting documents. No interest shall be
payable for any delay whatsoever in releasing the interimpayment.
The PMC/ARCHITECT shall, then verify the bills and certify the interim payments
after taking into account:
a. All deduction as applicable such as retention, secured advance towards basic price of
material received, payment certified till date and statutory deductions.
b. Part payment towards defects observed in works executed.
c. Ad-hoc payment released against PMC’s certificate.
Final Bill
a) Application for Final CertificatePayment
The Contractor shall make application to the PMC/ARCHITECT for the Final Certificate
of Payment within 90 days after the issue of the Certification of final Bill.
The application for the Final Certificate of Payment shall be accompanied by a final
account prepared by the Contractor.The final account shall give full details of the
value of work done under the Contract together with:
i) Such additions to or deductions from the Contract Price as have been agreed.
![Page 83: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/83.jpg)
83 | P a g e
b) Issue of final certificate of payment.
The ARCHITECT/PMC shall approve bill within 60 days. The Employer shall arrange to
make admissible payments within 90 days of the issue of certificate by the
ARCHITECT/PMC after effecting all recoveries, including advances and payments
The PMC/ARCHITECT shall have power to withhold certification if the Works or any
parts thereof are not being carried out to his satisfaction and/or the Contractor has
not returned to thePMC/ARCHITECT all Drawings, Specification and other documents
provided under the Contract. Payment of this bill shall not be considered conclusive
evidence as to the sufficiency of any Works or materials to which it relates, nor shall it
relieve the contractor from his liabilities arising from any defects noticed till the
completion of the Period of Maintenance (Defects Liability Period). No payment shall
be made to the Contractor if the Contractor fails to insure the Works and keep them
insured until the issue of the Completion Certificate.
Payment after Defect Liability Certificate
Upon the expiry of the Defect Liability Period as referred in APPPENDIX TF, or, if
different Defect Liability Period shall become applicable to different sections or parts
of the Works, upon the expiry of the latest of such period,thePMC/ARCHITECT shall
certify as payable to the Contractor security deposit and the retention amount as
detailed in the special conditions the Employer shall be entitled to withhold payment
until the completion of such Works of so much of the second half of security deposit
and the retention money as shall in the opinion of the PMC/ARCHITECT be the cost of
the works so remaining to be executed.
Provided further that in the event of different Maintenance Periods (Defect Liability Period)
having become applicable to different parts of the Works (Completion Certificate) hereof the
expiry of the Period of Maintenance (Defect Liability Period) shall for the purpose of this sub-
clause be deemed to mean the expiry of the last of such periods.
a) Final Certificate of Payment Conclusive
A Final Certificate of Payment shall be conclusive evidence of the value of the Works, that the
Works are in accordance with the Contract and that the Contractor has performed all his
obligations under the Contract.
![Page 84: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/84.jpg)
84 | P a g e
Payment of the amount certified in the Final Certificate of Payment shall be conclusive evidence
that the Employer has performed all his obligations under the Contract. A Final Certificate of
Payment or payment shall not be conclusive.
Correction withholding of Certificates.
The PMC/ARCHITECT may, by any payment certificate, make any correction or modification in
any previous payment certificates which might have been issued and shall have power to
withhold approval of any payment certificate if the Works or any part thereof are not being
carried out to his satisfaction or to deduct the value of damaged materials, plant or equipment
supplied by the Employer to the Contractor for the purposes of the works in the event of such
damage being caused by the Contractor's negligence or mishandling.
Time of Payment
Payment upon each of the PMC/ARCHITECT’s certificate shall be made by the Employer within
the time specified in the Appendix TF to the Tender Form after such certificate has been
delivered to the Employer by thePMC/ARCHITECT
TAXES
The Contractor shall be responsible to pay to the appropriate authorities all taxes, levies,
royalties, Custom duty, Cess, etc., as applicable from time to time for the purpose of
construction. The complete item rate would be inclusive of the above all mentioned taxes,
duties etc. GST SHALL BE PAID EXTRA as per Rules. No claims in respect of other Taxes, Duty
or Levy whether existing or future shall be entertained by the Owner. If the contractor fails to
pay the taxes to the authorities concerned, the owner reserves the rights to recover the said
amount from the amount payable to the contractor and pay the same to the Authorities
Concerned.
Income Tax
Each payment made from time to time to the Contractor, shall be subjected to standard at
source income Tax Deduction as per the provisions of the relevant Act and Rules prevailing at
that time.
Local authority charges payable to Municipality, corporation etc. towards temporary connection
of Water supply, Sewerage, and Electricity supply connection shall be to the contractors account.
Actual cost for consumption and usage for construction in works shall be paid by the Contractor.
![Page 85: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/85.jpg)
85 | P a g e
PROVISIONAL SUMS
Use of Provisional Sums
A Provisional Sum shall only be used, in whole or in part in accordance with the
PMC/ARCHITECT/Clients'sinstructions.
Ordering Work against Provisional Sums
In respect of every Provisional Sum the PMC/ARCHITECT may after due consultation with
the Employer and the Contractor order:
a) Work to be executed, including goods, materials or services to be supplied by the
Contractor. The value of such work executed, determined, shall be paid to the
Contractor in accordance with Clause 3.4.0, and
b) Goods and materials to bepurchased by the Contractor, for which payment will be
made. Invoices and Receipts
The Contractor shall, when required by the PMC/ARCHITECT, produce quotations,
invoices, vouchers and accounts or receipts in connection with expenditure in respect of
Provisional Sums. If the Contractor shall use materials less than that what he is required
under the contract, the value of the difference in ·the quantity of the materials he was
required to use and that he actually used shall be deducted from his dues. The decision
of the Owner shall be final and binding on the Contractor.
Payment against Provisional Sums
For all work executed or goods, materials or services supplied or purchased by the Contractor,
there shall be included in the sums paid to the Contractor:
a) The actual price paid or due to be paid by the Contractor, and
b) In respect of all other charges and profit, a percentage of the actual price paid or due to
be paid. Such percentage shall be as stated in the Schedule of Prices.
![Page 86: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/86.jpg)
86 | P a g e
NOMINATED SUB-CONTRACTORS
Definition of "Nominated Sub-Contractors"
All specialists, merchants, tradesmen and others executing any work or supplying any
goods, materials or services for which provisional sums are included in the Contract, who
may have been, or be nominated, or selected, or approved by the Employer or the
PMC/ARCHITECT, and all persons to whom by virtue of the provisions of the Contract, the
Contractor is required to sub-let any work shall, in the execution of such work or the supply
of such goods, materials or services, be deemed to be Sub- Contractors employed by the
Contractor and are referred to in this Contract as "Nominated Sub- Contractors."
ALTERATIONS, ADDITIONS AND OMISSIONS
Variations
The PMC/ Architect / Employer shall make any variation in the form, design requirement
of the Works or any part thereof that may, in his opinion, be necessary and for that
purpose, or if for any other reason it shall, in his opinion, be desirable, he shall have the
power to order the Contractor to do and the Contractor shall do any of the followings
(a) Increase or decrease the quantity of any Work included in the Contract,
(b) Omit any such Work,
(c) Change the character or quality or kind of any such Work,
(d) Change the levels, lines, position and dimensions of any part of the Works,
(e) Execute additional work of any kind necessary for the completion of the Works,
(f) Change any specified sequence or timing of construction of any part of the Works and no such variation shall in any way validate or invalidate the Contract, but the value, if any, of all such variations shall be taken into account in ascertaining the amount of the Contract Price.
Orders for Variations
No such variations shall be made by the Contractor without an order in writing of the PMC
/ARCHITECT/Employer.
Variation and extra item:
Variation to any extent in quantities will be paid for only on basis of quoted rate in contract.
Items not available in contract may be derived from similar items available in contract.
![Page 87: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/87.jpg)
87 | P a g e
If the items are not available in contract the contractor shall submit detailed rate analysis for
the same which will be scrutinized and finalized by PMC/Architect/Employer based on market
conditions and 15% consideration or over heads and profit margin.
Contractor to Proceed
On receipt of a Variation Order, the Contractor shall forth-with proceed to carry out the
variation and be bound to these Conditions in so doing as if such variation was stated in the
Contract.
The work shall not be delayed pending the granting of an extension of the Time for
Completion or an adjustment to the Contract Price.
Records of Costs
In any case where the Contractor is instructed to proceed with a variation prior to the
determination of the adjustment to the Contract Price in respect thereof the Contractor shall
keep records of the cost of undertaking the variation and of time expended thereon. Such
records shall be open to inspection by the PMC/ARCHITECT at all reasonable times.
3.9.0 BASIC RATES
(a) While making the tender, the tenderer shall base his rates for listed material as in the
Schedule `A' enclosed, which rates shall be hereinafter referred to as "the basic price".
The said prices shall be inclusive of taxes and all other duties levied by Government or
any public body, transportation, insurance, loading, unloading etc.
(b) In case during the currency of the Contract the aggregate of the selling prices of
approved /authorized stockiest, goes above the basic price of listed materials referred to
in sub-clause
(a) above, the excess shall be borne by the Employer but the Contractor shall not in any
way be entitled to any sums by way of overhead costs, profits or otherwise whatsoever
in respect of such excess; should this aggregate go below the said basic prices, the
benefit shall go to the Employer; and in either case the corresponding adjustment shall
be made in the Contractor's bill on production of all necessary vouchers duly certified by
the PMC/ARCHITECT. Wastage in listed materials shall be on the Contractor's account.
The Contractor shall furnish to the Architect periodically all purchases made by him
along with invoices and daily consumption report. Adjustment in prices on account of
material listed in Schedule `A' shall be made only in respect of materials to be used on
the site.
![Page 88: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/88.jpg)
88 | P a g e
(c) That in case the Employer is able to arrange for any listed material from schedule `A' for
the works either from its own stocks or from the manufacturers or stockiest or suppliers
or otherwise the Contractor shall use the same in the Works if so directed by the PMC/
Architect.
3.10.0 PRICE VARIATION ADJUSTMENT CLAUSE (PVA) FOR ALL WORKS EXCEPT INSTALLATION OF
LIFT WORK:
If the prices of materials and / or wages of labour required for execution of the work
increase or decreases, the price variation adjustment(PVA) shall be worked out as per
provision detailed below and the amount of the contract shall be accordingly be varied,
subject to the other condition that compensation for escalation in prices shall be available
only for the work done during the stipulated period of the contract including such periods
for which the contract is validity extended under the provision of relevant clause of the
contract.
Partial modification of (any) provisions made elsewhere in this Contract regarding rate
quoted in the tender being not subject to any variations,price adjustment to the value of the
work payable to the Contractor attended rates shall be made towards variation in the prices
of materials and labour applied by the Contractor in the manner specified hereinunder ,
after the written order to commence the work and during the operative period of this
contract including any authorized extensions of the original stipulated completion period-.
There be any variation in the consumer price index – general index – for industrial workers
(Base2001=100) (source data published from time to time in Indian Labour Journal by the
Labour Bureau, Government of India).
There be any variation in the All India Wholesale Price Index for all commodities (Base 2004-
2005=100) (as published from time to time in the RBI bulletin based on the data issued by the
office of the Economic Advisor to the Government of India).
Price Variation Adjustment (PVA) towards (1) labour component and(2) material component
for all materials shall be calculated in accordance with the formulae(A)and(B) respectively,
given below, subject to stipulations hereinafter mentioned.
Formula (A) for labour
VL = [0.78P x K1 / 100 X C1 – C0 / C0]
![Page 89: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/89.jpg)
89 | P a g e
Formula (B) for materials:-
VM = [0.78 P X K2 / 100 – C] X I1 – I0/ I0
Where,
VL = Amount of price variation adjustment – increase or decrease in rupees due to Labour
Component.
VM = Amount of Price Variation Adjustment – increase or decrease in rupees on account of
materials component.
P = Cost of work done during the period under consideration (bill period) as per Gross amount of
bill excluding, cost of extra or substituted items, rates of which are fixed on prevalent market
rates and advances on materials and / or adjustment thereof; if any. This will also exclude the
cost of installation of Lift works PVA for which will be paid under a separate clause as per
Annexure:
C = Cost of material, if any, for which basic rates are specified.
K1 = Percentage of labour component as calculated, as indicated in Note (1) below. K2 = Percentage of material component as indicator in Note (2) below.
Co = Consumer price index – General Index number for industrial workers (Base 2001 = 100)
referred to at (a) above, ruling on the last date for receipt of tenders, and as applicable to
the centre nearest to the place of work, for which the index is published.
C1 = Average of above mentioned consumer price index number during the period under
consideration (bill period).
I0 = All India Whole sale Price Index Number for all commodities referred to at (b) above, ruling
on the last date for receipt of tenders and as applicable to the centre, nearest, to the place
of work for which the index is published.
I1 = Average of above mentioned monthly All India Wholesale Price index Numbers during the
period under consideration (bill period).
Note (1): K1 shall be taken as under:-
a) Component of work: Civil work including ancillary works and external works and RCC/
tanks, septic tank etc., if any, for sanitary and plumbing work :30
b) Sanitary and plumbing works including fittings and fixtures (internal work only):20
c) Electrical installation work including fittings and fixtures (external and internal works):20
![Page 90: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/90.jpg)
90 | P a g e
Note (2): K2 shall be taken as under:-
Civil work including ancillary works as detailed under Note (1) (a) above: 70
Sanitary and plumbing works including fittings and fixtures as detailed under Note (1) above: 80
Electrical installation work including fittings and fixtures as detailed under Note (1) above: 80
Stipulation:
PVA clause is operative either way i.e. if the variations in above referred price indicates are
on the plus side, PVA shall be payable to the Contractor and if they are on the negative side
PVA shall be recoverable from the Contractor, for the respective bill period of occurrence of
fluctuations.
The rates quoted by the Contractor shall be treated as firm for the value of work required to
be done in the first 6 months of the contract period from the date of written order to
commence work, and no PVA is admissible on the same on any ground whatsoever. The
value of work required to be done during the first 6 months of the contract period shall be
taken as 80% of the value of work to be done on pro – rata basis in 6 months as compared
to the total stipulated completion period. No PVA is admissible on the value of work
required to be done in the first 6 months as worked out above, even if this work is actually
done in a period longer than 6 months.However,in case of any delay in the first 6 months
due to genuine reasons which are not attributable to the contractor and which are beyond
his control, such period of delay will be deducted from 6 months, and the value of work to
be done will be 80% of the prorate value of work to be done in such reduced period on
prorate basis.
For the purpose of admissibility of PVA all the cumulative periods of extension granted for
reasons which are solely attributable to the Contractor is excluded from the total extended
period of the contract and PVA shall not be admissible on the value of work done during such
period of extensions, which are granted for keeping the contract current, but only due to
reason for which the Contractor was solely responsible. Period of extensions granted on
account of genuine reasons, which are not attributable to the Contractor, and which are
beyond his control will, however, be included in the period for which PVA is admissible.
Notwithstanding anything to the contrary mentioned in any other clause / clauses of the
contract, extensions of the contract period shall be granted by the PMC without Owner prior
approval shall not bind the Owner for payment of PVA for work done in the concerned period
ofextension.
In working out the amount of PVA as per all the foregoing stipulations, value of such extra
![Page 91: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/91.jpg)
91 | P a g e
items or such portions of extra items the rates of which are derived from the prevailing
market rates of materials and labour will not be included in the value of work done. Value of
only such extra items or such portions of extra items, rates of which are derived from
tendered rates will be included in the value of work on which PVA is calculated.
For claiming the payment for PVA the Contractor shall keep such books of accounts and
other documents, vouchers, receipts etc., as may be required by the Owner / PMC, for
verification of the increased claims or reductions to be made as the case may be and he shall
also allow inspection of books,documents by thePMC/Architects and Owner’s Engineer and
/ or other duly authorized representatives of the Owner / PMC and furnish such information
as may be required or called for to enable verification of the claim within a week of such
request.
The Contractor is required to submit to the Owner, through the PMC, his claims for PVA
separately for each running bill for the individual bill period for the work paid to him by the
Owner. He wil also be required to submit detailed calculations in support of the claims.
No claim will be entertained from the contractor for interest or any other grounds for non –
payment or for any delay in payment of PVA due to late publication or non – availability of
the necessary price indices or due to delay in preparation of the running or final bills.
The increase / or decrease in statutory measures such as taxes, levies etc. will be considered
while working out the adjustments, in accordance with Formula (B).
In all case of disputes under this clause the decision of the General Manager (Premises) Bank
of India who shall give a reasonable hearing to the Contractor in person (not through Agents
/ Advocates) shall be final and binding.
Revision of wages in a statutory Act like the Minimum Wages Act
If the minimum wage of a category of labour employed in the works has been increased by
more than 10% due to statutory enactment and the Contractor has to actually increase the
wage accordingly, the actual increase may be reimbursed to the Contractor after subtracting
from it the portion already paid / payable as per General PVA adjustment formula due to cost
index variation for the labour component. In other words, if the actual increase is “E”, the
amount payable willbe
E (1- C1 – Co /Co)
For the period under consideration (refer the general PVA formula for abbreviation) and the
increase will pertain to all labourers thus affected and employed on the Muster surly checked
by the PMC / Owner.
![Page 92: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/92.jpg)
92 | P a g e
PRICE VARIATION ADJUSTMENT CLAUSE (PVA) FOR LIFTS
The Contractors’ quoted prices as accepted by the Employer after negotiations shall be
deemed based on the rates of raw materials / components and labour rates as on the date of
submission of tenders. In case of any variation in the index numbers of wholesale Price Index for
Metal Products and All India Average Consumer Price Index Number for Industrial Workers the
price shall be subject to adjustment up or down in accordance with the following IEEMA Formula
: P = Po { 15 + 55 MP + 15 Wo (D) + 15 Wo (I) }
100 {MPo Wo Wo
Where,
P = Price payable as adjusted in accordance with the above price variation formula
Po = Price accepted by Employer before award of Contract
MPo = Wholesale Price Index Number of Metal Products as published by the office of the
Economic Adviser, Ministry of Industry, Government of India, in their weekly bulletin
Revised Index Number of Wholesale Prices (Base: 2004-05=100), for the month in which the
Work Order is issued
Wo = All India Average Consumer Price Index Number for Industrial Workers (Base: 2001=100),
As published by Labour Bureau, Ministry of Labour, Government of India, for the month in which
the Work Order is issued.
MP = Wholesale Price Index Number for Metal Products as published by the Office of Economic
Advisor, Ministry of industry, Government of India, in their weekly bulletin Revised Index Number
of Wholesale Prices (Base: 2004-05=100), as prevailing during the month in which materials are
delivered to site, as published by IEEMA.
Wo (D) =All India Average Consumer Price Index Number for Industrial Workers
(Base: 2001=100) as published by Labour Bureau, Ministry of Labour, Government of India,
prevailing for the month in which the materials are delivered to site as published by IEEMA.
Wo(I)= All India Average Consumer Price Index Number for Industrial Workers (Base:2001=100)
as published by Labour Bureau, Ministry of Labour, Government of India prevailing for the
relevant month(s) during which installation is in progress or is completed.
Provisional payment may be made as per provisional indices published from time to time but
once final indices are published,only the final indices shall be considered for payment.
![Page 93: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/93.jpg)
93 | P a g e
In case of provisional price indices which are published and subsequent amended in later
official publications, the final indices published shall be considered for PVA.
The price adjustment clause shall be applicable only for the work executed during the contract
period including authorized extension, if any. In case the work is not completed within the
contract period including authorized extension and the provision of liquidated damages has to
be enforced, this adjustment clause will not be applicable for work done during that period. It is
also clarified that price adjustment clause will not be applicable to any extra / variation items.
The rates of which are based on prevailing market rates.
In view of the price adjustment in cost being covered as above, no other adjustments viz.
increase or decrease due to statutory measures / levies, etc. will be allowed for any reason
whatsoever.
For claiming the payment for PVA the contractor shall keep such books of accounts and other
documents, vouchers, receipts etc., as may be required by the Employer / PMC, for verification
of the increased claims or reductions to be made as the case may be and he shall also allow
inspection of books, documents by the PMC / Architects and Employer’s Engineer and / or other
duly authorized representatives of the Employer / PMC and furnish such information as may be
required or called for to enable verification of the claim within a week of such request.
The contractor is required to submit to the Employer, through the PMC, his claims for PVA
separately for each running bill for the individual bill period for the work paid to him by the
Employer.He will also be required to submit detailed calculations in support of the claims.
No claim will be entertained from the contractor for interest or any other grounds for non-
payment or for any delay in payment of PVAS due to late publication or non-availability of the
necessary price indices or due to delay in preparation of the running or final bills.
In all cases of disputes under this clause the decision of the General Manager (Premises) Bank of
India who shall give a reasonable hearing to the contractor in person (not through Agents /
Advocates) shall be final and binding.
*****
![Page 94: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/94.jpg)
94 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I PART – IV
REMEDIES AND POWERS
![Page 95: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/95.jpg)
95 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I (PART – IV)
REMEDIES AND POWERS
DEFAULT OF CONTRACTOR
If the Contractor shall become bankrupt, or have a receiving order made against him, or shall
present his petition in bankruptcy, or shall make an arrangement with or assignment in favour of
his creditors, or shall agree to carry out the Contract under a committee of inspection of his
creditors or, shall suffer any payment under this contract to be attached by or on behalf of any
of his/its creditors or shall charge or encumber this Contract or any payments due or which may
become due to the Contractor hereunder or being a corporation, shall go into liquidation or pass
a resolution for winding up voluntarily or subject to the supervision of the Court and the Official
Assignee or the Liquidator in such acts of insolvency or winding up, as the case may be, (other
than a voluntary liquidation for the purposes of amalgamation or reconstruction), or if the
Contractor shall assign the Contract, without the consent in writing of the Employer first
obtained, or shall have an execution levied on his goods or other process of Court attaching
property to be issued against him/it, or if the PMC/ARCHITECT shall certify in writing to the
Employer that in his opinion the Contractor:-
(a) has abandoned the Contract,or
(b) without reasonable excuse has failed to commence the Works or without lawful excuse
under these conditions has suspended the progress of the Works for fourteen days after
receiving from the PMC/ARCHITECT written notice to proceed,or
(c) has failed to remove materials from the Site or to pull down and replace any Work within
fourteen days after receiving written notice from the PMC/ARCHITECT that the said
materials or Work had been condemned and rejected by the PMC/ARCHITECT under these
conditions,or
(d) despite previous warnings by the PMC/ARCHITECT, in writing, is not executing the Works in
accordance with the Contract, or is persistently or flagrantly neglecting to carry out all or any
of his obligations under the Contract,or
(e) has, to the detriment of good workmanship, or in defiance of the PMC/ARCHITECT's
instructions to the contrary, sub-let any part of the Contract, then and in any of the said
cases the Employer may, notwithstanding any previous waiver, after giving fourteen
days’ notice in writing to the Contractor, determine the Contract, but without thereby
affecting the powers and rights of the PMC/ARCHITECT or the obligations and liabilities
of the Contractor, the whole of which shall continue in force as fully as if the Contract
had not been so determined, and as if the Works subsequently executed had been
executed by or on behalf of the Contractor. And further, the Employer by his agents or
![Page 96: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/96.jpg)
96 | P a g e
servants may, enter upon the Site and the Works and expel the Contractor therefrom
and may himself complete the Works or may employ any other contractor to complete
theWorks.
The Employer or such other contractor may use for such completion so much of the
constructional plant, Temporary Works and materials, which have been deemed to be
reserved exclusively for the execution of the Works, under the provisions of the
Contract, as he or they may think proper, and the Contactor shall not in any way
interrupt or do any act, matter or thing to prevent or hinder such other contractor or
other person or persons employed for completing and finishing or using the materials
and plant for the Works. When the works shall be completed or as soon, thereafter, as
convenient the PMC/ARCHITECT shall give a notice in writing to the Contractor to
remove his surplus materials and constructional plant and should the Contractor failto
do so within a period of fourteen days after receipt thereof by him, the Employer may
(but without being responsible for any loss or damage) at any time, sell any of the said
constructional plant, Temporary Works and unused materials and apply the proceeds of
sale in or towards the satisfaction of any sums due or which may become due to him
from the Contractor under the Contract.
Valuation at Date of Forfeiture
The PMC/ARCHITECT shall, as soon as may be practicable after any such entry and
expulsion by the Employer, fix and determine expert, or after reference to the parties, or
after such investigation or inquiries as he may think fit to make or institute, and shall
certify what amount, if any, had at the time of such entry and expulsion been reasonably
earned by or would reasonably accrue to the Contractor in respect of Work then actually
done by him under the Contract and the value of any of the said unused or partially used
materials, any constructional plant and anyTemporary Works.
Payment after Forfeiture
If the Employer shall enter and expel the Contractor under this clause, he shall not be
liable to pay to the Contractor any money on account of Contract until the expiry of the
Period of Maintenance (Defect Liability Period) and thereafter until the cost of execution
and maintenance, damages or delay in completion, if any, and all other expenses incurred by
the Employer have been ascertained and the amount thereof certified by the
PMC/ARCHITECT. The Contractor shall then be entitled to receive only such sum or sums, if
any, as the PMC/ARCHITECT may certify, would have been payable to him upon due
completion by him after deducting the said amount. If such amount shall exceed the sum
![Page 97: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/97.jpg)
97 | P a g e
which would have been payable to the Contractor on due completion by him, then the
Contractor shall, upon demand pay to the Employer the amount of such excess and it shall be
deemed a debt due by the Contractor to the Employer and shall be recoverable accordingly.
Assignment of Benefit of Agreement
Unless prohibited by law, the Contractor shall, if so instructed by the PMC/ARCHITECT within 14
days of such entry and termination referred to in Sub-clause 4.1.1 assign to the Employer the
benefit of any agreement for the supply of any goods or materials or services and/or for the
execution of any work for the purpose of the Contract, which the Contractor may have entered
into.
Termination of Contract for death
If the Contractor is an individual or the proprietor of a firm or the managing director or
promoter of a company and the individual or the proprietor dies and if a Partner of Partnership
firm dies, unless the Employer is satisfied that the legal successor of the individual or the
proprietor or surviving partner(s) or the promoters or the company are capable of carrying out
and completing the Contract satisfactorily, the Employer shall have the option to terminate the
Contract without compensation to the Contractor.
4.2.0 URGENT REPAIRS
If, by reason of any accident or failure, or other event occurring to, in, or in connection with the
Works or any part thereof, either during the execution of the Works or during the period of
Defect Liability Period, any remedial or other Work or repair shall, in the opinion of the
PMC/ARCHITECT be urgently necessary for the security and safety of the life or for the Works or
of adjoining property and the Contractor is unable or unwilling at once to do such work or
repair, the Employer may employ and pay other persons to carry out such work or repair as the
PMC/ARCHITECT or they may consider necessary. If the Work or repair so done by the
Employers is work which, in the opinion of the PMC/ARCHITECT, the Contractor was liable to
do at his own expense under the Contract, all expenses properly incurred by the Employer in so
doing shall be recoverable from the Contractor by the Employer or may be deducted by the
Employer from any moneys due or which may become due to the Contractor.
Provided always that the PMC/ACHITECT shall, as soon after the occurrence of any such
emergency as may be reasonably practicable, notify the Contractor thereof in writing. due
or which may become due to the Contractor. Provided always that the ARCHITECT shall,
as soon after the occurrence of any such emergency as may be reasonably practicable,
notify the Contractor thereof in writing.
![Page 98: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/98.jpg)
98 | P a g e
4.3.0. FORCE MAJEURE/ SPECIAL RISKS
Force Majeure means exceptional events of circumstance
a) Which is beyond a Party’sControl,
b) Which, having, arisen, such party could not reasonably have avoided or overcome,and
c) Which is not substantially attributable to the other party.
Special Risks are
a) War, hostilities, whether war be declared or not, invasion, act of foreign enemies.
b) Rebellion, Revolution, Insurrection, orMilitary or usurped power or Civil war.
c) Ionizing raditions or contamination by ratio activity from any nuclear fuel or from any nuclear waste from combustion of nuclear fuel, radioactive toxic explosive or other hazardous properties of explosive nuclear assembly or nuclear component thereof.
d) Pressure waves caused by air craft or any other aerial device traveling at sonic or supersonic speed.
e) Riot, commotion or disorder, unless solely restricted to employees of the contractor or of his sub-contractors and arising from the conduct or the work.
f) Floods, tornados, earth quakes and landslides.
g) Munitions of war, explosive materials, ionizing radiation or contamination by radio-activity, except as may be attributable to the Contractor’s use of such munitions, explosives, radiation or radio-activity,and
h) Natural catastrophe such as earthquake, hurricane, typhoon or volcanic activity.
4.4.0 EMPLOYER'S SPECIAL POWER OF FORECLOSURE OF THE WORKS
If at any time after the issue of Work Order, the Employer shall for any reason whatsoever
not require the whole or part of the Works to be carried out, the Employer shall give
notice in writing of the fact to the Contractor, who shall have no claim to any payment of
compensation or otherwise howsoever on account of any profit or advantage, which he
might have derived from execution of the Works in full but which he did not derive in
consequence of the foreclosing of the Works. He shall be paid at Contract Rates for the
portion of Works executed including such additional works e.g. clearing of the Site, etc. as
may be rendered necessary by the said foreclosing.
![Page 99: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/99.jpg)
99 | P a g e
4.5.0. Arbitration
4.5.1.0. All disputes or difference of any kind whatsoever.which shall at any time arise
between the parties hereto touching or concerning the works or the execution or
maintenance thereof of this contract or the rights touching or concerning the works or the
execution of maintenance thereof of this contract or the construction remaining operation
or effect thereof or to the right or liabilities of the parties or arising out of or in relation
thereto whether during or after determination foreclosure or breach of the contract (other
than those in respect of which the decision of any person is by the contract expressed to
be final and binding)shall after written notice of 60 days by either party to the contract to
the other of them and to the Employer hereinafter mentioned be referred for adjudication
to a Sole Arbitrator to be appointed as per the provisions of law. By the employer who
shall be the fellow of institution of India (or former judge of Bombay high court or
Supreme Court of India)
If the Arbitrator so appointed is unable or unwilling to act or resigns his appointment or
vacates his office due to any reason whatsoever another Sole Arbitrator shall be appointed
as per provision above.
The work under the Contract shall, however, have to continue during the Arbitration
proceeding and no payment otherwise due to the Contractor shall be withheld on account
of such proceedings.
It shall be condition precedent to arbitration that the Contractor shall deposit 5% of the
cost of claims required to be adjudicated as administrative charges for the bank to
participate with the proceedings. This shall not prejudice order of arbitral tribunal for
payment of fees and/or award of cost, if any,
![Page 100: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/100.jpg)
100 | P a g e
UNFORESEEABLE DIFFICULTIES
Except as otherwise stated in the contract:
a) the contractor shall be deemed to have obtained all necessary information as to risks,
contingencies and other circumstances which may influence or affect the works;
b) by signing the contract, the contractor accepts total responsibility for having foreseen all
difficulties and costs of successfully completing the works;and
c) the contract price shall not be adjusted to take account of any unforeseen difficulties or
costs;
* * * * *
![Page 101: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/101.jpg)
101 | P a g e
GENERAL CONDITIONS OF CONTRACT VOLUME – I
PART – V
GENERAL OBLIGATIONS OF THE CONTRACTOR
![Page 102: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/102.jpg)
102
GENERAL CONDITIONS OF CONTRACT
VOLUME – I
PART – V
GENERAL OBLIGATIONS OF THE CONTRACTOR
CONTRACTOR'S GENERAL RESPONSIBILITIES
The Contractor shall, subject to the provisions of the Contract and with due care and diligence,
execute, maintain and complete the Works remedy any defects there in accordance with the
provisions of the Contract and provide at its sole cost all labour, including the supervision
thereof, materials, constructional plant and all other things, whether of a temporary or
permanent nature, required in and for such design, execution and maintenance, completion and
remedying of any defects so far as the necessity for providing the same is specified in or is
reasonably to be inferred from the Contract.
The Contractor shall take full responsibility for the adequacy, stability and safety of all site
operations and methods of construction, provided that the Contractor shall not be responsible,
except as may be expressly provided in the Contract, for the design or specification of the
permanent works, or for the design or specification of any temporary works prepared by the
PMC/ Architect / Associate Consultants, and / or other consultants appointed by the Employer.
The contractor shall carry out all the works strictly in accordance with the drawings, details and
instructions of the PMC/ARCHITECT. In the opinion of the PMC/ARCHITECT if any changes are to
be made, the same shall be intimated in writing to the Contractor and the Contractor shall carry
out the same.
The Contractor shall be responsible for all injury or damage to persons, animals, or things, and
for all damage to property or death of any person under a contract of service with the
Contractor, which may arise from any factor / omission on the part of the Contractor or any Sub-
Contractor or any nominated Sub-Contractor or any of their employees. The liability under the
clause shall cover also, interalia any damage to structures, whether immediately adjacent to the
Works or otherwise, any damage to roads, streets, footpaths, bridges as well as damage caused
to the building and other structures and Works forming the subject matter of this Contract. The
Contractor shall indemnify and keep indemnified the Employer and hold him harmless in respect
of all and any loss and expenses arising from any such injury or damage to persons or property
or death of any person under a contract of service with the contractor as aforesaid and also
![Page 103: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/103.jpg)
103
against any claim made in respect of injury or damage, whether under any statute or otherwise
and also in respect of any award of compensation or damage consequent upon such claims.
Setting Out
The Contractor shall be responsible for
a) The accurate setting-out of the works in relation to original points, lines and levels of
reference given by the PMC/Architect in writing.
b) The correction,subject as above mentioned, of the position,levels,dimensions and
alignment of all parts of the work, and
c) The provision of all necessary instruments, appliances and labour in connection with
the foregoing responsibilities.
If, at any time during the progress of the Works, any error shall appear or arise in the
position, levels, dimensions or alignment of any part of the Works, the Contractor, on being
required so to do by the PMC/Architect, shall, at his own cost, rectify such error to the
satisfaction of the Architect, unless such error is based on incorrect data supplied in writing
by the PMC/Architect, in which case the expense of rectifying the same shall be borne by the
Employer. The checking of any setting-out or of any line or level by the PMC/Architect shall
not in any way relieve the Contractor of his responsibility for the correctness thereof and
the Contractor shall carefully protect and preserve all bench- marks, sight-rails, pegs and
other things used in setting-out the works.
CONTRACT AGREEMENT
The Contractor shall, when called upon to do so by the Employer, enter into and execute a
formal contract agreement as per enclosed draft as stated in tender form within time
specified after the award of the works or as specified in works order and shall pay for all
stamps and legal expenses incidental thereto.
GIVING NOTICES AND PAYMENT OF FEES
This contract shall, in all respects, be construed and operated as an Indian Contract and shall
be subject to Indian laws in force from time to time. The Contractor should conform to all
laws of the land in relation to the Works, and the regulations and bye- laws of any authority
and of any water or electric supply companies with whose systems the structure is proposed
to be connected.
![Page 104: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/104.jpg)
104
The Contractor shall give all notices required by the said acts, regulations or bye-laws
and pay all fees that may be properly chargeable in connection therewith and lodge
the receipts with the PMC/ARCHITECT. The Contractor shall protect and indemnify
the Employer against all claims or liabilities arising from his actions or omissions in
violation of such laws, ordinances, regulations and by-laws by him.
5.3.2 Compliance with Statutes, Regulations,etc.
The Contractor shall conform in all respects with the provisions of any such Statute,
Ordinance or Law as aforesaid and the regulations or bye-laws of any local or other
duly constituted authority which may be applicable to the Works and with such rules
and regulations of public bodies and companies as aforesaid and shall keep the
Employer indemnified against all penalties and liabilities of every kind for breach of
any such Statute, Ordinance or Law, Regulation or Bye-Laws.
PROGRAMME
Programme to be furnished Within the time stated in the Appendix TF to tender form, the Contractor shall, after the acceptance of his Tender, submit to the PMC/ARCHITECT for his approval a programme showing the order of procedure in which he proposes to carry out the Works. The Contractor shall whenever required by the PMC/ARCHITECT, also provide in writing for his information a general description of the arrangements and methods which the Contractor proposes to adopt for the execution of theWorks.
The Contractor shall submit to the PMC/ARCHITECT for his approval the Programme which shall
contain the following:
a) The order in which the Contractor proposes to carry out the Works (including design,
manufacture,delivery to Site,erection,testing and commissioning),
b) the times when submission and approval of the Contractor's Drawings are required,
c) the times by which the Contractor requires theEmployer:
(i) to furnish any Employer'sDrawings,
(ii) to provide access to the Site,
(iii) to have completed the necessary civil engineering work (including foundations for the
Plant) and
(iv) to have obtained any import licenses,consents,wayleaves and approvals necessary for the
purpose of the Works.
![Page 105: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/105.jpg)
105
The programme could also be crucial in determining the disrupting effect of any delays which
may occur during the course of the Contract and whether the Contractor is entitled to an
extension of time.
Alteration to Programme
If at any time should it appear to the PMC/ARCHITECT that the actual progress of the Works
does not conform to the approved programme referred to in sub-clause 5.4.1, the Contractor
shall produce, at the request of the PMC/ARCHITECT, a revised programme showing the
modifications to the approved programme necessary to ensure completion of the Works within
the time for completion as defined in clause 2.2.0 hereof. The revised programme shall be
submitted within 10 days from the date of the Architect’s letter. In the event that the
Contractor defaults in submitting the revised programme within 10 days as provided
hereinabove then he shall be liable to pay liquidated damages at Rs.2000/- per day for the delay
for first seven working days and beyond that at the rate of Rs.5000/- per day for a further
period of seven days. Beyond which the PMC/Architect/Employer shall be entitled to determine
the Contract for noncompliance by the contractor of the PMC/ARCHITECT/EMPLOYER’S
decision.. No material alteration to the Programme shall be made without the approval of the
PMC/ARCHITECT.
The submission to and approval by the PMC/ARCHITECT of such programmes or the furnishing
of such particulars shall not relieve the Contractor of any of his duties or responsibilities under
the Contract.
Revision of Programme
If the progress of the Works does not conform to the Programme, the PMC/ARCHITECT may
instruct the Contractor to revise the Programme and the Contractor is under obligation to do so
within 7 days or instruction. This is applicable even if it is due to changes to other agencies work
at site for whatever reasons.
5.5.0 FOSSILS ETC.
All fossils, coins, articles of value or antiquity and structures and other remains or things of
geological or archaeological interest discovered on the site of the Works shall, as between the
Employer and the Contractor, be deemed to be the absolute property of the Employer. The
Contractor shall take reasonable precautions to prevent his workmen or any other persons from
removing or damaging any such article or thing and shall immediately, upon discovery thereof,
and, before removal, acquaint the PMC/Architect of such discovery and carry out, at the
expense of the Employer, the PMC/Architect's orders as to the disposal of the same.
![Page 106: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/106.jpg)
106
5.6.0 PATENT RIGHTS ANDROYALTIES
The Contractor shall save harmless and indemnify the Employer from and against all claims and
proceedings for or on account of infringement of any patent rights, design trademark or name
or other protected rights in respect of any constructional plant, machine work, or material used
for or in connection with the Works or any of them and from and against all claims, proceedings,
damages, costs, charges and expenses whatsoever in respect thereof or in relation thereto.
Except where otherwise specified, the Contractor shall pay all tonnage and other royalties, rent
and other payments or compensation, if any, for getting stone, sand, gravel, clay or other
materials required for the Works or any of them. Also the contractor shall be responsible to
obtain license/permission for disposal of excavated material as per local law.The cost of license
fee and other charges if any shall be paid by the Contractor. All royalties or other sum payable in
respect of the supply and use of any patented articles, processes or inventions shall be deemed
to have been included in the Contract Price.
OPPORTUNITIES FOR OTHER CONTRACTORS
The PMC/ARCHITECT has the right to appoint a Commissioning Agent for overseeing the
testing and commissioning of various equipments and all the relevant agencies would
extended all support to them.
The Contractor shall, in accordance with the requirements of the PMC/ARCHITECT, afford all
reasonable opportunities for carrying out their work to any other contractors employed by
the Employer and their workmen and to the workmen of the Employer and of any other duly
constituted authorities, who may be employed in the execution on or near the site, of any
work not included in the Contract or of any contract which the Employer may enter into in
connection with or ancillary to the Works. If, however, the Contractor shall, on the written
request of the PMC/ARCHITECT, make available to any such other contractor, or to the
Employer or any such authority, any roads or ways for the maintenance of which the
Contractor is responsible, or permit the use by any such service of the Contractor's scaffolding
or other plant on the site, or provide any other service of whatsoever nature for any such
service, the Employer shall pay to the Contractor in respect of such use or service such sum or
sums as shall, in the opinion of the PMC/ ARCHITECT, be reasonable.
![Page 107: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/107.jpg)
107
5.8.0 INTERFERENCE WITH TRAFFIC AND ADJOINING PROPERTIES
All operations necessary for the execution and completion of the Works and the remedying
defects therein shall, so far as compliance with the requirements of the Contract permits, be
carried on so as not to interfere unnecessarily or improperly with the convenience of the public,
or the access to use and occupation of public or private roads and footpaths to or of properties
whether in the possession of the Employer or of any other person. The Contractor shall save
harmless and indemnify the Employer in respect of all claims, proceedings, damages, costs,
charges and expenses whatsoever arising out of, or in relation to, any such matters in so far as
the Contractor is responsible therefore.
5.9.0 CONTRACTOR TO KEEP SITE CLEAR
During the progress of the Works, the Contractor shall keep the Site reasonably free from all
unnecessary obstructions and shall store or dispose off any constructional plant and surplus
materials and clear away and remove from the site any wreckage, rubbish or temporary Works
no longer required.
5.10.0 CLEARANCE OF SITE ON COMPLETION
On the completion of the Works, the Contractor shall clear away and remove from the site all
constructional plant, surplus materials, rubbish and Temporary Works of every kind, and leave
the whole of the Site and works clean and in a workman like condition to the satisfaction of the
PMC/ARCHITECT.
5.11.0 WATCHING AND LIGHTING
The Contractor shall, in connection with the Works, provide and maintain at his own cost all
lights, guards, fencing and watching when and where necessary or as required by the
PMC/ARCHITECT, or by any duly constituted authority, for the protection of the Works, and, for
the safety and convenience of the public or others.
![Page 108: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/108.jpg)
108
SITE OFFICE FOR THE EMPLOYER
The Contractor shall provide, fit – up and maintain in at approved position proper temporary
office accommodation for his staff and shall also provide air-conditioned office
accommodation (with furniture) and assistance for maintaining the same for Client’s officers,
PMC, Architect as per requirement of Client. Also a room for site meeting should be provided.
Contractor’s offices shall be open at all reasonable working hours to receive instructions,
notices or communications and clear away on completion and make good all works
distributed.
5.12..2 Telephone : The Contractor shall maintain a Landline and/or Mobile phone and fax
facility at site at his own cost and shall pay all bills for calls and maintenance. The telephone
shall be installed by the Contractor maximum within 30 days from the date of commencement
of work and the Contractor shall allow the use of the telephone to all other Contractors
engaged on the works, if and a required and may recover proportionate call charges from them.
He shall also allow free use of the telephone to the PMC/Client/Architect/Structural Consultant
and their representatives and owner’s, for phone calls in connection with thework.
SAFETY PRECAUTIONS AND SAFETY PROCEDURES
Safety Precautions
The Contractor shall observe all applicable regulations regarding safety on the Site.
Unless otherwise agreed, the Contractor shall, from the commencement of work on Site until
taking over provide:
a) fencing, lighting, guarding and watching of the Works,and
b) temporary roadways, footways, guards and fences which may be necessary for the
accommodation and protection of owners and occupiers of adjacent property, the public and
others.
This Sub-Clause requires the Contractor to observe all applicable regulations regarding safety
on Site. Quite apart from any statutory regulations that may be applicable to the Contractor's
construction activities the Employer may well have his own Site safety regulations, copies of
which should be provided to the Contractor at the tender stage in order that he may allow for
any extra cost of compliance in his prices. If a "permit to work" system is in operation at the
Site, full details should be given at the tender stage. The Employer should also provide the
Contractor with a plan of the Site identifying any areas where hazardous material may be
stored or where any special care may need to be taken by the Contractor and his employees to
prevent an accident or injury.
![Page 109: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/109.jpg)
109
The Sub-Clause also sets out the Contractor's general obligations in relation to the security of
the Site itself and requires him to provide, unless otherwise agreed, fencing, lighting, guarding
and watching of the Works and any temporary roadways, footways, guards, fences necessary
for the protection of adjoining owners' other property and the public.
5.13.2 Safety Procedure
Contractor should submit a safety procedure prior to start of the construction activities for
Employer review. The procedure should include the safety measures to be taken during
construction work, firefighting / safety equipment which will be provided, number of safety /
fire officers and their role, periodical exercise on awareness of workers towards safety.
Familiarization of workers with safety equipment, teams for firefighting etc. In case of any
emergency, contractor should immediately mobilize all resources to combat the emergency and
co-ordinate with Employer suitably.
Contractor should ensure that all the contactor’s personnel have undergone the approved basic
training on fire fighting and sea survival before deployment.
In case of any accident at site causing injury to personnel, contractor shall inform ARCHITECT
immediately. Contractor shall also arrange for pickup and immediate medical attention for the
injured personnel.
5.14.0 MATERIALS AND WORKMANSHIP
Manner of Execution
All materials, Plant and workmanship shall be:
a) of the respective kinds described in the Contract and in accordance with the
PMC/ARCHITECT’s instruction and
b) Subjected from time to time to such tests as the PMC/ARCHITECT may require at the
place of manufacturer, fabrication preparation, or on the Site or at such other place or
places as may be specified in the Contract,or at all or any of such places.
The Contractor shall provide such assistance, labour, electricity, fuels, stores, apparatus and
instruments as are normally required for examining, measuring and testing any materials or
Plant and shall supply samples of materials, before incorporation in the Works, for testing as
may be selected and required by thePMC/ARCHITECT.
Samples
The Contractor shall be responsible for arranging and providing all samples, catalogues, details
as required by the specification to the approval of the PMC/ ARCHITECT. Method shall be as
detailed in Special Condition part 9.5.6. These shall be submitted 4 weeks prior to material is
![Page 110: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/110.jpg)
110
to be ordered. The approval shall be obtained in writing. The cost of samples, its testing if
required prior to approval shall be at the cost of the Contractor.
Cost of Test
The Contractor shall be required to carry out all test as directed by the PMC/ ARCHITECT at his
cost. The Contractor shall carry out all testing in the presence of the PMC/ARCHITECT’s
representatives and results jointly noted with due Certification by both i.e. the Contractor and
the PMC/ARCHITECT’s representative. The cost of setup arranging, visiting, transporting and
recurring expenses of site laboratory shall be borne by the Contractor within his quoted price.
Covering up Work
The Contractor shall give the PMC/ARCHITECT full opportunity to examine, measure and test
any work on Site which is about to be covered up or put out of view.
The Contractor shall give due notice to the PMC/ARCHITECT whenever such work is ready for
examination, measurement or testing.
The PMC/ARCHITECT shall then, unless he notifies the Contractor that he considers it
unnecessary, without unreasonable delay carry out the examination, measurement or
testing.
Uncovering Work
If so instructed by the PMC/ARCHITECT, the Contractor shall expose any parts of the Works. The
Contractor shall reinstate and make good such parts to the PMC/ARCHITECT's satisfaction.
Independent Inspection
The PMCARCHITECT may, if so provided in the Contract or with the Contractor's consent,
delegate inspection and testing of Plant to an independent inspector.
Any such delegation shall be effected in the manner required by the Contract, and for this
purpose such independent inspector shall be considered as an PMC/ARCHITECT's
Representative. Notice of such appointment (being not less than 14 days) shall be given by the
PMC/ARCHITECT to the Contractor.
Inspection and Testing During Manufacture
The PMC/ARCHITECT shall be entitled during manufacture to inspect, examine and test the
materials and workmanship and check the progress of manufacture of all Plant to be supplied
under the Contract. This shall take place on the Contractor's premises during working hours. If
Plant is being manufactured on other premises, the Contractor shall obtain permission for the
PMC/ARCHITECT to carry out such inspection, examination and testing on those premises.
![Page 111: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/111.jpg)
111
No such inspection, examination or testing shall release the Contractor from any obligation
under the Contract.
Dates for Inspection and Testing
The Contractor shall agree with the PMC/ARCHITECT the time and place for the testing of any
Plant as provided in the Contract. The PMC/ARCHITECT shall give the Contractor 24 hours’
notice of his intention to attend the tests.
Rejection
If as a result of the inspection, examination or testing referred here above, the
PMC/ARCHITECT decides that any Plant is defective or otherwise not in accordance with the
Contract, he may reject such Plant and shall notify the Contractor thereof immediately.
The Contractor shall then with all speed make good the defect or ensure that any rejected
Plant complies with the Contract.
If the PMC/ARCHITECT requires such Plant to be retested, the tests shall be repeated under
the same terms and conditions. AII costs incurred by the Employer by the repetition of the
tests shall be deducted from the Contract Price.
Permission to Deliver
The Contractor shall apply in writing to the PMC/ARCHITECT for permission to deliver Plant or
Contractor's Equipment to the Site. No Plant or Contractor's Equipment may be delivered to
the Site without the PMC/ARCHITECT's written permission.
The Contractor shall be responsible for the reception on Site of the Plant and Contractor's
Equipment.
Record of Materials
The Contractor shall maintain a record in the format specified by the PMC/ARCHITECT of all
materials brought to the Site. The Engineer may carry out inspection at any time to check the
records and whether they have been properly stored.
Reconciliation of Materials
The Contractor shall submit material reconciliation statements supported by complete
calculations. Recovery for unreconciled quantity will be made from the Contractor, on the
basis of sub- clause "a" and "b" of this clause.
(a) Wastage Limits
While accounting for the materials issued by the Employer, the wastage will be
considered up to the limits specified in schedule 'A'.
![Page 112: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/112.jpg)
112
(b) Penalty for exceeding wastage limits
For any wastage above the limits given in above clause 5.15.10 (a) the recovery will be
made at rates stated in Schedule ‘A’.
5.15.0 STANDARDS AND CODES OF PRACTICE
Work shall be carried out to Indian Standards and Code of practices. In absence International
standards shall be followed. These shall be latest issue. List given in contract documents is not to
be considered as conclusive and is for reference, guidance only. Any discrepancies / conflict
noticed shall be directed to the ARCHITECT for his direction / approval. However as a general
rule more stringent specification shall take precedence.
PUBLICITY
Site Display
The Contractor on award of work shall submit to the Engineer details about the type of display
board he proposes to put up at site. Its design, matter, sizes, etc. shall be approved by the
ARCHITECT with prior approval of the Employer.
Media Display
All requested information concerning the works by the news media or other organization (s) or
individual (s) shall be referred to the Employer. All plans for the publicity by the Contractor, his
Sub-Contractor or his suppliers shall be submitted to the Employer for his approval.
5.17.0 ERRORS AND OMISSION
Any apparent errors or omissions in drawings or specifications or instructions by the
PMC/Architect shall be brought to the notice of the PMC/ARCHITECT. The PMC/ARCHITECT
shall correct such error or omissions necessary to fulfill the interest of plans and
specifications. The Contractor shall neither be eligible for any additional cost, time etc. on
this account nor shall he be permitted to take any advantage thereof.
* * * * *
![Page 113: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/113.jpg)
113
GENERAL CONDITIONS OF CONTRACT VOLUME – I
PART – VI
SITE SUPERVISION
![Page 114: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/114.jpg)
114
GENERAL CONDITIONS OF CONTRACT
VOLUME – I
(PART – VI)
SITE SUPERVISION
PROJECT MANAGEMENT CONSULTANT PMC
The Project Manager Consultant (PMC) shall carry out duties as listed hereunder
along with associated consultant appointed by him or by the Employer in issuing
decisions, certificates and orders in accordance with the Contract. He may in his
absolute discretion and from time to time issue further Drawings and / or written
instructions which are here after collectively referred to as "PMC's Instructions" in
this regard to :
(i) The variation or modification of the design, quality or quantity of works or the
addition or omission or substitution of any work.
(ii) Any discrepancy in the Drawings or between the Bills of Quantities and/or Drawings
and/or Specification.
(iii) The removal from the Site of any materials brought thereon by the Contractor
and the substitution of any other material thereof.
(iv) The removal and/orre-execution of any Works executed by the Contractor.
(v) The dismissal from the Works of any persons employed thereupon.
(vi) The opening up for inspection of any Work coveredup.
(vii) The amending and making good of any defects under clause 2.8.6 hereof
PMC's instructions shall be final and binding on the Contractor and without any appeal.
PMC
PMC shall watch, monitor, administer and coordinate execution, supervision of the Works,
review and demand test reports and examine any materials to be used or workmanship
employed in connection with the Works record and check measurement. He shall have no
authority to relieve the Contractor of any of his duties or obligations under the Contract,
nor to order any Work involving delay or any extra payment by the Employer, nor to make
any variation of in the Works, except as expressly provided hereunder or elsewhere in the
Contract.
![Page 115: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/115.jpg)
115
The PMC may from time to time delegate in writing any of the powers and authority
vested in him and shall furnish to the Contractor and to the Employer all such written
delegation of powers and authorities. Wherever the term PM is used in this contract, it
shall include his authorized representative in so far as the powers are delegated to him.
All such instructions or approvals given by the PMC to the Contractor shall bind the
Contractor and the Employer as though it had been given by the PMC provided always as
follows,
(a) Failure of the Employer of PMC to disapprove any work or materials shall not
prejudice the power of the PMC thereafter to disapprove such work or materials
and to order the pulling down, removal or breaking up thereof.
(b) If the Contractor shall be dissatisfied by reason of any decision of the Employer of
PMC or any authorized Representative, he shall be entitled to refer the matter to
the PMC, who shall there upon confirm, reverse or vary such decision.
No Engineer or any representative of employer including PMC / Resident Engineer
shall have authority to change scope as to time and cost of the contract. This shall
only be changed or altered or amended only under signature of the contract
accepting authority.
CONTRACTOR'S SUPERINTENDENCE
The Contractor shall give or provide all necessary superintendence during the execution
of the Works and as long thereafter as the PMC may consider necessary for the proper
fulfilling of the Contractor's obligations under the Contract. The Contractor, or a
competent and authorized agent or representative approved of in writing by the PMC,
which approval may at any time be withdrawn, is to be constantly on the Works and
shall give his whole time to the superintendence of the same. If such approval shall be
withdrawn by the PMC, the Contractor shall, as soon as is practicable, having regard to
the requirement of replacing himas hereinafter mentioned, after receiving written
notice of such withdrawal, remove the agent from the Works and shall not thereafter
employ him again on the Works in any capacity and shall replace him by another agent
approved by the PMC. Such authorized agent or representative shall receive, on behalf
of the Contractor, directions and instructions from the PMC or, subject to the limitations
of clause 6.1.0 hereof, the PMC's representative.
Contractor's Design & Drawings
The Contractor is responsible to develop design based on parameters and guidelines
provided in the tender for various activities of the construction. It shall be in the form of
![Page 116: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/116.jpg)
116
descriptive and perspective.
The Contractor shall be obliged to prepare a list along with statement showing when and
how proposes to carry out these activities. The Contractor shall submit all details along with
design well in time for consideration and approval of PMC.
a) Design, drawings and details along with calculations where required shall be submitted
minimum 30 days in advance of starting of activity at site.
b) Methodology of construction work front drawings, details which are purely from
technical approach and site ease shall be submitted at least 15 days in advance of
ordering of materials or its useatsite.
c) Details shall include required samples, mockups or prototype samples in numbers as
required and shall be submitted atleast 15 days in advance of its use at site.
d) Time period for submission of such items shall be more where time for testing at site or
at factory or at outside laboratory is required. Minimum period required by the PMC is
14 days a detailed hereunder and the Contractor shall add the same to obtain approval
within time not to get workdelayed.
The PMC shall signify his approval or disapproval thereof. If he fails to do so within the
time given in the Contract or the Programme or if no time limit is specified, within 14
days of receipt, they shall be deemed to be approved.
Approved drawings, samples and models shall be signed or otherwise identified by the
PMC.
The Contractor shall supply additional copies of approved drawings in the form and
numbers stated in the Contract.
Contractor's Drawings are an integral part of the Contract. Although the Contractor is
responsible for the design of the Works he is required to submit his Drawings to the
PMCforapprovalinaccordancewith thedetailsgivenintheprogrammeorelsewhere in the
Contract. The Contractor must also provide the PM as the work proceeds with gen- eral
arrangements and detailed works drawings as specified in the Contract or as the PMC
may require. In general, the PMC has an unfettered right to request the Contractor to
provide drawings and information subject only to Sub-Clause 6.2.2 which provides that
unless otherwise specified the Contractor does not have to submit for approval, inter
alia, confidential manufacturing drawings (shop drawings).
![Page 117: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/117.jpg)
117
Consequences of Disapproval of Contractor's Drawings
Any Contractor's Drawings which the PMC disapproves shall be forthwith modified to meet
the requirements of the PM and shall be re-submitted.
Approved Contractor's Drawings
Approved Contractor's Drawings shall not be departed from except as provided in Clause 3.8.1.
Once Contractor's Drawings have been approved by the PM or deemed to have been
approved by the PM under the provisions of Sub-Clause 6.2.2, they may not be departed from
either by the Contractor or by the PM. If changes are required, these must be made by
Variation Order under the provisions of Clause 3.8.1 (Variations) and subject to the specific
variation order procedure laid down in thatClause.
Inspection of Contractor's Drawings
The PMC shall have the right at all reasonable times to inspect, at the Contractor's premises,
all Contractor's Drawings of any part of the Works.
Erection Information
The Contractor shall provide, within the times stated in the Contract or in the Programme,
drawings showing how the Plant is to be affixed and any other information required for:
(a) preparing suitable foundations or other means of support,and
(b) providing suitable access on the Site for the Plant and any necessary equipment to
the place where the Plant is to be erected,and
(c) making necessary connections to the Plant.
Operation and Maintenance Manuals
The Contractor shall be required to submit 4 sets of provisional operation manuals along with
executed drawings (as built drawings) for inspection testing and commissioning as per terms
of Contract. Further before the Works are taken over in accordance with Clause 2.7.0 the
Contractor shall supply four final sets of operation and maintenance manuals together with
drawings of the Works as built. These shall be in such details as will enable the Employer to
operate, maintain, adjust and repair all parts of the Works.
Unless otherwise stated in Special Conditions the manuals and drawings shall be in the ruling
language, and in such form and numbers as stated in the Contract.
Unless otherwise agreed,the Works shall not be considered to be completed for the purposes
of taking over until such manuals and drawings have been supplied to the Employer.
![Page 118: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/118.jpg)
118
Employer's Use of Contractor's Drawings
Contractor's Drawings may be used by the Employer for no other purpose than completing,
operating, maintaining, adjusting and repairing the Works.
Contractor's Use of Employer's Drawings
The Employer's Drawings, Specification and other information submitted by the Employer or
the PMC to the Contractor shall remain the property of the Employer. They shall not, without
the consent of the Employer, be used, copied or communicated to a third party by the
Contractor unless necessary for the purposes of the Contract.
Manufacturing Drawings
Unless otherwise specified in Special conditions the Contractor shall not be required to
disclose to the Employer or the PMC the Contractor's confidential manufacturing drawings,
designs, know-how or manufacturing practices, processes or operations.
Unless specified in Special conditions the Contractor is not required to disclose to the PMC
details, confidential manufacturing drawings, design, know-how or manufacturing practices,
processes or operations. Such matters are the "stock in trade" of the Contractor and there can
be very little justification for requiring their disclosure save in the most exceptional
circumstances.
Errors in Contractor's Drawings
The Contractor shall be responsible for any errors or omissions in the Contractor's Drawings
unless they are due to incorrect Employer's Drawings or other written information supplied by
the Employer or the PMC. Approval by the PMC of the Contractor's Drawings shall not relieve
the Contractor from any responsibility under this Sub-Clause.
The Contractor shall bear any costs he may incur as a result of delay in providing Contractor's
Drawings and other information or as a result of errors or omissions therein, for which the
Contractor is responsible.
The Contractor shall at his own cost carry out any alterations or remedial work necessitated
by such errors or omissions for which he is responsible and modifies the Contractor's
Drawings and such other information accordingly.
The performance of his obligations under this Clause shall be in full satisfaction of the
Contractor's liability under this Clause but shall not relieve him of his liability under Sub-
Clause 2.6.0 Compensation for delays on the part of contractor / liquidate damages.
![Page 119: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/119.jpg)
119
The Contractor is responsible for any errors or omissions in the Contractor's Drawings and must
at his own cost carry out any alterations or remedial work caused thereby. This includes
modification of the drawings and of any information that may be based thereon.
Errors by Employer or PMC
The Employer shall be responsible for the Employers Drawings and for other written
information supplied by the PM and for the details of special work specified by either of them.
If such Employers Drawings, information or details are incorrect and necessitate alterations of
the work, the Employer shall pay the Contractor the cost of the alterations as certified by the
PMC.
Errors by Contractor
If errors, omissions, ambiguities, inconsistencies, inadequacies or other defects are found in
the contractor’s documents, they and the works shall be corrected at the contractor’s cost,
notwithstanding any consent or approval under this clause.
CONTRACTOR'S EMPLOYEES
The Contractor shall provide and employ on the site in connection with the execution and
maintenance of the Works,
(a) only such technical assistants as are skilled and experienced in their respective callings
and such sub-agents, foremen and leading hands as are competent to ensure proper
supervision to the work they are requiredtosupervise
(b) such skilled, semi-skilled and unskilled labour as is necessary for the proper and
timely execution, maintenance of the Works and timely fulfilling of the contractor’s
obligation under the Contract and
Unauthorized persons shall not be allowed on the Site. The Contractor shall instruct all
such persons to keep out and shall take steps to prevent trespassing.
The PMC shall be at liberty to object to and require the Contractor to remove forthwith from
the Works any person employed by the Contractor in or about the execution or maintenance
of the Works who, in the opinion of the PMC, misconducts himself, or is incompetent or
negligent in the proper performance of his duties, or whose employment is otherwise
considered by the PMC to be undesirable and such person shall not be again employed upon
the Works without the written permission of the PMC.
![Page 120: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/120.jpg)
120
Any person so removed from the Works shall be replaced as soon as possible but not later
than 3 days from the date of the removal by a competent substitute approved by the RE.
The Contractor shall appoint at the site a Project Manager and a Senior Engineer/Billing
Engineer duly graduated and experienced to the satisfaction of the PMC/Architect / EMPLOYER
and shall continue him in such appointment at least up to three months after the grant of the
Virtual Completion Certificate to him. The PMC/Architect /EMPLOYER shall be entitled to
approve or disapprove without assigning reasons the appointment of such Engineer proposed
by the Contractor. This condition shall be reckoned as being the essence of the Contract and its
breach shall make the Contract revocable at the option of the Owner.
The Project Manager shall be assisted by a Senior Engineer cum Billing Engineer and at least two
Engineer one for Civil work and the other for MEP work and two supervisors in the respective
disciplines as required for the smooth and satisfactory execution of the work. The above
resources are the minimum required till the project completion. Substitutes provision to be
made during the absence of Engineers or supervisors for more than 4 days leave. However as
the work progress number of Engineers/Supervisors additionally required shall be provided to
meet up the quality and target for the stipulated completion of the project.
The Project Manager so appointed shall co-ordinate the execution of the work by Contractors of
other trades in general and shall perform the following functions in particular:
i) The Project Manager shall have adequate knowledge about the various
service involved in the job and shall take written instructions from PMC/Client and must close
those instruction timely and appreciate the importance of various interface activities to be
performed by the main civil work contractors in desire sequence so as not to hold up the work
of the service contractors as regards commissioning and testing of their respectiveservice.
ii) The Project Manager in-charge of co-ordination, shall be responsible for
providing all the necessary support required to be given by the main civil work contractors by
virtue of the Contract, to the Commissioning Engineers pressed into service by the various
services Contractor for the purpose of commissioning and testing of their respectiveservices.
The Project Manager should preferably have past experience of shouldering similar
responsibilities to appreciate the importance of this final critical phase of the Project where
utmost co-ordination is required for cutting down the delays in successful commissioning of the
entirefacility.
![Page 121: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/121.jpg)
121
6.4.0 WORK TO BE TO THE SATISFACTION OF PMC
Save in so far as it is legally or physically impossible, the Contractor shall execute and
maintain the Works in strict accordance with the Contract and to the satisfaction of the
PMC and shall comply with and adhere strictly to the PMC's instruction and directions on
any matter whether mentioned in the Contract or not, touching or concerning the Works.
The Contractor shall take instructions and directions only from the PMC or, subject to the
limitations referred to in clause 6.1.0 hereof, from thePMC.
INSPECTION OF OPERATIONS
Site Access
It is for the Contractor to provide the safe and guarded access for the PMC as detailed in
the safety code. For inspection of works, the Contractor shall arrange required ladders,
scaffolding materials, steel measuring tapes, plumb levels, the odolite or any other
instrument required to the satisfaction of the RE for his use at site at the Contractors cost.
The PMC and any person authorized by him shall at all times have access to the Works
and to all workshops and places where work is being prepared or from where materials,
manufactured articles or machinery are being obtained for the Works and the Contractor
shall afford every facility for and every assistance in or in obtaining the right to such
access.
Examination of Work before Covering up.
No Works shall be covered up or put out of view without the approval of the
PMC/ARCHITECT and the Contractor shall afford full opportunity for the PMC/ARCHITECT
to examine and measure any Works which is about to be covered up or put out of view
and to examine foundations before Permanent Work is placed thereon. The Contractor
shall give due notice to the PMC whenever any such Works or foundations is or are ready
or about to be ready for examination and the Engineer shall, without unreasonable delay,
unless he considers it unnecessary and advises the Contractor accordingly, attend for the
purpose of examining and measuring suchwork or of examining such foundations.
![Page 122: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/122.jpg)
122
Uncovering and Making Openings
The Contractor shall uncover any part or parts of the Works or make openings in or through
the same as the RE may from time to time direct and shall reinstate and make good such
part or parts to the satisfaction of the PMC. If any such part or parts have been covered up
or put out of view after compliance with the requirement of sub- clause 6.6.3 and are found
to be executed in accordance with the Contract, the expenses of uncovering, making
openings in or through, reinstating and making good the same shall be borne by the
Employer, but in any other case all costs shall be borne by the Contractor.
Removal of Improper Work and Materials
The PMC shall, during the progress of the Works, have power to order in writing from time
to time,
(a) the removal from the site, within such time or times as may be specified in the
order,of any materials which, in the opinion of the PMC,are not in accordance with
the Contract,
(b) the substitution of proper and suitable materials,and
(c) the removal and proper re-execution, notwithstanding any previous test thereof or
interim payment therefore, of any work which in respect of materials or
workmanship is not, in the opinion of the PMC, in accordance with theContract.
6.6.0 DEFAULT OF CONTRACTOR INCOMPLIANCE
In case of default on the part of the Contractor in carrying out such an order, the PM shall
be entitled to employ and pay other persons to carry out the same and all expenses
consequent thereon or incidental thereto shall be recoverable from the Contractor by the
Employer, or may be deducted by the PM from any moneys due or which may become due
to the Contractor.
![Page 123: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/123.jpg)
123
6.7.0 SITE MEETING
To facilitate satisfactory completion of the work under this contract, and to co-ordinate
work with the other agencies working at the site, meeting will be held in the office of the
PMC every fortnight / month or as directed PMC. During these meetings progress of
various works will be reviewed and those matters needing clarifications/ decisions to
expedite the work will be taken up. The PMC shall record minutes of these meetings.
CONTRACTOR’S ORGANISATION
The Contractor shall supply to the PMC/ARCHITECT within time specified in Appendix TF to
Tender Form of the effective date of commencement of works or prior to kick-of meeting
whichever is earlier, an organization chart showing the proposed organization to be
established by the Contractor for execution of the work including the identities and
curriculum Vitae of the key personnel to be deployed. The Contractor shall promptly
inform the PMC/ARCHITECT in writing, of any revision or alteration of such organization
charts.
The Contractor shall provide necessary supervision during the execution of the works and
thereafter as the PMC/ARCHITECT may consider necessary for the fulfillment of the
Contractor’s obligations under the Contract. The Contractor or his competent and
authorized representative(s) shall be constantly present at the Work site whole time for
supervision. The Contractor shall authorize the Residential Engineer of the Company / Firm
or his representative to receive directions and instructions from the PMC’s Representative.
The Contractor shall be responsible for the deployment, transportation accommodation
and catering of all labour local or expatriates required for the execution of the works and
for all costs/charges in connection thereof.
The Contractor shall be responsible for obtaining all necessary permits or visas from the
concerned authorities for the entry of all labour and personnel to be deployed, into the
country where the site is located.
The Contractor shall at his own expense be responsible for the repatriation to the country
from which they were mobilized for all his and his sub-contractor’s personnel deployed
upon the works at site and shall be responsible for the suitable maintenance of all such
personnel from the cessation of their deployment on the Works to their deployment on
the works to their departure from the country where the site is located.
![Page 124: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/124.jpg)
124
The contractor shall provide and deploy on the site for carrying out the works only those
technicians / assistants who are skilled and experienced in their respective trades and those
foremen and leading hands who are competent to give proper supervision to the work they are
required to supervise.
Further, only those skilled, semi-skilled and unskilled workmen who are necessary for the
proper and timely execution of the works shall be deployed at site.
The PMC may at any time object to and require the contractor to remove forthwith from the
site a supervisor or any other authorized representative or employee of the contractor’s sub-
contractor(s) or any person(s) deployed by Contractor or his Sub- contractor(s), if, in the opinion
of the PMC the person in question has misconducted himself or his deployment is otherwise
considered undesirable by the PMC, the contractor shall forthwith remove and shall not again
deploy the person in question of the work site without the written consent of the PMC.
The PMC may at any time instruct the contractor to remove from the work / site contractor’s
supervisor or any other authorized representative including any employee of the contractor or
his sub-contractor(s) or any person(s) deployed by contractor or his sub-contractor(s) for
professional incompetence or negligence or for being deployed for work for which he is not
suited. The contractor shall consider the PMC’s request and may accede to or disregard it. The
PMC, having made a instructed as aforesaid in the case of any person, which the contractor has
disregarded, may in the case of the same person at any time but on a different occasion, and for
a different instance of one of the reasons referred to above in this clause object to and require
the contractor to remove that person from deployment on the works which the contractor shall
then forthwith do and shall not again deploy any person so objected to on the works or on the
sort of work in question (as the case may be) without the written consent of the PMC.
The PMC shall state to the contractor in writing his reasons for any instruction or requirement
pursuant to thisclause.
The contractor shall promptly replace every person removed, pursuant to this section, with a
competent substitute.
* * * * *
![Page 125: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/125.jpg)
125
GENERAL CONDITIONS OF CONTRACT VOLUME – I
PART – VII
LABOUR AND INSURANCE
![Page 126: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/126.jpg)
126
GENERAL CONDITIONS OF CONTRACT
VOLUME – I
PART – VII
LABOUR AND INSURANCE
LABOUR
Engagement of Labour.
The Contractor shall make his own arrangements for the engagement of all labour, local or
otherwise, and, save insofar as the Contract otherwise provides, shall be solely liable and
responsible for the transport, housing, feeding and payment thereof.
Supply of Water.
The Contractor shall, so far as is reasonably practicable, having regard to local conditions,
provide on the site, to the satisfaction of the PMC/ARCHITECT, an adequate supply of drinking
and other water for the use of the Contractor's staff and work people. Further the Contractor
shall comply with model rules framed by Government for labour welfare, protection of
health, sanitation, etc., failing which the PMC/ARCHITECT reserves the right to effect such
arrangements at the Contractors' risk and cost. The Employer shall not at any time be liable
for any such provisions and the Contractor shall indemnify the Employer in this regard.
Alcoholic Liquor or Drugs
The Contractor shall not, in accordance with the Statutes, Ordinances and Government
Regulations or Orders for the time being in force, import, sell, give, barter or otherwise
dispose off any alcoholic liquor or drugs or permit or suffer any such importation, sale, gift,
barter or disposal by his sub-Contractors, agents or employees.
Arms and Ammunition
The Contractor shall not give, barter or otherwise dispose off to any person or persons, any
arms or ammunition of any kind or permit or suffer the same as aforesaid.
Festivals and Religious Customs
The Contractor shall in all dealings with his labour in his employment in connection with the
Works have due regard to all recognized festivals, days of rest and religious or other customs.
![Page 127: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/127.jpg)
127
Epidemics.
In the event of any outbreak of illness of an epidemic nature, the Contractor shall comply with
and carry out such regulations, orders and requirements as may be made by the Government,
or the local medical or sanitary authorities for the purpose of dealing with and overcoming
the same.
Disorderly Conducts
The Contractor shall at all times take all reasonable precautions to prevent any unlawful,
riotous or disorderly conduct by or amongst his employees and for the preservation of peace
and protection of persons and property in the neighborhood of the Works against the same.
Observance by Sub-Contractors
The Contractor shall be responsible for observance by his sub-Contractors of the foregoing
provisions.
First Aid
The Contractor shall, at his cost, provide, equip and maintain throughout the construction
period and so far as may be necessary during the Period of Maintenance (Defect Liability
Period), in a position on site approved by the PMC/ARCHITECT, suitable and sufficient first aid
facilities for the general use of his and his sub-contractors' staff and workpeople.
LABOUR LAWS
Acts
The Contractor shall in respect of labour employed by him either directly/or through sub-
contractors comply with the provisions of all labour legislation including the latest
requirements of all the Acts, Laws, any Regulation or Bylaws or any local or other statutory
Authority applicable in relation to the execution of Works, such as the Payment of Wages Act,
1936, Minimum Wages Act, 1948, Apprentices Act 1961. Any other Act including E.S.I.C. or
enactment relating thereto and rules framed there under from time to time, Industrial
Employment (Standing Order) Act, 1946 (Amended), Personal Injuries (Compensation
Insurance) Act, 1963 and any modifications thereof and Rules made thereunder from time to
time, Employees Provident Fund and Miscellaneous Provision Act,1952, Employer's Liability
Act, 1938, Workmen's Compensation Act, 1923 (Amended Act No.65 of 1976), Maternity
Benefit Act,1961, the Contract Labour Regulation and Abolition Act, 1970 (Amended) and
Mines Act, 1932 Equal Remuneration Act 1976, and Modifications thereof in force or
amended from time to time and any other labour legislation, which may be applicable to the
employees of the Contractor from time to time.
![Page 128: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/128.jpg)
128
Employment of Labour
The Contractor shall provide the quantum of labour he deems necessary, or required by the
PMC/ARCHITECT, for the construction and completion of the Works. The Contractor shall employ
local labour, as far as possible. Arrangements which affect the engagement, transport, paying,
feeding and housing of labour and all other matters in connection therewith shall be subject to
the regulations and orders of the Government now in force or which may be made from time to
time during the continuance of the Contract.
Rates of Wages and Hours
The Contractor shall, in respect of all persons employed by him in or about the execution of the
Contract including the Works, pay rates of wages emoluments and expenses and observe hours
and conditions of labour according to the conditions established for the trade or industry or
prescribed by regulation or order in force in the district where the work is carried out.
PMC’s Power to Recover
The PMC shall, on report having been made by an Inspecting Officer as defined in the
Contractor's Labour Regulations, have the power to deduct from the moneys due to the
Contractor any sum required or estimated for making good the loss suffered by a worker or
workers by reason of non-fulfillment of the conditions of the Contract for the benefit of
workers, non-payment of wages or of deductions made from his or their wages which are not
justified by the norms of the Contract or non-observance of the said Contractor's Labour
Regulations.
7.3.0 EMPLOYEE’S STATE INSURANCE SCHEME
The Contractor shall be liable to pay his contribution and Employee’s contribution to the State
Insurance Scheme in respect of all labour employed by him or for the execution of the contract in
accordance with the provisions of "The Employees' State Insurance Act, 1948" as amended from
time to time. The tenderer shall be obliged to ascertain the application at project site and shall
make allowance as he deemed fit. The Employer shall be indemnifies on this account.
![Page 129: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/129.jpg)
129
RETURNS OF LABOUR
The Contractor shall maintain all prescribed registers, records and other documents in
compliance with applicable labour laws and allow the RE to have access to these documents for
inspection. However these inspections shall not absolve the Contractor of his responsibility for
any breach or violation of rules and regulations under the respective acts.
The Contractor shall obtain prescribed recommendations from the Regional Provident Fund
Commissioner under the Employees' Provident Fund and Misc. Provisions Act, 1952 and shall
cause provident fund contributions from all eligible employees to be deposited regularly with
the prescribed authority and in token of which shall submit every month necessary
documentary evidence as may be required by the RE.
The Contractor shall indemnify the Employer against any payments, suits, lien or default charges
to be made under and for observance of the Regulations aforesaid without prejudice to his right
to claim indemnity from his sub-Contractors.
The Contractor must fully satisfy himself as to these points and allow coverage for the same in
the rates while giving his tender.Nothing extra shall be paid on these accounts.
The Contractor shall, if required by the PMC/ARCHITECT, deliver to the PMC / Engineer, or at his
office, a return in detail in such form and at such intervals as the PMC/ARCHITECT may prescribe
showing the supervisory staff and the numbers of the several classes of labour from time to
time employed by the Contractor on the site and such information regarding the constructional
plants as deployed in format as the PMC/ARCHITECT may require.
INSURANCES
Insurance of Works
The insurances taken shall be free of any cost to the bank.
The Contractor shall at his own expense effect and maintain contractors all risk insurance policy
(CAR policy) in the joint names of the Employer and the Contractor, the name of the former
being placed first in the policy covering the following and shall be in full force up to completion
of maintenance (defect liability) period.
![Page 130: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/130.jpg)
130
a) The Works at the contract price together with the materials for incorporation in the
works at their replacementvalue.
b) All plants and equipment and other things brought to the site by the Contractor at their
replacement value (if designed by theContractor).
c) The insurance shall be against all losses or damages from whatever causes, other than
excepted risks,for which the Contractor is responsible under the contract.The insurance
cover shall be for the period of contract and also for the Defect Liability Period, for loss
or damage arising from a cause prior to commencement of the Defect Liability Period,
and for any loss or damage,occasioned by the Contractor in the course of any operations
carried out for the purpose of complying with his obligations under clause 2.8.0.
Such insurance shall be effected with an insurer and in terms approved by the Employer.
The Contractor shall, deposit the policy or policies and the receipts for payment of the
current premiums with the Employer before commencing the Works.
Third Party Insurance
Before commencing the execution of the Works, the Contractor shall insure against his
liability for any material or physical damage, loss or injury which may occur to any property or
life including that of the Employer or to any person, including any employee of the Employer,
by or arising out of the execution of the Works or in the carrying out of the Contract. The sum
insured will be as stated in Appendix TF.
Such insurance shall be effected and maintained with an insurer and in terms approved by
the Employer and for at least the amount stated in the Appendix TF to Tender Form. The
Contractor shall submit to the ARCHITECT the policy or policies of insurance and the receipts
of payment of the current premiums.
Workmen's Insurance
The Employer shall not be liable for any payment in respect of any damages or compensation
payable according to law in respect or in consequence of any accident or injury or loss of life
to any workman or other person in the employment of the Contractor or any sub-contractor,
except an accident or injury resulting from any act or default of the Employer, his agents or
servants. The Contractor shall insure against such liability with an insurer approved by the
Employer for sum of the established norms during the entire period till completion of Period
of Maintenance (Defect Liability Period).
![Page 131: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/131.jpg)
131
The Contractor shall also indemnify the Employer against all claims which may be made upon
the Employer, whether under the Workmen’s Compensation Act or any other statute in force,
during the currency of this contract or at common law in respect of any employee of the
Contractor or of sub-contractor and shall be at his own expense effect and maintain until the
term of the Contract, with an Insurance Company, approved by the Employer, a policy of
Insurance against such risks and deposit such policy or policies with the ARCHITECT / Employer
from time totime.
Without prejudice to the other rights of the Employer against the contractor in respect of such
default, the Employer may so insure and shall be entitled to deduct the premiums paid along
with his service charges of 0.25% of the Contract Price and liquidated damages of 0.5% of the
Contract Price for noncompliance from any sums payable to the Contractor under this Contract
or such amount may be recoverable by the Employer from the contractor as debt.
The Contractor shall be responsible for any liability which may not be covered by the insurance
Policies referred to above and also for all other damages to any person, animal or defective
workmanship in carrying out of this Contract, whatever, may be the reasons due to which the
damage shall have been caused.
The Contractor shall also indemnify and keep indemnified the Employer against all and any costs
charges or expenses arising out of any claim or proceedings relating to the Works and also in
respect of any award of damage or compensation arising there from.
The Contractor, in case of re-building or reinstatement after fire, shall be entitled to such
extension of time for completion as the ARCHITECT may deem fit, but shall, however not be
entitled to reimbursement by the Employer or any shortfall or deficiency in the amount finally
paid by the Insurer in settlement of any claim arising as set out herein.
Period of Policies
All the insurance covers for full amount as detailed in Appendix TF to tender form shall be kept
in full force (alive) during the entire period of the contract (till end of maintenance period).
Remedy on Contractor's Failure to Insure
If the Contractor shall fail to effect and keep in force the insurances referred to above, or any
other insurance which he may be required to effect under the terms of the Contract,then and in
any such case the Employer on advice of the ARCHITECT may effect and keep in force any such
insurance and pay such premium or premiums as may be necessary for that purpose and from
time to time deduct the amount so paid by the Employer as aforesaid from any moneys due
![Page 132: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/132.jpg)
132
or which may become due to the Contractor, or recover the same as debt due from the
Contractor as set out in Clause 7.5.4 above.
The contractor shall also indemnify and keep indemnified the Employer against all and any
costs, charges or expenses arising out of any claims which may be made upon the Employer,
whether under the Workmen’s Compensation Act or any other statute in force, during the
currency of this contract or at Common Law in respect of any employee of the Contractor or
of sub-contractor and shall be at his own expense effect and maintain until the completion of
the contract( till end of maintenance period) with an Insurance Company, approved by the
Employer, a policy of Insurance against such risks and deposit such policy or policies with the
Employer from time to time during the currency of this contract.
* * * * *
![Page 133: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/133.jpg)
133
GENERAL CONDITIONS OF CONTRACT VOLUME – I
PART – VIII
SAFETY CODE
![Page 134: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/134.jpg)
134
GENERAL CONDITIONS OF CONTRACT
VOLUME – I
(PART – VIII)
SAFETY CODE
GENERAL
The Contractor shall ensure and arrange at his cost fire and the safety provisions, as per safety
code of C.P.W.D., Indian Standards Institution and safety manuals of the Employer for all labour,
directly or indirectly employed in the works for performance of this contract and such as locally
in force from time to time. Contractor will indemnify the Employer from any consequence
arising due to contractor's failure in respect of safety code.
Safety codes mentioned in special conditions of contract may be referred. Following Codes be
referred;
1. IS5121
IS5916
Safety code for piling and other deep foundation.
Safety code for construction involving use of hot bituminous materials.
3. IS 7293 Safety code for working with construction machinery
4. IS 7969 Safety code for handling and storage of building materials.
5. IS 8989 Safety code for erection of concrete framed structures.
6. IS 10291 Safety code for dress divers in civil engineering works
7. IS 13415 Protective barriers in and around buildings – Code of Safety.
8. IS13416 Preventive measures against hazards at work places –
Recommendation (Part – 1 to5)
9. IS13430 Safety during additional construction and alteration to existing
buildings code of practice.
10.
SP70 Hand book on construction Safety Practice.
![Page 135: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/135.jpg)
135
SAFETY, SECURITY AND PROTECTION OF THE ENVIRONMENT
a) The Contractor shall, throughout the execution and completion of the Works and the
remedying of any defects therein.
b) provide and maintain at his own cost all lights, guards, fencing, warning signs and watching,
when and where necessary or required by the PMC / ARCHITECT or by any duly constituted
authority, for the protection of the Works or for the safety and convenience of the public or
others as set out hereunder, take all reasonable step, to protect the environment on and off
the Site and to avoid damage or nuisance to persons or to property of the public or others
resulting from pollution, noise or other causes arising as a consequences of his methods of
operation,
c) shall maintain all statutory records and will fulfill all obligation stipulated vide different
statutes commensurate with location and type of Work,
d) shall be liable to pay compensation / penalty for violation of safety rules and for each
accident sooccurred.
FIRST AID & INDUSTRIAL INJURIES
First aid facilities at easily accessible place shall be provided by the Contractor as per
provisions of Labour Act or Authority where work is carried out.
The Contractor shall make outside arrangements with hospitals for ambulance service and for
treatment of industrial injuries to meet eventualities needing these facilities. The Engineer
shall be informed of their telephone numbers and addresses.
All critical industrial injuries shall be reported promptly to the Engineer. Report shall cover
type, nature, cause, physician's report and actions for prevention of those types again.
GENERAL RULES
Smoking within plant, restricted areas, closed areas, near storage place of lubricant oil and
fuel etc. is strictly prohibited.
The Contractor shall erect and maintain barricades required in connection with his operation
to guard or protect
(a) Excavation
(b) Hoisting/lifting
(c) Slab openings
(d) Hazardous areas
(e) Employer's existing property likely to be subjected to damage by the Contractor's operations
(f) Rail road, unloading spots.
![Page 136: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/136.jpg)
136
8.3.3 High RiserBuilding/s.
The Contractor shall provide and maintain closely knitted PVC net all round building throughout
the construction period. He shall also provide all around from external face about 1.5M+ wide
temporary platforms at every 6-7th floor covered with welded steel mesh. This shall be
maintained and updated throughout the construction period to avoid any accident due to
dropping of construction material/debris. This shall be strictly followed and work shall be
permitted only when complied with total satisfaction of the Engineer. Failing which the
Employer reserves the right to get same carried out at the contractor’s risk and cost.
8.4.0 DISPLAY
These safety provisions shall be brought to the notice of all concerned by display on a notice
board at a prominent place at the work spot. Persons responsible for ensuring compliance with
the safety code shall be named therein by the Contractor. Contractor shall organize safety
training from time to time.
8.5.0 SCAFFOLDING
Suitable scaffolds shall be provided for workmen, for all Works that cannot safely be done from
the ground or from solid construction except such short period work which can be done safely
from ladders. When a ladder is used, extra mazdoors shall be engaged for holding the ladder
and if the ladder is used for carrying materials as well, suitable footholds be provided on the
ladder and the ladder shall be given an inclination, not steeper than 1/4 to 1 (1/4 horizontal and
1 vertical). No portable single ladder shall be over 3 meter in length. The width between the side
rail shall not be less than 30cm.and distance between two adjacent rungs shall not be more than
30cm.
8.6.0 GUARDRAILS
Scaffolding or staging more than 3.25 meters above the ground or floors, swung or suspended
from an overhead support or erected with stationary support, shall have guard rail properly
attached, bolted, braced and otherwise secured at least 1 meter high above the floor or
platform of such scaffolding or staging and extending along the entire length of the outside
and ends. Therefore, with only such openings as may be necessary for the delivery of materials,
such scaffolding or staging shall be so fastened as to prevent it from swaying from the building
or structure.
![Page 137: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/137.jpg)
137
8.7.0 WORKING PLATFORM
Working platform, gangways, and stairways shall be so constructed that they do not sag unduly
or unequally, and if height of platform or gangway or stairway is more than 3.25 meters above
ground level or floor level, it shall be closely guarded, have adequate width and be suitably
fenced, as described in clause 8.6.0 above.
8.8.0 FLOOR OPENING
Every opening in the floor of a building or in a working platform shall be provided with suitable
means to prevent fall of persons or materials by providing suitable fencing or railing of
minimum 1 meterhigh.
8.9.0 ACCESS
Safe means of access shall be provided to all working platforms and other working places. Every
ladder shall be securely fixed. No portable single ladder shall be over 3 meters in length. Width
between side rails in a rung ladder shall in no case be less than 30 cm for ladders up to and
including 3.0 m in length. For longer ladders this width shall be increased at least 16 mm for
each additional 30 cm length. Step spacing will be uniform and shall not exceed 30 cm.
8.10.0 EXCAVATION ANDTRENCHING
All trenches, 1.5 meters or more in depth shall, at all times, be supplied with at least one ladder
for each 30 meters length or fraction thereof. A ladder shall be extended from bottom of trench
to at least 1 meter above the surface of the ground. Sides of a trench which are 1.5 M or more
in depth shall be stepped back, to give suitable slope, or securely held by timber bracing so as to
avoid the danger of sides collapsing.Excavated materials shall not be placed within 1.5 meters of
edge of trench or half depth of trench, whichever is more. Cutting shall be done from top to
bottom. Under no circumstances shall undermining or under cutting bed one.
![Page 138: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/138.jpg)
138
DEMOLITION
Before any demolition work is commenced and also during the process of the work:
(a) All the roads and open areas adjacent to the Work site shall be closed or suitably protected.
(b) No electrical cable or apparatus which is liable to be a source of danger to an
operator shall remain electrically charged.
(c) All steps shall be taken to prevent danger to persons employed from risk of fire
or explosion or flooding.No floor, roof, or other parts of a building shall be so
overloaded with debris or materials as to render it unsafe.
(d) All blasting material shall be stored and handled as per guidelines of relevant authorities.
8.12.0 DROWNING
When work is done near any place where there is risk of drowning, all necessary
rescue equipment shall be provided and kept ready for use and all necessary steps
taken for prompt rescue of any person in danger, and adequate provision made for
prompt first-aid treatment of all injuries likely to be sustained during the course of
the work.
8.13.0 ACCIDENT
No materials on the sites shall be so stacked or placed as to cause danger or
inconveniences to any person or to the public. The Contractor shall provide all
necessary fencing and lights to protect the public from accidents and shall be bound
to bear expenses of defense of every suit, action or other proceedings at law, that
may be brought by any person, for injury sustained, owing to neglect of the above
precautions and to pay any damages and costs which may be awarded in any such
suit, action or proceeding to any such person or which may, with the consent of the
Contractor be paid to compromise any claim by any such person.
8.14.0 ELECTRICAL EQUIPMENT
All temporary and permanent electrical installations, power distribution and supply
required for execution of Work shall be carried out conforming to existing industrial
and domestic safety rules and regulations. Important specific points to be noted are
as under,
(a) Meter room and main switches should be freely accessible at all times and
fully protected against all weathers.
(b) Power distribution system shall be identifiable with display marking on switches.
![Page 139: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/139.jpg)
139
(c) All power distribution shall be carried out with coated, adequately insulated
and of appropriate current/load rating cables. It shall be securely routed for
this purpose. No loose, naked, hanging wires shall be permitted.
(d) Over load protection devices shall be installed whenever and wherever heavy
current/load consuming construction or plant machinery susceptible to hazard
is in use and as directed by the ARCHITECT.
(e) Metallic plugs and sockets shall be used in field work. Switch board shall be in
close proximity so as to have quick control over the supply.
(f) Proper and adequate earthing connection to be provided for all installation,
plant machinery and distribution system.
(g) Hand lamps and inspection lamps shall be adequately insulated and guarded
with wire mesh and will have proper plugs for use.
(h) Security and illuminator light shall be secured firmly and protected to
withstand all weather.
HOISTING MACHINES / TACKLES
(a) These shall be of good mechanical construction, of sound material and adequate
strength and free from patent defects and shall be keptin good working order and
well maintained.
(b) Every rope used in hoisting or lowering materials or as a means of suspension
shall be of durable quality and adequate strength and free from patent defects.
Every crane driver or hoisting appliance operator shall be properly qualified
and no person under the age of 21 years shall be in charge of any hoisting
machine including any scaffold, winch or for giving signals to operators.
In case of every hoisting machine and of every chain ring hook, shackle, swivel
and pulley block used in hoisting or lowering or as means of suspension, safe
load shall be ascertained by adequate means. Every hoisting machine and gear
referred to above shall be plainly and prominently marked with safe working
load. In case of hoisting machine having a variable safe working loads each safe
working load and the conditions under which it is applicable shall be clearly
indicated. No part of any machine or of any gear referred to above in these
paragraphs shall be loaded beyond safe working load except for the purpose of
testing as laid down by manufacturers.
In case of departmental machines, safe working load shall be notified by the
Engineer. As regards Contractor's machines, the Contractor shall notify safe
working load of each machine to the Engineer whenever he brings it to site of work
![Page 140: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/140.jpg)
140
and gets it verified by the Engineer.
(a) Motors, gearing transmission, electrical wiring and other dangerous parts of
hoisting appliances shall be provided with efficient safeguards;
(b) hoisting appliances shall be provided with such means as will reduce to the
minimum, risk of an accidental descent or of any part of suspended load becoming
accidentally displaced;
(c) Workers employed on energized electrical installations, will use insulated
foot mats and in addition shall wear apparel such as gloves, sleeves and
boots,which as may be necessary,shall be provided. Workers shall not wear any
rings, watches and keys or other materials which are good conductors of electricity.
8.16.0 MAINTENANCE
All scaffolds, ladders material handling equipment etc. and other safety devices mentioned or
described herein shall be maintained in a safe condition as prescribed by manufacturer of each
equipment and no scaffold, ladder or equipment shall be altered or removed while it is in use.
Adequate washing and maintenance facilities shall be provided at or near places of work.
PERSONNEL SAFETY AND PERSONNEL MOVEMENTS
Personnel Safety
All necessary Personnel / personal safety equipment as considered adequate by the Engineer shall
be available for use of persons employed on the Site and maintained in a condition suitable for
immediate use and the Contractor shall take adequate steps to ensure proper use of equipment
by those concerned.Contractor shall ensure that all personnel deployed by him at Site are issued
with necessary personal protective items of best quality / appropriate type / duly tested and
examined and as per standard specifications like helmets, safety belts, goggles, respirators, life
jackets, life buoys with lifeline, etc during working hours. Any defaulters shall be removed from
the Site immediately.
(a) Workers employed on mixing asphaltic materials, cement, and lime mortars / concrete shall
be provided with protective footwear and protective gloves.
(b) Those engaged in handling any materials which are injurious to eyes shall be provided with
protective goggles.
(c) Those engaged in welding works shall be provided with welder's protective eye shields and
protective gloves
(d) Stone breakers shall be provided with protective goggles and protective clothing and seated
at sufficiently safe spacing.
(e) Workers employed on erection works, etc. shall be provided with helmets, safety belts etc.
![Page 141: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/141.jpg)
141
(f) Workers employed on concrete finishing, welding, painting and other works above 2 meters
height shall be provided with a suitable safety belt, as per Factory Rules of the locality.
(g) When workers are employed in sewers and manholes, which are in use, the Contractor shall
ensure that manhole covers are opened and manholes are ventilated at least for an hour
before workers are allowed to enter them. Manholes so opened shall be cordoned off with
suitable railing and provided with warning signals or boards to prevent accidents to the
public.
(h) The Contractor shall not employ any worker below the age of 18 and women on the work of
painting with products containing lead in any form. Whenever men above the age of 18 are
employed on the work of lead painting, the following precautions shall be taken:
(i) No paint containing lead or lead products shall be used except in the form of paste or ready-
madepaint.
(ii) Suitable face masks shall be supplied for use by workers when the paint is applied in the form
of spray or a surface having lead paint is dry rubbed andscraped.
(iii) Overalls shall be supplied by the Contractor to workmen and adequate facilities shall be
provided to enable working painters for wash during and on cessation ofwork.
(iv) Contractor shall ensure that no persons other than the ones deployed by him are present on
the site without adequate safetymeasures.
Personnel Movement
Good well-signed pedestrian access routes and vehicular traffic routes around and
within work sight physically segregated from vehicles must be established and maintained to
avoid accidents.
Proper barricader and barriers should be erected around the danger area and prohibited area.
Any changes in traffic routes should be immediately notified to all the personnel connected with works.
8.18.0 ENFORCEMENT
To ensure effective enforcement of the rules and regulations relating to safety precautions,
arrangements made by the Contractor shall be open to inspection by the ARCHITECT or his
representatives and the Inspecting Officer as defined in the Contractor's Labour Regulations.
![Page 142: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/142.jpg)
142
STORAGE AND FABRICATION AREA
Storage Area
Allocate clearly defined areas for each contractor and each purpose.
Should have good vehicle access for other activities such as evacuation of personnel, material etc. in case of any accident. Easy entry / exit of fire tender, material handling equipment etc. should be kept in mind at all times.
Should have good surface conditions to prevent tripping and wastage of materials Should have good lighting to avoid injury to personnel while working.
Storage of Fuel, Oil and Lubricants
The Contractor shall take approval from the safety officer of the Employers for storing the
lubricants, oil and fuel at site for running the machinery required for the construction.
Fabrication Area
Should have good ground conditions, sufficient lighting and well ventilated. Area should be kept tidy at all times. Ease of access and working should be kept in mind.
FIRE EXTINGUISHING AND FIRE FIGHTING ARRANGEMENT
The contractor shall provide suitable arrangements for firefighting. For this purpose, he shall
provide :
i) Requisite number of fire extinguisher for all types of fire.
ii) Adequate number of buckets kept filled with water and sand
These equipments shall be provided at suitable, prominent and easily accessible locations
where they shall be regularly properly maintained.
![Page 143: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/143.jpg)
143
The contractor may be subject to periodic fire prevention inspections and fighting drills and
any deficiencies or unsafe condition shall be corrected by contractor at his own cost and to
the approval of ARCHITECT and relevant authorities.
This fire prevention inspection shall include but not limited to the following:
i) Proper handling, storage and disposal of comestibles materials, liquid and waste.
ii) Work operations which can create fire hazard.
iii) Access for firefighting equipment including that of local authorities.
iv) Type,size, number and location of fire extinguishers or other fire fighting equipment for
all types of fire. Adequacy of the same.
v) Inspection and maintenance records for all types of fire fighting equipment.
vi) Type, number and location of containers for the removal of surplus material and rubbish.
vii) Safe routing of electrical cables, junction boxes, switch boards, safety devices, earthing
etc. No electrical loose connections.
viii) Generalhousekeeping.
Safety / Fire Protection
Contractor shall take all necessary measures to protect the work and workmen against
accidents and occupational disease. They shall observe and comply with all Governmental
safety regulations as well as Employer’s and accepted industry safety practices as required
for this work.
The contractor will be required to demonstrate that:
i. The management systems and the erection are adequate to ensure that the design and
the operation of the erection and the equipment are safe;
ii. The potential hazards of the erection and the risks to personnel and environment have
been identified and appropriate controls provided;
iii. Adequate provision is made for ensuring,in the event of a major emergency affecting the
installation, the safe evacuation and rescue of personnel and
iv. The statutory and Employer requirements relating to safety and pollution control
measures are complied with.
![Page 144: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/144.jpg)
144
8.21.0 RULES IN FORCE
Notwithstanding the conditions stated hereof, the Contractor is obliged to enforce other Rules in
force or as required in the opinion of the Engineer or his Representative.
TRAINING OF PERSONNEL IN FIRST AID AND FIRE FIGHTING
Contractor will organize periodic training and practice sessions for his workers to handle first
aid and firefighting equipment as per schedule approved by PMC/ ARCHITECT / Engineer
record of which will bekept.
All the employees of contractors shall be made conversant with action to be taken in case of
accident, injury, fire and any untoward incidents. Such awareness programmes shall be organized
by the contractor at suitable intervals fixed mutually.
* * * **
![Page 145: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/145.jpg)
145
CONDITIONS OF CONTRACT VOLUME
– I
PART – IX
SPECIAL CONDITIONS
![Page 146: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/146.jpg)
146
GENERAL
Employer
Bank of India, Head Office, Premises Department, Star house 2, 3rd floor, C-4, G-Block, Bandra
Kurla Complex, Bandra (East), Mumbai – 400 051.
Project
The Project is the Interior and Allied Services work of 3rd Corporate Office Building at C-29, G-Block, Bandra-Kurla Complex, Mumbai.
Site
The site is situated at 3rd Corporate Office Building at C-29, G-Block, Bandra-Kurla Complex,
Mumbai.
Type of Contract
The Contract is Item Rate. Quantities set out in the bills of quantities are tentative. Tenderers
shall quote for each item at the place given in the bills of quantities. Cost evaluation shall be
based on these quantities and price quoted. Work shall be measured in actual and paid as per
terms set out in Contract.
Mobilisation Period
The Contractor shall carry out the following minimum activities within first 15 days. Within 3
days of the work order the Contractor shall submit to the ARCHITECT drawings giving his
proposed layout of locating offices, stores, godowns, yards, water, electric network etc. for the
approval of the ARCHITECT.
Part temporary office of the Contractor.
Line out including establishing of grid line levels and its approval from the ARCHITECT.
Tapping temporary electric and water connections.
One cement godown (ware house) and steelyard.
Obtaining insurance policies as per the Contract.
Obtaining Labour license
Obtaining approval of local authorities or any statutory requirements prior to actual start of work to work as“Contractor”.
![Page 147: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/147.jpg)
147
Submitting programme (MS–Project format) as detailed in clause 9.5.0
(Method of carrying out work) here of and approval by the ARCHITECT.
Submitting list of proposed specialized Sub-Contractor/agencies for
approval of the ARCHITECT as detailed in conditions.
a) Water-proofing Contractor (As per list from Approved Agency)
b) Anti-termite treatment Contractor (Valid Licensed Holder from IS-6313- 2(2001)Certification)
c) Electrical
Contractord
d) Plumbing Contractor
e) Firefighting Contractor
f) Aluminum Sliding Window/Door and
g) Submission of Preliminary concrete design mix
h) Establishing water and electric network within site to extent possible.
Submitting detail site set up of engineering and office staff. The power of Attorney,
Name and signature of his authority’s representative who shall be in charge of the
execution ofwork.
Definitions
The following person(s)/firm(s) shall include their legal representatives or in the event of
their ceasing, person(s)/firm(s) as nominated by the Employer, not being a
person(s)/firm(s) to whom the contractor shall object for reasons considered sufficient
by the Employer. Provided always that no person(s)/firm(s) subsequently appointed
under this contract shall be entitled to disregard or overrule any decision or approval or
direction given or expressed in writing.
Engineers/Supervisors
Engineers and Supervisors appointed by the ARCHITECT to assist the ARCHITECT under his guidance for supervising construction of the project work as per this tender.
Jurisdiction
In case of any litigation under this Contract, the courts of law in the city of Mumbai only, shall have the jurisdiction.
![Page 148: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/148.jpg)
148
Assignment or Subletting
In case of breach of any of the conditions stated in clause 1.3.7 and 1.3.8 of General Conditions of
contract the Employer may issue a notice in writing on the contractor terminating the Contractor,
where upon the security deposit shall stand forfeited without prejudice to the Employer’s other
remedies against the Contractor.
Access
The Contractors are to verify the work site details including:
a) Access,
b) Availability of water supply and electrical energy.
c) Space for dumping stores and materials,
d) Space for erection of site office,
The Contractors are deemed to have catered for all contingencies connected with the
site and access.
9.2. Rate to Include
The rates quoted in the tender shall include all charges for tools, plants, temporary water and
electric connections (if any), overhead reservoirs, sheds for material (of the Contractor and as
issued by the Employer), sampling, testing on material including supplied by the employer and all
test specified at various stages in specification or ordered by PMC/ARCHITECT, hire charges if any,
maintenance of all services and equipment clearing the Site, etc., for the execution of the Works. It
shall also include all taxes such as, or any other duties of any public body or corporation (duly
authorized to collect). GST SHALL BE PAID EXTRA as per Rules.
9.3 ExtraItem/Variations
All additional items and variance from those given in BOQ and accepted by the Architect shall be
treated as extra items. These shall be expressly ordered by the ARCHITECT/PMC in writing prior to
start of that work by the Contractor. The Contractor shall be paid as per similar item of BOQ. In
absence, actual rate analysis shall be prepared and submitting by the contractor considering market
rates of labour, materials and towards operational cost of plants and equipment, overheads and
profit (15%) plus prevailing works contract and service tax as applicable. The Contractor shall have
to produce voucher / Tax invoice to support the rate analysis. The ARCHITECT / PMC/ EMPLOYER
reserves the right to call additional quotations for material, labour / workmanship if felt necessary
and rates approved by the ARCHITECT /PMC/ EMPLOYER shall be final. The PMC/ ARCHITECT/
EMPLOYER's decision shall not be subjected to arbitration.
![Page 149: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/149.jpg)
149
Execution of Additional work
The successful tenderer is bound to carry out any items of work necessary for the completion of
the job even though such items may not be part of his tender. He shall be instructed in writing by
the ARCHITECT/PMC for such works and rates shall be settled as detailed above.
Compensation by Extension of Time only
The Contractor shall not be entitled to any compensation for any loss suffered by him on account
of delays may be, including delays arising out of modifications to the works entrusted to him or in
any sub-contract agencies connected there with or delays in awarding contracts for other trades
of the project or in commencement or completion of such works or in procuring government
controlled or other building material or for any other reasons whatsoever and the Employer shall
not be liable for any claim in respect thereof. The Employer does notaccept any liability for any
such besides the tender amount, subject to such variation as are provided for herein.
PROGRAMME AND METHOD OF WORKING
PROGRAMME OF WORK
The Contractor shall, within the stipulated time in Appendix TF of Tender Form, submit to the
PMC/ARCHITECT for his approval a detailed programme covering
a) Descriptive note explaining sequence of various activities.
b) Network (PERT/CPM) in MSP.
c) Quarterly programme of supply of materials by the Employer, if any.
d) Quarterly cash flow indicating money to be earmarked by the Employer for
the purpose of the contract.
e) Programme for supply of working drawing.
f) Phased requirements of plant and equipment to be deployed by the Contractor.
g) Monsoon period is inclusive of completion period.
Method of Working
The Contractor shall, within the stipulated time in Appendix TF of Tender Form, submit to the
ARCHITEC/PMC for his approval following information
a) A general tentative lay-out plan of construction plant and equipment for the execution of
Work within time period stipulated in schedule.
b) Drawings or prints showing the location of major plants and other facilities which he
propose to put up at the Site, including any changes in the general layout, at least 15 days
![Page 150: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/150.jpg)
150
prior to the commencement of the respective Work.
c) Layout and details of Temporary Works that the Contractor wants to carry out to fulfill his
obligation under the Contract.
d) Shall indicate shuttering system to be followed as per requirement given in 9.10.0
e) Detail activity wise MS / Primavera Programme for completion of project. Programme
shall include skilled, unskilled work force for each activity and specified duration. It shall
include cashflow based on programme.
Within 7 days the ARCHITECT/PMC shall give their approval to proceed with Work with or
without modification. However acceptance of programme and method of working as submitted
by the Contractor or with any modification thereto in the opinion of the PMC/ARCHITECT, shall
not relive the Contractor of any of his contractual obligations.
All these programmes and plans submitted by the Contractor and approved by the
PMC/ARCHITECT shall become part of the Contract.
The acceptance of programmes as submitted by the Contractor or with any modification thereto
in the opinion of the PMC/ARCHITECT, shall not relieve the Contractor from any of his obligation
to complete the work within stipulated contract period or entitles him for extension of time unless
delay, if any, is expressly sanctioned by the PMC/ARCHITECT.
Sample Room
The Contractor shall be required to build and identify lockable room for storing the approved
samples by the PMC/ARCHITECT. These samples shall be stored and duly indexed. All samples shall
maintain till end of the project. One key of sample room shall be given to the RE for convenient
access to room at any time.
PLANT EQUIPMENT REQUIREMENTS
The Contractor shall submit, with the programme and method statement mentioned as in 9.5.0 hereof, a comprehensive plant schedule which shall include the dates of arrival on site and removal from site of each major item of plants.
Sufficiency
The Contractor shall take upon himself the full and entire responsibility for the sufficiency of
plants, centering, scaffolding, timbering, machinery, tools or implements and generally for all
means used for the fulfillment of the Contract. In the event of any of these means proving
![Page 151: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/151.jpg)
151
insufficient, the Contractor even then shall be fully and entirely responsible for the sufficiency of
these means notwithstanding any previous approval or recommendation that may have been
given by the PMC/ARCHITECT.
9.7.0 DRAWINGS
The Contractor will receive from the ARCHITECT three prints of the drawings approved for
construction for Architectural and structural works, public health, mechanical, electrical and
drainage installations.
9.8.0 STANDARDS TO BE FOLLOWED
At various places throughout this specification and the bills of quantities, reference is made to the
standards, specifications and bye-laws issued by the Indian Standard Institution and other similar
organizations. These references shall in every case be deemed to include the latest edition or issue
of such standards, specifications and bye- laws including all revisions, amendments and addenda
subsequently issued. Where materials are not specified and standards exists in respect of such
materials, then the materials shall in all respects comply with the relevant and current I.S.I. In such
cases where I.S.I. do not exist, the specified manufacturers' specification shall be followed; in
absence of all these, the ARCHITECT/PMC's instructions shall befollowed.
The Contractor is required to maintain at site all standards and codes listed in Specification for
ready reference to PMC/ARCHITECT and himself and PMC/ARCHITECT during execution of work.
MATERIALS
Materials Generally
All the materials and manufactured goods are to be the best of their respective kinds and as
described in the specifications, drawings and bills of quantities. The Contractor shall submit for the
approval of the PMC/ARCHITECT through the RE within a reasonable time (allowing 7 days
approval time to PMC/ARCHITECT, required lead time to procure and shall be available 7 days at
site prior to incorporation work) after receipt of the Employer's order to commence the Works, a
list of the names and addresses of the manufacturers, the trademarks and types of all materials
and articles he proposes to employ together with all specifications and descriptions and samples
that may be required in this connection before any orders are placed. Within a 7 days’ time the
PMC/ARCHITECT shall issue written decision on the Contractor's proposals. If any of the
manufacturers, materials, etc., have been rejected then the Contractor must propose acceptable
alternatives within one week of such rejection. In case of material not available locally, the
Contractor shall arrange from areas with longer leads and on this account shall, neither be paid
any extra nor shall be granted extension of time. The ARCHITECT/PMC's decision shall be final and
![Page 152: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/152.jpg)
152
binding on the Contractor. The Contractor shall submit to the Engineer copies of all orders for
materials.
Where a particular proprietary product, supplier or supplier's catalogue is referred to in this
specification or in the bills of quantities, the material specified is for quality type, etc. Other equal
and approved source shall be permitted in use.
If, during the course of the Contract, certain materials required for use in the Works should be
unobtainable despite the best efforts of the Contractor, then the Contractor may offer substitute
materials for the approval of the PMC/Architect / Employer. These substitute materials,although
not complying fully with the specification, must nevertheless be suitable and appropriate for use
in the Works.
Acceptance or refusal of such substitute materials shall be at the sole discretion of the
ARCHITECT/PMC/EMPLOYER. In the event of acceptance of the substitute materials a suitable
price reduction shall be made in respect of decrease in quality or value but no price addition shall
be made in respect of increase in quality or value. In the event of refusal of the substitute
materials, the Contractor shall not be relieved of any of his obligations under the Contract and
shall be solely liable for any delay or loss occasioned by his failure to provide materials as
specified.
SAMPLE MATERIAL The Contractor shall furnish for approval, with reasonable promptness, samples of all materials
and workmanship. The Engineer shall check and confirm in consultation with PMC/Architect,
approval of such samples with reasonable promptness only to conform to the design concept of
the Works and for compliance with the information given in the contract documents. The work
shall be in accordance with approved samples. The procedure for submission and approval of
samples shall be as follows:-
(a) All material samples of adequate numbers, sizes, shades and pattern as per
specification shall be delivered to the Engineer's office at the Contractor's
cost. Samples shall be properly labeled with
Name of Project
Name of Contractor
Name of Product
Name of Manufacturer
![Page 153: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/153.jpg)
153
Reference No of BOQ
Date ofSubmission
Date of fabrication/casting – if applicable
(b) Samples shall be accompanied with technical specification/ manufacturer'scatalogue
(c) In case the Contractor intends to keep an approved sample in his possession he shall
submit additional samples for the ARCHITECT's approval.
(d) Samples shall be furnished well in advance to give the PMC/ARCHITECT 15 days for their
consideration.
Specialized Sub Contractors / Agencies
The Contractor shall furnish for approval, with reasonable promptness, 2-3 names of all sub-
contractors / agencies (from approved list if given in tender) proposed to be used for each item of
work. Submission shall include all details as listed below. The Resident Engineer shall check and
confirm approval of sub-contractor / agencies with reasonable promptness in consultation
ofPMC/ARCHITECT. The work shall be got executed through the approved agency.Proposal shall
consist of
Name of Project
Name of Main Contractor
Name of proposed Sub-Contractor
Profile of Sub-Contractor including list of work completed and ongoing along with name of client, Architect, structural consultants, contact information.
Item no. of BOQ for which proposed
Methodology for each item.
Catalogues of each product.
Date of submission
Date by which order to be placed.
Test
The Contractor shall be required to test each and every lot of cement, steel, reinforcement
steel received and other materials as ordered by the PMC/ARCHITECT during construction and
report shall be submitted to RE. Material once approved by the PMC/ARCHITECT shall be
allowed to be used in work. All test results shall be duly filed and record maintained for
inspection at any time.
![Page 154: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/154.jpg)
154
TEMPORARY WORKS
The Contractor is entirely responsible for the design, construction, maintenance and removal of
all Temporary Works employed in carrying out the Contract. Within a reasonable time (and in
any case not less than fifteen days) before he intends to commence construction of any
Temporary Works, the Contractor shall submit full particulars including drawings of the same, for
the approval of the Engineer. The Engineer's approval will in no way relieve the Contractor of his
responsibility for the safety of the Works, operators, adjoining property, structures or services
and compliance with appropriate regulations and codes of practice. Temporary Works
supporting adjoining buildings, property and public utilities and roads shall also be submitted to
the appropriate authority for their approvalif requested/required.
The Temporary Works shall be designed and constructed in such a manner as to enable the
permanent structures to be built around them without detriment to their effectiveness and due
allowance will be deemed to have been made for all necessary adjustments thereto to enable
the Works to proceed.
Timber shoring, boards, struts or similar items shall not be left in position upon completion of
the Works without the written consent of the Engineer.
All services or utilities on or adjoining the Site which are required to be maintained operational
shall be protected from movement, subsidence or damage from any cause whatsoever by adequate
temporary props, struts, shores and protective screens to the approval of the Engineer and the
agent of the service or utility.
The Contractor shall make safe and reinstate all areas affected by Temporary Works.
The Contractor shall design purpose made steel staging platforms for carrying out work above
3.0 M height. All required staging for supporting, centering, shuttering of beams, slab, masonry
work, etc. shall be carried out strictly as per the approved arrangement. It is to be noted that
designing of such work shall be carried out by Contractor and shall be submitted for approval of
the Structural Engineer of this project. No work above 3.0 M shall be permitted without
compliance of this condition.
ISSUE OF MATERIALS
All materials, including those specified in the Contract Schedule `A' shall be procured and
arranged for by the Contractor after approval by the PMC/ARCHITECT to its quality and
specification as of tender. Materials listed in Schedule – ‘A’ with note as basic rate shall be
![Page 155: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/155.jpg)
155
purchased and procured only after procurement rate is approved by the PMC/ARCHITECT. The
Employer reserves the option to supply on his own. Tests for materials shall be carried out by the
Contractor as directed by the Engineer and costs of all such tests shall be paid for by the
Contractor.
The Contractor shall procure sufficient quantities of materials of approved quality, well in
advance, to ensure completion of Works in stipulated time especially stock of river sand, steel,
block, gypsum and cement.
No claim by the Contractor for compensation on account of loss due to delay in supply of
materials by the Employer will be entertained.
The Contractor shall not be entitled to claim any compensation from the Employer for loss
suffered by him on account of delay by the Employer in the supply of materials where such delay
is causedby
(a) Difficulties relating to the supply due to transportation beyond Employer'scontrol.
(b) ForceMajeure
(c) Act of God
(d) Act of theGovernment
(e) Any other reasonable cause beyond the control of theEmployer.
In the case of such delay in the supply of materials, the Employer shall grant such
extension of time for the completion of the works as shall appear to the
PMC/ARCHITECT to be reasonable in accordance with the circumstances of the
case.The decision of the PMC/ARCHITECT as to the extension of time shall be
accepted as final by the Contractor.
WATER / ELECTRICAL SUPPLY
WATER SUPPLY
The Contractor should make his own arrangements for required water supply, drainage
etc. at the work site at his own cost during the currency of contract and shall pay water &
sewerage charges to Municipal Corporation for the construction period.
ELECTRICAL SUPPLY
Responsibility for getting temporary power for construction at his own cost inclusive of all
deposits shall remain with Contractor. Consumption charges will be payable by the
![Page 156: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/156.jpg)
156
Contractor. Temporary power connection shall be in the Employer’s name. In the event of
unavailability of power from utility companies, the contractor shall make arrangements for
installing D.G. Sets of adequate capacity at his own cost.
SITE FACILITIES
Contractor's Offices, Godowns, Workshop
The Employer shall allow at his own discretion and convenience land for the construction of
the Contractor's site office, godowns, workshop assembly yard near the site. The Contractor
shall construct and maintain at his cost, all these temporary works which shall be well
ventilated, air conditioned, lighted and provided with water, electricity and sanitary
arrangement to the approval of the Engineer.
The Contractor shall remove immediately on completion of the work such building and make
good, to the satisfaction of the Engineer, all the damages sustained. The Employer through
the PMC/ARCHITECT may order, if so required by the Employer removal of such building or
buildings and the Contractor shall carry out such instructions at no additional cost to the
Contract.
PMC’S / ARCHITECT'S / ENGINEER’S / EMPLOYER’S OFFICES -
A) Aircondition Portacabin (Site Office) with computer,printer and other stationary
The Contractor shall be required to construct and maintain at all times an air conditioned site
office and Meeting room structure for the use of Architect / Owner’s representatives. The
area of such office shall be approx. 250 sq.ft. and shall be provided with suitable partitions
and doors as the following, for the exclusive use of the Architect's / Owner's representatives.
Adequate toilet facilities as directed by the Architect connected to septic tank/soak pit,
Furniture and equipment such as Chairs, Tables, Cupboards, Water Filters, Crockery, etc.
display boards etc. as directed.
The entire office shall be maintained in a neat clean and working condition by the Contractor
for the duration of the entire Contract period. These premises shall be demolished, material
carted away and the site landscaped as directed, on completion of the works contracted for.
The contractor shall allow in his prices for re-locating the offices to suit the construction
activities on site. The Contractor make a provision of stationary, computer including printer /
Scanner. The communication system indicated previously should be provided.
B) Service Lift for inspection
The contractor shall install service lift from 1st floor onward till terrace for Client and PM
Cathis own cost & maintain the lift in running condition all the time for checking all the site
![Page 157: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/157.jpg)
157
activities as the work of floor progress from ground floor till terrace level and be removed
after the completion of the Project.
For water and power the contractors for subsidiary trades appointed by the Employer shall be
allowed connection from the temporary water and power supply arranged by the General
Contractor for civil works and for the use of these facilities the subsidiary trade Contractors will
pay to the General Contractor the charges to be decided by the ARCHITECT. The Contractors shall
install a sub-meter for measuring electric energy at their own cost and maintain the wiring
installation in good condition and good order and pay the consumption charges directly to the
General Contractor.
TESTING LABORATORY
The Contractor shall establish a field laboratory for the various field tests for items like concrete
cubes, cement, aggregates, sand, blocks for masonry, tiles, wood and for similar items as directed
by the PMC. A Site Laboratory of approximately 5.0 x 7.0 m. area with platform etc. shall be
constructed for items similar as directed by the PMC/ARCHITECT.
The Laboratory must have the following equipment dully
calibrated;
Slump Cone : 3nos.
as per ISI
Cube mouldsforconcrete : 72nos.
Cube moulds forcementmortar : 6nos.
Cementtestingequipment : 1 set
Soundnessaccelerated (Initial and final setting, fineness,compressive
test equipment, etc.)
Oven : 1no.
Cube Testing Machine capacity up to 2000T
Dullycalibrated : 1 no. Digital Weigh Balance weigh upto
1 kgs to500kgs : 1No.Digitaltypeto weighupto10Kgs
Glass-measuringCylinders : 6nos.
UltrasonicEquipment : 1no.
MicroMeter : 1no.
Verniercaliper : 1no.
MoistureMeter : 1 no. Permeability Test meter /Equipment
![Page 158: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/158.jpg)
158
Model : 1 No.
Construction of Laboratory building well-equipped with equipment as listed above is incidental to
the work and no separate payment will be made for this.
The Contractor shall carry out other various tests for various items and materials at approved
laboratory as directed by the RE / ARCHITECT at Contractor's own cost. At the end of each month
for each category of the work, e.g. RCC work, masonry work, etc. the Contractor shall give
statistical analysis of all the test results in the format prescribed by the Engineer and take
corrective action in the work in accordance with these results.
All test required by contract shall be done by the Contractor at his cost within quoted rate. Test
shall be conducted at approved laboratory by PMC/ARCHITECT. Test may be witnessed by PMC/
ARCHITECT’s representative if he chooses so.
SITE DRAINAGE / CLEANING / NUISANCE
All water which may accumulate on the Site during the progress of the Works or in trenches
and excavation, shall be removed from the site to the satisfaction of the Engineer at the
Contractor's cost.
The Site shall be maintained free from rubbish. Proper stacking of scaffolding material,
shuttering material, bricks/brickbats, steel pieces, etc. needed for work on day to day basis
shall be organized in proper stacks. Heaps in unplanned manner and disorderly fashion shall
not be permitted. The Engineer's decision in this matter shall be final.
The Contractor shall not, at any time, do cause or permit any nuisance on the site or do
anything which shall cause unnecessary disturbance or inconvenience to the Employer, tenants or
occupants of other properties near the Site and to the public in general.
9.16.0 SAFETY CODE
The Contractor shall, at his own expense, arrange for the safety provisions as given in Part - VIII of
Vol – I, required by the authorities and as required by the Engineer, in respect to all labour directly
or indirectly employed for performance of the Work and shall provide all facilities in connection
therewith. The Contractor shall provide crèche facility to labours working at site as per local
authority rules or as directed by the PMC/ARCHITECT. In case the Contractor fails to make
arrangements to provide necessary facilities as aforesaid, the PMC/ARCHITECT shall be entitled to
do so and recover the cost thereof, from the Contractor.
![Page 159: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/159.jpg)
159
9.17.0 WATCHING ANDLIGHTING.
The Contractor shall provide and maintain at his own cost all areas fully ventilated, illuminated
and guarded. Any instruction in this regard given by the Engineer for the protection of the
Works or for safety and convenience of those employed on the Works or the public shall be
carried out at the Contractor'scost.
9.18.0 FIREPRECAUTIONS
The Contractor shall comply with regulations of the controlling authority in force at the site of
the Works relating to the precautions to be taken against fire hazards.
9.19.0 ACCIDENTS
Should any accidents, fatal or otherwise occur, a detailed report about the same shall be made
promptly by the Contractor to the PMC/ARCHITECT. The Contractor should at all times during
execution of work keep the Employer fully indemnified against all risks, claims, litigations and
financial burdens arising out of all incidental operations on work and accidents.
9.20.0 USE OFSITE
The Contractor shall not use any portion of the Site for purpose not connected with the works
without the prior written approval of the PMC/ARCHITECT. He shall maintain permanent and
Site access roads free of spillage and shall not interfere with the flow of traffic. Also same shall
apply to terraces and other developed areas.
9.21.0 PROTECTION
Adequate protection against any form of damage or deterioration shall be provided for in all
sections of the Works. This shall include protective tapes, casings, guard rails and the likes,
which shall be provided if necessary. Particular care shall be taken to self- finished surfaces
during the application of adjacent in-situ work. The Contractor shall carry out all steps taken in
pursuance of this clause, as directed and instructed by Engineer to hissatisfaction.
9.22.0 CLEANING OFWORKS
Immediately prior to handing over the works, the Contractor shall thoroughly clean all buildings
and external paved areas, and generally clean the Works to the approval of the Engineer.
![Page 160: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/160.jpg)
160
LABOUR ACCOMMODATION
WASHING & BATHING PLACES:
(a) Adequate washing and bathing places shall be provided, separately for men and women.
(b) Suchplacesshallbekeptincleananddrainedcondition.
(c) SCALE OF ACCOMMODATION IN LATERINES &URINALS:
There shall be provided within the precincts of every work place latrine and urinals in an
accessible place and the accommodation, separately for each of them shall not be less than the
following scale.
No. of seats
(a) Where the number of persons does not exceed 50 m 2
(b) Where the number of persons exceeds 50 but does not
exceed100 3
(c) For every additional 100 3 per100
In particular cases, the Engineers shall have the powers to vary the scale where necessary.
LATRINES & URINALS FOR WOMEN:
If women are employed, separate Latrines & urinals screened from those for men and marked in
vernacular in conspicuous letters “for women only” shall be provided on the scale laid in Rule 6.
Those for men shall be similarly marked “For men only”. A poster showing the figure of men or
women shall also be exhibited at the entrance of latrines for the respective sex. There shall be
adequate supply of water close to the Latrines & Urinals.
LATRINES & URINALS:
All latrines shall be provided with septic tanks or leach pits in case of small units. All the latrines
shall be kept in good sanitary condition.
CONSTRUCTION OF LATRINES:
The inside walls shall be constructed of masonry or some suitable heat resisting non – absorbent
materials and shall be cement washed inside and outside at least once a year. The dates of
cement washing shall be noted in a regular maintained for this purpose and kept available for
inspection. Latrines will not be of a standard lower than bore – hole system and should have
thatched roofs.
DISPOSAL FOR EXCRETA:
Unless otherwise arranged for the local sanitary authority arrangements for the proper disposal
of excreta shall be made by septic tank or leach pit duly approved by the PMC and in conformity
with the requirements of local public health authorities.
![Page 161: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/161.jpg)
161
PROVISION OF SHELTER DURING REST:
At every work place there shall be provided free of cost two suitable sheds, one for meals and
the other for rest separately for men and women for the use of labour. The height of the shelter
shall be not less than 3.5m from the floor level, to the lowest part of the roof. The sheds should
be roofed with at least thatch and mud flooring will be provided with a dwarf wall around not
less than 750mm. Sheds should be kept clean and the space should on the basis of at least 0.50
square metre per head.
CRECHES:
a) At every work place, at which 50 or more women workers are ordinarily employed, there
shall be provided two huts for the use of children under the age of 6 years belonging to such
women, one hut shall be used for infants, games and play and the other as their bed room.
The huts shall not be constructed on a lower standard then the following:
Thatched roofs
Mud floors and walls
Planks spread over the mud floor and covered with matting.
The huts shall be provided with suitable and sufficient openings for light and ventilation. There
shall be adequate provision of sweepers to keep the place clean. There shall be two daises in
attendance. Sanitary utensils shall be provided to the satisfaction of the Health Officer of the
area concerned. The use of the hut shall be restricted to children, their attendants and mothers
of the children.
Where the number of women workers is more than 25, but less than 50, the Contractor shall
provide at least one hut and one dai to look after the children of women workers.
The size of crèche or crèches shall vary according to the number of women workers.
The crèche or crèches shall be properly maintained and necessary equipment like toys etc.shall be provided.
CANTEEN:
a) A cooked food canteen on a moderate scale shall be provided for the benefit of workers
wherever it is considered expedient.
b) The above rules shall be incorporated in the contracts and in notices inviting tenders and
shall form an integral part of thecontract.
![Page 162: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/162.jpg)
162
APPROVAL OF SPECIALIST
Tenderer shall submit along with tender, names and address of their specialist sub-
contractor in the field of electrical, plumbing, water proofing, anti-termite, piling etc. These shall
be approved as per clause no.1.5 of General Conditions of Contract.
INSURANCE
The Contractor shall be responsible for all insurances and shall start execution of work only
after payment of premium for following policies
a) CAR Policy for entire cost ofproject
b) Workmen compensation
c) Third Party
And copy of receipts are deposited with OWNER. All policies shall be in full force for full amount
during contract period.
9.26.0 PERMISSIONS
During the course of construction the Contractor may have obtained the permissions from
authorities for use of materials and installation of the equipments. Same shall be transferred to
the Employer on the completion of work i.e. when completion Certificate under Clause No. 2.7.0
is given. The Contractor will have to liaison with various concerned authorities to obtain various
Statutory N.O.C.’s / Commencement Certificates at various stages / Permanent Water
Connection / Permanent Drainage Connection / Permanent Electric Connection and all other
necessary Approvals during the work or at completion stage. Necessary drawings or assistance
shall be given by the Architect if.found necessary. Actual official charge paid on behalf of Owner
for which receipt will be issued, such payments will be reimbursed by the Owner.
9.27.0 DESIGN, DRAWINGS AND CO-ORDINATION (MEP)
The contractor is responsible for the final MEP design and co-ordination of this design with the
Architectural and Structural schemes. If any clashes are found when developing the MEP design,
then the architectural design intent will take priority and the MEP design must be modified to
suit.
9.28.0 WEEKLY REPORTING TO THE CLIENT
Weekly Reports on Labour, Materials, Progress and Hindrances shall have to be submitted by
the Contractor through the Architects, to the Owner. A set of minimum Ten coloured
PHOTOGRAPHS (8" X 6") size from different angles of the building / site of construction shall also
be submitted once a month to show the progress by the Contractor at their cost.
![Page 163: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/163.jpg)
163
9.29.0 TRAFFIC
The Contractor shall have to make all necessary arrangements for regulating traffic day and
night during the period of construction and to the entire satisfaction of the ARCHITECT. This
includes the construction and maintenance of diversion, if necessary, at no extra cost to the
Corporation. The Contractor shall provide necessary caution boards, barricade, flags and lights,
watchmen etc. so as to comply with the latest Motor Vehicle Rules and Regulations and for
traffic safety. The Contractor shall be responsible for all claims for the accidents which may arise
due to his negligence whether in regulating traffic, in stacking materials on the road or by any
other reason.
9.30.0 ALIGNMENT AND BENCHMARKS
The alignment of the work to be carried out under the contract shall be marked on the ground
as per the drawing and as per the instructions of the RE. For the purpose of facilitating the work,
the series of temporary bench marks on masonry pillars will have to be established. These pillars
will be constructed along with the alignment and such other locations as may be initiated by the
RE. All expenses involved in the process of marking alignment on ground, checking the
alignment, constructing masonry pillars in establishing bench marks thereon, shall be borne by
the Contractor. It will be responsibility of the Contractor to ensure that the masonry pillars so
constructed are not damaged during the period of work in progress.
9.31.0 COMPLIANCE WITH CONTRACT LABOUR ACT
The successful tenderer is required to produce to the satisfaction of the ARCHITECT a valid
license issued in his favour under the provisions of the Contract Labour (Regulation & Abolition)
Act 1970, before starting the work. On failure to do so, the acceptance of the tender is liable to
be withdrawn and also the earnest money forfeited.
9.32.0 PREVENTION OF MOSQUITO BREEDING AT CONSTRUCTION SITE
The Contractor shall on the respective construction site install mosquito proof and accessible
water storage tanks or to cover/protect the present water storage tanks properly.
The Contractor shall periodically give larvaecidal treatment to water storage tanks, sites of
water stagnation, water collection. Any expenditure that may be incurred by Employer to
ensure that the above conditions are fulfilled by the Contractor will be debitable to Contractor's
account and will be recovered from the bills of the Contractor from time to time.
![Page 164: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/164.jpg)
164
9.33.0 ADJUSTMENT OF ERRORS IN SCHEDULE OF RATES AND QUANTITIES
The several documents forming the contract are to be taken as mutually explanatory of one
another, detailed drawings being followed in preference to small scaled drawings and figured
dimensions in preference to scaled dimensions.
The tendered amount shall be deemed to include for the full and entire completion of the
works and the Contractor shall have no claims on account of any errors.
Any error in description, quantity in Schedule of Offer or any omissions there from, shall not
vitiate the Contract or release the Contractor from the execution of the whole or any part of the
works comprised therein according to drawings and specifications or from any of his obligations
under the contract. Any error in amount quoted in Schedule of Offer of the price bid, shall be
adjusted in accordance with the following rules contained hereinafter.
GST REGISTRATION
Employer is registered under GST.
All the Contractors who are going to quote shall furnish their GST Registration number. Cess
from local bodies if levied shall be paid by the Contractor.
9.35.0 FENCING
The Contractor shall provide at his own cost fencing around proposed building as per
requirement with the prior permission of PMC/ARCHITECT/EMPLOYER.
WORKING HOURS:-
Site Office working hours shall normally be fixed as may be prevailing in the locality.
Normally no construction work of important structural nature shall be carried out on Sundays,
holidays and during nights. In exceptional circumstances, however, the work may be carried
out with prior approval of Client /Architect, Site Engineer who shall depute supervising staff to
be present on the occasion.The Contractor is free to work for any hour, subject to local
restriction, if any, by any statutory authority like Labour Department etc.
9.37.0 SAMPLE DWELLING UNITS - STANDARD OF WORKS:-
To determine the acceptable standard of workmanship and also to decide if any variations are
required in the layout of internal services or finishes, the contractor shall execute sample
dwelling unit I/flat. This complete dwelling unit /flat shall be put up for
inspection and approval within 12 month from the date of commencement of work
indicated in the work order issued by the Owner.
![Page 165: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/165.jpg)
165
For all items of works, services, and finishes such as floors, internal plaster, joinery including all
fittings and hardwares, sanitary fittings, plumbing, electrification, entire kitchen, and toilet
fittings, wall finishes, and painting etc. Shall be completed in all respects before putting up for
inspection and approval. The sample of work shall be jointly approved by
PMC/Achitect/EMPLOYER.
9.38.0 IDLE LABOUR:-
Whatever the reasons may be, no claim for idle labour, additional establishment cost of hire and
labour charges of tools and plants would be entertained under any circumstances.
9.39.0 CONCEALED WORK:-
The Contractor shall give due notice to the Employer whenever any work is to be
buried in the earth, concrete or in the walls or otherwise, becoming inaccessible later on,
in order that the work may be inspected and correct dimensions taken before such burial, In
default whereof the same shall, at the opinion of the Employer be either opened up for
measurement at the Contractor's expenses or no payment may be made for such materials,
shall any dispute or difference arise after the execution or any work as to
measurements etc. or other matters which cannot be conveniently tested or checked, the
notes of the employer shall be accepted as correct and binding on the Contractor.
SETTLEMENT OF DISPUTES:-
Excepted matters
If any dispute or difference pertaining to the undernoted matters arises, the decision in
writing of the supervising PMC/Architect /EMPLOYER shall be, conclusive and
binding on the Contractor/s.
a) Written Instructions.
b) Permissions from Local Authorities.
c) Proof for quality of materials and the works.
d) Assigning or subletting of the contracted works.
e) The causes of delays and extension of time.
f) Rectification of defects during the progress and Defects Liability Period.
g) Contractor's due diligence care and supervision at the works.
h) Measurements of works.
i) Reports on quality and progress of works.
j) Contractor's abandoning of the contract, partially/fully.
![Page 166: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/166.jpg)
166
k) Notice of termination I determination of the contract by theEmployer.
9.41.0 PERMITS AND LICENSES:-
Permits and License for release of materials which are under Government control will be
arranged by the Contractor. The Owner will render necessary assistance, sign any forms or
applications that may be necessary. Charges, if any are to be borne by the Contractor.
9.42.0 CONTRACTOR IMMEDIATELY TO REMOVE ALL OFFENSIVE MATTERS:-
All soil, filth or other matters of any offensive nature taken out of any trench, sewer drain
cesspool or other place shall not be deposited on the surface but shall be at once carted away
by the Contractor.
The Contractor shall keep the foundations and works free from water and shall provide,
maintain at his own expenses electrically or other power driven pumps and other plants to the
satisfaction of the Owner for the purpose until the building is handed over to the Owner.
The Contractor shall arrange for the disposal of the water so accumulated to the
satisfaction of the Owner and local authority and no claims will be entertained afterwards
if he does no including his rates for thepurpose.
9.43.0 DATUM:-
The average ground level will be considered as thecrown of the nearest road, which
should be taken as "Datum"which is however, subject to final confirmation by the
Owner / Architects. All levels shown in the drawings are to be strictly adhered to.
9.44.0 DIVERSION OF ROAD, NULLAH ETC:-
The Contractor shall, wherever necessary for execution of the work, divert the existing roads or
nullahs, if any, at his own cost without causing any hindrance to the shall thoroughfare. No
extra payments shall be made for this work. In all such cases, the Contractor restores the road
or nullah to its original condition for which no extra payments will be made.
9.45.0 MATERIALS SUPPLIED BY THE OWNER:-
If any materials are supplied by the Owner, the Contractors must satisfy themselves that the
same conform to the Specifications.If the Contractor has any complaint about the said
materials or the quality thereof, the Contractor before using the said materials in writing
their entire objection to the Owner. Should the Contractors fail to do so, they will be deemed
to have satisfiedthemselves as to the quality and the suitability of the said materials for
being used in the Contract works and the Contractors will be in the same position as if the
![Page 167: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/167.jpg)
167
Contractors themselves had purchased the saidmaterials.
9.46.0 BANK'S EMPLOYEES:-
No employee of the Bank is allowed as a Contractor for a period of two years of his
retirement from bank service without the previous permission of the Bank. The Contract is
liable to be canceled if either the Contractor or any of his employees is found at any time to
be such a person who had not obtained the permission of the Bank as aforesaid before
submission of the tender as engagement in the Contractor'sservice.
SPILLED OVER OBLIGATIONS FOR BALANCED WORK
This contract is entered into for performance of the incomplete/ balance work for execution
of Construction Of Building For Bank Of India On 3rd Corporate Office Building at C-29, G-Block,
Bandra-Kurla Complex, Mumbai.and therefore the special and particular statements made
here below in this article constitute the special conditions and obligations for the balance
work that is required to be executed for completing the project. These
terms/conditions/obligations shall supersede all that is stated elsewhere in the contract
where they create any inconsistency/ambiguity. The statements below are to be read as
statements of final intention for performance of the contract.
The rates quoted are for full and complete scope of the work intended to be performed and
shall have nothing deemed as omitted or list out so far the completion of the scope is
concerned and are inclusive of all obligations related to relevant specifications for
performance of the items.
No variation or change order shall be assumed as agreed unless the same is constituted as
part of this contract by signing a joint memorandum of understanding in respect of such
variations and changes accept in so far as such variation and changes relate to the quantities
involved and manifested through issue of drawings and the rates intended for such items
shall be those as included in this contract. For the purpose of avoiding any doubt as to
intention of this provision, it is stated that there shall be no change in scope,rates and time
for performanceof any extra orvariation and change order unless the same is reduced to
writing and jointly signed by both the parties to the contract.
It is agreed and acknowledged by both the parties that the provision of compensation in event of
delay in performance is an agreed amount as true compensation intended to compensate the
employer/ owner for liquidating the financial consequences resulting from delay having been
caused by the contract.
![Page 168: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/168.jpg)
168
It is acknowledged by the contracting agency that the complete status of pervious work done in
respect of quality and quantity have been fully examined and appreciated so as to accept that the
rates quoted are adequate and sufficient for performance of the balance work henceforth and
are inclusive of whatever incidental work is required to commence and continue further
performance and for defects and deficiencies to be overcome to place the previous work done in
position to continue further performance of balance work. For clarity, it is emphasized that the
rates quoted shall be all inclusive and payable for the balance performance of the work and no
extra payment shall be due and payable otherwise.
The contracting agency acknowledges its complete obligations for completing the balance work
as constituting the scope of work for the specifications as expected and for as laid down in
relevant Indian Standards, whichever is more stringent and directed by Engineer-in-charge.
The owner shall be indemnified against any or all losses or damages likely to be suffered on
account of any performance by the contractor and shall own all liabilities in respect of defect
liability period as spelt out in this contract.
It is understood by both the parties to the contract that the work intended to be executed is
being governed and controlled by rules and regulations laid down by the Municipal Corporation
of Greater Mumbai and therefore any suspension as may result from enforcement of any of such
rules and regulations shall only be compensated in terms of adjustment of time and no other. It is
further acknowledged that either party to the contract shall liberty to opt out of contract in event
of such suspension exceeding 90 days and in that event, the settlement of dues shall be brought
about on work done on the basis of as is where is and no other compensation shall be due and
payable to eitherparties.
9.48.0 WITNESSING THE TENDER: ·
The tender for the work shall not be witnessed by a Contractor or Contractors who himself /
themselves has/have tendered or who may and had/have tendered for the same work.
Failure to observe this condition would render tender of the Contractor's tendering as well as
witnessing the tender liable to summaryrejection.
* * * * *
![Page 169: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/169.jpg)
169
CONDITIONS OF CONTRACT VOLUME
– I
PART – X
MAINTENANCE OF RECORDS
![Page 170: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/170.jpg)
170
TESTING OF MATERIALS
A chart showing the time and quality schedule for conducting test on various
building material is given. Please ensure that tests are carried out according to the
above guideline. Contractor’s rate shall include for necessary expenditure for
testing including transport of sample of following test as per IS provision subject
to provision
No
.
Material Test Test Procedure
Minimum
Qty
consumed
Frequency
1 Sand Silt Content
Bulking
C)Particle size
distribution
Field
Field
Field
20Cum
20Cum
40Cum
20 cum or part
there off
---Do---
Every 40 cum
required for RCC
work
2 Stone A) Soft
and
deleterious
B) Particle
size
distribution
IS: 2336 (
Part - I)
Field
20 cum
As required Every 45 cum
part thereof for
RC work for rest
of work as
desired
3 Reinforced
Cement
concrete
Slump
Cube strength
Field
Field Laboratory
10 cum
slab,
beams
and
connecte
d column
One a day or as
desired
Every 20 cum of
a day concrete.
4 Steel A) Ultimate IS: 1786 10 tone Every 20 tone or a
Tensile strength - part
B)Bend/Rebend ------Do-----
-----Do-- ---Do-----
strength
![Page 171: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/171.jpg)
171
C) Yield Strength -------Do-----
-----Do------
---Do----
D).Unit weight Per
-------Do-----
--- -Do---- -----Do----
running meter ----Do----- ------Do--- -----Do---
E).Elongation
5 Block (if
consumpti
on
A) Dimension IS 2185 Designati
o n of
blocks
Every 5000 nos.
and part
thereof.
![Page 172: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/172.jpg)
172
6 Chequere
d tiles (if
consumpti
o n is
more than
2500 tiles)
Abrasion
B) Water
Absorpti
on
C) Transver
se
Strength
Dimension
IS:13801: 2013
IS: 2-1960
5000 No. For 5000 or part
One test
persource
7 Marble A) Moistu
re absorption
B) Mhos scale
hardness
IS:1124-1974
IS:1706-1972
Rs.
50000
/-
Rs. 100000/- or
part thereof(
value)
8 Timber A) Moisture IS:11215-1985 0.5 cum Every one cum one
Content IS: 287-1993 part
B) Specific gravity
IS: 4021-1995
C) Density
9 Aluminiu
m door or
window
fitting
Thickness of
anodizing
coating
andsections
IS: 5523-1969 Rs. 10000/- or
part thereof
10 Ceramic
tiles /
Vitrified tiles, designer precast concrete tiles
SurfaceQuality
B) Dimensio
n, thickness
&surfaceflatnes
s
C) Physic
al properties
IS- 13630 Part-I
---Do---
IS- 13630Part-II
IS- 13630 (Part-
11)-2006
1000 tiles
---Do---
---Do---
2000 tiles or part
---Do---
---Do---
---Do---
![Page 173: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/173.jpg)
173
Scratch hardness
o
f surface
Abrasion resistance
IS- 13630 (Part-
3)-2006
---Do---
---Do---
---Do---
---Do---
F) Resistance to staining agent
---Do---
---Do---
---Do---
---Do---
G)Chemical
properties
H) Moisture
Expansion
![Page 174: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/174.jpg)
174
11 Flush Door A) End immersion IS: 2207 22-65 1 No. / 500 door
B) knife IS: 22002 Part-1 66-100
C) Adhesion IS: 4020 Part-1 101-180
D) Glue Adhesive
E) Thickness of 181-300
Laminates 301-500
F) Dimension & 501-above
squareness
G) Flatness
12 R.C.C. Mix
1:1:2
All test as per IS: 456:2000 As directed As directed
13 Gypsum A) Chemical
Composition
IS: 1288
Appendix A,B,C
up to bag
100 - 2Bag
B) Initial & Final
Setting time
IS: 2547-1976
Part- I & II 150 - 4bag
300- 5bag
500 - 7bag
C)Transverse
Strength Above 500-10 bag
D) Soundness
E) Mechanical
resistance
F) Residue om
1.18mm IS sieve %
G) Expansion on
setting %
14 Modular
Kitchen,
Wardrobe
A) Glue Adhesion
test
B) Glue shear
strength test
IS: 303 Per lot of
manufacture of 50
No.or partthereof
C) Mycological test
D) Moisture
content
![Page 175: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/175.jpg)
175
15 Paver Block A) Dimension IS: 15658-2006 2000 Block or part
there of
B)Compressive
Strength test
---Do---
C)Water
Absorption test
---Do---
D) Thickness of
wearinglayer ---Do---
16 Ceramic
tiles
A)Dimension
&surface quality
B)Physical
properties
Is: 1363 Part- 1
IS: 1363
Part:2,3,4,5,6,9,
13
2000 tiles or part
C)Chemical
properties
Is: 1363 Part- 8
17 Rock A) Type &
Identification of
rock
B) Crushing
strength ofrock
30 No. Of test
Note: The Contractor will have to take necessary material tests other than above tests as per I.S.
code for above ·material or for other than above materials, if required and as directed by the
Architect / Owner at their cost. The frequency of tests may be reduced by the owner/Architects,
if it is found necessary and the necessary expenditure is also to be borne by the Contractor for
increased number of tests.
![Page 176: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/176.jpg)
176
16. INSPECTION REQUEST
To,
Engineer in charge Construction Manager
Site Office
Dear Sir,
The following items of work are ready for execution. We have checked the
same and find everything in order. You are requested to inspect the same and
approve execution of the said items.
S.NO. Item of Work Location
Drawing B.O.Q. Item Grid Wing Floor
REMARKS OF ENGINEER IN CHARGE
ENGINEER IN CHARGE
![Page 177: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/177.jpg)
177
IRRECEIVEDON AT (SIG) CONTRACTOR
IRRECEIVEDON AT (SIG)
![Page 178: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/178.jpg)
178
TABLE-17 DAILY WORK PROGRESS REPORT REGISTER
PROJECT :- BANK OF INDIA, BKC
OWNER :- MCGM BANK OFINDIA CONT:-
ARCHITECT- SITE REP.- PMC:-
A) GENERAL SITE
DETAILS
B) Location:
C) Weather Condition:-
D) SCOPE OFWORK
Todays Progress:-
1
2
3
4
5
Work Progress Major Activities
Activity Approx.Qty TillY-Days Today Tilldate Balance
Excavation 0-1.5m
Excavation 1.5-3m
Excavation 3- 5m
Filling with site material
![Page 179: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/179.jpg)
179
Filling murrum
Filling sand
Subgrade(Soling)
Anti-termite
treatment PCC
1:3:6 (M10)
PCC 1:2:4(M15)
PCC 1:4:8(M7.5)
Shuttering-
PCC RCC
M20
RCC M25
RCC M35
RCC M40
Reinforcement
![Page 180: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/180.jpg)
180
C) RESOURCES i) Materials- This list includes any extra
Materials
Till 'Y' Days
Today
Till Date
Remarks/Make
Cement PCC M-7.5 PCC M-10 PCC M-15 RMC M-20 RMC M-25 RMC M-35 RMC M-40 Shabad Stone
Bricks Rein-Steel Subgrade Rein-Steel 8
TOR 10 TOR
12 TOR
16 TOR 20 TOR
25 TOR
32 TOR
TOTAL
Remarks/Make
Till 'Y' Day
CRS Steel
Today
Till Date
0
0
0
0
0
0
0
0
ii)Labour Strength
LABOUR
CARPENT ER
FITTER
MACHINARY
CURING
TOTAL
Male
Female
Skill
Unskill
Skill
Unskill
Tractor
Roller
Dozer
Water Tanker
HELPERS OPERATORS MASONARY WELDER CHIPPERS
iii)Machinery Steel Cutting M/C-Small/Big CONCERNS/REMARKS
Steel bending M/C Earth Compactor/Plate compactor
Vibrator-Needle 60 mm & 40 mm
![Page 181: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/181.jpg)
181
Dewatering Pump-Vibrator
Welding M/C-Small Mechanical Excavator/Pocklain
Dumper/Tractor RMC Pumping M/C 10 ton road roller Dozer Water tanker D) Attachments/Remarks/ Observations:-
![Page 182: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/182.jpg)
182
18. DRAWINGS RECEIVED REGISTER
S. No.
Date
Referenc e
Title
of
Drawi
ng
DRG.No.
RCV/Date
Signature Remarks
CLIENT PMC Cont.
![Page 183: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/183.jpg)
183
![Page 184: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/184.jpg)
184
23. SLAB PASSING
a) SHUTTERING
Date Particulars Received Date
Signature Remarks
CLIENT PMC Contr.
![Page 185: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/185.jpg)
185
23. SLAB PASSING
b) REINF ORCEMENT
Date Received Particulars Date
Signature
IATES Remarks
Contr.
25. CONCRETE POUR CARD
Grade of Concrete
Quantity of
Concrete
S.No. Itemdescription Starttime Finishtime
A. Checklist forShuttering
1 MaterialQuality
2 Orientation
3 ShutteringQuality
4 Dimensions
5 Centerline
6 Diagonals
7 Covers
8 Gapssealing
9 Support/Bracing
10 Plumb
11 FillingLevel
12 AdequateProps
13 Bolting
B Checklist forReinforcement
1 MainBars
2 Distribution
3 ExtraBars
4 Laps
5 Dowels/Anchors
6 Stirrups
7 Chairnos
8 ChairDimensions
9 BindingWire
![Page 186: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/186.jpg)
186
C Checklist beforeConcreting
1 Cleaning Junction/Corner
![Page 187: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/187.jpg)
187
2 Staging/ Platform
3 Concrete Tray
4 Ghani Register
5 Vibrators
6 Slump Cone
7 Cubes 6 nos.
8 Light for Night Concreting
9 Tarpaulin
10 Walk Way
11 Covers
D
Mix Propertion & Quality
1
Batch, Date & No. of Cement
2 Grade of Concrete
3 Weigh Batcher
4 Volumetric Batcher
5 Silt Content of Sand
6 Metal I
7 Metal II
8 Sand
9 Grid
10 Cement
11 Fly Ash
12 Water
13 Admixtures
14 Slump
15 Shear Keys
![Page 188: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/188.jpg)
188
16
Cubes taken (nos)
E
Checklist for MEP
1
Electric/ Telephonic Conduits
2 Plumbing/ HVAC Conduits
3 Sleeves/ Cutouts
4 Hooks, if any
F
Cement/ Fly Ash Consumption
1
Cement (Batch No./Lot No.)
2 Fly Ash (Theoretical/ Practical)
Remarks Confirmation after remarks
For Contractor
For PMC
![Page 189: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/189.jpg)
189
TABLE-26 REQUEST FOR INFORMATION
BAK OF INDIA
CLIENT : BANK OF INDIA Document Reference No:
PMC
ARCHITECT
26. REQUEST FOR INFORMATION
RFI No / Initiator:
Rev. Date:
Approval Required Date:
[]CIVIL. []ARCH. []STR. []ELECT. []MECH []IBMS. [ ]OTHERS
Area/Floor
Item
Drg. Ref
Spec Ref
BOQ Ref
(copy attached)
(copy attached)
INFORMATION REQUESTED:
ATTACHMENTS:
Signature and Date
Signature and Date
(Initiator) (ARCHITECTS)
Comments
Architect / PMC’s Signature and Date:
![Page 190: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/190.jpg)
190
TABLE-27 SUBMITTAL FORMAT
Name of the Project: BAK OF INDIA
Client BAK OF INDIA
PMC
Architects
27. DOCUMENT/SAMPLE SUBMITTAL FOR APPROVAL
Submittal No: Ref: Date:
To:
Approval Required Date:
From:
Sr. No SERVICES BOQ Ref. No. Description Drg.Re f. no
Rev Qty
Enclosures:
Prep. by
Reviewed by
Signature of the Contractor
(Name )
(Name) (Name)
Approval Process
[ ] A - Approved [ ] B - Approved with Comments
(Resubmission not Required) (Resubmission Required)
[ ] C - Additional Information Required [ ] D – Rejected
Comment s:
Client Signatur eand Date:
Architects Signature and Date: Contra ct or
Signature and Date:
![Page 191: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/191.jpg)
191
TABLE - I
PROFORMA OF 10 YEARS GUARANTEE BOND FOR WATERPROOFING TREATMENT TO ROOF, STAIR ROOF, UNDER GROUND RESERVOIR, OVERHEAD RESERVOIR AND TOILETS IN THE PROPOSED BUILDING FOR BANK OF INDIA AT C-29, G-BLOCK, BANDRA-KURLA COMPLEX, MUMBAI.
The Bond is to be submitted on a Non-judicial Stamp Paper of Rs. 100/• before claiming
any payment from the Bank
We hereby guarantee that after completion of the Waterproofing work at at building of Bank of
India at C-29, g-block, Bandra-Kurla Complex, Mumbai for Bank of India and within 10 years
thereafter the date of virtual completion of the Project by the main contractor, if at any time or
times the roofs, moris, toilets, water tanks and any other portion thus treated by M s
---------------------------------------------------------- (hereinafter called "the Contractor") starts leaking
or in any way give way to the influence of water including forming wet patches, dampness etc.,
due to the inadequacy of the work carried or due to any other reason whatsoever relating to the
specification, workmanship etc. including the responsibility for any surface treatment and
plumbing etc. works carried out by other agencies, the Contractor shall, without any extra cost,
to the-------•-----------------or to the Occupants, carry out necessary remedial measures to such
extent and so often as may be necessary to free the said premises from leakage etc. . The
question of whether there is any leakage or the treatment has given away to water or moisture
of the treatment aforesaid and before --------------------200 , shall be decided by the -------------------
and the decision of the in this regards shall be final and binding on us. We shall reinstate the
surface to the original condition after carrying out the rectification work, if necessary, by bringing
new materials at no extra cost to the BANK theOwner --.
Signature of Witness with the address Signature of Waterproofing Contractor with seal
1. Place:
2. Date:
![Page 192: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/192.jpg)
192
Signature of Witness withtheaddress Signature of the Main Contractor with seal
Place:
Date :-
(Note: - Guarantee to be submitted by both the Contractors, Main Civil Contractors and the
Waterproofing Specialist Agency before receiving any payment towards water proofing work)
![Page 193: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/193.jpg)
193
TABLE -II
PROFORMA FOR RUNNING A/C. BILL
1) Name :
2) Name of Contractor/Agency :
3) SI. No. of this Bill :
4) M.B. No.Pages No.s :
5) No. and date of Previous Bill :
6) Reference to Agreement No :
7) Date of Written Order to commence :
8) Date of Completion as per :
Sr. No. Item
descrip
tion
Unit Rate
(Rs.)
As per Tender Present addition Up to Date (
Gross bill
Remark
Qty. Amoun
t (Rs.)
Qty. Amoun
t
(Rs.)
Qty. Amoun
t
(Rs,)
1 2 3 4 5 6 7 8 9 10 11
Note: 1) If part rate is allowed for any items, it shall be indicated with reasons for
allowing such a rate. Total up dated Value of the bill
2) If ad-hoc payment is made, it shall be mentioned specifically with reasons.
![Page 194: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/194.jpg)
194
Site Engineer Architect
CERTIFICATE
The measurements on the basis of which the above entries for the Running Bill No ---------- • were made
Have been taken jointly on---------------------and are recorded at pages--------------to ------------------------- of
measurement Book No. ---------
Signature and date of PMC’S Representative (Seal)
/Engineer/SiteEngineer
CERTIFIED that the Materials supplied, work done and recorded as above has been actually
completed at the site satisfactorily and as per tender drawings, conditions and specifications.
![Page 195: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/195.jpg)
195
TABLE-III
FOR 75% COST OF MATERIALS RECEIVED AT SITE, IF ADMISSBLE
(Only Against valid indemnity bond, validupto ...................... )
*** Value of the materials received at Site based on the documents / receipts/challans...... Rs.
Cost of materials at site @ 75%, of above value- (B)
CERTIFIED (i) that the materials mentioned above have actually been brought by the
Contractor to the site of the work
(ii) that the materials are of NON perishable nature and are all required by Contractor for use
in the work in connection with the items for which rates of finished items of work have been
agreed upon.
Dated Signature of the Contractor
Dated signature of Site Engineer preparing the bill (Rank)
Dated signature of Bank's Architects / consultant (Name of the Architects)
No. Item Quantity Unit Amount ( Rs. ) Remarks
1 2 3 4 5 6
![Page 196: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/196.jpg)
196
TABLE-IV
PROFORMA FOR APPLICATION FOR EXTENSION OF THE PERIOD
1) Name of Contractor :
2) Name of the work as given in the Agreement :
3) AgreementNo. :
4) Estimated TenderAmount :
5) Date of commencement of work as per Agreement :
6) Period allowed for completion of work As per Agreement:
7) Date of Completion Stipulated in Agreement :
8) Period for which extension of time has been :
given previously
a) 1st extension vide Architect's/ Bank'sletter
No. Dated Month Days
b) 2nd extension vide Architect's/ Bank'sletter
No. Dated Month Days
c) 3rd extension vide Architect's/ Bank'sletter
No. Dated Month Days
![Page 197: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/197.jpg)
197
d) 4th extension vide Architects/ Bank'sletter
No. Dated Month Days
Total extensions previously given.
9) Reasons for which extensionhave been previously given (Copies of previous applications shall be attached) :
10) Period for which extension is applied for :
11) Hindrance on account of which extension is applied for with
dates on which hindrances occurred and the period for
which these are likely to last.
(a) SerialNo. :
(b) Natureofhindrance :
(c) Dateofoccurrence :
(d) Period for which it is likely to last :
(e) Period for which extension required for this particular hindrance :
(f) Overlapping period if any, with Reference too item (e) above
(g) Net extension applied for :
(h) Remarks, if any:
12) Extension of time required,amount involved :
13) Details of extra work and amount involved :
a) Total value ofextra work :
b) Proportionate period of extension of time : on estimated amount put to Tender
14) Total extension of time required for 11&12 :
Submitted to the Architect /Owner -----------------------------------------------------
Date: Signature of the Contractor
![Page 198: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/198.jpg)
198
TABLE-V MEMORANDUM OF PAYMENT
Tom/s.........................… R/A Bill No.-------
1) Total value of work done uptil now Rs ------------ (A)
2) 75% cost of materials received at site Rs -------------- (B)
3) Total amount upto date of this Bill Rs ------------- (C)
(C) = (A+B) Rs.
4) Total PVA if any as detailed in
a separate statements enclosed.(+ or-) Rs ------------ (D)
5) Total R.A.billNo. amount (C+D) Rs ------------ ( E)
(Recoverable From next Bill)
DEDUCTIONS / RECOVERIES (those not recovered in (C) above):-
1) Retention money on value as(E)above Rs.---------------
amount.
i. Less already recovered Rs.----------------
ii. Balance to be recovered Rs.---------------
iii. Cr. ToR.M.ale Rs.----------------
iv. Cost of Any other material supplied by the Bank, Rs.----------------
v. Charges to be recovered if any, as per Contract,
(Water, Power telephone etc.)enclose statement Rs.----------------
vi. Recovery Towards defective work asper
CTE'sReport noticed afterwards etc, Rs.----------------
vii. Recovery towards Liquidated Damages Rs.----------------
![Page 199: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/199.jpg)
199
viii. Recovery of the R.A. Bill amount at (E)
Of the previous Memo upto previous RA No. Rs.----------------
ix. Recovery of the Adhoc payments if any Rs.----------------
Deduction / recoveries as above(-) Rs -------------- (F)
Additions if any out of (F) in the previous bills and not included
in(A)above. Amount less received by
Contractor in the Memo no.or in
RIA Bill no. as per details enclosed Rs ---------------- (G)
Net amount payable as per this bill (E-F+G): Rs.----------------
Required insurance covers have been obtained and are kept valid till the likely completion of
the project by the Contractor. (Rupees----------------------------------------------------------------) as
above has been Certified by us after due supervision andchecking of the measurements and
rates for all the items of work at the site and the same is recommended forpayment.
Date: Signature of Architect/ consultant with Seal.
The Bill amounting to Rs ----------------------------- certified by the Architect/consultants has
been scrutinized by me after due test checking of measurements of works as required and
is recommended for payment for an amount of Rs. -----------------------
STATUTORY DEDUCTIONS:
1) Total amount due (E) Rs.----------------
2) Less : l.T. recoverable Rs.----------------
3) Less : S.T. recoverable Rs.----------------
![Page 200: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/200.jpg)
200
Cheque Amount Rs.----------------
Date: Signature of Owner's Engineer /officer.
![Page 201: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/201.jpg)
Sr
.
N
o.
Bill
No.
And
Dat
e
Amount Payable To
tal
Details of Disbursement and Recoveries Chequ
e
Amoun
t
Paymen
t of
Mobiliza
t ion
Advanc
e
Pris
e
vari
a
tion
Paid
Sec
u
red
Adv
a
nce
Se
c
uri
ty
De
po
sit
Lab
o ur
tax
Lab
o ue
cess
Secur
ed
Adva
nce
Principl
e
mobiliz
a tion
Interes
t on
mobili
z ation
advan
c
e
Any
Othe
r
Reco
v ery
XV
II - Th
e D
ocu
me
nts fo
r CV
C co
mp
lian
ce to
be
ma
inta
in a
s pe
r pe
rfom
a A
, B, C
, D, a
nd
An
ne
xure
III
PR
OFO
RM
A-A
DE
TA
ILS OFP
AY
MEN
T
195
![Page 202: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/202.jpg)
N
a
Signature :
![Page 203: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/203.jpg)
203
PROFOMA-B
Cement Consumption Statement for Last Bill Paid
Last Date
of
Measureme
nt
Theoretical requirement
of Cement in Bag / M.T.
Actually
consumed in
Bags / M.T.
Recovered
/ Received
at site
Remark
Quantities
of item
Consuming
Cement
Factor
adopted for
consuming
Cement
Name :
Signature:
![Page 204: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/204.jpg)
204
PROFOMA-C
DETAILS OF STEEL REINFORCEMENT FOR LAST RA BILL PAID
TOR Steel / TMT
Steel
(Dia. In mm)
8 10 12 16 20 22 25 28 32 36 40 42
Qty. Issued by
Department /
Qty. brought to
site by
Contractor
Qty. Measure
for payment
(M.T.)
Qty. Recovered
from bill / Qty.
Consumed (
M.T.)
Notes:
1) If mild steel reinforcement isused, information may be furnished in same Proforma
as for TOR Steel.
2) If structural Steel isused, information may be furnished in similar Proforma for
various section instead of various Diameter.
Name:
Signature :
![Page 205: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/205.jpg)
Sr.
No.
Description of
Material
Qty.
Consum
ed till
Date (
M.T.)
Descripti
o n of
test
asperBI
S
/
agreeme
n t
provisio
n
Frequ
e ncy
of
test
as
perBI
S
/
agreem
ent
provisio
n
No. Of Test Lab.
Wher
e test
cond
ucted
Lab.
Whe
t her
appr
o
ved
by
Gov.
Status
of test
result
( Pass/
fail )
If
fail
what
acti
o n
is
take
n
Whether
testing
charged
born by
department
/ agency (
Refer to
agreement
provision )
Recov
ery
propo
sed
for
short
fill in
test /
filled
result
Requ
ired
Co
n
duc
ted
1 2 3 4 5 6 7 8 9 10 11 12 13
PR
OFO
MA
-D
ST
AT
EM
EN
T O
F T
ES
T O
F M
AT
ER
IAL
198
![Page 206: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/206.jpg)
NAME :
Signature :
![Page 207: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/207.jpg)
207
Annexure - III
Following documents are generally asked for during inspection.
1) Proforma A – Complete Payment detail with all the recoveries. Complete payment for
R/A bills, Secured advances, Escalation, any advance, all reimbursements etc.
2) Copies of 1st R/A bill, March bill, latest bill, Advances bill (MA with utilization
certificates, T& P advance, Secured Advance, any other advance etc.), Escalation Bills
with copies of indices.
3) Proforma B – Cement consumption with up to date quantities, theoretical requirement
and actual cement procured by Contractor.
4) Proforma C – Steel consumption- Total quantities paid and brought by the contractor dia
wise and for structural steel.
5) Proforma D-Complete testing record including pile testing, compaction test, all
materials, concrete test, and structural steel tests DP/RT etc…..along with sample test
reports of all registers as well as outside lab test reports.
6) Bank guarantees-Statement of all B.Gs. and copy of B.Gs. with confirmation from Bank.
7) Insurance policies- statement and copy
8) Labour License
9) P.F registration and sample challans
10) ESI registration ans sample challans
11) Royalty on materials-Statement of total royalty required to be paid and actual paid.
12) Engineers deployed by the contractor. As per contracts v/sactual
13) T & P including Lab. Instruments. As per contracts v/sactual
14) Copy of mix designs for concrete and bitumen.
15) RMC challans with ratio of materials used in the RMC.
16) EOT detail mile stones, recovery, bar chart etc.
17) Detail of checking by departmenta lvigilance, 3rd party quality control, QC of
department, accounts audit, Accidents etc.
18) Extra items approval and analysis.
19) Statement of makes of material used.As per contract v/sActual used at site with
approval of any deviation. Sample invoices of all these materials.
20) Copy of T.S./estimate with analysis of rates.
![Page 208: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/208.jpg)
208
21) Award file.-Nothing pages complete, Board notes, comparative statement, justification,
Minutes of meetings of tender documents etc. All relevant papers.
22) Test check detail.
23) Documents for consultants…Award, bill detail, copies of bills, B.Gs., Insurance manpower
deployment w.r.t contract.
24) Photographs.
![Page 209: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/209.jpg)
209
CONTRACT CONDITIONS
VOLUME – I
SCHEDULE`A'
Basic Price of Materials
1 Tile - As given in the BOQ of the respective items.
NOTE
1.0 Steel to be used and brought at site shall be from leading manufacturers like SAIL, TISCO,
Vizag or any other firms having minimum manufacturing experience of 3 years and IS
license. Steel manufacturers shall conform steel produced conforms IS requirements for
reinforced cement concrete works. Steel shall not react chemically with ingredient of
reinforced cement concrete which are harmful to strength, durability of reinforced
cement concrete.
2.0 The Contractor to make necessary arrangement to verify quality and testing on receipt of
each lot of steel and cement as and when received at site. Cost of testing shall be paid by
the Contractor.
3.0 Material shall be restricted to works being executed at site and forming part of permanent
or temporary works (such as site office, stores, godown, etc.) but not for labour hutments,
Ready mix concrete(purchased from market), RCC pipes, RCC jalies, etc. Materials listed
above shall not be considered for bought out items, procured by the Contractor from
suppliers and/or manufacturers where in such material might be incorporated during their
manufacture like Ready mix concrete, hume pipes, RCC jalies etc.
4.0 Property rights of the materials shall continue to vest with the Employer. The Contractor
shall not utilise the materials or deal with them in any manner whatsoever except for use
in the Contract.
5.0 The Employer/ARCHITECT / PMC reserve the right to direct the Contractor to procure basic
price material from supplier. It shall be Contractor's responsibility to co-ordinate and
receive delivery of material in time from suppliers/manufacturers when instructed by the
ARCHITECT / PMC
6.0 Cement brought shall be stacked by the Contractor in weather tight sheds constructed on
work site away from walls and on a damp proof floor. Consignments shall be used in the
order in which they are received. Adequate arrangements shall be made for keeping the
shed dry during the wet weather by all means or as directed by the ARCHITECT / PMC.
7.0 Steel received at site shall be stacked on firm ground with proper use of sleepers to avoid
contamination with mud / soil etc. Steel shall be kept covered with plastic to avoid normal
rusting.
![Page 210: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/210.jpg)
210
8.0 All other materials shall be stacked in secured godown preferably weather tight. Floor shall
be firm and stacking shall be in most planned manner to avoid damage, contamination,
warping, obstruction etc. It shall allow 1stcome 1st used facility.
9.0 All godowns shall be lockable and under strict control of the Contractor's representative.
The ARCHITECT / PMC or his representative shall have access at any time to all stores,
godown etc. His guidance and instruction in up keeping shall be followed.
10.0 While reconciling for the materials, the wastage shall be considered as specified and
approved by the ARCHITECT / PMC. Any additional wastage shall be recovered at the rate
1.25 times the market / basic price whichever is higher.
Signature of Contractor :
Date :
* * * * *
![Page 211: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/211.jpg)
211
FORM OF AGREEMENT
ARTICLES OF AGREEMENT
ARTICLES OF AGREEMENT made at Bombay on the______day of 20___between
“Bank of India” a body constituted by the Act having its office at Star House 2, 3RD Floor, C-4,
G-block, Bandra Kurla Complex, Bandra (E), Mumbai-400051. (Hereinafter called “the owner”)
of the one part
AND
(hereinafter called
“the Contractor” which expression shall, unless repugnant to the context, mean and include of
the otherpart.
WHEREAS
The Owner is desirous of getting constructed Building of Bank Of India (Hereinafter referred to
as the said plot of land) and the said Building is more fully described in the layout drawings and
for the purpose the parties hereto have agreed to enter into this contract (hereinafter referred
to as the work).
The Owner has for the purpose, caused the building plans, drawings and specifications, describing the works to be done; prepared by “ARK Designs Pvt Limited” its Architects having office at 101, Anish Tower CHS LTD., Senapati Bapat Marg, Matunga West, Mumbai- 400016.(Hereinafter referred to as the Architects)
The Owner has appointed ARK Designs Pvt Limited as the Project Management Consultants,
having their office at Hamam House, 34-38, Ambalal Doshi Marg, Mumbai -
400001(Hereinafter referred to as the PMC) for management, monitoring and supervision of
day – to day works and progress thereof.
The said drawings have been signed by or on behalf of the parties hereto and are annexed as
Annexure I hereto in series.
The Contractor has agreed to execute the said works viz. construction of the said office
complex and other structures etc. subject to the provisions hereinafter contained and subject
also to general conditions of contract, special conditions of contract with appendix, annexure,
![Page 212: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/212.jpg)
212
specifications, priced schedule of quantities, preamble, construction schedule and drawings as
per list all of which are hereinafter collectively referred to the contract documents strictly in
accordance with the building plans approved / to be approved (hereinafter referred to as “The
approved building plans”) by the NMMC/ CIDCO and the drawings annexed hereto,
specifications and the schedule of quantities referred to above at or for the respective rates
set out therein amounting the sum as there under arrived at or such other sums as shall
become payable there under. (Hereinafter referred to as the said contract value).
NOW IT IS HEREBY AGREED AS FOLLOWS:-
In consideration of the said contract value to be paid by the Owner to the Contractor at the time
and in the manner set forth in the said contract documents and in accordance with the Schedule of
payments to execute and complete the work shown upon the said Drawings and the approved
building plans strictly in accordance with the specifications and priced schedule of quantities and
other contract documents.
The expression “Architect” in the said documents shall mean architect for construction of said
office complex viz.ARK Designs PVT Limited., and the expression PMC shall mean Project
Management Consultant for the construction of the said office complex viz.ARK Designs PVT
Limited or in the event of their or any of them ceasing to the Architect or PMC, as the case may be,
for whatever reason, such other person or persons as shall be appointed by the Owner for that
purpose PROVIDED ALWAYS that no person subsequently appointed to be Architect or PMC shall be
entitled to disregard any opinion or decision or approval or instructions given or expressed in
writing by the Architects or the PMC for the timebeing.
The said contract documents shall be read and construed as forming part of this contract and the
parties hereto shall respectfully abide by, submit themselves to the said conditions and perform the
agreements on their part respectively contained in the said conditions.
The expression “Structural Consultant” shall mean and refer to Structural Consultants for
construction of the said office complex viz. V.V Joshi & Associates Consultant Pvt. Ltd engaged by
the Architect to carry out on his behalf structural consultancy with the approval of the Owner or in
the event of their ceasing to be the Structural Consultants for this project, such other person or
persons as may be appointed by the Architect with the approval of the Owner.
This contract shall be neither a fixed lumpsum Contract nor a piece work contract but shall be a
contract to carry out the work in accordance with contract documents on item rate basis to be
carried out and to be paid for according to the actual measured quantities at the rates priced in
schedule of rates.
The Contractor shall afford every reasonable facility for the carrying out of all works
relating to contract as may be awarded by the Owner in respect of specialized jobs such as
external and internal electrical works, central air conditioning, lifts installation, water
![Page 213: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/213.jpg)
213
treatment plant etc. and other ancillary works in the manner laid down in the said
conditions and shall make good any damage caused by him to such works.
The approved building plans and drawings mentioned herein shall also form the bases of
this contract.
The contract herein contained shall comprise not only the works mentioned above but all
subsidiary works connected there with at and within the same site as may be ordered to
be done from time to time by the said PMC for the time being, even if such work may not
be shown on the said drawings or described in the said of the specifications and Priced
Schedule of Quantities.
The Owner reserves to itself the right of altering the drawings and the nature of the work
through the Architects / PMC by adding to or omitting any items of work or having
portions of the same carried out without prejudice to this contract.
Time shall be considered as the essence of this contract and the Contractor hereby agrees
to commence the work within 15 days from the date of work order or handing over the
site as provided for in the said terms and conditions, whichever is later, and shall complete
the entire work within __months from the date of work order or handing over the site
subject, nevertheless, to the provisions for extension of time as may be agreed to by the
Owner and as contained in the said conditions.
All payments by the Owner under this Contract will be made only at Mumbai.
All disputes arising out of or in any way connected with this contract shall be deemed to
have arisen at Mumbai and only courts in Mumbai shall have jurisdiction to determine the
same.
This contract shall be signed in quadruplicate, the original whereof shall be kept in the
custody of the Owner, the duplicate with the Contractor, the triplicate with the Architects
and the quadruplicate with PMC.
IN WITNESS WHEREOF the Owner has set its hand hereunto and three duplicates hereof
through its duly authorized official and the Contractor has caused these presents and
three duplicates hereof under its common seal / by its duly authorized representatives at
the place and on the date month and year first hereinabove written.
SIGNATURE CLAUSE
SIGNED SEALED AND DELIVERED by Bank of India by the
Hand of Shri.__________________________________________
![Page 214: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/214.jpg)
214
(Name and Designation)
(1) in the presenceof
Address
(2) Address
SIGNED SEALED AND DELIVERED BY
M/s.
the Contractor by the name of Shri (Name
& Designation) in the presence of:
(1)
Address
(2)
Address
WITNESS
OR
THE COMMON SEAL OFM/s. the contractor
was hereunto affixed pursuant to the resolutions passed by its Board of Directors
at the meeting held on in the presence
of:
(1)
(2)
Directors who have signed these presents in token thereof in the presence of
(1)
(2)
![Page 215: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/215.jpg)
215
PERFORMA OF MATERIAL ADVANCE (INDEMNITY BOND)
PROFORMA OF UNDERTAKING HYPOTHECATION IN CONNECTION WITH PAYMENT OF
ADVANCE ON MATERIALS BROUGHT BY THE CONTRACTOR TO THE SITE
This undertaking executed at this day of 20 by
(hereinafter called the Contractors) IN FAVOUR
OF which expression shall include its
.
The Bank of India, having its office at Star House, Bandra Kurla Complex, Bandra (E), Mumbai-
400051. (hereinafter called the Owner) which expression shall include its successors and
assigns.
The Owners and the Contractors have entered into an Agreement dated for
construction of on office complex on piece of land belonging to the Owner
at_____________(hereinafter called as the said agreement) in terms of which Contractors will
be paid an advance of 75% of the cost of non – perishable building materials brought by the
Contractor to the site for consumption in the works at the discretion of the Owner.
The Contractor have since applied to the Owner that they be allowed advances as the security
of materials absolutely belonging to him and brought by them to the site of work and the
Owner has since agreed to do so on the terms and conditions hereinafter set out.
Now this letter of undertaking witnesses that in consideration of the said agreement, and in
consideration of the amount paid / payable to the Contractors by the Owner and of any further
advances as may be made to the Contractors as aforesaid, the Contractors hereby agree with
the Owner and undertake as under:
The amount advanced by the Owner to the Contractors as aforesaid and all or any further sum
or sums advanced as aforesaid shall be employed by the Contractor (s) in or towards expediting
the execution of the said works and for no other purpose whatsoever.
That the materials which have been offered to and accepted by the Owner as security are
absolutely the Contractor’s own property and free from encumbrances of any kind and the
Contractors will not make any applications for or receive a further advance on the security of
materials which are not absolutely his own property and free from encumbrances of any kind
and the Contractors indemnifies the Owner against all claims to any materials in respect of
which an advance has been made to them as aforesaid.
![Page 216: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/216.jpg)
216
That the materials on the security of which any further advance or advances may hereafter be
made as aforesaid(hereinaftercalledthesaidmaterials)shall be used by the Contractors solely in
the execution of the said works in accordance with the directions of the Owner / PMC and in the
terms of the said agreement.
That the Contractor shall make at his own cost all necessary and adequate arrangement for the
proper storage, watch, safe custody, accounting and protection against all risks of the said
materials and that until used in construction as aforesaid, the said materials shall remain at the
site of the said works in the Contractor’s custody and on the responsibility and shall at all times
be open to inspection by the Owner / PMC or any officer authorized by the Owner. In the event
of the said materials or any part thereof being stolen, destroyed or damaged, the Contractor will
forthwith replace thesame with other materials of like quality or repair and make good the same
as required by the Owner / PMC.
That the said materials shall not on any account be removed from the site of the said works
except with the written permission of the Owner of his authorized representatives.
That the advances shall be repayable in full at or before the Contractor receives payment from
the Owner of the price payable to them for the said works under the terms and provisions of the
said agreement provided if any intermediate payments are made to the Contractors on account
of work done, then on the occasion of each such payment the Owner will be at liberty to make a
recovery from the Contractor’s bill for such payment deducting there from the value of the said
material then actually used in the construction and in respect of which recovery has not been
made previously the value for this purpose being determined in respect of each description of
materials at the rates at which the amounts of the advances made under these presents were
calculated.
That if the Contractor shall at any time make any default in the performance or observance in
any respect of any of the term and provisions of the said agreement or of these presents,the
total amount of the advance or advances that may still be owing to the Owner together with
interest thereon at 18% (Eighteen percent) per annum from the date or respective date of such
advance or advances to the date of repayment and with all costs, charges, damages and
expenses incurred by the Owners in or for the recovery thereof or the enforcement of this
security or otherwise by reason of the default of the Contractor and the Contractor hereby
covenants and agrees with the Owner to repay and pay the same respectively to him
accordingly.
That the Contractor hereby hypothecates all the said materials for the time being at site or to be
brought at site from time to time until therepayments to the Owner of the sum or sums
advanced as aforesaid and all costs, charges, damages and expenses payable under these
presents PROVIDED ALWAYS and it is hereby agreed and declared that notwithstanding anything
![Page 217: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/217.jpg)
217
in the said agreement and without prejudice to the powers contained therein if and whenever
the covenant for payment and repayment hereinbefore contained shall become enforceable and
the money owing shall not be paid in accordance therewith, the Owner may at any time
thereafter adopt all or any of the following courses as he may deem best.
Seize and utilize the said materials or any part thereof in the completion of the said works on
behalf of the Contractor in accordance with the provisions in that behalf contained in the said
agreement, debiting the contractor with the actual cost of effecting such completion and the
amount due in respect of advances under these presents and crediting the Contractor with the
value of work done as if he had carried it out in accordance with the said agreement and at the
rates thereby provided. If the balances is against the Contractor, he is to pay same to the Owner
on demand together with interest accruing thereon.
Remove and sell by public auction the seized materials or any part thereof and out of the
moneys arising from the sale retain all the sums aforesaid repayable or payable to the Owner
under these presents including expenses incurred by owner in connection with such auction and
pay over the surplus (if any) to theContractor.
Deduct all or any part of the money owing hereunder out of the security deposits or any sum
payable to the Contractor under the said agreement.
That except in the event of such default on the part of the Contractor a aforesaid, interest on the
said advances shall not be payable.
That in the event of any conflict between the provisions of these presents and the said
agreement the provisions of these presents shall prevail and in the event of any dispute of
difference arising over the construction of effect of these presents and settlement of which has
not been herein before expressly provided for, the same shall be referred to the Employer’s
General Manager, Premises Dept., whose decision shall be final and no appeal shall lie against
his decision before any court, arbitrator orauthority.
The provision of this undertaking shall be deemed to be supplemental to the said agreement.
IN WITNESS WHEREOF the Contractors have set their hands to these presents the day and year first
hereinabove written.
SIGNED, SEALED AND DELIEVERD BY THE SAID CONTRACTOR IN THE PRESENCE –
WITNESS: SIGNATURE
NAME
![Page 218: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/218.jpg)
218
ADDRESS
WITNESS: SIGNATURE
NAME
ADDRESS
![Page 219: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/219.jpg)
219
CONTRACT CONDITIONS VOLUME – I
LIST OF DRAWINGS
Enclosed with Volume - IV
![Page 220: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/220.jpg)
220
ANNEXURE A
BANK OF INDIA FINAL NOC FOR OC
1 Electricity board Final NOC and permanent power connection
2 Superintendent of Garden Final NOC
3 Pest Control Officer Final NOC
4 Assessment (AA & C) Final NOC
5 Sewerage and Planning Final NOC including house drain
Connection
6 Storm Water Drain Final NOC including drain connection
7 MTNL Final NOC
8 Hydraulic Engineer Final NOC including P form and permanent water connection
9 Chief Fire Officer Final NOC and inspection of works for NOC of
occupancy
10 Fresh Property Registration Card
11 EE Mechanical Final NOC
12 GVK (Civil Aviator) Final NOC
13 Road Demarcation for setback from survey department
14 Road setback Handy over (front and rear) NOC
15 Separate Property Registration Card for road setback handover with FSI rights
16 Debris NOC Compliance
17 Compilation of all issues raise in existing NOC
18 PWD Lift Manual
19 Building compilation certificate from MMRDA
20 Occupancy Certificate by MMRDA
![Page 221: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/221.jpg)
221
SAFETY MANUAL
![Page 222: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/222.jpg)
222
Health and safety is the responsibility of everyone who is employed by,or contracted to the BANKOFINDIA. Systems and procedures have been developed to provide a structure by which health and safety can be managed.These are based on the requirements of the Health and Safety Act 1974 and Safety,Health and Welfare Act 1986.
CONTRACTOR SAFETY REQUIREMENTS
All construction activities shall be conducted in accordancewith each contractor’s Safety Plan. All such plans
shall, at a minimum, conform to applicable laws, standards and regulations, and shall incorporate
BANKOFINDIA’srequirements.
The contractor is solely responsible for ensuring the safety of its employees, and is responsible for the safety of all of its subcontractors, agents or representatives.
The contractor shall include a job hazard analysis for any potentially high hazard activities as partof their safety plan.
The standards are not all-inclusive-other elements may be added,or may be conveyed individually to contractors to whom they may expressly apply.There are other essential elements that the contractor, by nature of the specific type of work being performed, must integrate within their own safety program.
The communication of the safety program elements will be achieved through new employee orientation, weekly toolbox talks, contractor safety meetings, contractor/owner safety meetings, sub- contractor safety management meetings, and the continuous evaluation of the worksite for safety enhancements.
Site safety signs, posters, barricades, dangertape, and employee incentive programs are important in order to enhance safety awareness and safety communication.
ACCOUNTABILITYANDRESPONSIBILITIES It is imperative that site management and job supervisors exercise positive leadership in orienting and motivating their employees toward performing their jobs effectively, efficiently, and with a high regard for safety.
![Page 223: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/223.jpg)
223
A. GENERAL CONTRACTOR Contractors shall be solely responsible for initiating, maintaining and supervising the safety and health of
persons and property in connection with their work.
The General Contractor will have the overall responsibility for ensuring that all contractors and their employees incorporate safety and health standards in to all design and construction phases of the project, and for ensuring that this is reflected in all agreements and contracts, and by all contractors, subcontractors,supervisors, employees, vendors, visitors and any one else connected with the project.
TheGeneral Contractor will also:
1. Keep BANK OF INDIA and the Project Manager informed of events, potential safety risks,project safety statistics and progress pertaining to safety issues.
2. Develop site specific Safety Plans.The site specific Safety Plan must include occupational safety, employee orientation and training, security, potential hazards, accident investigations, documentation for siteaudits, equipment inspections, disciplinary programs, and emergency contingency plans.
3. Confirm contractor's safety education and orientation requirements are consistently met.
4. Document weekly safety briefings for construction personnel.
5. Conduct all-hands safety meetings once per month, to include all sub tier contractor employees. Document the meeting subject, date and names of attendees by contractor and subcontractor. Submit documentation of the all-hands safety meeting to the construction manager.(MonthlyReport)
6. Conduct weekly on-site safety inspections including a review of safety training, hazard correction and accident records.Inspection findings and corrections shall be furnished to BANK OF INDIA upon its request.
7. Review and timely abate the results of safety inspections to include recommendations made for correction of hazards and prevention of accidents, and follow-up measures taken to ensure compliance.
8. Monitor and document compliance by contractors with mandatory safety and health laws, regulations, standards and codes.
9. Maintain records of all accidents experienced by contractors and subcontractors in assigned project area of responsibility in accordance with the Occupational,Health and safety
![Page 224: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/224.jpg)
224
requirements. Copies of records shall be forwarded to BANK OF INDIA.
10. Provide a monthly report that shall include the following information:
A summary of all safety inspection reports and documentation that confirm that all safety deficiencies have been corrected.
Documentation that“ToolboxTalks”safety meetings have been conducted with all workers,including all subcontractors,atleastweekly.Copies of all sign-in sheets,curriculum and any handouts shall be provided.
Copies of all employees’safety suggestions and solutions by the contractor.
11. In conjunction with engineering and scheduling personnel, develop and implement specific safety and health procedures and effective safe work practices.
12. Provide protection of the public on or adjacent to construction sites.
13. The general or prime contractor shall provide a competent safety representative that must be on the project site at all times.
14. Any worksite with non-English speaking workers shall have a person(s) fluent in the language(s) spoken and English to translate as needed, on site at all times when work is being performed.
15. The General Contractor’s Safety Program should consist of:
a) Establishing a firm and positive accident prevention policy that includes: a management statement, the supplying and requiring the use of safety equipment like hardhats, ladders, firstaid materials, and safety devices on equipment.
b)Ensuring that capable, responsible supervisors and the on site competent safety representative make regular inspections of all excavations, forms, scaffolds, stairs, ladders, structures, machinery, and equipment at frequent intervals; take immediate corrective measures to eliminate hazards directly under the control of the employer,or report violations of Occupational Health and safety regulations and unsafe practices to the responsible employer.
c) Assurance that the site supervisors assume responsibility for accidents, and complete a written report for each reported accident and that each report suggest a feasible means of avoiding future accidents of a similar nature.
d) Monthly,or more frequent,meetings of all supervisors held under the direction of the superintendent for a discussion of safety concerns and accidents that have occurred. Have something specific ready for discussion, such as safety regulations, or anychangesin equipment and methods that are to be adopted for safety reasons.
a) Display safety posters and warning signs. (Each contractor and/or subs
![Page 225: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/225.jpg)
225
must post at their work location a copy of OCCUPATIONAL HEALTH AND SAFETY’s poster informing employees of their rights and responsibilities as defined within the OCCUPATIONAL HEALTH AND SAFETY regulations).
b) Consider the advisability of establishing various forms of safety competition, including suitable rewards or recognition to individuals and crews with good records.
c) Require supervisors to give individual safety instructions and orders, as needed, to new workers and those found to be working in an unsafe manner.
d) Ensure the job site supervisors conduct "toolbox" safety meetings with their crews once a week on the job, to emphasize some particular safety concerns that require special attention.
e) Encourage safety suggestions from all workers and, if the suggestion cannot be followed promptly,explain why to the worker.Give each worker a copy of important safety rules that they are expected to follow.
f) Arrange for frequent and regular field safety inspections.
16. The contractor shall respond in writing to BANK OF INDIA as to the corrective action(s) for all non-compliance safety observations reported by BANK OF INDIA Safety within five(5) Business days.
17. The contract or and subcontractors will be expected to immediately abateimminent danger safety hazards.(Forexample:excavation safety,confined space entry,etc.)
B. ALL CONTRACTORS SHALL:
1. As a condition of their contract, assume responsibility for the safety and health of their employees and require the same of sub contractors and their employees, and other persons under the direc tor indirect control of the contractor on the work site.
2. Assign a competent safety representative that must be on the project sit, eat all times.
3. Immediately report any accidents, significant illnesses and injuries to the BANK OF INDIA. Investigate accidents and near missincidents to determine root causeand develop/implement correctiveactions to prevent reoccurrence. Accident investigation reports are to be completed and turned into the General Contractor within 12 hours of the occurrence.Copies of such reports shall be forwarded to BANK OF INDIA.
4. Comply with all applicable OCCUPATIONAL HEALTH AND SAFETY and Indian
![Page 226: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/226.jpg)
226
laws, regulations, ordinances, conditions of contract, rules or orders of any public authority having jurisdiction relating to safety of persons or property.
5. Ensure that all employees, subcontractors and their employees are briefed on all of the applicable safety regulations and requirements for the work to be performed.Contractors shall,in accordance with law, adopt procedures providing that any employee who disregards these rules or other applicable safety and health regulations shall be subject to appropriate disciplinary action or discharge.
6. Have their safety representative participate in the weekly safety walk-through meetings and progress meetings.
7. Ensure that: a) Prior to the performance of any work, each employee involved in the construction knows and understands each of the safety and security rules that apply to the job site in which he/she is performing for the project.
b) Personal protective equipment (inclusive of mandatory IS approved hard hat with appropriate footwear) shall be used on site at all times, worn properly, and maintained in proper condition.Appropriate footwear includes general construction shoes with ankle high support,no tennis shoes and/or leather sole shoes on site.
c) Employees shall not engage in practical jokes and/or horseplay.
d) An employee is not to undertake any work that he or she is not properly qualified, trained or equipped to do. In this regard, each employee shall be required to attend safety training or (toolbox) meetings weekly and sign an attendance sheet.
e) All site personnel shall be made aware there is a“Zero Tolerance”for the use of intoxicating substances or illegal drugs on the site.Employees reporting for work while under the influence of intoxicating or illegal drugs will not be allowed to assume their duties.Employees reporting for work while under the influence of prescription or over the counter medications that impair their ability to work safely will also not be allowed to assume their duties.
8. Each contractor is to provide training anddocumentation to site management that their employees have been provided with information and training on the Hazard Communication Standard and site hazardous material storage and use conditions. In addition, each contractor is responsible for making provisions to provide copies of Material Safety Data Sheets (MSDS), and provide information on measures that need to be taken for personnel protection to all affected employees and workers within the vicinity of the hazardous substance.
![Page 227: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/227.jpg)
227
a. Contractors are responsible for daily clean up of working areas and the removal of trash and construction debris.
b. Each employee must always know where he or she is in relation to work in progress and avoid hazardous situations around equipment or construction. Employees must advise supervisory personnel of their work location.They should not work alone in an isolated area until arrangements have been made for periodic contact with another employee or supervision.
c. Each contractor is to provide training and documentation to
site management that their employees have been provided with
information and training on the site Fire Prevention Plan.
OVERVIEW OF BANK OF INDIA - CONTRACTOR SAFETY STANDARDS AND REQUIREMENTS
A. PURPOSE
The purpose of this Section is to assist all contractors and subcontractors in establishing basic safety and health rules for this Project. Strict enforcement of and compliance with Safety and Health rules guidelines will aid in keeping personal injuries,occupational illnesses, and equipment and property damage to a minimum.
B. APPLICABILITY
The rules listed below apply to all on site contractors, subcontractors and vendors on
site for these contractors, including employees with supervisory and non-supervisory assignments. The General Contractor and their subcontractors are to promote
accident prevention through indoctrination, safety and health training and on-the-job application, and shall use this Overview of Safety Standards and Requirements.
All contractors and subcontractors on the project shall provide their new employees New Hire Orientation to better understand the Overviewof Safety Standards and Requirements.
As a minimum requirement, superintendents, supervisors,safety representatives and all employees must learn and abide by the general rules plus the safety and health rulest hat are applicable to their particular trade,task or occupation.These rules should be incorporated into pre-work indoctrination.
Individual trade safety and health rules apply not only to supervisors and to the workers, but also to helpers, assistants, apprentices, and to any one else who might be in the work area.Supervisors shall ensure that new workers or visitors are made aware of and abide by the safety and health rules that are in effect.
![Page 228: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/228.jpg)
228
C. GENERAL SAFETY AND HEALTH RULES
1. All persons shall follow this Overview of Safety Standards and Requirements and all safety rules and regulations of their employer, and local and state requirements.
2. Failure to abide by the Overview of Safety Standards and Requirements or any applicable rules and/or regulations may result in removal of personnel and the contractor from the BANK OF INDIA project.
3. Immediately report any unsafe conditions, accidents, injuries or illness to your
supervisor or superintendent. Also immediately report any accidents, significant illnesses
and injuries to the BANK OF INDIA.
4. If employees are unsure of the safe method to do your job, STOP and ask your supervisor. Ignorance is no excuse for a safety violation.
5. No one shall be knowingly permitted towork while the employee's ability or alertnessis impaired by fatigue, illness, and prescription or over the counter drugs or other substances. Employees who are suspected of being under the influence of illegal or intoxicating substances, impaired by fatigue or an illness, shall be prohibited from working.
6. BANKOFINDIA projects should have a“ZeroTolerance”for the use of illegal drugs and alcohol on the job site.
7. Horseplay, scuffling, fighting and other acts that tend to have an adverse influence on the safety or well being of the employees are prohibited.
8. All work shall be well planned and supervised to prevent injuries in the handling of materials and inworking together with equipment.
9. Keep your work area clean,free of debris,electrical cords and other hazards.
10. Immediately cleanup spilled liquids.If hazardous materials or chemicals are spilled the
appropriate protective measures must be taken and the BANK OF INDIA’s Department of Security and Safety immediately advised of the spill condition.
11. Always notify all other individuals in your area who might be endangered by the work you are doing.
12. Do not operate equipment that you are not familiar with.Do not attempt to use such equipment until you are fully trained and authorized.
13. Never bring fire arms, weapons, illegal drugs or alcoholic beverages on the project site.
14. Lockout and Tag-out system identifies equipment that is NOT to be
![Page 229: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/229.jpg)
229
operated,energized or used.All lockout and tag-out notices and procedures must be observed and obeyed.All lockout and tag-out operations/applications must be coordinated with the appropriate BANK OF INDIA personnel.
15. “Danger”taped are as or are as enclosed with barricades,signs and fencing(orprotective barriers) are considered danger zones and shall be respected as such. Admittance to or passage through such areasis prohibited without permission except to those employees working within the barricaded area.
16. When lifting heavy objects,mechanical means should be used,otherwise,buddy-up with a partner and share the load.When manually lifting,the large muscles of the leg instead of the smaller muscles of the back shall be used.
17. Do not block exits,fire doors,aisles,fire extinguishers,firstaid kits,emergency equipment, electrical panels,or traffic lanes.
18. Do not leave tools,materials,or other objects on the floor that might cause others to trip and fall.
19. Donot run on the job site or in the shop,yard oroffice area.
20. Do not distract others while working. If conversation is necessary; make sure eyecontact is made prior to communicating.
21. Employees shall not enter manholes, underground vaults, chambers, tanks,
silos, or other similar places that may have limited ventilation, or other hazards
unless it has been determined that it is safe to enter and is being properly ventilated. Established permit required confined space entry requirements must be
followed.
22. Employees shall ensure that all protective guards and other protective devices are in proper place and adjusted when operating equipment. Report deficiencies promptly to the foreman orsuperintendent.
23. Materials or other objects shall not be thrown from buildings or structures unless and until proper precautions and barricading has been erected to protect people and property from injury and damage from the falling objects.
24. Employees shall cleanse thoroughly after handling hazardous substances, and follow special instructions from authorized sources.
25. Gasoline or other flammable liquids shall not be used for cleaning purposes or improperly stored on the job site.
26. A hot work permit is mandatory for all burning, welding, or other source of ignition for all BANK OF INDIA projects.
27. Any damage to scaffolds, falsework, or other supporting structures shall be immediately reported to the supervisor and repaired before use.
![Page 230: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/230.jpg)
230
28. No driving or operating of equipment while talking on the radio,cellphone and or texting.
29. No talking or texting on the cellphone walking around or operating equipment in the construction site.
D. USE OF PERSONAL PROTECTIVE EQUIPMENT
1. Use the correct PPE for each job assignment. If you don’t know or don’t have necessary/proper equipment ask your supervisor for assistance.
2. PPE shall be maintained in good condition and cleaned regularly.
3. PPE shall be stored properly when not in use to protect it from damage.
4. Damaged or broken PPE must be returned to your foreman for replacement.
5. Hardhats must be worn on jobsites at all times.
6. Appropriate eye protection shall be worn when indicated by the nature of the job, including those jobs for which eye protection may be recommended by an equipment and/or material manufacturer,material safety datasheet,etc.
7. Face shields with safety goggles are required when grinding or working with hazardous chemicals, alongwith all other appropriate PPE required for work with the specific hazardous chemical.
8. Employees must wear safety work shoes in the yard and on the job site. The shoes must have complete leather upper sand skid resistant soles and bein good condition.Steel toe or equivalent protection is required.
9. Athletic style shoes, tennis shoes, open toe shoes,sandals, plastic or vinyl shoes or shoes with decorative metal accessories are not to be worn on construction job sites.
10. Hearing protection must be worn when working with loud equipment such as cut off saws,chain saws,air hammers or grinders.
11. Be sure the protective clothing you wear will not hamper or restrict freedom of movement due to improper fit.
12. Long pants of heavy-duty material must be worn.No shorts or sweat pants are allowed.
13. Do not wear loose, torn or frayed clothing,dangling ties,fingerrings,dangling earrings, jewelry items, or long hair unless contained in a hair net, while operating any machine, which could cause entanglement.
14. If required, wear NIOSH-approved respirators when applying adhesives,
![Page 231: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/231.jpg)
231
paint,welding, grinding or working with chemicals.Read the MSDS to find out which type of respirator is required. Facial hair may not be permitted in certain circumstances. (The contractor and subcontractor supervisors shall manage their own programs.)
E. TRENCHING AND EXCAVATION SAFETY
1. Compliance with OCCUPATIONAL HEALTH AND SAFETY’s Excavation Safety Requirements. Excavations is a must on all projects for BANK OF INDIA. Failure to comply with the required excavation requirements may result in stopping the contractor’s work and/or termination of the contract.
2. Contractors planning to excavate as part of their project shall provide to BANK OF INDIA prior to the start of the excavation job the name of their assigned and onsite Competent Person working the project. (If the competent person changes, BANK OF INDIA shall be informed immediately.) This individual shall have authority (as defined by OCCUPATIONAL HEALTH AND SAFETY) for all work performed during the excavation-including the ability to stop the work.
3. All excavations and trenches 5 feet deep(or in unstablesoil at lesser depths)or greater must be properly shored,sloped,orbenched to protect workers from the hazards of moving earth. Contractors must furnish the appropriate tabulated data for the protective system being used upon request.
4. All excavation work must be performed to avoid underground utilities and to avoid damaging lines pipe.
5. Do not work under loads handled by lifting or digging equipment.
6. Ladders shall be provided and used for access to trenches and excavations 4
feet deep or greater.
7. Keep all spoils at least 2feet from the edge of the excavation,regard less of
the depth.
8. Trenches shall be properly barricaded, protected and posted to warn and prevent someone from falling into the excavation.
9. The competent person on the jobsite must inspect all trenches and excavations daily, before work,to look for signs of shifting earth.Employees are not to enter the trench unless it has been verified to be safe by the competent person.
10. Appropriate traffic control measures may also be required for excavations dugin roadways or sidewalks.Protective measures shall comply with the DOT’s requirements and all entries shall include continuous atmospheric monitoring of the space.
![Page 232: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/232.jpg)
232
F. CONFINED SPACE ENTRY PROGRAM
OCCUPATIONAL HEALTH AND SAFETY Confined Space requirements and procedures must be followed
G. FALL PROTECTION
1. Fall protection, such as standard railings or a safety harness and lanyard, shall be used at all times, when working 6 feet or more above the level below in accordance with OCCUPATIONAL HEALTH AND SAFETY.
2. Floor and wall openings, unfinished balconies,elevator shafts and similar areas must be properly protected and/ or covered to prevent some one from falling into the structure.
3. Do not cut or disassemble existing railing systems unless specifically required by the project design documents.Railing systems removed shall be replaced with an equally protective system. Removed rails must be immediately replaced with a protective barrier to ensure no one can fall into the existing opening. Always seek permission from the respective BANK OF INDIA operation supervisors and BANK OF INDIA project manager if railings are required to be removed for any reason– even for a short time.Always replace these items when finished with your task.
4. All safety harnesses shall be the full body type with a shock-absorbing lanyard attached to a substantial anchorage capable of supporting twice the maximum load.Lanyards shall be attached at the wearer’supper back. Bodybelts are not to be worn as fall protection.
5. Read and obey all manufacturer’s instructions relating to your fall arrest system (safety harness and lanyard).
6. Inspect all components of your harness and lanyard prior to each use and after a fall.Defective equipment is not to be used. Lanyards must be destroyed after a fall and neve rreused.
7. Safety harnesses and lanyards should limit freef all distance to less than 6 feet and prevent contact with any level or objects below you.
8. Never use any part of a fall arrest system, such as a harness or lanyard, to hoist materials or for any other purpose.
9. Safety harnesses and shock absorbing lanyards are required to be worn at all timeswhile inboom lifts.
H. DRY CUTTING AND DRY GRINDING OF MASONRY MATERIALS PROHIBITED
![Page 233: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/233.jpg)
233
Dry cutting and dry grinding of masonry materials is prohibited and shall not be performed except under the limited circumstances and conditions
I. LOCKOUT/TAGOUT(LOTO)
1) All machinery and electrical equipment shall be locked out and tagged prior to
repair, cleaning, or adjustment.
2) All LOTO operations/applications must be coordinated with the appropriate BANK OF INDIA Staff.
3) Use your own lock and key.No one else should have a key for your lock.Destroy all duplicate keys.
4) Maintain control of your key at all times to prevent unauthorized use.
5) Never remove another employee’s lock orenergize tagged equipment.
6) If multiple employees are working on the same equipment, each employee shall
install their own lock.
7) Notify all affected employees that a lock-out/tag-out is required and the reasons
for it.
8) If the equipment is operating, shut it down by the normal stopping procedure (depress stop button,open toggle switch,etc.).
9) Operate the switch,valve or other energy isolating devices so that the energy
source(s) (electrical,mechanical,hydraulic,etc.) is disconnected or isolated from the equipment.
10) Stored energy, such as that in capacitors, springs, elevated machine members,
rotating flywheels, hydraulic systems, and air,gas or water pressure,etc.must also be dissipated or restrained bymethods such as grounding,repositioning,blocking,bleedingdown,etc.
11) Lock-out all energy isolation devices with an individual lock.
12) After ensuring that no employees are exposed and as a check of having
disconnected the energy sources,operate the push button or other normal operating controls to make certain the equipment will not operate.Caution:Return operating controls to neutral position after the
test.
13) The equipment is now locked-out. Install red lock-out tag on operating controls.
14) After repair is complete and the equipment is ready for testing or normal
operation, check the equipment to see that all cover plates and safety devices have been reinstalled.
15) When the equipment is clear, remove all locks and tags.The energy isolating
devices may be operated to restore energy to the equipment.
![Page 234: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/234.jpg)
234
16) For additional information on BANK OF INDIA’s Lockout/Tagout Program contact the
BANK OF INDIA Project Manager.
J. GENERAL ELECTRICAL SAFETY
1. Only trained, qualified and authorized employees are allowed to make electrical repairs or work on electrical equipment or installations.
2. All electrical equipment and systems shall be treated as energized until tested or otherwise proven to be de-energized.Always check your tester on a known circuit to make sure it isworking. Assured equipment ground conductor programsshall beutilized for all temporary electrical installations.
3. All energized equipment and installations will be de-energized prior to the commencement of any work.If the equipment or installation must be energized for test or other purposes, special precautions will be taken to protect against the hazards of electric shock.
4. All equipment shall be locked out to protect against accidental or inadvertent operation when such operation could cause injury to personnel.Do not attempt to operate any switch, valve, or otherenergy-isolating device bearing a lock.
5. Safety grounds shall always be used where there is adanger of shock from
backfeeding or other hazards.
6. Polyester clothing or other flammable types of clothing shall not be worn near electrical circuits.Cotton clothing is much lessl ikely to ignite from arcblast. Employees working on live circuits shall be provided Nomex or equivalent fire resistant clothing.
7. Suitable eye protection must be worn at all times while working on electrical equipment.
8. Always exercise caution when energizing electrical equipment or installations. Take steps to protect yourself and other employees from arcblast and exploding equipment in the event of a fault.
9. All powertools will be grounded or double insulated.Tools with defective cords or wiring shall not be used.
10. Metal jewellery should not be worn around energized circuits.
11. Extension and temporary power cords must be heavy duty and grounded.Frayed or defective cords shall not be used.
12. Suitable temporary barriers or barricades shall be installed when access to opened enclosures containing exposed energized equipment is not under the control of an authorized person.
13. Electrical installations must be protected from accidental contact by enclosures or tight fitting covers.
![Page 235: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/235.jpg)
235
14. GFCI’s are required on all power outlets.
15. Circuits shall not be overloaded with equipment or extension cords.
16. Metal measuring tapes, fishtapes, ropes or other metal devices are prohibited where they may contact energized parts of equipment or circuits.
K. USE AND STORAGE OF HAZARDOUS MATERIALS AND CHEMICALS
1. Contractors using hazardous material on BANK OF INDIA property must provide the Department of Security and Safety acopy of the respective MSDS prior to use of theproduct.In turn, the BANK OF INDIA Department of Security and Safety will provide the contractor MSDS as requested.
2. Read all warning labels and Material Safety Data Sheets (MSDS) before using any chemicals.MSDS contain personal protective equipment and safety information and are available from your foreman.
3. Hazardous materials shall be handled in accordance with the MSDS and label. If protective equipment is required,use it.
4. Eye and/or face protection must be worn when working with hazardous materials or chemicals.
5. Mixing of chemicals is prohibited at all times unless required by the label. Before you mix- review all MSDS.
6. Always wash your hands thoroughly after handling chemicals and before eating or smoking, even if you were wearing protective gloves.
7. Never use solvents for hand cleaning.Use the non-toxic hand cleaners provided.
8. Store all hazardous materials properly insuitable containers that are properly labelled.
9. Use chemicals only in well-ventilated areas.
10. Chemical or hazardous material spills – if a spill should occur notify the BANK OF INDIA’s Department of Security and Safety immediately and inform them of the spill, type of chemical, location, and quantity of the spill andwhether there are any injuries. If the chemical is hazardous to health, immediately protect from others entering the area. If the chemical is spreading, protect the immediate area to prevent the chemical from reaching a storm drain or spilling into the water or waste water system.
11. When using secondary containers,ensure that they are labeled as to their contents and hazards.
12. When working with asbestos, approved asbestos requirements shall be
followed.
![Page 236: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/236.jpg)
236
13. Do not disturb any asbestos. If you do disturb any asbestos , STOP work and tell your supervisor and then report to the BANK OF INDIA ProjectManager.If you are not sure,STOP and ask.
14. Do not cut or weld stainless steel or galvanized metal without respiratory protection. These items create toxic fumes.(Remember,hot work permits are required when cutting,grinding, welding,etc.)
15. Work with lead, asbestos, cadmium,TENORM and other toxic compounds requires special precautions.Do not attempt to perform this work without appropriate special equipment and training.
L. CONTRACTOR VEHICLES ON BANK OF INDIA PROPERTY AND PROJECTS
1. All vehicles and equipment on a BANK OF INDIA jobsite shall comply with the appropriate state license requirements and contain documented proof of compliance.(Farm vehicles or unlicensed vehicles and equipment are not authorized for use on BANK OF INDIA property.) Vehicles and equipment such as cranes,forklifts,etc.,shall also maintain a current and valid inspection documentation.
2. Only authorized and properly licensed employees are to be permitted to operate contractor vehicles and equipment on BANK OF INDIA sites.
3. Drive defensively and obey all traffic laws,highway and jobsite vehicle restrictions. Vehicles shall not exceed 15 mph while on BANK OF INDIA property.
4. All occupants shall properly wear a seat belt at all times the vehicle is in motion.
5. Report all accidents immediately to your supervisor.
6. Do not permit employees to ride in the back of pick up trucks or equipment.
7. Do not jump from the cab or bed of company vehicles. Always use the stairs or a ladder.
8. Inspect your vehicle and report and correct any defects or operating problems to your superviso rso that repairs can be made.
9. No smoking while refueling.
10. All vehicles and equipment shall be properly parked in the designated locations for contract workers.
11. All vehicles working within construction areas shall be equipped with the appropriate backup alarm. Backup alarms may also be required on vehicles and equipment in areas with heavy pedestrian traffic.
12. All drivers shall be observant of the surroundings on the Plant.
13. Contractor and subcontractor vehicles and equipment shall not be left running or idling when not in use.
![Page 237: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/237.jpg)
237
14. Only authorized vehicles are to be left on BANK OF INDIA property overnight.
15. Above ground storage tanks (AST’s) are not permitted on BANK OF INDIA property without prior approval from the Department of Safety and Security.
16. All vehicles entering or operating on BANK OFI NDIA property are subject to inspection by designated BANK OF INDIA personnel.
M. LADDER SAFETY
1. Inspect the ladder before using it. If it is broken, throw it out.Never repair a broken ladder, get a new one. Keep portable stairways, ladders and step stools in good condition and use them only in a safe manner.
2. Use the proper ladder for the job.Do no tuse“A”frame ladders as straight ladders. Make sure the ladder is tall enough to reach the work area.Do not use metal ladders for electrical work.
3. Do not place ladders in passage ways, doorways, or any location where they might be hit or jarred,unless protected by barricades or guards.
4. Ladders should only be placed on hard level surfaces.Make sure the ladder feet are not placed on sandy, slippery, or sloping surfaces.Cleanor sweep the area where the ladder feet will be and make sure the rubber feet are in good shape.
5. Ladder rung sand steps must be kept free of grease, oil, mud, or other slippery substances.
6. Arrange your works oyou are able to face the ladder and use both hands while climbing.Do not carry tools or equipment while climbing a ladder.Climb the ladder,and then hoist the tools or equipment with a line or ahoisting device.
7. Avoid temporary ladders. Always use a commercially made,construction grade ladder of the proper length for the work being performed.
8. Secure portable ladders in place and at a pitch so the leveling indicator is in alignment or the distance from the wall to the base of the ladder is at 1 foot for every 4 feet height.
9. Straight ladders shall be tied off at the top and bottom of the ladder to prevent slipping.
10. Beaware of objects below you.Move or cover sharp objects in case you fall. Cap or bend all rebar.
11. Do not stand on or work from the 2n drung from the top or above.Also do not reach too far from the ladder.Keep your belt buckle between the side rails.
12. Extension ladders shall extend at least 36 inches above the level being accessed.
13. On all ladders, do not step on cross bracing that is not intended to be used for climbing.
![Page 238: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/238.jpg)
238
N. HAND AND POWER TOOLS
1) Proper eye protection must be worn when using hand and power tools.
2) Know your hand and power tool applications and limitations. Always use the proper tool for the job.
3) Inspect cords and tools prior to use. Do not use tools that are faulty in any way. Exchange them for safe tools immediately.
4) Power tools must be grounded or double insulated. All power tools are to be plugged into a grounded GFCI outlet.
5) Do not use power tools in damp,wet or explosive atmospheres.
6) Do not lift, lower or carry portable electrical tools by the power cord.
7) Keep all safety guards in place and in proper working order.
8) Keep tools in their proper storage place when not in use.Do not leave tools where they might present a tripping hazard, fall on somebody or be stolen. Do not carry sharp edged tools in your pockets.
9) Use clamps or vises to secure work pieces.Never use your hand as a work rest.
10) Do not force hand power tools. Apply only enough pressure to keep the unit operating smoothly.
11) Return all tools and other equipment to their proper place after use.
12) Unplug all power tools before changing bit sand/or grinding disks.
13) Never leave chuckkeys in the tool during operation.
14) Do not use a screw driver as a chisel.
15) Before using sledges, axes or hammers make sure the handles are securely fastened with a wedge made of sound material.
16) Do not use a handle extension on any wrench.
17) Files should be equipped with handles and should not be used as a punch or pry.
O. FIRE PREVENTION AND HOUSEKEEPING
1. Always take precautions to prevent fires which may be started, particularly from oily waste, rags, gasoline, flammable liquids, acetylenetorches, improperly installed electrical equipment and trash.
2. Hot work permits must be obtained before any torchcutting, grinding, welding or burning activities. Combustible gas monitoring with LEL alarm capability shall be conducted prior
![Page 239: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/239.jpg)
239
to and continuously during all hot work activities.No hot work will be permitted near grass areas when the humidity level is less than 30%. A sample hot work permit is attached.
3. Fire watches shall be maintained a minimum of 30 minutes after the activity stops for all hot work permit projects.
4. All flammable liquids must be stored in designated areas at all times.Refueling is to be done only at designated areas.
5. Fire suppression equipment is to be inspected on a regular basis.All discharged, damaged or missing equipment is to be immediately reported to a supervisor for replacement. Tampering with fire equipment is prohibited.
6. If your project requires working on afire alarm, sprinkler system or other automated system,you are required to coordinate the work with the Construction Manager and Engineering Department to make proper internal BANK OF INDIA arrangements and notifications.
7. Access to fire extinguishers must be kept clear at all times.Make note of the location of fire fighting equipment in your worka rea.
8. Never use gasoline or flammable solvents for cleaning purposes.
9. Smoking is prohibited inside all BANK OF INDIA facilities.Smoking is allowed outdoors only in designated areas.
10. In case of fire, employees shall consider the safety of themselves and other individuals before saving property. Immediately report the incident to the appropriate authorities and stand by to assist emergency personnel. BANK OF INDIA has established emergency procedures for each facility.Upon assignment of your contract, specific guidance and direction will be provided during the pre-construction meeting.
11. Keep your work areas free of debris. Remove useless material from the work area as fast as required to help reduce tripping hazards.
12. Maintain awareness of potential hazards when walking about the job site.
13. Keep tools,materials and equipment out of walkways and stairways at all times.
14. Sharp wires or protruding nails must be kept bent.
15. Place tools and equipment so they will not slide off the roof or work area.
16. Tie material down at day'send so the wind will not blow it off the roof or other elevated work area.
P. TRAFFIC SAFETY IN CONSTRUCTION AREAS
1. All employees exposed to traffic hazards (construction equipment included ) are required to wear a
high visibility safety vest or other appropriate high visibility reflectorized garments meeting requirements (shirts,vests,jackets) at all times.
2. When possible, construction vehicles are to be placed between the employees and
![Page 240: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/240.jpg)
240
traffic to prevent vehicles from entering the work area and hitting members of the crew.
3. All traffic controls will be established in accordance with the Mumbai Department of Transportation requirements and the DOT Manual of Uniform Traffic Controls for Construction and Maintenance Work Zones.
4. Traffic controls are to be properly maintained throughout the workday. Signs and cones must be kept upright, visible and in their proper position at all times.
5. Road closure procedures are specifically defined for BANK OF INDIA. Contact the Department of Security and Safety for assistance or additional information.
Q. USE OF SCAFFOLDS
1. Scaffolds are to be erected, dismantled, altered or repaired by the scaffold contractor or designated employees only.
2. Inspect scaffolds prior to use and report any damage immediately to your foreman. Do not use damaged or make shift scaffolds.
3. You are not permitted to ride on rolling scaffolds being moved.
4. Atleast 2 people are required to move rolling towers.Secure or remove all tools and materials before moving.
5. Always use guard railings on all scaffolds regardless of height.
6. .Use only high quality planking on scaffolds and be sure the planks are secure to prevent
shifting.
7. Always apply caster brakes and use out riggers when scaffolds are stationary.
8. Do not throw material or debris from scaffolds unless the area below is properly barricaded to protect other workers and materials and equipment.
9. Do not use planks or guardrails as a temporary means of obtaining greater height.
10. Beaware of the objects below you; move or cover sharp objects in case you fall. Cap or bend all rebar.
R. CRANES AND RIGGING
1. No employee is permitted to ride on loads, hooks, or slings of any crane, hoist or derrick.
2. Only properly trained and authorized employees are allowed to operate cranes.
3. Do not work or stand under any suspended load.Crane operators shall avoids winging loads over people.
4. Always know the weight of the load and the forces applied to the slings and rigging.
![Page 241: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/241.jpg)
241
5. Always use taglines on loads.
6. Proper communication must be maintained with the crane operator at all times.
7. Inspect all slings and chains prior to use.Do not use defective slings, chains, or rigging.
S.BOOM AND SCISSOR LIFTS
1. Only trained and authorized employees are allowed to use boom or scissor lifts. If you aren’t trained, stay off.
2. Read and obey all manufacturer’s instructions and safety precautions.
3. Inspect all lifts prior to use.Defective equipment shall not be used.
4. A safety harness with shock absorbing lanyard must be worn while using boomlifts. Harnesses are not required for scissor lifts, provided you do not leave the work platform with surrounding guard rail.
5. Always stay inside the platform railing. Do not use planks or ladders to extend your reach.
6. Keep the safety chains upon scissorlifts.
7. Platforms or shelves are not allowed on the rails at any times.
8. Always lower the lift before moving.
9. Never use scissor lifts on uneven or unstable ground.They are designed for use primarily on concrete floors.
![Page 242: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/242.jpg)
242
T. WELDING,CUTTING AND GRINDING
I. Hot work permits are required for all welding, cutting, grinding, and any other activities producing sparks, open flame, or other heat that could potentially ignite a fire. Hot work permits must be obtained before any torch cutting, grinding, welding or burning activities occur. Combustible gas monitoring with LEL alarm capability shall be conducted prior to and continuously during all hot work activities. No hot work will be permitted near grass areas when the humidity level is less than 30%.
II. Make sure your welding equipment is installed properly and grounded and in good working condition.All hoses and cables must be regularly inspected and in good condition.
III. Always wear protective clothing suitable for the welding or cutting to be done.
IV. Always wear proper eye protection when welding, brazing, soldering or flame cutting. Once you remove your welding helmet, put on safety glasses.
V. Keep your work area clean and free of hazards. Positively be sure that no flammable, volatile or explosive materials are in or near the work area prior to work.Prior to work confirm the absence of combustible gas by use of a combustible gas meter with % LEL readings and alarm. Continuously monitor the atmosphere with a combustible gas meter with alarm.
VI. Handle all compressed gas cylinders with extreme care.Keep caps on when not in use.Make sure that all compressed gas cylinders are secured to the equipment carriage, wall or other structural supports. When compressed gas cylinders are empty, close the valve, install the cap and return to correct bottle storage area.
VII. Store compressed gas cylinders in a safe place with good ventilation.Acetylene cylinders and oxygen cylinders should be kept atleast 20 feet apart.
VIII. Do not weld or cut in confined spaces without special precautions and your Foreman’s authorization.
IX. Do not weld on containers that have held combustibles or flammable materials.
X. Use mechanical exhaust ventilation at the point of welding when welding lead, cadmium, chromium, manganese, brass, bronze, zinc or galvanized metals. These metals are highly toxic and their fumes should not be breathed.
XI. Make sure all electrical connections are tight and insulated. Do not use cables with frayed, cracked or bare spots in the insulation.
XII. When the electrode holder or cutting torch is not in use,hang it on the brackets provided. Never let it touch a compressed gas cylinder.
XIII. Dispose of electrode and wires tubs in proper containers as stubs and rods on the floor are asafety hazard.
XIV. Use weld curtains to shield others from the light rays produced by your welding.
![Page 243: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/243.jpg)
243
XV. Make sure all compressed gas connections are tight and check for leaks. Do not use hoses with frayed or cracked spots.
XVI. Keep your leads orderly and out of walkways. Suspend them whenever possible.
XVII. DO NOT WELD if leads or machine are in or near water.
XVIII. Make sure a portable fire extinguisher is nearby.
XIX. Keep your work area clean and free of hazards. When flame cutting, sparks can travel 30- 40feet. Do not allow flame cut sparks to hit hoses, regulators or cylinders.
XX. Use oxygen and acetylene or other fuel gases with the appropriate torches and tips only for the purpose intended.
XXI. Never use acetylene at a pressure in excess of 15 pounds per square inch.Higher pressure can cause an explosion.
XXII. Never use oil, grease or any other material on any apparatus or thread fitting in the oxyacetylene or oxfuel gas system.Oil and grease in contact with oxygen will cause spontaneous combustion.
XXIII. Always use the correct sequence and technique for assembling and lighting the torch. Always use the correct sequence and technique for shutting off a torch.
XXIV. Check valves must be used on all compressed gas cylinders to prevent back flow of the gas.
U. FIRST AID AND MEDICAL
Contractors shall comply with applicable OCCUPATIONAL HEALTH AND SAFETY requirements pertaining to first aid and medical services for their personnel.
![Page 244: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/244.jpg)
244
CONSTRUCTIONSITESAFETY
Only Employees who need to enter a site for their job are allowed
Blocked off construction site, creating a safety buffer for the public
Employees must wear required PPE when entering a site
![Page 245: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/245.jpg)
245
This tool box talk will outline the safety requirements that all visitors must observe when entering a construction site.
How to Identify a Construction Site: Exterior construction projects will be cordoned off with chain link fence, orange construction fence,or warning tape
Interior renovations will typically have access closed by rope, warning tape, or a closed door with a sign posted
Harvard Employees should only enter a construction site if their job requires them to and their presence is known to the general contractor
Look for signs posted along the perimeter informing the
public: Who the GeneralContractoris
What PPE is required
Site access limitations
PERSONAL PROTECTIVE EQUIPMENT (PPE)
HEAD PROTECTION
![Page 246: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/246.jpg)
246
In the vast majority of construction operations, there is a fore seeable risk of persons incurring an injury to the head, either due to falling material, or due to the head striking against an other object.
Required SafetyStandards;
• A safety helmet is required to be used on construction site, excavation work, over head crane operation, low structures/pipes/beams or whenever there is risk of head injury.
• All contracts shall be classed as “Hard Hat Areas” and notices shall be displayed. • Any one having control over other persons at work has a duty to ensure that head protection is
worn. This applies to main contractors, sub contractors and also to individuals such as site managers,foremen, engineers and surveyors. Examples below are situations where head protection may not be required, but will still have to be worn to cross the site:
• Maintenance work on completed buildings where there is sufficient head room and no multi layers of workinglevels.
• Inside site offices, temporary accommodation etc. • Inside the cabs of vehicles and plant, if provided with falling object protection. • When work is at ground level,eg.road works such as kerblaying or resurfacing
EYEPROTECTION
Required Safety Standards • Should be industrial standard eye protectors like spectacles, goggles and faceshields. • Suitable face and eye protect or must be worn by employees to protect face/eyes
against any flying particles/ splash of chemical/hot solutions. • Impact resistant safety glasses with side shields/safety goggles/full face shield
suitable for grinding, buffing, chipping operators shall be provided and used. • Welding masks with appropriate filter glasses must be used when performing welding operations • In addition, eye wash fountain shall be readily available at the site. In remote
locations,eye wash bottles may be substituted.
![Page 247: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/247.jpg)
247
HEARING PROTECTION
Ear defenders are used to prevent loss of hearing when persons would otherwise be exposed to levels of noise which are considered to be hazardous.
The maximum levels to which persons may be exposed are expressed as a function of intensity and time, eg. 90 decibels [db (A)] for a period of 8 hours or its equivalent. This value is quoted as the equivalent continuous sound level or 90 db(A).The noise levels in any particular working environment to shout over a distance of 1 metre of 1 metre or less in order to be heard,then the noise level may be excessive. Required safety standards
• Persons working in areas with excessive noise above 90 dB(A), shall wear ear muffs/earplugs. • High noise level areas should be identified and appropriate warning notices should be exhibited to
warm employees.
FOOT PROTECTION
Required safety standards • Standard safety boots with metal toe caps must be worn by all personnel on site and in places
where foot injury could occur.
![Page 248: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/248.jpg)
248
• Inspecific operations, rubber boots with steel toe should be used.
Protective footwear is used to: • Provide protection to the toes in the event of material falling on the foot by the use of a steel toe
cap built into the boot or on the outside surface. • Prevent injury by the penetration of nails and similar sharp objects.Steel mid soles are standard
only on some boots and shoes and are preferred for building construction sites. • Provide protection against the ingress of water. Rubber/ wellington boots are used when persons
are required to work with their feet in wet substances, such as concrete or mud and for work in places such as sewers.
• Provide a good grip on surfaces which are potentially slippery. • Provide protection during certain specific operations, eg: special electrical safety shoes should be used
by those involved in electrical trades.
![Page 249: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/249.jpg)
249
HAND PROTECTION
Required safety standards • Hand gloves must be used in jobs likely to cause injury to hands. • Gloves must be used near moving machinery parts. • PVC/rubber gloves must be used when handling chemicals. • Electricians using tested rubber gloves must check them for defects prior to start of work. • Select and use the gloves suitable for the job.
![Page 250: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/250.jpg)
250
BODY PROTECTION
Require safety standards • Wear proper protective clothing/cover all (loose or baggy clothing is not permitted in work areas) • A PVC apron must be worn against splash from any chemical or corrosive substances, hazard of hot
metal/sparks. • Full PVC suit to cover full body is required for persons entering
tanks/vessels/sumps/pits to protect against any chemical /corrosive substance.
Type of body protection
Wet weather clothing
• Usually in the form of PVC either one or two piece suits, and often in company livery. PVC clothing particularly prone to condensation on the inside and the incorporation of vents will help all eviate the problem. Clothing manufactured from a breathable fabric is available, but is quite expensive.
High visibility clothing
• Normally in the form of waist coats or jackets for use when workers are working adjacent to moving
traffic, either on public highways,or on such operations as earth moving.These garments will incorporate retro reflective strips front and rear.
Overalls
• These will normally be made of poly cotton and arrangements must be made for regular cleaning specialist trades such as asbestos strippers and leadburners will have lightweight overalls suited to the operation, such overalls may be of the disposable type.
![Page 251: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/251.jpg)
251
Leather aprons • Used by welders and burners to provide protection againsts parks and molten metal
which might otherwise ignite their clothing • Trousers
• Incorporating ballistic nylon nor similar material are available to give round leg protection to chain saw operators.
RESPIRATORY PROTECTIVE EQUIPMENT(RPE)
Whether toxic materials, which are liable to produce, dust, gases or vapours are being used, or are present in the working environment, there is always a respiratory hazard. Ideally, the contaminant shouldbe controlled at source to minimize the hazard, but this is often not possible. If it is necessaryto provide RPE the first step is to determine whether the environment is deficient in oxygen is present, but the air is contaminated air, purifying equipment (respirators) can be used.
The overall choice of equipment is wide. As the wrong choice could seriously affect the health of the wearer, or lead to asphyxiation, expert advice is essential combined with training and information being given to the wearer. In addition, cleaning and maintenance facilities for the equipment must be provided to ensure continued effective protection.
Required safety standards
• Dust mask respirators must be worn to protect against dust particles. • Chemical cartridge respiration must be worn when painting/spraying solvent or chemicals. • When there is potential for the presence of toxic gas/vapour or oxygen deficient
atmosphere, the self-contained breathing apparatus should be used. • Only authorised/qualified personnel can issue Respiratory Protective Equipment. • Persons trained/ certified on the usage of self contained breathing apparatus shall be engaged and
the work should ne done under direct supervision. The basic tests to ensure proper fitting of face
![Page 252: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/252.jpg)
252
masks must be done before each operation. • Proper selection and use of RPE should be ensured by taking into consideration hazardous
operation, contaminant time, protection from the particular equipment,limitations, state of health of individual.
• When working with asbestos, staff shall be provided with respiratory equipment approved for use with asbestos which does not allow penetration by, or retain dust and which should be a cause fit with head cover.
• When engaged in girl blasting, the use of air supplied hood is essential if blasting in direct contact with the dust/grit.
SAFETYHARNESSESANDBELTS
![Page 253: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/253.jpg)
253
The main reason for the use of safety harnesses is to limit the distance of any fall and thereby minimisingthe risk of injury. They will also be used to facilitate the rescue or persons working in confined spaces, such as manholes etc. Safety belts are not suitable for arresting a fail, but only as a restraint to preven taccess to a danger area.
![Page 254: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/254.jpg)
254
Required safety standards
• Safety belts with lifelines must be worn when hazards of falling from height exist or when working on elevated platforms or baskets.
• Select the proper safety belts and use it.
• Safety belts shall be examined periodically. Defective and worn out safety belts must never be used.
• Rescue safety belts with harness/lifeline must be worn when an employee is working in a confined space.
• When using ladders,a fall arrest device connected to bodyharness must be used.
Types of harnesses and belts
Full body harness
This comprises straps, fittings, buckles etc.suitably arranged to support the whole body of a person and to restrain the wearer during a fall and after the arrest of a fall. The harness should be fittedwitha lanyard which will limit the fall to maximum of 2m. The use of an energy absorber to further minimise risk of injury during arrest, is strongly recommended.
General purpose belts and chest harnesses Are used in situations where short duration work is necessary in areas where provision or fall prevention measures would be impracticable. Belts and harnesses should be fitted with a line of the appropriate length to prevent access to the danger area.
Rescueharness A rescue harness is used for protecting or rescuing workmen entering dangerous enclosed places it must be capable of reasonable adjustment, be easy to fit in a emergency and the used in such a way that the fall is limited to 600mm.
Use of harnesses and belt It is of the utmost importance that, whenever a safety belt or harness is provided, there is also an effective means of fixing it to the structure at all times while the protection is required. All too often, a belt or harness is provided in the hope that the wearer may find some whereto attach it. It is also vital that the fixing point for a harness is strong to withstand the snatch load of a fall. The use of two lanyards will sometimes be necessary to ensure constant attachment whilst moving.
The distance of fall should be as small as is possible, and to that end, the harness lanyard should be fixed to the structure, or fixing point,as high as practicable above the working position.
![Page 255: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/255.jpg)
255
ENERGYABSORBINGDEVICES
An energy absorber should be part of a fall arrest system whenever possible. In order to reduce the possibility of injury to the body in the event of a fall, energy absorbers have been developed. These devises installed between harness and the anchorage point, allow the fall to be slowed down, thus absorbing energy and reducing the final load on the body.
Use
• Choose the correct type of anchorage point or restraint system. • Choose the correct type of equipment. • Assess the possible free fall distance. • Check for dangerous obstacles which a person could hit or swing into.
Inspection Check the equipment prior to use for damage Note: if a harness and lanyard has been subjected to a fall, they should be disposed of and replaced. The human eye cannot evaluate the stresses that have been put on the equipment and next time they may not work. A suitably qualified person should inspect energy absorbing devices, anchorages and systems annually or following afall.
Training
• Ensure you have received comprehensive instructions from the supplier asto the devices proper use and application.
• Train personnel in the correct use of equipment and the procedures that should be followed. • Putin place emergency procedures and have means available to promptly rescue an employee
should a fall occur, since the suspended employee may not be able to reach a work level independently.
![Page 256: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/256.jpg)
256
SCAFFOLDSAFETY
More than half of scaffold accidents in construction are falls. Several fatalities are also related to scaffolds each year.The number and severity of injuries involved make scaffold accidents one of the more serious safety problems in construction.
PROBLEM AREAS Themain problem areas are
• Erecting and dismantling scaffolds • Climbing up and down scaffolds • Planks sliding off or breaking • Improper loading or over loading • Platforms not fully planked or“decked” • Platforms without guardrails • Failure to installall required components such as baseplates,connections,and braces • Moving rolling scaffolds in the vicinity of overhead electrical wires • Moving rolling scaffolds with workers on the platform.
1. Erecting and Dismantling
From 15 to 20% of scaffold-related injuries involve erecting and dismantling. The most common problem is the failure to provide an adequate working platform for a worker to use when installing the next lift of scaffold. Working from one or two planksis not recommended. The next important consideration involves components, such as tie-ins,which you should install as the assembly progresses.Failure to do so makes the scaffold less stable and, while it may not topple, it may sway or move enough to knock someone off the platform. This happens more often when platforms are only one or two planks wide and guardrails are missing, as is frequently the case during erection and dismantling.
2. Climbing Up and Down
Approximately 15% of scaffold-related injuries occur when workers are climbing up and down.Climbing up and down frames is a common but unacceptable practice that has resulted in numerous injuries and fatalities. Climbing up and down braces is also a frequent cause of accidents. You must provide adequate ladders to overcome this problem.Inaddition,workers must use proper climbing techniques (three-pointcontact).
3. Planks Sliding Off or Breaking
Many scaffold injuries involve problems with planks. If scaffold planks are uncleated or otherwise unsecured they easily slide off– this causes a surprising number of injuries. Scaffold planks can also break if they are in poor condition or overloaded.It is therefore important to use proper grades of lumber and to inspect planks before erection to ensure that there are no weak areas, deterioration, or cracks. Another common problem is insufficient or excessive overhang of planks at their support. Excessive overhang can cause a plank to tip up when a worker stands on the overhanging portion. Insufficient overhang is a leading cause of planks slipping off.
![Page 257: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/257.jpg)
257
4. Improper Loading or Overloading Overloading causes excessive deflection in planks and can lead to deterioration and breaking. Overloading occurs most often in the masonry trade where skids of material can exceed 1,500 kg(3,000lb.).If materialis left overhanging the scaffold platform it can cause an imbalance leading to the scaffold overturning.
5. Platforms Not Fully Decked This situation is related to injuries not only during erection and
dismantling but in general scaffold use. The Construction Regulation (On tario Regulation 213/91) requires that all scaffold platforms must beat least 450 mm(18inches)wide.All platforms above 2.4 metres(8 feet)must be fully decked.
6. Platforms without Guardrails
Platforms without guardrails are a serious safety problem in construction. Guardrails are an important fall prevention measure not only for high platforms but also for low ones. Over one-third of the falls from scaffolds are from platforms less than 3 metres (10 feet) in height. Therefore, guardrails are recommended during normal use for all scaffold platforms over 1.5 metres (5 feet) high. Guardrails for all working platforms should consist of a toprail, a mid-rail, and a toeboard.
7. Failure to Install All Required Components
Failure to use all of the proper scaffold components Is a serious safety problem.Workers are more likely to cut corners when scaffolds are only a few frames in height.All too frequently they fail to install baseplates, braces, proper securing devices such as“banana”clips or“pigtails”at the pins of frame scaffolds, and adequate tie-ins. Those erecting the scaffold must have all the necessary components, and must use them to ensure that the scaffold is safe. Further more, workers should install these parts asthe scaffold erection progresses.
8. Electrical Contact with Overhead Wires
Scaffolds seldom make contact with overhead electrical lines, but when it does happen it almost always results in a fatality. Failure to maintain safe distances from overhead power lines while moving scaffolds is a major Problem. Before attempting to move rolling scaffolds in outdoor open areas, check the route carefully to ensure that no overheadwires are in the immediate vicinity. Partial dismantling may be necessary in some situations to ensure that the scaffold will make the required safe clearances from overhead power lines. Hoisting scaffold material by forklift or other mechanical means requires careful planning and should be avoided in the vicinity of powerlines. Transporting already erected scaffolds by forklift, particularly in residential construction, has been the cause of many electrical contacts—this is a dangerous practice.Workers handling materials or equipment while working on the platform must also take care to avoid electrical contact.
9. Moving Rolling Scaffolds with Workers on the Platform
Moving rolling scaffolds with workers on the platform can be dangerous. Where it is impractical for workers to climb down, and the scaffold is over 3 metres (10feet) in height, each worker must be tied off with a full body harness and lanyard. Lifelines must be attached to a suitable
![Page 258: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/258.jpg)
258
anchor point other than the scaffold. Holes, depressions, curbs, etc. have all been responsible for scaffolds overturning while being moved. In some jurisdictions, moving a scaffold with workers on the platform is prohibited if the platform exceeds acertain height.
Supported scaffolds
Never use scaffolds that do not have proper guardrails installed
![Page 259: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/259.jpg)
259
Unstable objects will not be used as working platforms
Cross-braces prohibited as means of access
![Page 260: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/260.jpg)
260
No barrels, boxes or ladders on top of scaffolds
The planking is to be of Scaffold Grade wood or metal, free of defects that may contribute to an accident.
![Page 261: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/261.jpg)
261
3 SELECTION
The safe and efficient use of scaffolding depends first on choosing the right system for the job. If the scaffold s̓ basic characteristics are unsuited to the task, or if all the necessary components are not available, personnel are forced to make do and improvise. These conditions lead to accidents. Proper selection of scaffolding and related components requires basic knowledge about site conditions and the work to be done.Considerations include:
Weight of workers,tools,materials, and equipment to be carried by the scaffold Siteconditions (e.g., interior, exterior, backfill, concrete floors, type and condition of walls,
access for the equipment, variations in elevation,anchorage points)
Height or heights to which the scaffold may be erected.
Type of work that will be done from the scaffold (e.g., masonry work, sand blasting, painting,metal siding,mechanical installation,suspended ceiling installation).
Duration of work
Experience of the supervisor and crew with the types of scaffolds available. Requirements for pedestrian traffic through and under the scaffold Anticipated weather conditions Ladders or other access to the platform Obstructions configuration of the building or structure being worked on Special erection or dismantling
problems including providing practical fall protection for the erector.
Casters and wheels locked to prevent movement while in a stationary position
Open-ended or open-sided platforms must have standard guardrails
![Page 262: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/262.jpg)
262
FIRESAFETY
Familiarize yourself with the nearest pull stations and fire extinguishers
![Page 263: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/263.jpg)
263
Fire doors should never be propped open by using a foreign object.
Basic fire safety knowledge is an important skill that can save your life on or off the job. Here we will break down basic characteristics of a fire, important fire safety tips, what to do if you find yourself involved with a fire and some discussion points for your group.
Characteristics of Fire
To support fire, you must have; HEAT, FUEL, OXYGEN, and SUSTAINED CHEMICAL REACTION A small fire can grow out of control in as little as 30 seconds. A room involved with a fire can have a temperature of 100° Cat floor level and 600° Cat In less than 5 minutes a room can flash over.
Fire starts bright but will quickly turn the room pitch black from releasing smoke and
be familiar with your surroundings and evacuation routes!
Fire Safety Tips
An important fire safety tip is to look for and eliminate any potential fire hazards before they become a reality!
Know where pull stations and extinguishers are located. Time is the biggest enemy, get out of the
building!
If a fire, pull nearest fire alarm if possible, if not, call for help from a safe location outside.
If smoke, stay a slow to the ground as possible.
If safe, close all doors behind you as you leave the building.
![Page 264: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/264.jpg)
264
Don’t use the elevator for evacuation because the shaft can act as a chimney.
Elevators also present an entrapment hazard if they fail. Never return to a burning
building.
ELECTRICALSAFETY
With this tool box talk we will shed light upon basic electrical safety geared towards non- electricians.
Extension cords/Power Strips Extension cords should not be used in place of permanent wiring. Ensure that cords are in proper working condition (the outer insulation should not be cracked/broken, the ground pin needs to be intact). Discard unsafe extension cords.
Only licensed electricians are authorized to replace plugs, or splice cords. Extension cords need to be protected from motor vehicles,forklifts, pallet jacks,heavy pedestrian traffic,etc. Power strips should not be permanently mounted to a wall or any other structure, even if the power strip has specific mounting fittings.
Power strips or extension cords should not be connected to each other.Doing this can overload the circuit creating a potential fire hazard.
Circuit Overload Protection Devices: These devices are designed to protect the wiring in a house/building and to prevent a potential fire. Fuses- Break the circuit when too much current is flowing through the circuit. A small conductor inside the fuse heats up and melts when it reaches a specific temperature. Circuit Breakers- As current increases in the circuit, an electro magnet inside the breaker
generates increased magnetic force, eventually being great enough to pull the switch on the breaker from the “on”to the“off” position.
Ground Fault Circuit Interrupters GFCIs are designed to protect people from an electric shock. A GFCI works by detecting a current drop from the hot to the neutral wiring in a circuit.The GFCI detects energy that is escaping the circuit. GFCIs should be installed wherever a water hazard is present. You will commonly find GFCI plugs on hairdryers,wet vacs,etc.
![Page 265: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/265.jpg)
265
GFCIs can be at the breaker, the outlet, incorporated with the plug of the appliance/piece of equipment, or part of a short extension cord.
Other common Electrical Safety Issues Discard any piece of equipment that gives you even the slightest shock. If the resistance through your body is lowered i.e.standing in water or touching metal,even the slightest shock can be deadly. Never use electrical equipment in or around water. Junction boxes and electrical panels need to have proper covers in place to conceal all wiring. Hard wiring should not be exposed/accessible to non-electrical employees.
![Page 266: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/266.jpg)
266
Never connect extension cords/power strips to each other
GFCI– Should be installed in any location with apotential water hazard. (Either at the outlet or the circuit breaker)
![Page 267: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/267.jpg)
267
COMPRESSEDGASCYLINDERS
Storage: Cylinders must be secured to prevent tipping.
Transportation- Use appropriate carts for transporting cylinders
Compressed gas cylinders can pose serious hazards.Their contents can present chemical hazards (flammable, toxic, corrosive) and the cylinders could present a physical hazard.
Transportation Valve protection caps must be in place when compressed gas cylinders are transported. Secure compressed gas cylinders in an upright position on an approved carrier while being transported. Cylinders should never be stored horizontally in a vehicle.
![Page 268: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/268.jpg)
268
Handling Use only approved spark igniters to light torches.
If a leak develops in a cylinder and it cannot be immediately corrected,move the cylinder to a safe location outside thebuilding if possible and contact the fire department. Keep oxygen and flammable gas regulators in proper working order and a wrench in position on the acetylene valve when in use.
Storage
Valve protection capsmust be in place when compressed gas cylinders are stored. Close cylinder valves and replace valve protection caps when work is complete and when cylinders are
empty or moved. Keep cylinders at a safe distance or shielded from welding or cutting operations. Do not place
cylinders where they can contact an electrical circuit. Cylinders must not be taken into or stored in confined spaces, including sheds, gang boxes and
office/storage trailers. Do not store hoses and regulators in unventilated or closed containers or areas.
CONTRACTORS: Do not leave behind partially filled or empty cylinders.Always remove them from the site. If not connected to a manifold for immediate use, separate oxygen and flammable gas cylinders by 20-feet or a 5-foot high 30-minute fire rated barrier.
![Page 269: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/269.jpg)
269
CONFINEDSPACE
Training– Employees entering a permit required space need to receive Entry Training
A confined space must meet all of the following criteria: Have limited means of egress Manholes RemovablePlates/Hatches Ladder as an Entrance/Exit Hole/Pit/Excavation Site with a depth of 5ft. The space must be large enough to enter. The spaceis not designed for continuous human occupancy
When is a Confined Space Entry Permit Needed? If a confined space has any recognized hazards such as an atmospheric hazard, an engulfment hazard or an entrapment hazard then a permit is required for entry.
Remember that certain work activities in a Confined Space can make a permit necessary. Only workers that have attended the Confined Space Entry training or annual refresher training are allowed to enter a permit-required space.
![Page 270: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/270.jpg)
270
FORKLIFTSAFETY
Improperlydistributed loadsmaytiptheforklift becausethe
centerof gravityhasshifted
Tilting the mast back reduces the load distance and makes the load safer to carry
![Page 271: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/271.jpg)
271
Handling The Load Preparation
Secure the load so it is safely arranged and stable. Do not carry damaged merchandise unless it has been secured by wrapping or
banding. Center the load as nearly as possible. Use caution when handling off-center loads that cannot be centered. Distribute the
heaviest part of the load nearest the front wheels of the forklift. Do not overload.Know the stated capacity of your forklift and do not exceed it.Only by
keeping within the weight limit can you operate the forklift safely. A forklift's capacity is rated for a specified loadcenter.I f the load is off-center, improperly
distributed, or oversized, it may exceed capacity and unbalance the forklift. Use the load extension backrest.
Approaching the Load Approach the load slowly and carefully, stopping 8 to 12 inches in front of the load. Place the truck squarely in front of the load with the forks at the correct height. Set the direction control to neutral. Do not raise or lower the forks unless the forklift is stopped and the brake is set.
Fork Position Level the forks before inserting them into the pallet. The forks must be placed under the load as far as possible. Slide the forks into the pallet until they are fully under the load.The forks should be atleast two- thirds the length of the load. Be careful that the forks do not go through to the other side where pallets are closely stacked. Center the weight of the load between the forks.Adjust the forks to distribute the weight evenly. Tilt the mast backcarefully to stabilize the load.
Lifting the Load Check that there is adequate overhead clearance before raising the load. Make sure there is sufficient headroom under over head installations, lights, pipes, etc. Carefully lift the load up above the lower stack about 4 inches. Lift the load and then tilt the mastback slightly to rest the load against the back rest extension. Ensure that the load does not catch on any obstructions. Slowly return the lift control lever to the neutral position.
![Page 272: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/272.jpg)
272
HAND & POWER TOOLS
Pre-Use Inspection- Always inspect tools before use, discard or professionally repair
Protective Equipment-Always wear appropriate protective equipment when using tools
Often times we over look the hazards associated with the common tools that are used on a dailybasis. With this talk we hope to bring some awareness to the potential hazards of these tools and how to minimize these hazards.
Training: Each employee using hand and portable powertools must receive initial training and an annual refresher.
Pre Inspection Use (Done before every use): Damaged or cracked housing, power source, or bits / accessories Dull blades are often more dangerous than sharp blades. Missing guards or protective devices Leaking gasoline, oil or other fluids Tool appears to be in poor condition. Does the tool have a 3 wire cord, if not is it double insulated? Ensure areais free of any potential trip hazards. Do not underestimate the importance of a clean work area.
![Page 273: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/273.jpg)
273
Proper Use: Ensure you are wearing the correct PPE You should always wear eye protection Use the proper tool for the job. Follow the manufacturer’s instructions. If unsure about use, ask a supervisor or co worker for clarification. Insure tools are not pointed at or operated in close proximity to other individuals. Use spark resistant tools when working near a fuel source. Do not use excessive force to cut/drill through hard materials Gasoline/Mixed Fuel Powered Tools must be off and cool when re-fueled,use only in well ventilated areas.
Storage: Drain fluids (gasoline) if equipment will be in storage for an extended period of time De-energize tool prior to storage (includes removing air pressure, hydraulic pressure and removing loads). Store electric tools in dry areas. Store flammables in accordance with applicable regulations
![Page 274: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/274.jpg)
274
HEATSTRESS
Water- On hot summer days drink a cup of water every 15 minutes when working outside.
What is Heat Stress: Heat stress occurs when the body is unable to cool itself by sweating. Heat stress can lead to heat exhaustion or heat stroke.
Symptoms of Heat Exhaustion: Headache, dizziness, light headedness, fainting Weakness and moist skin Mood changes, irritability, confusion Nausea, vomiting.
Symptoms of Heat Stroke: Dry, hot skin with no sweating, Mental confusion or loss of consciousness, Seizures or convulsions can be fatal
Preventing Heat Stress:
• Know signs/symptoms of heat related illnesses, Block out sun or other heat sources. • Use fans/A.C. units • In high heat, drink 1 cup of water every 15 minutes • Wear light weight, light colored, loose fitting clothes. • Avoid alcohol, caffeinated drinks, or heavy meals. • Wear sunscreen of SPF 15 or >; reapply every 2 hours
How to Treat Heat-Related Illness Seek immediate medical attention; call 911
While Waiting
Move worker to cool shaded area Loosen or remove heavy clothing Provide cool drinking water Fan and mist person with water.
![Page 275: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/275.jpg)
275
HOTWORK
Employees must wear required PPE
Operations that create a spark or flame such as welding and soldering are referred to as hot work. Special precautions are necessary to perform hot work safely. Hot work procedures must be understood by operators and building managers and all occupants should be familiar with basic safe work practices.
. Roles and Responsibilities Employee:
Use equipment safely Alert affected employees of hot work activities being conducted in their area. Ensure hot work activities are conducted incompliance with the Standard. Obtain a completed Hot Work Permit from their supervisor
![Page 276: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/276.jpg)
276
Obtain approval from Permit Authorizing Individual (PAI) for that facility before commencing hot
work activities. Cease operations if unsafe conditions arise. Have a fire extinguisher readily available. Complete hot work training prior to conducting any hot work activities. Wear required personal
protective equipment.
Fire Watch:
Alert affected employees of hot work activities. Ensure safe work practices are maintained during hot work operations. Stop work if the hot work operations become unsafe. Have a fire extinguisher readily available. Be familiar with the facility’s procedures for sounding an alarm. Activate the facility alarm if
a fire starts. Extinguish small fires if it is safe to do so.
Facility Manager: Authorize University hot work permits for their building. Coordinate fire protection systems hut down with the contractor.
Major provisions of the Standard
Fire and explosion prevention.
Storage of compressed gas cylinders.
Personnel protection, Health protection & ventilation.
![Page 277: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/277.jpg)
277
LADDERSAFETY
Non Self-Supporting Ladders-Move the base of the ladder out 1’for every 4’ of Elevation
The use of Metal Ladders is prohibited
![Page 278: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/278.jpg)
278
Choosing the correct ladder: Non-Conductive Ladder: Harvard employees are not allowed to use aluminum portable ladders. Fiber glass or composite rail ladders (non-conductive) are recommended to be used by Harvard Employees.
Wooden Ladder: Wooden ladders may be used by Harvard employees if they are in good condition. Replace damaged/old wooden ladders with non-conductive ladders.
Step Ladder: Employees are never to stand on the top two rungs of a step ladder. A step ladder must be used with the spreaders fully opened and secured.
Straight or Extension Ladders:
If accessing an elevated surface, extend the ladder 3 rungs above the leading edge and secure the top of the ladder top revent slipping.
Never fastent straight ladders together unless both ladders are specifically designed to do so.
Inspect the ladder before use: Ensure rail sand rungs/steps are not cracked, bent, loose or covered in oily debris. Ensure step ladders have two spreaders (hold the ladder open) that are not damaged and that open and close properly. Ensure the fly section of an extension ladder extends properly and securely locks into place. Discard and mark any damaged portable ladders.
Proper set up of aladder: Secure or barricade the work site if in a high traffic area (doorways etc.). Place the ladder on a firm level surface. Straight or extension ladders must be angled at a 4 to 1 ratio. (For every 4ft of elevation the ladder must extend 1 ft from the base)
Proper useof a portable ladder:
Maintain 3 points of contact when working on the ladder. Face the ladde rwhen climbing up or down.
Keep ladder free of oil/grease and other slipping hazards. Don’t over-reach while on the ladder.
Don’t shift, move or extend a ladderwhile in use.
Don’t load ladder beyond the maximum intended load (see manufacturer label).
![Page 279: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/279.jpg)
279
LIFTINGSAFETY
Proper LiftingTechnique
Keep back straight and lift with the legs
Use Resources-Ask for help from coworkers and use available mechanical aids.
Back injuries are one of the most common injuries found throughout in industry.With this Tool box Talk we will address proper lifting techniques, how to reduce the risk of a back injury and some other general safety tips.
Preparation:
Ensure that you are wearing proper clothing and PPE Steel toe shoes should always be worn when lifting heavy items.
Gloves are also recommended when lifting certain objects. Stretch before you attempt to lift a heavy object or at beginning of shift. If
possible, store materials at waist height to reduce the strain on yourback. Have materials delivered as close to final destination as possible. Assess the object you are going to be lifting. Determine the weight of the object before lifting. Determine best place to grip the object. Ensure that your travel path is free of slipping and tripping hazards. Know your own lifting restrictions and capabilities.
![Page 280: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/280.jpg)
280
Get Help: Use carts, dollies, forklifts andhoists to move materials. When lifting a load more than 50 lbs, get help from another worker. Use carrying tools with handles to carry odd-shaped loads.
Proper Lifting Techniques:
a) Have your feet spread about shoulders-width apart. Your feet should be close to the object. b) Get a firm grip on the object. c) Keep your back straight and elbows close to your body. d) Keeping your back straight and headup, straighten your legs to lift object. e) At the same time tighten your stomach muscles to provide back support. (Don’t hold
your breath while doing this) f) While carrying the object DO NOT twist or bend at the waist, move your feet and legs
when turning. Keep the load as close to your body as possible. g) To set the object down, use the same technique used to lift the object.
Other Useful Safety Tips: Take your time! You are more likely to be injured when you are tired or cold.
Lift as smoothly as possible, try not to “jerk” the lift.
![Page 281: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/281.jpg)
281
LOCKOUT-TAGOUT
Employees are never allowed to work on “live” equipment
Locate the correct energy isolating device
![Page 282: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/282.jpg)
282
Ensure you have the proper tools to properly perform a lockout-tagout
Types of Hazardous Energy:
![Page 283: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/283.jpg)
283
Electrical, Hydraulic, Pneumatic, Gravitational, Chemical and Thermal.
When are Lockout-Tagout Procedures Required:
a) Servicing/performing maintenance on energized equipment. b) Any form of work on equipment when safety guards or measures are by passed. c) Any form of work which requires the individual to place any part of their body in the point of
operation or designated danger zone.
When Are Lockout-Tagout Procedures Not Required: a) Minor tool changes or adjustments (i.e.blade and bit changes, table saw adjustments). b) Cord and plug control led devices (i.e.portablepowertools). c) Routine, repetitive changes or adjustments that are integral to the use of the equipment; provided the
work is performed using alternative measures that provide effective protection.
Lockout-Tagout Definitions: Affected Employee: An employee whose job requires them to operate or use a piece of equipment that is affected by the
Lockout-Tagout or is working in the area where the maintenance/service is being performed.
AuthorizedEmployee: A trained employee who locks out or tags out equipment to perform maintenance/service.
Supervisor: The manager/supervisor of the Authorized Employee. Lockout: The placement of a lockout device on an energy isolating device that ensures the equipment controlled by that
energy isolating device cannot be operated until the lock is removed.
Tagout: The placement of a tag on an energy isolating device notifying individuals of the work being performed.Harvard
University policy never allows just a tag to be affixed to the energy isolating device,a lock and tag must be used any time equipment needs to be de-energized and serviced.
Stored or Residual Energy: Examples of stored or residual energy: Capacitors, springs, elevated components, rotating flywheels, hydraulic systems, and air, gas, steam water pressure etc.
Methods of Dissipating or Restraining: Grounding, repositioning, bleeding, blocking etc.
When CanHarvard Employees work on EnergizedEquipment: Never– Harvard Employees are required to de-energize equipment in accordance with the Harvard Lockout- Tagout: Control ofHazardous Energy Standard.
![Page 284: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/284.jpg)
284
MACHINEGUARDING
Table saws need to have proper guards
Barrier devices create a safety buffer for employees
Basic Terminology: Parts of the Machine Requiring Guarding Point of Operation: Area where machine performs work on material.
Power Transmission Apparatus: Belts, gears, flywheels, chains, pulleys, spindles, couplings, cams, machine components that transmit energy. Other Moving Parts: Reciprocating, rotating, traversing motions, auxiliary machine parts.
Types of Mechanical Motion that Must be Guarded: Pinch Points:Points at which it is possible to be caught between moving parts,or between moving
and stationary parts of a piece of equipment. Rotating: Circular motion of shafts with a protrusion sticking out can grip clothing or pull body part into point of operation.
![Page 285: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/285.jpg)
285
Reciprocating: Back-and-forth or Up-and-Down motion that may trap/strike an employee between the moving
object and a fixed object. Traversing: Movement in straight, continuous line that may strike or catch an employee in a pinch or shear
point between a moving and fixed object.
Cutting: Action of sawing, boring, drilling, milling, slicing. Punching: Action resulting when a machine moves a slide (ram) to stamp a sheet of metal or other material. Shearing: Movement of a powered slide or knife during metal trimming or paper cutting. Bending: action occurring when power is applied to a slide to draw or form metal or other materials.
Common Machines That Require Machine Guards:
Circular Saw ReciprocatingSaw BandSawJointer
Power FeedPlaner
Shaper LatheSander
DrillPress GrindingWheels MechanicalPower Press
Mortising Machine
![Page 286: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/286.jpg)
286
MEANS OF EGRESS
Review evacuation mapsfor primary and secondary evacuation routes
![Page 287: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/287.jpg)
287
Emergency exit routes must be clear of all obstructions
Emergency Evacuation Drill Procedures: Harvard Employees are required to evacuate during emergency evac drills. The primary functions of these drills are:
a. Ensure fire protection equipment is operating properly. b. Employee training on how to properly evacuate.
c. When the alarm sounds, employees are to safely and promptly evacuate the building using a designated evacuation route.
d. Once outside the building, proceed to the emergency meeting site.
Discovering a Fire or Smoke at Work: Remember R.A.C.E. RELOCATE- If it is safe to do so,relocate people in immediate danger.Instruct others to report to their designated gathering areas.Beaware of persons who may need assistance. ALARM- Pull the building fire alarm to alert others.Move to a safe location and report the precise location of the fire.
CONFINE- Close all doors, windows andother openingsto confine the fire, if this can be done safely.
EVACUATE- Evacuate building.Do not use elevators.Go to your area of refuge outside at meeting site.
![Page 288: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/288.jpg)
288
Fire Rated Stairwells: Materials storage is prohibited in all fire rated stairwells. Each fire door including frame and hardware must be listed or approved by a nationally recognized
testing facility. Employees must be able to open an exit route door from the inside at all times without keys, tools, or
special knowledge. Fire doors are only allowed to be held open by magnet door holds. Remove all door wedges, latches, coathangers, fire extinguishers, etc.that are being used
to hold doors open. Fire doors must be able to close fully on their own.
Exit Route Capacity:
The ceiling of an exit route must be at least seven feet six inches (2.3 m)high.
An exit access must be atleast 28 inches (71.1cm) wide at all points.Where there is only one
exit access leading to an exit or exit discharge, the width of the exit and exit discharge must be atleast equal to the width of the exit access.
Objects that project into the exit route must not reduce the width of the exit route
to less than the minimum width requirements for exit routes.
![Page 289: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/289.jpg)
289
OILSPILLRESPONSE
Floor Drains- use speedy dry, booms or drain covers to prevent oil from entering drains
Storm Drains- Frequently check hydraulic lines for trash compacters that are near storm drains
All employees having a roleinmanaging or maintaining oil containing devices must be able to initiate an appropriate oil spill response.
![Page 290: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/290.jpg)
290
Oil Spill Response: 1. Assess the severity of the situation.
Determine if the situation is immediately hazardous to your well being, evacuate if in danger. For large spills that can reach a drain or catch basin. If situation allows, quickly cover/block the floor drain/catch basin with a drain over, boom, speedy dry,etc.
2. Contain Small Incidental Spills.
Contain spill without endangering self or others. Block storm drains and floor drains/openings to prevent spilled material from reaching the environment. Ensure the area is properly ventilated.
3. Small Spill Clean Up
Wear the Proper Protective Equipment (safety goggles, oil resistant gloves, etc.) Use absorbent materials to clean spill (pads, speedy dry,etc.)
4. Manage the Contaminated Waste Appropriately
Store contaminated materials/waste from the clean up in appropriate covered buckets or drum with a secured lid.
Affix aHazardous Waste label on the container (except cooking oil). If the contaminant is 1 galon or less of cooking oil and is completely absorbed, it is acceptable to dispose of with normal waste.
Oil Spill Prevention: All waste oil containers need to be placed in/on secondary containment that has a storage capacity of 110% of the container size. Perform monthly inspections on all oil containing devices that have a capacity of 55 galons or greater. Know where all spill kits are located in your facility and take time to ensure they are properly
stocked.
![Page 291: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/291.jpg)
291
PNEUMATICTOOLS
Pneumatic tools offer great versatility and the capability to get a job done quickly and efficiently. As with any energized equipment there is the potential for harm to people or property. With this Spotlight we will discuss basic handling, use and storage techniques that will minimize potential hazards created by these tools.
Proper use of pneumatictools: Read the manufacturer supplied manual before operating the tool. Wear appropriate PPE. A baseline of safety glasses/goggles, hearing protection and safety shoes is required. (Face protection, and abrasive gloves may also be needed). Never use compressed air for cleaning unless fitted with an attachment to reduce the pressure at the nozzle to 30psi. Never point the nozzle at another person or yourself, rust particles can be discharged from the compressor at a high velocity causing injury.
Attachments Always double check to ensure the attachment is securely connected to the hose. A positive locking device, chain or a short wire attaching the tool and hose is recommended for added protection. Attachments that shoot fasteners at pressures greater than 100psi need to be equipped with a device that only ejects fasteners when the muzzle is pressed up against the work surface.
Hoses If using a hose greater than 1/2” diameter, a safety excess flow valve must be installed at the source of the air supply.
Use hoses that have a minimum working pressure rating of 150% the maximum pressure produced by the compressor. Inspect hoses on a regular basis for bulges, cuts, cracks etc. Use hoses that are resistant to abrasion,crushing, and cutting. Blow any air out of the line before attaching a tool. When using hoses, minimize trip hazards and protect the physical condition of the hose to the best of your ability.
![Page 292: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/292.jpg)
292
Air Compressors Do not adjust air pressure greater than the attachments rating. Drain the tank after 4 hours of use to prevent water buildup which could lead to rust. Allow engine to completely cool before refueling. Only use gas powered compressors in well ventilated areas. Electric compressors need to be plugged into a properly grounded plug (use GFCI when needed).
![Page 293: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/293.jpg)
293
WORKING AT ELEVATIONS
A standard guardrail must be 42 inches in height, have an intermediate rail, proper
Spacing of the post sand be capable ofsupporting 200 lbs of force.
A roof boundary system is used to limit employees access to the fall hazard.The system
includes posts, rope and warning flags distributed along the rope.
![Page 294: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/294.jpg)
294
Working at Elevations.
Injuries from falls are oneof the most commonand severe workplace accidents. Employees must understand how to identify fall hazards and the ways they can protect themselves.
Areas Where Fall Hazards Exist: Any height greater than 4 feet is considered ahazard and mustbe protected. This includes:
Ways to Protect Employees from Fall Hazards:
The most effective way to protect employees from falls is by eliminating the hazard.Passive systems such as guardrails and covers remove the employee’s exposure to the hazard.
Fall protection equipment must be usedand cared for properly: Guardrails- Always work within the confines of the guardrail. Must meet design requirements (spacing, height, etc.). Floor Hole/Opening Covers- Must support the intended load or atleast 400lbs. (20,000lbs.if vehicle traffic). Must lay even with the floor; protruding covers create a tripping hazard.
Boundary Lines System-
Must be erected 6 feet from the edge of the roof or fall hazard. Only used in certain roofing activities; not approved by OSHA.
Must be 34 inches high and visible in all weather conditions.
Safe Work Distances- Minimum distance of 15 feet to the edge– travel within 15 feet will require fall protection . Path way must be clearly marked and employees need to be trained. This is a best management practice. Personal Fall Arrest System-
a. Inspect lanyard, harness, rings and other components before each use. b. Inspect anchors annually and have them tested every 10 years.
![Page 295: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/295.jpg)
295
c. Ensure the lanyard is the correct length for the height you will be working at. Must train employees on how to use, inspect and maintain fall arrest equipment. Replace equipment that is damaged or subjected to loads from a fall.
MATERIALSTORAGE
Storage of lumber
Remove nails before stacking
Stacked level and on sills
Stack lumber so that it is stable and selfsupporting
Piles not to exceed 20 feet
![Page 296: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/296.jpg)
296
Stack bricks in a manner that will keep them from falling.
Storage are as must be kept free from accumulation of materials that create hazards from:
Tripping
Fire
Explosion
Pest harborage
![Page 297: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/297.jpg)
297
SAFETYINEXCAVATIONS
• Excavation can result in serious injury,fatality or property damage due to the following causes: Collapse of earth work due to lack of inadequate or weal shoring. Persons faling into excavations due to lack of barriers or inadequate fencing. Asphyxiation from exhaust gases that havec ollected in the bottom of excavation. Soilfrom excavations not being thrown clear of the sides that then become over loaded and colapse. Failure to maintain shoring, particularly after rain and sand storm. Water seepage Persons working to oclose together The striking of services, eg.Electricity/communication cables and oil/gas pipes Persons not being provided with ornotusing proper tools for the job. Vehicles or plant too close to the edge, causing the edge to collapse Workers in the excavation being struck by soilor materials fallingi nto the excavation. False through unsafe means of access in too rout of thee xcavation Workers being struck by excavating machinery,e.g. excavator bucket Vehicles being driven into the excavation due to driving errors, inadequate barriers, or the absence of stop blocks
MAIN SAFETY REQUIREMENTS
ACCESS Safe means of getting into and climbing out of an excavation must be provided. Ladders must be securely fixed and properly maintained and should permit quick and easy escape in case
of flooding or fall s of materials.
GUARDINGOFEXCAVATIONS Where a person may fall more than 2m, suitable barriers must be erected, but it is sensible to erect barriers
even for quite shallow excavators where any one faling may come to harm.
Barriers should also serve to keep materials, plant and equipment away from the edges of an excavation.
Barriers may be removed to permit access of men, plant and equipment, etc., but should be replaced as soon as possible.
During darkness, the edges of an excavation should be marked with hazard warning lights, especially where they are close to public thorough fares.
Where excavation work is carried out on the roads, Traffic Police approval are necessary and appropriate barricades and warning notices shall be erected.
![Page 298: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/298.jpg)
298
STOP BLOCKS
Where vehicles are used for tipping materials into an excavation, safety measures such as well anchored stop blocks should be used to prevent the vehicle over running the edge.
These must be placed at a sufficient distance from the edge to avoid the danger of it breaking away under the weight of vehicles.
SITE LIGHTING
The workplace must be adequately lit, in particular at access points and openings, and whenever lifting operations take place.
VENTILATION Excavations must be kept clear of suffocating, toxic or explosive gases. There may be natural gases like hydrogen sulphide, methane and methane and sulphurdioxide
or exhaust gases from near by plant,or leaks from pipes or installations.
These can seep through the soil and can accumulate at the bottom of an excavation below ground level
Leakage of propane and butane from LPG cylinders is potentially very dangerous; the gases will sink to the lowest point and form an explosive concentration.
The most common method of ventilation is to blow clean air in to the excavation in sufficient volume to dissipate any gas accumulation.
MAINTENANCE All excavation work requires careful watching, especially when they are first opened and sides are unsupported, even when support work has been installed,constant vigilance is essential.
Smal movements of earth, resulting in movements in the timbering of no more than 6-12mm are usually the only sign of the progressive weakening in cohesive soils which can cause collapse. Such small movements can easily pass unnoticed but they are signs that something is wrong.
Movements can be detected from slight distortion in timbering, bowing of poling boards and walings or signs of local crushing.
Main points to consider are: All timber must be regularly checked, for if it remains in position for any length of time, it
may dry out, shrink or not.
The only positive method of checking the state of timber is to drill small holes with a nauger.
Ground,too,may dry out and shrink-which loosens the timbering.
The soil face,wedges or telescopic struts holding them must always be kept tight.
Raking or angle, struts should all be regularly examined for signs of having been dislodged.
Safety helmets and safety boots should be worn at all times since earth and other material can slide down or fall.
![Page 299: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/299.jpg)
299
During bad weather soil heap stend to slump,and loose boulders or masonry may fall in to the excavation.
Heavy vehicles should not be allowed near the edge of excavations unless the supportwork has been specially designedto permit it.
When loads are being moved in to or out of the excavation by skip or bucket, care should be taken to avoid damage to struts or walings.
HAZARDCOMMUNICATION
Hazard Communication, also referred to as “HAZCOM” and “The Employee Right to Know Act” was developed to ensure that employers provide employees with important safety information for chemicals used in their workplace.
Hazard Communication requirements are aimed at reducing the risk of chemical-related occupational illnesses and injuries by making available specific information to help identify and evaluate hazardous chemicals in the workplace. Tools such as Container Labeling and Safety Data Sheets (SDS) assist employers in identifying and communicating these hazards.
SDS: An SDS is a fact sheet developed by the manufacturer that contains information on all of the hazards associated with a particular chemical. It also provides guidance on how to protect yourself from these hazards and emergency information/procedures in the event of an accident. You may obtain an SDS from the manufacturer or on-line at the EHSwebsite. Personnel must be
![Page 300: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/300.jpg)
300
trained to be able to read an MSDS and understand the hazards presented by various substances.
ContainerLabel: Every container is required to have a label that lists all of the hazard information for the chemical it contains. If you use a generic container, such as a spray bottle, you must label it with all of the required information.
Every container used to store a chemical mustbe labeled. Chemicals should never be mixed with one another. Chemicals into separate containers such as generic spray bottles, employees must label these containers with the chemical’s name and a hazard warning briefly describing the hazardous effects of the chemical. This includes terms such as“flammable”and“causes lung damage.”
![Page 301: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/301.jpg)
301
HAZARD REPORTING FORM
Reported by: Name of Employee: Reported To: Working Location: Date o fReport:
Report of Hazard:
Location of Hazard concerns:
Please describe hazard concern:
Please describe safety issue:
Rate Hazard Class using criteria listed below: Hazard Class
“A”(major) High risk (immediately dangerous to life and health)
“B”(moderate) Medium risk( medium term potential for non-life threatening injury)
“C”(minor) Lowrisk (long term potential for slight injury or ilness)
![Page 302: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/302.jpg)
302
ACCIDENTINVESTIGATION REPORT Name& Site/ Location:
Dateof Incident: Time:
IdentifyingInformation
Injury or Ilness PropertyDamage OtherIncidents
Injured Name: Property
Damag
ed:
Natureof Incident:
Part of Body: Day
s
Lost
:
Nature
of
Damage:
IncidentCost:
Object/SubstanceInflictingHarm: Object/Substance
InflictingDamage:
Object/SubstanceRelated:
Occupation: TimeonTask:
Person WithMost
Control of Item:
Person With Most Control ofItem:
Risk
EvaluationofLoss
Potentialifnot
Corrected
LossSeverityPotenti
al Major Serio us
Minor
ProbableReoccurrence
FrequentOccasi
onal Seldom
Description
Describe how the incident occurred, including Assessment of Accident Scene(use photos,attach drawings if necessary)
101101EyewitnessesName(s)andStatement:
Cause Analysis Immediate Causes.What substandard action or conditions caused or could have caused the event?
Basic Causes.What specific personal or job factors caused or could cause this event?
Action Plan
What has and /or should be done to control the causes listed? (Work order,Warning,More Training,etc.)Corrective Actions.
![Page 303: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/303.jpg)
303
Signature of Investigator: Date: Follow- Up Date:
Safety Committee Review
![Page 304: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/304.jpg)
304
Signature Health & Safety Representative:
Date:
Safety Committee Members: Date:
Injury / Incident Corrective Action Form
Date of Injury/Incident: Injury / Incident number:
Date:
Corrective Action Taken (as indicated on the Accident/InvestigationForm):Recommendations
Date assigned
Responsibility assigned to:
Details of What is to be done
Who has completed it
When it was completed
![Page 305: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/305.jpg)
305
INDIAN GREEN BUILDING COUNCIL (IGBC) RULES The proposed project is targeting for IGBC Certification. Hence under this pretext the appointed contractor to follow all the norms and requirement mentioned and otherwise for the credit compliance.
1. Basic Facilities for Construction Workforce As Per IGBC Intent: Promote welfare of the construction workforce by providing safe and healthy work conditions. Compliance Options: Provide basic facilities for Construction workforce to exceed the guidelines of ‘The Building and other Construction Workers Act, 1996 & Rules, 1998’.
Adequate housing to meet or exceed local / labour byelaw requirement.
Sanitary facilities:
Provide at least 3 toilet seats & 3 urinals for the first 100 workers and one additional toilet seat & urinal for every 100 workers thereafter (or) as defined by local / labour byelaw.
(The sanitary measures should be provided separately for men and women).
First-aid and emergency facilities.
Adequate drinking water facilities.
Personal protective equipment (by owner / contractor).
Dust suppression measures. The site to be barricaded up to at least height of 11 ‘-0” to prevent construction air pollution. The materials carrier / vehicles entering the site should be prevented from spreading air pollution by wheel washing.
Adequate illumination levels in construction work areas.
Site emergency alarm.
Day care/ crèche facility for workers’ children. (Only if, more than 50 female building workers are employed full time)
![Page 306: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/306.jpg)
306
Note: The project can consider ‘Constructional Practices and Safety Guidelines’ from National Building Code (NBC) of India 2005, Part 7 - Constructional Practices and Safety.
2. Handling of Waste Materials, During Construction Intent: Facilitate segregation of construction and demolition waste at source to encourage reuse or recycling of materials, thereby avoiding waste being sent to landfills. Compliance Options: Demonstrate that at least 95% of waste generated during construction (as per owner / developer’s scope) is diverted from landfills, for reuse or recycling. Use consistent metrics, either weight or volume, to show compliance. (Please refer the annexure -1) The documentation of all challans, paperworks to be maintained for all the construction waste.
Notes: • Construction waste here refers to civil & interior building waste. • Excavated earth & stones should not be considered under this credit, as these are natural resources. • Temporary materials such as materials used for formwork, scaffolding, etc., shall not be considered for this credit calculation.
3. Use of low VOC materials Intent: Reduce the quantity of indoor air contaminants that are odorous or potentially
irritating to provide installer and occupant health and comfort.
Objective: Limit indoor air quality problems by selecting low VOC (Volatile Organic Compound)
products in:
Adhesives & Sealants
Paints
Carpets
Composite Wood & Agri-fibre products.
VOCs (Volatile Organic compounds) are chemical compounds that vaporize in room
temperature itself and contribute air quality problems.
Note: Adhesives used for Mechanical, Electrical and Plumbing work are included in the calculations for this credit.
![Page 307: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/307.jpg)
307
Requirements: Limit the VOC level for adhesives, sealants, paints, composite wood products,
and carpet systems. Please refer to annexure -2 for the limits.
4. Records Recycle & regional Materials Note: The contractor has to maintain record of the recycle content and regional distance of materials. And submit with all RA Bills. The letters from necessary manufacturing agencies to be collected from all the materials provided. (Sample letters attached in annexure -3)
![Page 308: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/308.jpg)
308
Annexure -1 Sample sheet for Construction waste calculations
SR. NO Construction Waste (MT)
Estimated Total waste to be generated (MT)
Total waste intended to be diverted (MT)
Location/method of diversion
1 Concrete Waste Debris
e.g .Used as Filling on Site
2 Steel Waste
e.g.To be sold to recycler
3 Glass Waste
4 Wood Waste
6 Empty paint buckets
7 Cement Bags
10 Tiles waste
11 Stone waste
13 Brick work waste
Total 0 0
Note: Please note this sheet is sample sheet. All the materials used on site and having waste need to bedocumented.
![Page 309: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/309.jpg)
309
Annexure-2
A. Requirements
1. Adhesives & Sealants:
Limit the VOC level of the adhesives & sealants as per below:
Substrate specific Application VOC Limit (g/l less water)
Metal to Metal 30
Plastic Foams 50
Porous material (except wood) 50
Wood 30
Fibre Glass 80
Sealants VOC Limit (g/l less water)
Architectural 250
Non membrane roof 300
Roadway 250
Single ply roof membrane 450
Other 420
![Page 310: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/310.jpg)
310
Sealant primers VOC Limit (g/l less water)
Architectural, non porous 250
Architectural, porous 775
Others 750
Aerosol Adhesives VOC Limit (by weight)
General purpose mist spray 65%
General purpose web spray 55%
Special purpose aerosol adhesives
(all) 70%
Architectural applications VOC Limit (g/l less water)
Indoor Carpet Adhesives 50
Carpet Pad Adhesives 50
Wood Flooring Adhesive 100
Rubber Floor Adhesive 60
Sub floor Adhesives 50
Ceramic Tile Adhesives 65
VCT and Asphalt tile Adhesive 50 Dry wall and panel adhesives 50
Multipurpose construction adhesives 70
Structural Glazing Adhesives 100
PVC Welding 510
CPVC Welding 490
ABS Welding 325
Plastic Cement Welding 250
Adhesive primer for plastic 550
Top & Trim Adhesive 250
Contact adhesive 80
Special purpose Contact Adhesive 250
Structural Wood purpose adhesive 140
Sheet applied rubber lining operations 850
![Page 311: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/311.jpg)
311
2. Paints & Coatings
Paints VOC Limit (less water)
Non – Flat 150 g/L
Flat 50 g/L
Anti Rusting & Anti Corrosive
Paints Coating Type VOC Limit (g/L less water)
Flat 250
Gloss 250
Semi Gloss 250
Coating Type VOC Limit
Clear Wood Finishes - Varnish 350 g/L
Clear Wood Finishes - Lacquer 350 g/L
Floor Coatings 100 g/L
Stains 250 g/L
Water proofing Sealers 250 g/L
Sanding sealers 275 g/L
Other Sealers 200 g/L
3. Carpets
Carpets must be Carpet and Rug Institute (CRI) certified.
All carpet cushion installed in the building interior shall meet the
requirements of Carpet and Rug Institute’s Green Label Indoor Air
Quality Test Program.
All carpet adhesive shall meet the requirements of EQ Credit 4.1: VOC limit of
50 g/l
![Page 312: BANK OF INDIAbankofindia.com/UploadData/TenderFiles/VOL - 1... · 2020. 1. 18. · 1 | P a g e BANK OF INDIA STAR HOUSE-2, 3RD FLOOR, PREMISES DEPARTMENT, C-4, G- BLOCK, BANDRA KURLA](https://reader033.fdocuments.us/reader033/viewer/2022053108/60774498e4aa6e17f77074ad/html5/thumbnails/312.jpg)
312
4. Composite Wood & Agri-Fibre Products
Composite wood and agrifiber products used on the interior of the building must contain no added
urea-formaldehyde resins. Composite wood and agrifiber products being as follows:
Particleboard,
Medium density fiber board (MDF),
Plywood,
Wheat board,
Strawboard,
Panel substrates and
Door cores.
5. FSC Certified wood
Use Forest Stewardship Council (FSC) certified wood to encourage
sustainable forest management
FSC principles & criteria:
• To ensure the health & productivity of the forest
• Certificate is awarded to companies that manufactured & sell wood
products based on the standards.
The wood products include:
Structural framing
General dimensional framing
Flooring
Sub-flooring